Am_0005.pdf

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 11/2016)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBER

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

12. ACCOUNTING AND APPROPRIATION DATA (If required) copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

Previous edition unusable

Amendment No.0005 W9128F

CONSOLIDATED HELO/TRF OPS/AMU AND ALERT FACILITY AT FE WARREN AFB, WYOMING

See attached documentation for content of the changes to RFP.

Date for receipt of proposals is 5 OCT 2021 at 1400 hours

Government Point of Contact: Brian Finerty, Contract Specialist (402) 996-3715

U.S ARMY CORPS OF ENGINEERS, OMAHA DISTRICT

CONTRACTING OFFICE

1616 CAPITOL AVE.

OMAHA, NE 68102-4901

See Item 6

W9128F-21-R-0070

09/02/2021

07/30/2021

09/02/2021

Am #0005 - 2 (Continuation SF 30)

2 SEP 2021

Solicitation No. W9128F21R0070

Date of Issue: 30 JUL 2021 NEW Date of Receiving Proposals: 5 OCT 2021

SUBJECT: Amendment No. 0005 to Request for Proposal Solicitation Package for Construction of

CONSOLIDATED HELO/TRF OPS/AMU AND ALERT FACILITY AT FE WARREN AFB, WYOMING

TO: Prospective Offerors and Others Concerned

1. The specifications and drawings for subject project are hereby modified as follows (revise all specification indices, attachment lists, and drawing indices accordingly).

a. Specifications (New and/or Revised and Reissued). Delete and substitute or add specification pages or sections as noted below. The substituted pages or sections are revised and reissued with this amendment. For convenience, on the revised specification pages, changes have been tracked in sections listed with asterisks.

Pages or Sections Deleted Pages or Sections Substituted or Added 00 10 00 00 10 00* 01 30 00.24 01 30 00.24* 09 67 23.15 09 67 23.15* 09 67 23.16 09 67 23.16* 23 56 13 23 56 13*

b. Drawings (Reissued). The following drawings are revised, with latest revision dates indicated in their title blocks, and reissued with this amendment.

1) Sheet FE96S-600, COLUMN SCHEDULE

2) Sheet FE96S-601, COLUMN SCHEDULE

3) Sheet FE96FP504, FIRE SUPPRESSION DETAILS

4) Sheet FE96P-601, PLUMBING SCHEDULES

5) Sheet P-602, PLUMBING SCHEDULES

6) Sheet P-615, PLUMBING SCHEDULES

7) Sheet M-604, MECHANICAL SCHEDULES

8) Sheet M-605, MECHANICAL SCHEDULES

9) Sheet M-704, AIRFLOW DIAGRAMS

10) Sheet E-401, ENALRGED PLANS

11) Sheet E-613, PANEL SCHEDULES

12) Sheet E-614, PANEL SCHEDULES

2. This amendment is a part of the proposing papers and its receipt shall be acknowledged on the SF30. All other conditions and requirements of the request for proposal remain unchanged.

3. Electronic Proposal/Email. See Section 00 22 00 for how to submit electronic proposals.

4. Electronic Offers will be received until 2:00 p.m., local time at place of receiving proposals, 5 OCT 2021, as stated in the Request for Proposal.

Am #0005 - 3 (Continuation SF 30)

Attachments:

Spec Pages listed in 1.a., above Site Visit Sign-In Sheet Drawings listed in 1.b., above (under separate cover)

U.S. Army Corps of Engineers, Omaha District 1616 Capitol Avenue Omaha, Nebraska 68102-4901

2 SEP 2021

jlb/2099

00 10 00 Page 1

SOLICITATION, OFFER

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

W9128F-21-R-0070

2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED

30 JUL 2021

PAGE OF PAGES

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

7. ISSUED BY CODE CT 8. ADDRESS OFFER TO

U.S.ARMY CORPS OF ENGINEERS, OMAHA

Contracting Division (CENWO-CT) 5475 Tech Center Drive, Suite 205 Colorado Springs, Colorado 80919

U.S.ARMY CORPS OF ENGINEERS, OMAHA

Attn: CONTRACTING DIVISION (CENWO-CT) 5475 Tech Center Drive, Suite 205 Colorado Springs, Colorado 80919

9. FOR INFORMATION

EMAIL:

a. NAME Brian Finerty

b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS) brian.c.finerty@usace.army.mil

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date):

The offeror hereby agrees to do all work described in the documents entitled:

CONSOLIDATED HELO/TRF OPS/AMU AND ALERT FACILITY

FE WARREN AFB, WYOMING

RETURN WITH OFFER: INFORMATION REQUIRED BY SECTION 00 10 00 (SF1442), SECTION 00 22 00, AND SECTION 00 45 00.

