W912DS19B0009.pdf

Project Title: Invitation for Bid (IFB) Green Brook Segment C1, Borough of Middlesex, New Jersey.

1. 100% Unrestricted Full and Open Competition w ith HubZone Price Evaluation Preference

2. NAICS Code 237990, Size Standard $36,500,000.00

3. Project Magnitude Range: $10,000,000.00 and $25,000,000.00

4. Submit Bids no later than 2:00pm EST on 27 Aug 2019

U.S. Army Corps of Engineers New York District, Contracting Division, Room 16-300 26 Federal Plaza, New York, NY 10278-0090

Erica Miller, Contract Specialist

Due to heighted security at US. Government installation, all Bidders are instructed to allow ample time to get through security check point in order to have their bids delivered before 2:00pm on the date of the bid opening.

X

ERICA B MILLER 917-790-8121

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

25-Jul-2019

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______5 calendar days and complete it w ithin ________730 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________Specif ications

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specified in Item 8 by ___________ local time ______________27 Aug 2019 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______120 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

US ARMY CORPS OF ENGINEERS, NEW YORK

26 FEDERAL PLAZA, RM 16-300

NEW YORK NY 10278-0090

W912DS

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

212-264-3013FAX:TEL: (917)790-8026 TEL: FAX:

W912DS19B0009 58

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

Section 00 10 00 - Solicitation

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job

VIBRATION MONITORING

FFP

All work to monitor structures for potential effects of the contract work in accordance with the specifications.

FOB: Destination

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0002 1 Job

LEVEE, ACCESS ROAD, 30” CROSS DRAIN

FFP

UNDER RAMP AND RAMP TO BROOK. All work to construct approximately 430 LF of earthen embankment levee between stations 0+00D to 4+30D, an approximately 223 LF paved access road between stations 0+50B to 2+73B, an approximately 500 LF swale between stations 0+50A to 5+50A, and an approximately 154 LF paved access ramp to brook between stations 0+00C To 1+54C. Work includes but not limited to, excavation, fill placement, dewatering, embankment and swale, paving, riprap, storage pond and access clear area, 30” RCP pipes including the headwalls and manhole, access area around the Generator Building, soil stabilization system, and erosion control measures all in accordance with the drawings and specifications.

FOB: Destination

NET AMT

0003 1 Job

BYPASS CHANNEL AND CHANNEL RETAINING

FFP

All work to construct approximately 399 LF of earthen and Turf Reinforcement Mat by pass channel between stations 0+00E and 3+99E, an approximately 265 LF of a channel retaining wall, and a gravel toe drain and earthen berm. Work includes but not limited to, excavation, dewatering, shoring, backfill, and erosion control measures, all in accordance with the drawings and specifications.

FOB: Destination

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0004 1 Job

FLOODWALL

FFP

All work to construct approximately 450 LF of floodwall and sheetpile between stations 3+69.56 to 3+78.70 for the sheetpile and between stations 3+78.70 to 8+11.2 for the floodwall, including but not limited to, excavation, shoring, dewatering, backfill, concrete filled pipe pile foundations and pile tests, concrete cap, sheet pile, conduits, outlet chambers, swales, toe drain, toe drain cleanouts and erosion control measures, all in accordance with the drawings and specifications.

0005 1 Job

STABILITY BERM - NORTH SIDE OF NJTRR

FFP

All work necessary to construct approximately 1,150 LF of a rip rap stability berm along the north side of the NJT Rail Road embankment from station 0+00F to 11+50F, including but not limited to excavation, placement of rip rap, and erosion control measures in accordance with the drawings and specifications.

FOB: Destination

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0006 1 Job

GENERATOR BUILDING, CONCRETE FUEL PAD,

FFP

PUMP CHAMBER AND RETAINING WALL - All work necessary to construct a fully functioning generator building including control panels, mechanical and electrical equipment, a concrete fuel pad with above ground fuel tank, and pump chamber with all mechanical and electrical equipment required to make it functional, retaining wall, and connecting electric service, all in accordance with the drawings and specifications.

0007 1 Job

ACCESS ROAD – SOUTH SIDE NJTRR

FFP

All work necessary to construct an asphalt access road and access area between stations 0+00G to 9+05G from South Avenue to Proposed Bridge under NJTRR, in accordance with the drawings and specifications.

