08112021W912DS21B00140006.pdf

W912DS21B0014

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is to extend the bid opening date, revise specifications, and update clause 52.211-10. Offeror must acknow ledge receipt of this amendment by the date specified in the proposal (or as amended) by one of the follow in methods: in the space provided on SF1442, by separate letter, or by signing block 15 below FAILURE TO ACKNOWLEDGE AMENDMENTS BY THE DATE AND TIME SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER IN ACCORDANCE WITH THE SUBMISSION, MODIFICATION, REVISION, AND

WITHDRAWAL OF PROPOSALS (FAR 15.208).

1. CONTRACT ID CODE PAGE OF PAGES

1 6

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 11-Aug-2021

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W912DS21B0014

X 9B. DATED (SEE ITEM 11)

01-Jul-2021

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

11-Aug-2021

CODE

US ARMY CORPS OF ENGINEERS, NEW YORK

26 FEDERAL PLAZA, RM 16-300

NEW YORK NY 10278-0090

W912DS 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00 10 00 - SOLICITATION

The required response date/time has changed from 12-Aug-2021 02:00 PM to 17-Aug-2021 02:00 PM.

SECTION 00 21 13 - INSTRUCTIONS TO BIDDERS

The following have been modified:

BID SUBMISSION INSTRUCTIONS

B ID SUBMISSION INSTRUCTIONS

The bidder shall be submitted electronically, as described below. The IFB will provide the Government address and receipt date for bid submittal.

The bid shall not contain classified data. The use of hyperlinks in proposals is prohibited.

NOTE: Notice of Intent to Bid must be submitted to Sandra Schenning Sandra.L.schenning@usace.army.mil SandraNicholas Emanuel N icholas.P.Emanuel@usace.army.mil two (2) days before the bid opening.

Bids are due 17-Aug-2021 at 2:00 P.M. est however the reading of the bids will happen at 2:30 P.M. to allow for time to download the bids before they are read.

Bids received after 17-Aug-2021 at 2:00 P.M. est on h ttps://safe.apps.mil/ will be considered late

It is recommended that bidders submit their bids at least 2 hours before to allow enough time for the bid to be uploaded. Please note that bidders do not need to wait until the day of bid opening to submit their bids.

The only authorized transmission method for the bid in response to this solicitation is electronically via SAFE online submission. NO OTHER

TRANSMISSION METHODS (EMAIL,

FACSIMILE, REGULAR MAIL, HAND

CARRIED, ETC.) WILL BE ACCEPTED.

The bid must be received by the Government by the date/time specified in the solicitation. The Bidder shall submit their bid using the following link:

h ttps://safe.apps.mil/

NOTE: Problems accessing the DoD SAFE site by external (non-CAC) users are typically due to SSL and/or client certificate issues. If the user receives a warning about a problem with the website's security certificate, this is because their browser is not configured to trust the DoD certificate authorities. The user can either import the DoD certificate authorities by following the instructions in the DoD PKI PMO's guide on Install Root or they can accept the risk and click on the option to continue to the website. The current guide on Install Root can be found Problems accessing the DoD SAFE site by non-CAC users -h ttps://safe.apps.mil/about.php

INSTRUCTIONS FOR SUBMITTING ELECTRONIC PROPOSALS:

In an effort to reduce paperwork and cost, all bids shall be submitted electronically through the SAFE site. Submission shall be in Adobe PDF format. You are limited to five (5) maximum files per upload (total size cannot exceed 2GB).

If you have a large number of files, recommend that you combine or ZIP your files before uploading to the SAFE site. Bidders may use compression utility software such as WinZip or PKZip to reduce file size and facilitate transmission.

REQUEST FOR UPLOAD CODE: Offerors must email Contract Specialist Sandra Schenning Sandra.L.schenning@usace.army.mil and Nicholas Emanuel N icholas.P.Emanuel@usace.army.mil no later than two (2) working days prior to the bid due date to receive a request code which will allow for file uploads via the SAFE site. Bidders that fail to email for request a code two (2) working days before bid submission date may not be able to receive a request code in time to upload their submission.