*BLOCK 13A. – REFER TO SECTION 00 22 00 FOR THE NUMBER OF COPIES TO BE SUBMITTED WITH THE ORIGINAL OFFER.

THIS PROJECT IS 100 PERCENT DESIGNED CONSTRUCTION RFP..

11. The Contractor shall begin performance within 10 calendar days and complete it within 720 calendar days after receiving award, notice to proceed. This performance period is mandatory, negotiable.

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12b.)

YES NO

12b. CALENDAR DAYS

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and 1 copy to perform the work required are due at the place specified in Item 8 by 1400 (hour) local time 13 SEP5 OCT 2021. If this is a sealed bid solicitation, offers must be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

b. An offer guarantee is is not required.

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than 60 calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

STANDARD FORM 1442(REV. 8/2014)

Prescribed by GSA - FAR(48 CFR) 53.236-1(d)

Am_0005

00 10 00 Page 2

OFFER (Must be fully completed by offeror)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

DUNS or Unique Entity Identifier Number:

16. REMITTANCE ADDRESS (Include only if different than Item 14)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within 60 calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

AMOUNTS

SEE ATTACHED CLIN PRICING SCHEDULE

Contractor’s Fax No. CAGE CODE Contractor’s E-Mail address

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation - give number and date of each)

AMENDMENT NO.

DATE

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) ( ) 41 U.S.C. 3304(a) ( )

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

U.S. Army Engineer District, Omaha 1616 Capitol Ave.

Omaha, Nebraska 68102-4901

USAED Omaha c/o USACE Finance Center 5722 Integrity Drive Millington, TN 38054-5005

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (contractor is required to sign this document and return _______ copies to issuing office.) Contractor agrees to furnish and deliver all items or perform all work, requisitions identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award,

(b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation, is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA

BY

31c. AWARD DATE

STANDARD FORM 1442 (REV. 8/2014) BACK

Section 00 10 00 W9128F-21-R-0070

CLIN SCHEDULE 00 10 00 - 3

OFFEROR'S NAME:____________________________

CONTRACT LINE ITEM (CLIN) BIDDING SCHEDULE

ITEM

NO.

DESCRIPTION QUANTITY UNIT UNIT

PRICE

LINE ITEM AMOUNT

BASIC ITEMS

0001 All work complete to Construct Consolidated Helo/TRF Ops/AMU and Alert Facility, excluding items listed below MILCON FUNDED

1 Job XXX $_______________________

0002 All work complete to Construct Site Work outside the 5’ line of the Consolidated Helo/TRF Ops/AMU and Alert Facility, excluding items listed below MILCON FUNDED

1 Job XXX $_______________________

0003 All work complete to Construct Power and Lighting Site Work in cooperation with High West Energy, excluding items listed below

MILCON FUNDED

1 Job XXX $_______________________

0004 All work complete to Construct Natural Gas Site Work in cooperation with Black Hills Energy, excluding items listed below MILCON

FUNDED

1 Job XXX $_______________________

TOTAL BASIC AMOUNT $_______________________

[Option

Additional Cost for Construction of Crash/Fire Rescue Facility MILCON

FUNDED

1 Job XXX $_______________________

[Option

Additional Cost for Construction of Additional Storage Shelter Bay

MILCON FUNDED

1 Job XXX $_______________________

[Option

Additional Cost for Construction of Additional Apron Parking Space

MILCON FUNDED

1 Job XXX $_______________________

[Option

Additional Cost for Construction of Reinforced Snow Melt Panels for Hangar Doors MILCON FUNDED

Section 00 10 00 W9128F-21-R-0070

CLIN SCHEDULE 00 10 00 - 4

[Option

Additional Cost to Procure and Install Generators, Rectifiers, and Aircraft Wash Equipment MILCON

FUNDED

1 Job XXX $_______________________

[Option

Additional Cost to Procure and Install Air Compressor for CRF MILCON

FUNDED

1 Job XXX $_______________________

[Option

Additional Cost to Procure and Install Prefabricated POL and HAZMAT Storage Buildings MILCON

FUNDED

1 Job XXX $_______________________

[Option

Additional Cost to Relocate Prefabricated Armory Building

MILCON FUNDED

1 Job XXX $_______________________

[Option

Additional Cost to Procure and Install Consolidated Helo/TRF Ops/AMU and Alert Facility Furniture, Fixtures, and Equipment Package O&M