FOB: Destination

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0008 1 Job

NEW BRIDGE UNDER NJT RAIL ROAD

FFP

EMBANKMENT - ll work necessary to construct a new two span bridge, each span 25 ft wide by 11 ft tall and 85 ft long under the existing NJT Rail Road embankment, including temporary ground stabilization, on-site forming, excavation, disposal, shoring, dewatering, and over a weekend moving into location and backfilling and all other activities to construct the bridge such that NJT is operational by end of the weekend as specified and in the NJT occupancy permit. All work to be performed in compliance with NJ Transit rail road requirements.

0009 4,700 Cubic

Yard

TOP SOIL

FFP

All work necessary to obtain top soil, meeting all state residential requirements, and transport it to the project site in accordance with the drawings and specifications.

“Estimated Quantities”

FOB: Destination

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0010 1 Job

NJT TRAINING

FFP

New Jersey Transit Training to be provided to all workers.

0011 1 Job

NJT FLAGGER

FFP

New Jersey Transit Flagger to be provided during all work in the New Jersey Transit boundaries. Actual payment will be based on actual costs. Prepriced CLIN $150,000.00 and max that shall be paid.

FOB: Destination

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0012 1 Job

NJT RAIL, TIE AND BALLAST REMOVAL AND

FFP

REPLACEMENT - Contract New Jersey Transit to remove all rails, ties and ballast necessary to allow the bridge structure to be constructed and to replace such once the bridge and back fill are in place. NJT shall provide all labor, equipment and material for this work. Material not used in the replacing the tracks such as damaged ties, excess rail road embankment material, ballast etc. associated with the work performed by NJT rail road staff or their contractors shall be disposed of by them. Actual payment will be based on actual costs. Contractor to perform all needed coordination with NJ Transit rail road and their direct contractors. Prepriced CLIN $350,000.00 and max amount that shall be paid.

FOB: Destination

NET AMT

$150,000.00

$350,000.00

0013 1 Job

VERION CONDUIT

FFP

All work for the installation of one (1), four (4) inch conduit, inner duct, hand holes, drag lines, polydome and

(1) pipe penetration including clearing, excavation, shoring, dewatering and backfill.

FOB: Destination

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0014 1 Job

VERIZON FIBER OPTIC CABLE

FFP

Design, disconnect, remove, install and reconnect permanent Verizon fiber optic lines and service connections, providing all labor, equipment and material for this work.

Actual payment will be based on actual costs. Prepriced CLIN $70,000.00 and max amount that shall be paid.

FOB: Destination

$70,000.00

0015 1 Job

FIBER OPTIC CABLE NJTRR EMBANKMENT

FFP

Design, disconnect, remove, install and reconnect permanent Light Tower and Zayo fiber optic lines and service connections, providing all labor, equipment and material for this work. Actual payment will be based on actual costs. Prepriced CLIN $520,000.00 and max amount that shall be paid.

FOB: Destination

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0016 1 Job

SIGNAL AND ELECTRIC SERVICE

FFP

Design, disconnect, remove, install and reconnect permanent Signal and Electric lines owned by NJTRR and service connections, providing all labor, equipment and material for this work. Actual payment will be based on actual costs incurred. Prepriced CLIN $200,000.00 and max amount that shall be paid.

FOB: Destination

NET AMT

$520,000.00

$200,000.00

0017 1 Job

PASSENGER TRANSPORT DURING TRACK OUTAGE

FFP

Contract New Jersey Transit for temporary transport of passengers during period of track shutdown for installation of the new bridge. Work shall include all vehicles and labor and fees associated with the temporary transport of passengers.

Contractor to perform all needed coordination with NJ Transit rail road and their direct contractors. Actual payment will be based on actual costs incurred. Prepriced CLIN $300,000 and max amount that shall be paid.

