127EAW26R0001 - Brush Creek Work Center Construction
Closed Solicitation Posted
This opportunity was awarded. See the award notice from .
- Solicitation number
- 127EAW26R0001
- Agency
-
Forest Service
Department of Agriculture
- Responses due
- Set-aside
- Total Small Business
Opportunity facts
- NAICS code
- 236220 Commercial and Institutional Building Construction
- Place of performance
- Berry Creek, California 95916, United States
- Points of contact
Notice details come from SAM.gov. Updated .
About this opportunity
The U.S. Department of Agriculture Forest Service is procuring construction services for the Brush Creek Work Center facility reconstruction in Berry Creek, California, a project with a magnitude exceeding $10,000,000. The contractor must possess a California Type B General Contractors license or equivalent and is responsible for demolition of existing structures and comprehensive new construction including a six-person barracks, engine garage, warehouse, shop building, storage containers, seedling cooler, pump house, and associated site utilities and infrastructure. Evaluation will be conducted using a tradeoff source selection method based on four technical factors—relevant past performance (projects completed within the last five years), work plan and capability, key personnel qualifications, and performance schedule—weighted approximately equally with price. The Requests for Information deadline has been extended to March 6, 2026, at 1:00 PM PST, the mandatory site visit was rescheduled to February 25, 2026, at 12:00 PM PST, and proposals are due April 2, 2026, at 1:00 PM Pacific Time.
This solicitation (127EAW26R0001) is designated as a Total Small Business Set Aside under NAICS code 236220 with a $45 million size standard threshold, and no current contractors or potential incumbents are identified in the documentation. The contract is firm-fixed-price with a 650-calendar-day performance period commencing within 10 days of award, with liquidated damages assessed at $1,137.77 per calendar day for delays beyond the contract completion deadline. The contractor must submit pricing for thirteen base construction line items and five optional add items on a lump-sum basis, including general conditions, demolition, building construction, utilities, site improvements, and landscaping. Performance and payment bonds equal to 100% are required, along with a bid guarantee of 20% of the bid price or $1,000,000 (whichever is less) due within 10 calendar days of award. Work is to be performed at 12815 Oro Quincy Highway, Berry Creek, California 95916, with the contractor responsible for all hazmat abatement, permitting, third-party inspections, and compliance with Davis-Bacon prevailing wage requirements and environmental protection standards.
Notice text
7 versions
Update #7 · Latest ·
127EAW26R0001 - Brush Creek Work Center - A00006: Proposal Due Date
The purpose of this amendment is to confirm proposal due date / time. Amendment A00005 erroneously had block 11 "is extended" checked when the proposal due date was not extended.
Proposal due date and time remains April 2nd, 2026 at 1:00 PM Pacific Time.
////////////////////////////////////////////////////////////////////////////////////////////////
127EAW26R0001 - Brush Creek Work Center - A00005: RFI Responses 3 & SOI
The purpose of this amendment is to post RFI responses, and other applicable documentation.
////////////////////////////////////////////////////////////////////////////////////////////////
127EAW26R0001 - Brush Creek Work Center - A00004: Time Extension and RFI Responses
The purpose of this amendment is to extend the proposal due date, post RFI responses, and other applicable documentation.
////////////////////////////////////////////////////////////////////////////////////////////////
127EAW26R0001 - Brush Creek Work Center - A00003: Time Extension and RFI Responses
The purpose of this amendment is to extend the proposal due date, post RFI responses, and other applicable documentation.
////////////////////////////////////////////////////////////////////////////////////////////////
127EAW26R0001 - Brush Creek Work Center - A00002: Site Visit Roster
The purpose of this amendment is to post the sign in sheet from the Forest Service led site visit held on 25 February 2026.
////////////////////////////////////////////////////////////////////////////////////////////////
127EAW26R0001 - Brush Creek Work Center - A00001: Site Visit Reschedule
This purpose of this amendment is to cancel and reschedule the current site visit due to inclement weather, and extend RFI submission due date.