FUNDED

1 Job XXX $_______________________

[Option

Additional Cost to Procure and Install CRF Furniture, Fixtures, and Equipment Package O&M FUNDED

1 Job XXX $_______________________

[Option

Additional Cost to Procure and Install Consolidated Helo/TRF Ops/AMU and Alert Facility Public Address System O&M FUNDED

1 Job XXX $_______________________

[Option

Additional Cost to Procure and Install CRF Public Address System O&M

FUNDED

TOTAL AMOUNT (BASIC + OPTIONS) $_______________________

NOTES:

1. See 00 21 00, INSTRUCTIONS TO OFFERORS, for evaluation of options. The Government reserves the right to exercise MILCON options within 180 and O&M options up to 365 calendar days after issuance of Notice to Proceed.

2. Prices must be entered for all items of the schedule. Total amounts submitted without prices being entered on individual items will be rejected. In case of variation between the lump-sum prices and the total amount, the lump-sum prices will be considered the price submitted.

A modification to a bid which provides for a single adjustment to the total amounts, should state the application of the adjustment to each respective lump-sum price affected. If the modification is not so apportioned, the single adjustment will be applied to Item No. 0001.

Consolidated Helo/TRF OPS/AMU & Alert Facility FE96

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 30 00.24

OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

04/20

PART 1 GENERAL

1.1 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

1.2 CONTRACTOR SUPPLY AND USE OF ELECTRONIC SOFTWARE FOR PROCESSING

CONSTRUCTION WAGE RATE REQUIREMENTS STATUTE CERTIFIED LABOR

PAYROLLS

1.3 VETERANS EMPLOYMENT EMPHASIS FOR U.S. ARMY CORPS OF ENGINEERS

CONTRACTS

1.4 COMPLETION OF WORK

1.5 CONTRACTOR PERFORMANCE EVALUATIONS

1.6 MANPOWER REPORTING

1.7 LIQUIDATED DAMAGES-CONSTRUCTION

1.8 ANTITERRORISM (AT)/OPERATIONS SECURITY (OPSEC) PROVISIONS

1.9 MISSION DELAY DAYS

1.10 CONTRACT DRAWINGS AND SPECIFICATIONS

1.10.1 SETS FURNISHED

1.10.2 REPRODUCTION AND DISTRIBUTION

1.10.3 NOTIFICATION OF DISCREPANCIES

1.10.4 OMISSIONS

1.11 SUBMITTALS

1.12 CONCURRENT CONSTRUCTION

1.13 PAYMENT

1.13.1 PROMPT PAYMENT ACT

1.13.2 PAYMENT FOR MATERIALS DELIVERED OFFSITE

1.13.3 CONTRACTOR PAYROLL RECORD

1.14 AVAILABILITY OF UTILITY SERVICES

1.15 UTILITY SERVICE INTERRUPTIONS

1.16 DIGGING PERMITS AND ROAD CLOSINGS

1.17 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

1.18 INSURANCE REQUIRED

1.19 SECURITY REQUIREMENTS

1.19.1 Contractor's Employee Identification

1.19.2 Entry Requirements

1.19.3 F.E. Warren AFB Entry Requirements

1.19.4 F.E. Warren AFB DBIDS Sponsor Privileges

1.20 CONTRACTOR QUALITY CONTROL (CQC)

1.21 NONDOMESTIC CONSTRUCTION MATERIALS

1.22 DAILY WORK SCHEDULES AND WEEKLY COORDINATION MEETINGS

1.23 AS-BUILT DRAWINGS

1.24 SIGN

1.25 EQUIPMENT ROOM DRAWINGS

1.26 CONTRACTOR FURNISHED EQUIPMENT DATA

1.27 ACCOMMODATIONS FOR GOVERNMENT INSPECTORS

1.28 PARTNERING

1.29 PROFIT

1.30 LABOR CONDITIONS APPLICABLE TO TEMPORARY FACILITIES

SECTION 01 30 00.24 Page 1

1.31 DRAWING SCALES

1.32 WAGE RATE APPLICATION

1.33 FEDERAL HOLIDAYS

1.34 BASE HOURS

1.35 Haul Route

PART 2 NOT USED

PART 3 EXECUTION

3.1 APPENDIX A- CONTRACT DOCUMENT DISTRIBUTION LIST

3.2 F.E. WARREN AFB ID CARD APPLICATION

ATTACHMENTS:

Appendix A - Contract Document Distribution List

Project Sign Details

General Wage Decision No. WY20200023

F.E. Warren AFB ID Card Application

-- End of Section Table of Contents --

SECTION 01 30 00.24 Page 2

SECTION 01 30 00.24

OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

04/20

PART 1 GENERAL

Attachments:

Appendix A - Contract Document Distribution List

Project Sign Details General Wage Decision No. WY20200023 F.E. Warren AFB ID Card Application

1.1 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

In accordance with FAR 31.105(d)(2)(i)(b), for the predetermined schedule of construction equipment use rates, use Engineer Pamphlet (EP) 1110-1-8, Construction Equipment Ownership and Operating Expense Schedule. Copies of each regional schedule may be obtained through the following internet site:

https://www.publications.usace.army.mil/USACE-Publications/Engineer-Pamphlets/ on pages 10 and 11 of 13.

1.2 CONTRACTOR SUPPLY AND USE OF ELECTRONIC SOFTWARE FOR PROCESSING

CONSTRUCTION WAGE RATE REQUIREMENTS STATUTE CERTIFIED LABOR PAYROLLS

a. The Contractor is encouraged to use a commercially-available electronic system to process and submit certified payrolls electronically to the Government. The requirements for preparing, processing and providing certified labor payrolls are established by the Wage Rate Requirements statute.

b.The Contractor is responsible for obtaining and providing for all access, licenses, and other services required to provide for receipt, processing, certifying, electronically transmitting to the Government, and storing weekly payrolls and other data required for the Contractor to comply with the Wage Rate Requirements statute. When the Contractor uses an electronic payroll system, use the electronic payroll service used by the Contractor to prepare, process, and maintain the relevant payrolls and basic records during all work under this construction contract. The electronic payroll service must be capable of preserving these payrolls and related basic records for the required three years after contract completion. The Contractor must obtain and provide electronic system access to the Government, as required to comply with the Wage Rate Requirements over the duration of the construction contract.

(c) The Contractor's provision and use of an electronic payroll processing system must meet the following basic functional criteria:

(1) commercially available;

(2) compliant with appropriate Wage Rate Requirements statute payroll

SECTION 01 30 00.24 Page 3 provisions in the FAR;

(3) able to accommodate the required numbers of employees and subcontractors planned to be employed under the contract;

(4) capable of producing an Excel spreadsheet-compatible electronic output of weekly payroll records for export into an Excel spreadsheet to be imported into the contractor's mode of Resident Management System 3.0;

(5) demonstrated security of data and data entry rights;

(6) ability to produce Contractor-certified electronic versions of weekly payroll data;

(7) ability to identify erroneous entries and track the data/time of all versions of the certified Wage Rate Requirements statute payrolls submitted to the government over the life of the contract;

(8) capable of generating a durable record copy in a Compact Disc (CD) or Digital Versatile Disc (DVD) and Portable Document Format (PDF) file record of data from the system database at the end of the contract closeout. This durable record copy of data from the electronic payroll processing system must be provided to the Government during contract closeout.

d. All Contractor-incurred costs related to the Contractor's provision and use of an electronic payroll processing service must be included in the Contractor's price for the overall work under the contract. The costs for compliance with the Wage Rate Requirements statute by using electronic payroll processing services must not be a separately bid or reimbursed item under this contract.

1.3 VETERANS EMPLOYMENT EMPHASIS FOR U.S. ARMY CORPS OF ENGINEERS CONTRACTS

In addition to complying with the requirements outlined in FAR Part 22.13, FAR Provision 52.222-38, FAR Clause 52.222-35, FAR Clause 52.222-37, DFARS

222.13 and Department of Labor regulations, U.S. Army Corps of Engineers (USACE) contractors and subcontractors at all tiers are encouraged to promote the training and employment of U.S. veterans while performing under a USACE contract. While no set-aside, evaluation preference, or incentive applies to the solicitation or performance under the resultant contract, USACE contractors are encouraged to seek out highly qualified veterans to perform services under this contract. The following resources are available to assist USACE contractors in their outreach efforts:

- U.S. Department of Labor Veterans’ Employment and Training Service

(VETS):

https://www.dol.gov/vets/

- Federal Veteran Employment Information: https://www.fedshirevets.gov/

- Veterans Opportunity to Work (VOW) Program:

https://www.benefits.va.gov/vow/

- U.S. Army Warrior Transition Command Employment Index:

https://wct.army.mil/modules/employers/index.html

- Hiring Our Heroes: https://www.uschamberfoundation.org/hiring-our-heroes

SECTION 01 30 00.24 Page 4

1.4 COMPLETION OF WORK

See Section 00 73 00 SUPPLEMENTARY CONDITIONS (SPECIAL CONTRACT

REQUIREMENTS), FAR 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF

WORK (APR 1984).