FOB: Destination

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0018 10,000 Cubic

Yard

HAUL, DISPOSAL AND REPLACEMENT OF

FFP

UNSATISFACTORY MATERIAL - All work necessary to excavate and dispose of unsatisfactory material at an approved off-site location and excavation backfill with suitable material in accordance with the drawings and specifications. “Estimated Quantities”

FOB: Destination

$300,000.00

0019 4.755 Each

MITIGATION CREDITS

FFP

Forested wetland. All cost associated with purchasing mitigation credits in accordance with specifications section 01 22 00.00.10 Price and payment procedurces FOB: Destination

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0020 2.311 Each

Riparian Zone

FFP

All costs associated with purchasing mitigation credits in accordance with Specification Section 01 22 00.00.10 Price and Payment Procedures

0021 .23 Each

OPEN WATER

FFP

All costs associated with purchasing mitigation credits in accordance with Specification Section 01 22 00.00.10 Price and Payment Procedures

FOB: Destination

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0022 1 Job

LIABILITY INSURANCE

FFP

New Jersey Department of Environmental Protection (NJDEP), Middlesex County, and the Borough of Middlesex Liability Insurance. The amount bid will be the maximum amount payable. Actual payment will be based on actual costs.

0023 1 Job

NEW JERSEY TRANSIT RAILROAD INSURANCE

FFP

The amount bid will be the maximum amount payable.

Actual payment will be based on actual costs.

FOB: Destination

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0024 1 Job

AS BUILT

FFP

Contractor shall complete the Record (Contractor shall complete the Record (“As- Builts) CAD submittals as required by Specification Section 01 78 00 CLOSEOUT SUBMITTALS for Record Drawings (“As-Builts) Requirements and Section 01 12 00 DESIGN AND RECORD DRAWING REQUIREMENTS for CADD Standards and compliance. Prepriced CLIN $100,000.00 and max amount that shall be paid.

FOB: Destination

$100,000.00

0025 1 Job

SUBMERSIBLE PUMP

FFP

All work associated with furnishing and installing the submersible pump in accordance with Specification Section 35 45 02.00 10 Submersible Pump, Axial-Flow and Mixed-Flow Type and Specification Section 25 14 01 Pump Station Instrumentation and Control Panels.

FOB: Destination

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0026 1 Job

OPTION OPTIONAL ITEM 1

FFP

FLOODWALL- All work to construct approximately 650 LF of floodwall between stations 8+11.2 to 14+77.52, including but not limited to, excavation, shoring, dewatering, backfill, concrete filled pipe pile foundations and pile tests, concrete cap, sheet pile, conduits, outlet chambers, swales, toe drain, toe drain cleanouts and erosion control measures, all in accordance with the drawings and specifications.

0027 1 Job

OPTION OPTIONAL ITEM 2

FFP

PLUG EXISTING 36”x 42” RCP UNDER NJTRR- All work necessary to plug an existing 36”x 42” RCP under the NJT Rail Road embankment at approximately station 11+21F and to attach a new inlet with 24” diameter flared end section to an existing Inlet on the South Side of South Avenue including but not limited to, saw cutting the existing pavement, excavation, dewatering, backfill, paving and erosion control measures in accordance with the drawings and specifications. All work within NJT right of way to be performed in compliance with NJ Transit rail road requirements.

FOB: Destination

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0028 2,000 Cubic

Yard

OPTION OPTIONAL ITEM 3

FFP

CONTAMINATED NON-HAZARDOUS MATERIAL REMOVAL - All work for handling, transport, treatment and off-site disposal of material exceeding NJDEP residential soil cleanup criteria and classified as contaminated non-hazardous (ID27 WASTE), suitable for landfill cover, roadway subbase and recycling facilities, complete.

“Estimated Quantities”

0029 2,000 Cubic

Yard

OPTION OPTIONAL ITEM 4

FFP

CONTAMINATED NON-HAZARDOUS MATERIAL REMOVAL - All work for handling, transport, treatment and off-site disposal of material exceeding NJDEP residential soil cleanup criteria and classified as contaminated non-hazardous (ID27 WASTE), suitable for landfill cover, roadway subbase and recycling facilities, complete.