Forest Serivce led site visit on 18 Feb 2026 is hereby canceled. Site visit is rescheduled for 25 Feb 2026 at 12:00 PM PST.
RFI due date is hereby extended to 6 March 2026 at 1:00 PM PST.
////////////////////////////////////////////////////////////////////////////////////////////////
127EAW26R0001 - Brush Creek Work Center
Disclosure of Magnitude of the Construction Project: More than $10,000,000
Set Aside: Total Small Business Set Aside
IMPORTANT NOTES:
See Section L, Paragraph L.3 for the Documents to Submit with Your Proposal
All Requests for Information (RFI's) shall be submitted to the Contracting Officer, Greg Cunningham, on the attached RFI form not later than 1300 hours PST, February 27th, 2026.
An organized site visit will be held on Wednesday Feb 18th, 2026, 1:00 PM PST. See page attachment "1. Statement of Work" for full details. In no event shall failure to inspect the site constitute grounds for a claim after contract award.
PLEASE RSVP TO THE SITE VISIT BY EMAILING: GREGORY.CUNNINGHAM@USDA.GOV
Update #6 ·
127EAW26R0001 - Brush Creek Work Center - A00005: RFI Responses 3 & SOI
The purpose of this amendment is to post RFI responses, and other applicable documentation.
///////////////////////////////////////////////////////////////////////////////////////////////////////
127EAW26R0001 - Brush Creek Work Center - A00004: Time Extension and RFI Responses
The purpose of this amendment is to extend the proposal due date, post RFI responses, and other applicable documentation.
///////////////////////////////////////////////////////////////////////////////////////////////////////
127EAW26R0001 - Brush Creek Work Center - A00003: Time Extension and RFI Responses
The purpose of this amendment is to extend the proposal due date, post RFI responses, and other applicable documentation.
///////////////////////////////////////////////////////////////////////////////////////////////////////
127EAW26R0001 - Brush Creek Work Center - A00002: Site Visit Roster
The purpose of this amendment is to post the sign in sheet from the Forest Service led site visit held on 25 February 2026.
///////////////////////////////////////////////////////////////////////////////////////////////////////
127EAW26R0001 - Brush Creek Work Center - A00001: Site Visit Reschedule
This purpose of this amendment is to cancel and reschedule the current site visit due to inclement weather, and extend RFI submission due date.
Forest Serivce led site visit on 18 Feb 2026 is hereby canceled. Site visit is rescheduled for 25 Feb 2026 at 12:00 PM PST.
RFI due date is hereby extended to 6 March 2026 at 1:00 PM PST.
///////////////////////////////////////////////////////////////////////////////////////////////////////
127EAW26R0001 - Brush Creek Work Center
Disclosure of Magnitude of the Construction Project: More than $10,000,000
Set Aside: Total Small Business Set Aside
IMPORTANT NOTES:
See Section L, Paragraph L.3 for the Documents to Submit with Your Proposal
All Requests for Information (RFI's) shall be submitted to the Contracting Officer, Greg Cunningham, on the attached RFI form not later than 1300 hours PST, February 27th, 2026.
An organized site visit will be held on Wednesday Feb 18th, 2026, 1:00 PM PST. See page attachment "1. Statement of Work" for full details. In no event shall failure to inspect the site constitute grounds for a claim after contract award.
PLEASE RSVP TO THE SITE VISIT BY EMAILING: GREGORY.CUNNINGHAM@USDA.GOV
Update #5 ·
127EAW26R0001 - Brush Creek Work Center - A00004: Time Extension and RFI Responses
The purpose of this amendment is to extend the proposal due date, post RFI responses, and other applicable documentation.
///////////////////////////////////////////////////////////////////////////////////////////////////////
127EAW26R0001 - Brush Creek Work Center - A00003: Time Extension and RFI Responses
The purpose of this amendment is to extend the proposal due date, post RFI responses, and other applicable documentation.