FILE DESCRIPTION: Include a “File Description” for each file(s) you upload. The “File Description” will be included in the email notice to each of the recipients you choose to have access your file(s). NOTE: Do NOT enter Privacy Act Data (Personal Identification Information (PII)) in the File Description.)

Submission shall be in Adobe PDF format.

INSTRUCTIONS TO FOLLOW ON THE SAFE WEBSITE:

1. Once at the SAFE website select the “Drop-off” icon. This allows users without a CAC or users whose computer is not configured to read a CAC the option to access the SAFE site as a guest.

2. After selecting the “Click Here” link you will be prompted to add your personal information, file information, recipient (Government representative) information and email settings.

3. When completing your file information for transmittal via the SAFE website, you will be required to enter the email address for all recipients. For this solicitation, the recipients are the Contract Specialist and the Contracting Officer. The Contract Specialist for this solicitation is Sandra Schenning

Sandra.L.schenning@usace.army.mil, and the Contracting Officer is N icholas.P.Emanuel@usace.army.mil. The E-Mail address of the Government Employee who initiated the request code will be automatically entered. The Proposer must enter the E-Mail address for both the Contracting Officer and Specialist. The Proposer can enter an additional E-Mail address if desired.

After entering the email address, click the ADD button to add the person(s) email to the “Recipients List” of your response. When your proposal is submitted, a notification will be sent to the recipients you added.

NOTE: Do NOT send the SAFE site packages to group email accounts.

Even if you successfully upload your proposal to the SAFE site, notification will not be sent to the government recipients until you verify your email address.

Entering an incorrect email may result in the rejection of your submission for lateness. A Proposer can confirm proper submission by the ‘Drop-Off Completed” screen which generates based on proper file submission.

NOTE: It has been reported that documents are more quickly uploaded into the SAFE website when using a Firefox web browser. The Government cannot verify that this is true and offers no guarantee that Offerors will have more success utilizing any particular browser.

RECEIPT OF SUBMISSIONS:

For the purposes of establishing whether a proposal submission is considered timely, the government considers the date and time the submission is completely uploaded into the SAFE website. For proposals larger than the 2GB capacity of the SAFE website and require multiple submissions, the Government will consider the date and time the last submission is completely uploaded into the SAFE website. Do not assume that electronic communication is instantaneous. It can take several minutes or even hours in some cases.

The government will not be responsible for submissions delivered to any location or to anyone other than those designated to receive proposals. Offerors are responsible for ensuring that proposals are submitted so as to reach the designated recipient. Offerors are responsible for allowing sufficient time for the proposal to be received in accordance with the instructions provided.

Bidders are encouraged to call into the following teleconference line:

Call number

+1-844-800-2712 US Toll Free +1-669-234-1177 US Toll Access code: 199 476 8533

Bidder must keep their phone on mute as to not disrupt the reader. Please limit the amount of company employees calling into the line so that the line does not disconnect. The abstract of bids will be posted to the Beta.Sam website.

ADDITIONAL INSTRUCTIONS

Potential Bidders are reminded that only the minimum documents are required for bid submission:

1. Signed 1442.

2. Acknowledged amendments.

3. Filled out bid schedule and totals.

4. Bid Guarantee.

5. Bidders must check off box (d) in 52.204-8 Annual Representations and

Certifications (DEC 2019) for being on SAM.gov

This will help reduce file size and speed up electronic transfer in the DoD SAFE site.

SECTION 00 70 00 - CONDITIONS OF THE CONTRACT

The following have been modified:

152.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) -

ALTERNATE I (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 5 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use before March 17, 2022. The date stated for completion must include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by August 31st 2021. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of clause)

(End of Summary of Changes)

The following items are applicable to this modification:

CHANGES

SPECIFICATIONS:

1. The following SPECIFICATION SECTIONS have been ADDED and are provided in their entirety herein:

-None

2. The following SPECIFICATIONS SECTIONS have been DELETED in their entirety:

-None

3. The following SPECIFICATION SECTIONS have been REVISED and REISSUED in their entirety:

-None

4. The following SPECIFICATION SECTIONS have been REVISED but NOT REISSUED:

-Section 01 11 00

REVISED SPECIFICATIONS:

-Section 01 11 00 – paragraph 1.1 (b), revised first sentence to “The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 31 August 2021.”