“Estimated Quantities”

FOB: Destination

NET AMT

TOTALS SECTION

BASE TOTAL AMOUNT (CLIN 0001-0025) $________________

OPTIONAL ITEM 1 TOTAL AMOUNT (CLIN 0026) $________________

OPTIONAL ITEM 2 TOTAL AMOUNT (CLIN 0027) $________________

OPTIONAL ITEM 3 TOTAL AMOUNT (CLIN 0028) $ ________________

OPTIONAL ITEM 4 TOTAL AMOUNT (CLIN 0029) $________________

GRAND TOTAL - BASE AMOUNT PLUS OPTIONAL ITEMS 1 – 4 AMOUNTS (CLIN 0001-

0029)

NOTES:

1. Bidders are required to bid on all items on the Bid Schedule or their bid will be rejected.

2. The low bidder for the purpose of award will be the confirming responsible bidder offering the lowest price for the Total Base Bid and Optional Bid Amount for all Items. The Government is under no obligation to award the optional items.

3. Any bid which is materially unbalanced as to prices for the Base Bid and Optional Items may be rejected. An unbalanced bid is one in which the price of one or more contract line items is significantly over or understated as indicated by the application of cost or price analysis techniques.

4. Bidders are reminded that they must bid on the issued plans and specifications as amended. Any deviations, conditions or attachments made by the bidders thereto may render the bid non-responsive and be cause for its rejection.

5. The Options may be exercised at the discretion of the Government and are not mandatory.

6. If Option #1 is exercised, Bid Item No. 0026 shall be exercised within 365 calendar days of issuance of the Base Bid NTP. No additional time shall be added to the contract duration.

7. If Option #2 is exercised, Bid Item No. 0027 shall be exercised within 365 calendar days of issuance of the Base Bid NTP. No additional time shall be added to the contract duration.

8. If Option #3 is exercised, Bid Item No. 0028 shall be exercised within 365 calendar days of issuance of the Base Bid NTP. No additional time shall be added to the contract duration.

9. If Option #4 is exercised, Bid Item No. 0029 shall be exercised within 365 calendar days of issuance of the Base Bid NTP. No additional time shall be added to the contract duration.

Section 00 21 13 - Instructions to Bidders

SECTION 00 21 13

ELECTRONIC SUBMITTAL

GENERAL INSTRUCTIONS: Electronic Submission: In addition to the hard copies required in block 13 of the Standard Form 1442, all offerors shall submit their bids on a CD-ROM. Written portions of the bid shall be in MS Word or Adobe Acrobat PDF format. The electronic version shall be either a single file tabbed in the same order as the hard copy or multiple files hyperlinked to a single table of contents. Any portion of the bid not available in electronic format, i.e. cut sheets, if applicable, should be scanned in Adobe Acrobat PDF format, thus making it available electronically. The CDROM must be clearly labeled by solicitation number, project name, installation, and offeror’s name. The CD-ROM shall be marked with a label stating “Unclassified//Controlled Unclassified Info.” In the event of any conflict between the electronic submission and the hard copy submission, the hard copy submission will govern and will be the material upon which the Government bases its evaluation and ultimately, its decision.

Electronic media may be submitted in an un-editable format.

CPARS

The Federal Acquisition Regulation (FAR) requires that Past Performance Information (PPI) be collected on DoD contracts. The Contractor Performance Assessment Reporting System (CPARS) is a web‐enabled application the supports the completion, distribution and retrieval of all contract performance evaluations. Contractor Representative are responsible for reviewing and commenting on evaluations submitted on the Contractor Performance Assessment Reporting System (CPARS) website at https://www.cpars.gov/index.htm

ATOPSEC

The Contractor must pre-screen Candidates using the E-verify Program (http://www.uscis.gov/e-verify) website to meet the established employment eligibility requirements. The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to enrollment to ensure the correct information is entered into the E-verify system. An initial list of verified/eligible Candidates must be provided to the COR no later than 3 business days after the initial contract award." *When contracts are withindividuals, the individuals will be required to complete a Form I-9, Employment Eligibility Verification, with the designated Government representative. This Form will be provided to the Contracting Officer and shall become part of the official contract file.

ATOPSEC

The Contractor must pre-screen Candidates using the E-verify Program (http://www.uscis.gov/e-verify) website to meet the established employment eligibility requirements. The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to enrollment to ensure the correct information is entered into the E-verify system. An initial list of verified/eligible Candidates must be provided to the COR no later than 3 business days after the initial contract award."

*When contracts are withindividuals, the individuals will be required to complete a Form I-9, Employment Eligibility Verification, with the designated Government representative.

This Form will be provided to the Contracting Officer and shall become part of the official contract file.