///////////////////////////////////////////////////////////////////////////////////////////////////////
127EAW26R0001 - Brush Creek Work Center - A00002: Site Visit Roster
The purpose of this amendment is to post the sign in sheet from the Forest Service led site visit held on 25 February 2026.
///////////////////////////////////////////////////////////////////////////////////////////////////////
127EAW26R0001 - Brush Creek Work Center - A00001: Site Visit Reschedule
This purpose of this amendment is to cancel and reschedule the current site visit due to inclement weather, and extend RFI submission due date.
Forest Serivce led site visit on 18 Feb 2026 is hereby canceled. Site visit is rescheduled for 25 Feb 2026 at 12:00 PM PST.
RFI due date is hereby extended to 6 March 2026 at 1:00 PM PST.
///////////////////////////////////////////////////////////////////////////////////////////////////////
127EAW26R0001 - Brush Creek Work Center
Disclosure of Magnitude of the Construction Project: More than $10,000,000
Set Aside: Total Small Business Set Aside
IMPORTANT NOTES:
See Section L, Paragraph L.3 for the Documents to Submit with Your Proposal
All Requests for Information (RFI's) shall be submitted to the Contracting Officer, Greg Cunningham, on the attached RFI form not later than 1300 hours PST, February 27th, 2026.
An organized site visit will be held on Wednesday Feb 18th, 2026, 1:00 PM PST. See page attachment "1. Statement of Work" for full details. In no event shall failure to inspect the site constitute grounds for a claim after contract award.
PLEASE RSVP TO THE SITE VISIT BY EMAILING: GREGORY.CUNNINGHAM@USDA.GOV
Update #4 ·
127EAW26R0001 - Brush Creek Work Center - A00003: Time Extension and RFI Responses
The purpose of this amendment is to extend the proposal due date, post RFI responses, and other applicable
documentation.
///////////////////////////////////////////////////////////////////////////////////////////////////////
127EAW26R0001 - Brush Creek Work Center - A00002: Site Visit Roster
The purpose of this amendment is to post the sign in sheet from the Forest Service led site visit held on 25 February 2026.
///////////////////////////////////////////////////////////////////////////////////////////////////////
127EAW26R0001 - Brush Creek Work Center - A00001: Site Visit Reschedule
This purpose of this amendment is to cancel and reschedule the current site visit due to inclement weather, and extend RFI submission due date.
Forest Serivce led site visit on 18 Feb 2026 is hereby canceled. Site visit is rescheduled for 25 Feb 2026 at 12:00 PM PST.
RFI due date is hereby extended to 6 March 2026 at 1:00 PM PST.
///////////////////////////////////////////////////////////////////////////////////////////////////////
127EAW26R0001 - Brush Creek Work Center
Disclosure of Magnitude of the Construction Project: More than $10,000,000
Set Aside: Total Small Business Set Aside
IMPORTANT NOTES:
See Section L, Paragraph L.3 for the Documents to Submit with Your Proposal
All Requests for Information (RFI's) shall be submitted to the Contracting Officer, Greg Cunningham, on the attached RFI form not later than 1300 hours PST, February 27th, 2026.
An organized site visit will be held on Wednesday Feb 18th, 2026, 1:00 PM PST. See page attachment "1. Statement of Work" for full details. In no event shall failure to inspect the site constitute grounds for a claim after contract award.
PLEASE RSVP TO THE SITE VISIT BY EMAILING: GREGORY.CUNNINGHAM@USDA.GOV
Update #3 ·
127EAW26R0001 - Brush Creek Work Center - A00002: Site Visit Roster
The purpose of this amendment is to post the sign in sheet from the Forest Service led site visit held on 25 February 2026.
///////////////////////////////////////////////////////////////////////////////////////////////////////
127EAW26R0001 - Brush Creek Work Center - A00001: Site Visit Reschedule
This purpose of this amendment is to cancel and reschedule the current site visit due to inclement weather, and extend RFI submission due date.