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions NOV 2013 52.204-7 System for Award Management OCT 2018

52.204-17 Ownership or Control of Offeror JUL 2016 52.214-3 Amendments To Invitations For Bids DEC 2016 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.252-1 Solicitation Provisions Incorporated By Reference FEB 1998

CLAUSES INCORPORATED BY FULL TEXT

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm Fixed price contract resulting from this solicitation.

(End of provision)

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS--SECONDARY SITE OF THE WORK (MAY

2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements,of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

52.223-22 PUBLIC DISCLOSURE OF GREENHOUSE GAS EMISSIONS AND REDUCTION GOALS--

REPRESENTATION (DEC 2016)

(a) This representation shall be completed if the Offeror received $7.5 million or more in Federal contract awards in the prior Federal fiscal year. The representation is optional if the Offeror received less than $7.5 million in Federal contract awards in the prior Federal fiscal year.

(b) Representation. [Offeror is to check applicable blocks in paragraphs (b)(1) and (2).]

(1) The Offeror (itself or through its immediate owner or highest-level owner) [ ___ ] does, [ ___ ] does not publicly disclose greenhouse gas emissions, i.e., make available on a publicly accessible Web site the results of a greenhouse gas inventory, performed in accordance with an accounting standard with publicly available and consistently applied criteria, such as the Greenhouse Gas Protocol Corporate Standard.

(2) The Offeror (itself or through its immediate owner or highest-level owner) [ ___ ] does, [ ___ ] does not publicly disclose a quantitative greenhouse gas emissions reduction goal, i.e., make available on a publicly available Web site a target to reduce absolute emissions or emissions intensity by a specific quantity or percentage.

(3) A publicly accessible Web site includes the Offeror's own Web site or a recognized, third-party greenhouse gas emissions reporting program.

(c) If the Offeror checked ``does'' in paragraphs (b)(1) or (b)(2) of this provision, respectively, the Offeror shall provide the publicly accessible Web site(s) where greenhouse gas emissions and/or reduction goals are reported:

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from Nicholas Emanuel at 26 Federal Plaza, Room 16-300 New York, NY 10278-0090.

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

Section 00 45 00 - Representations and Certifications

CLAUSES INCORPORATED BY REFERENCE

52.204-8 Annual Representations and Certifications OCT 2018 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.209-2 Prohibition on Contracting with Inverted Domestic Corporations--Representation

NOV 2015

52.215-20 Requirements for Certified Cost or Pricing Data or Information Other Than Certified Cost or Pricing Data

OCT 2010

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

52.209-12 CERTIFICATION REGARDING TAX MATTERS (FEB 2016)

(a) This provision implements section 523 of Division B of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts.

(b) If the Offeror is proposing a total contract price that will exceed $5,000,000 (including options), the Offeror shall certify that, to the best of its knowledge and belief, it--

(1) Has [ ] filed all Federal tax returns required during the three years preceding the certification;

(2) Has not [ ] been convicted of a criminal offense under the Internal Revenue Code of 1986; and

(3) Has not [ ], more than 90 days prior to certification, been notified of any unpaid Federal tax assessment for which the liability remains unsatisfied, unless the assessment is the subject of an installment agreement or offer in compromise that has been approved by the Internal Revenue Service and is not in default, or the assessment is the subject of a non-frivolous administrative or judicial proceeding.

252.204-7007 ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (APR 2019)

Substitute the following paragraphs (d) and (e) for paragraph (d) of the provision at FAR 52.204-8:

(d)(1) The following representations or certifications in the System for Award Management (SAM) database are applicable to this solicitation as indicated:

(i) 252.209-7003, Reserve Officer Training Corps and Military Recruiting on Campus--Representation. Applies to all solicitations with institutions of higher education.

(ii) 252.216-7008, Economic Price Adjustment--Wage Rates or Material Prices Controlled by a Foreign Government. Applies to solicitations for fixed-price supply and service contracts when the contract is to be performed wholly or in part in a foreign country, and a foreign government controls wage rates or material prices and may during contract performance impose a mandatory change in wages or prices of materials.

(iii) 252.225-7042, Authorization to Perform. Applies to all solicitations when performance will be wholly or in part in a foreign country.

(iv) 252.225-7049, Prohibition on Acquisition of Certain Foreign Commercial Satellite Services--Representations.

Applies to solicitations for the acquisition of commercial satellite services.

(v) 252.225-7050, Disclosure of Ownership or Control by the Government of a Country that is a State Sponsor of Terrorism. Applies to all solicitations expected to result in contracts of $150,000 or more.

(vi) 252.229-7012, Tax Exemptions (Italy)--Representation. Applies to solicitations when contract performance will be in Italy.

(vii) 252.229-7013, Tax Exemptions (Spain)--Representation. Applies to solicitations when contract performance will be in Spain.

(viii) 252.247-7022, Representation of Extent of Transportation by Sea. Applies to all solicitations except those for direct purchase of ocean transportation services or those with an anticipated value at or below the simplified acquisition threshold.

(2) The following representations or certifications in SAM are applicable to this solicitation as indicated by the Contracting Officer: [Contracting Officer check as appropriate.]

____ (i) 252.209-7002, Disclosure of Ownership or Control by a Foreign Government.

____ (ii) 252.225-7000, Buy American--Balance of Payments Program Certificate.

____ (iii) 252.225-7020, Trade Agreements Certificate.

____ Use with Alternate I.

____ (iv) 252.225-7031, Secondary Arab Boycott of Israel.

____ (v) 252.225-7035, Buy American--Free Trade Agreements--Balance of Payments Program Certificate.

____ Use with Alternate I.

____ Use with Alternate II.

____ Use with Alternate III.

____ Use with Alternate IV.

____ Use with Alternate V.

(e) The offeror has completed the annual representations and certifications electronically via the SAM Web site at https://www.acquisition.gov/. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in FAR 52.204-8(c) and paragraph (d) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer, and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below ____ [offeror to insert changes, identifying change by provision number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR/DFARS Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications located in the SAM database.

Section 00 72 00 - General Conditions

CLAUSES INCORPORATED BY REFERENCE

52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006 52.203-7 Anti-Kickback Procedures MAY 2014 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-11 Certification And Disclosure Regarding Payments To

Influence Certain Federal Transactions

SEP 2007

52.203-12 Limitation On Payments To Influence Certain Federal Transactions

OCT 2010

52.203-13 Contractor Code of Business Ethics and Conduct OCT 2015 52.203-14 Display of Hotline Poster(s) OCT 2015 52.203-17 Contractor Employee Whistleblower Rights and Requirement

To Inform Employees of Whistleblower Rights

APR 2014

52.204-2 Alt I Security Requirements (Aug 1996) - Alternate I APR 1984 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2018

52.204-13 System for Award Management Maintenance OCT 2018 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-22 Alternative Line Item Proposal JAN 2017 52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters

OCT 2018

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.210-1 Market Research APR 2011 52.211-13 Time Extensions SEP 2000 52.211-18 Variation in Estimated Quantity APR 1984 52.214-26 Audit and Records--Sealed Bidding OCT 2010 52.214-27 Price Reduction for Defective Certified Cost or Pricing Data -

Modifications - Sealed Bidding

AUG 2011

52.214-28 Subcontracting Certified Cost Or Pricing Data-- Modifications--Sealed Bidding

OCT 2010

52.214-29 Order Of Precedence--Sealed Bidding JAN 1986 52.214-29 Order Of Precedence--Sealed Bidding JAN 1986 52.215-11 Price Reduction for Defective Certified Cost or Pricing Data--

Modifications

AUG 2011

52.215-15 Pension Adjustments and Asset Reversions OCT 2010 52.215-18 Reversion or Adjustment of Plans for Postretirement Benefits

(PRB) Other than Pensions

JUL 2005

52.215-19 Notification of Ownership Changes OCT 1997 52.215-21 Requirements for Certified Cost or Pricing Data and Data

Other Than Certified Cost or Pricing Data -- Modifications

OCT 2010

52.217-5 Evaluation Of Options JUL 1990

52.219-1 Alt I Small Business Program Representations (Sept 2015) Alternate I

SEP 2015

52.219-4 Notice of Price Evaluation Preference for HUBZone Small Business Concerns