Forest Serivce led site visit on 18 Feb 2026 is hereby canceled. Site visit is rescheduled for 25 Feb 2026 at 12:00 PM PST.
RFI due date is hereby extended to 6 March 2026 at 1:00 PM PST.
///////////////////////////////////////////////////////////////////////////////////////////////////////
127EAW26R0001 - Brush Creek Work Center
Disclosure of Magnitude of the Construction Project: More than $10,000,000
Set Aside: Total Small Business Set Aside
IMPORTANT NOTES:
See Section L, Paragraph L.3 for the Documents to Submit with Your Proposal
All Requests for Information (RFI's) shall be submitted to the Contracting Officer, Greg Cunningham, on the attached RFI form not later than 1300 hours PST, February 27th, 2026.
An organized site visit will be held on Wednesday Feb 18th, 2026, 1:00 PM PST. See page attachment "1. Statement of Work" for full details. In no event shall failure to inspect the site constitute grounds for a claim after contract award.
PLEASE RSVP TO THE SITE VISIT BY EMAILING: GREGORY.CUNNINGHAM@USDA.GOV
Update #2 ·
127EAW26R0001 - Brush Creek Work Center - A00001: Site Visit Reschedule
This purpose of this amendment is to cancel and reschedule the current site visit due to inclement weather, and extend RFI submission due date.
Forest Serivce led site visit on 18 Feb 2026 is hereby canceled. Site visit is rescheduled for 25 Feb 2026 at 12:00 PM PST.
RFI due date is hereby extended to 6 March 2026 at 1:00 PM PST.
///////////////////////////////////////////////////////////////////////////////////////////////////////
127EAW26R0001 - Brush Creek Work Center
Disclosure of Magnitude of the Construction Project: More than $10,000,000
Set Aside: Total Small Business Set Aside
IMPORTANT NOTES:
See Section L, Paragraph L.3 for the Documents to Submit with Your Proposal
All Requests for Information (RFI's) shall be submitted to the Contracting Officer, Greg Cunningham, on the attached RFI form not later than 1300 hours PST, February 27th, 2026.
An organized site visit will be held on Wednesday Feb 18th, 2026, 1:00 PM PST. See page attachment "1. Statement of Work" for full details. In no event shall failure to inspect the site constitute grounds for a claim after contract award.
PLEASE RSVP TO THE SITE VISIT BY EMAILING: GREGORY.CUNNINGHAM@USDA.GOV
Update #1 ·
127EAW26R0001 - Brush Creek Work Center
Disclosure of Magnitude of the Construction Project: More than $10,000,000
Set Aside: Total Small Business Set Aside
IMPORTANT NOTES:
See Section L, Paragraph L.3 for the Documents to Submit with Your Proposal
All Requests for Information (RFI's) shall be submitted to the Contracting Officer, Greg Cunningham, on the attached RFI form not later than 1300 hours PST, February 27th, 2026.
An organized site visit will be held on Wednesday Feb 18th, 2026, 1:00 PM PST. See page attachment "1. Statement of Work" for full details. In no event shall failure to inspect the site constitute grounds for a claim after contract award.
PLEASE RSVP TO THE SITE VISIT BY EMAILING: GREGORY.CUNNINGHAM@USDA.GOV
Files
Show all 22
Notice history
| Notice | Type | Posted |
|---|---|---|
| 127EAW26R0001 - Brush Creek Work Center Construction | Award Notice | |
| This notice | Solicitation |
Similar open opportunities
| Opportunity | Agency | Set-aside | Responses due |
|---|---|---|---|
| Camptonville Housing Decommissioning | Forest Service | Total Small Business | |
| GAOA Facilities, Barracks Inyo NF | Forest Service | Total Small Business | |
| AZ BL COLO 7528(1) Burro Creek Road | Federal Highway Administration | Total Small Business |
On GovTribe
Work this opportunity
- Track it in your pipeline
- Find teaming partners
- Similar opportunities
- Ask GovTribe AI about this opportunity