OCT 2014

52.219-8 Utilization of Small Business Concerns OCT 2018 52.219-9 Small Business Subcontracting Plan AUG 2018 52.219-16 Liquidated Damages-Subcontracting Plan JAN 1999 52.222-1 Notice To The Government Of Labor Disputes FEB 1997 52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards - Overtime

Compensation

MAY 2018

52.222-6 Construction Wage Rate Requirements AUG 2018 52.222-7 Withholding of Funds MAY 2014 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-19 Child Labor -- Cooperation with Authorities and Remedies JAN 2018 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-35 Equal Opportunity for Veterans OCT 2015 52.222-36 Equal Opportunity for Workers with Disabilities JUL 2014 52.222-37 Employment Reports on Veterans FEB 2016 52.222-38 Compliance With Veterans' Employment Reporting

Requirements

FEB 2016

52.222-40 Notification of Employee Rights Under the National Labor Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons JAN 2019 52.222-54 Employment Eligibility Verification OCT 2015 52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015 52.222-62 Paid Sick Leave Under Executive Order 13706 JAN 2017 52.223-1 Biobased Product Certification MAY 2012 52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts

SEP 2013

52.223-3 Hazardous Material Identification And Material Safety Data JAN 1997 52.223-4 Recovered Material Certification MAY 2008 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-6 Drug-Free Workplace MAY 2001 52.223-10 Waste Reduction Program MAY 2011 52.223-15 Energy Efficiency in Energy-Consuming Products DEC 2007 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

AUG 2018

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.224-3 Privacy Training JAN 2017 52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.227-1 Authorization and Consent DEC 2007 52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

DEC 2007

52.227-4 Patent Indemnity-Construction Contracts DEC 2007

52.228-2 Additional Bond Security OCT 1997 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 Pledges Of Assets AUG 2018 52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.228-14 Irrevocable Letter of Credit NOV 2014 52.228-15 Performance and Payment Bonds--Construction OCT 2010 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-17 Interest MAY 2014 52.232-23 Assignment Of Claims MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

OCT 2018

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-15 Schedules for Construction Contracts APR 1984 52.236-16 Quantity Surveys APR 1984 52.236-17 Layout of Work APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995 52.242-5 Payments to Small Business Subcontractors JAN 2017 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.243-4 Changes JUN 2007 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.247-34 F.O.B. Destination NOV 1991 52.248-3 Value Engineering-Construction OCT 2015 52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984 52.253-1 Computer Generated Forms JAN 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.203-7003 Agency Office of the Inspector General DEC 2012 252.203-7004 Display of Hotline Posters MAY 2019

252.203-7005 Representation Relating to Compensation of Former DoD Officials

NOV 2011

252.204-7000 Disclosure Of Information OCT 2016 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7006 Billing Instructions OCT 2005 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting

OCT 2016

252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991 252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of Terrorism

MAY 2019

252.215-7008 Only One Offer OCT 2013 252.219-7003 Small Business Subcontracting Plan (DOD Contracts) MAY 2019 252.223-7004 Drug Free Work Force SEP 1988 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7012 Preference For Certain Domestic Commodities DEC 2017 252.225-7021 Trade Agreements--Basic DEC 2017 252.225-7048 Export-Controlled Items JUN 2013 252.227-7013 Rights in Technical Data--Noncommercial Items FEB 2014 252.227-7016 Rights in Bid or Proposal Information JAN 2011 252.227-7017 Identification and Assertion of Use, Release, or Disclosure

Restrictions

JAN 2011

252.227-7020 Rights In Special Works JUN 1995 252.227-7022 Government Rights (Unlimited) MAR 1979 252.227-7023 Drawings and Other Data to become Property of Government MAR 1979 252.227-7033 Rights in Shop Drawings APR 1966 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

DEC 2018

252.232-7004 DOD Progress Payment Rates OCT 2014 252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.236-7008 Contract Prices-Bidding Schedules DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 5 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 730. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $4,118 for each calendar day of delay until the work is completed or accepted.

The “second tier” demurrage shall be assessed at the rate calculated below in the event the contractor fails to complete documented punchlist items after the date of beneficial occupancy” Second Tier - $1,030/day

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (JULY 2013)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is ``not dominant in its field of operation'' when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/content/table-small-business-size-standards.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation required by paragraph (b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was…