1.5 CONTRACTOR PERFORMANCE EVALUATIONS

Federal Acquisition Regulation (FAR) Subpart 36.201(Evaluation of Contractor Performance) requires evaluation of the construction contractor's performance throughout the contract period of performance.

For construction contracts valued at or above $700,000.00, including all modifications, the USACE will evaluate Contractor's performance using the web-based Contractors Performance Assessment Reporting System (CPARS).

After the USACE drafts an evaluation (interim or final), the Contractor will have the opportunity to access, review, comment and either concur or non-concur with the evaluation in the CPARS system for a period of 60 days. Access to the CPARS system requires either specific software called PKI certification (recommended method) or a username and password. The PKI certification is a Department of Defense recommendation and to provide security in electronic transactions. The certification software could cost approximately $110 - $125 per certificate per year and may be purchased from an External Certificate Authorities (ECA) vendor. Current information about the PKI certification process and contacting vendors can be found on the web site: https://www.cpars.gov .

1.6 MANPOWER REPORTING

Contractors may direct technical questions to the "Send an Email" link at website or email contractormanpower@hqda.army.mil for current information on CMRA. Information regarding changes to the reporting process, when data should be entered, general policy information, how data is protected, and how to enter certain data can be found under the Frequently Asked Questions (FAQ) section at the CMRA website. Reporting inputs will be for the labor executed during the period of performance during each Government fiscal year (FY), which runs October 1 through September 30. While inputs may be reported any time during the FY, all data shall be reported no later than October 31 of each calendar year, beginning with 2013.

The Office of the Assistant Secretary of the Army (Manpower & Reserve Affairs) operates and maintains a secure Army data collection site where the contractor will report ALL contractor manpower (including subcontractor manpower) required for performance of this contract. The contractor is required to completely fill in all the information in the format using the following web address: https://ecmra.mil (https://cmra.army.mil). The required information includes: (1) Contracting Office, Contracting Officer, Contracting Officer's Technical Representative; (2) Contract number, including task and delivery order number; (3) Beginning and end dates covered by reporting period; (4) Contractor name, address, phone number, e-mail address, identity of contractor employee entering data; (5) Estimated direct labor hours (including sub-contractor); (6) Estimated direct labor dollars paid this reporting period (including sub-contractor); (7) Total payments (including subcontractor); (8) Predominant Federal Service Code(FSC) reflecting services provided by contractor (and separate predominant FSC for each sub-contractor if different); (9) Estimated data collection cost; (10) Organizational title associated with the Unit Identification Code (UIC)

SECTION 01 30 00.24 Page 5 for the Army Requiring Activity (the Army Requiring Activity is responsible for providing the contractor with its UIC for the purposes of reporting this information; (11) Locations where contractor and sub-contractors perform the work (specified by zip code in the United States and nearest City, Country, when in an overseas location, using standardized nomenclature provided on website); (12) Presence of deployment or contingency contract language; and, (13) Number of contractor and sub-contractor employees deployed in theater this reporting period (by country). As part of its submission, the contractor will also provide the estimated total cost (if any) incurred to comply with this reporting requirement. Reporting period will be the period of performance not to exceed 12 months ending September 30 of each government fiscal year and must be reported by 31 October of each calendar year. "*

*Note: Information from the secure web site is considered to be proprietary in nature when the contract number and contractor identity are associated with the direct labor hours and direct labor dollars. At no time will any data be released to the public with the contractor name and contract number associated with the data. For internal Army analysis, the reports and queries from the database shall not contain proprietary data.

1.7 LIQUIDATED DAMAGES-CONSTRUCTION

See Section 00 73 00 SUPPLEMENTARY CONDITIONS (SPECIAL CONTRACT

REQUIREMENTS), FAR 52.211-12 LIQUIDATED DAMAGES-CONSTRUCTION (SEPT 2000).

1.8 ANTITERRORISM (AT)/OPERATIONS SECURITY (OPSEC) PROVISIONS

1. AT Level I Training

All Contractor employees, to include subcontractor employees, requiring access to Army installations, facilities and controlled access areas shall complete AT Level I awareness training within 30 calendar days after contract start date or effective date of incorporation of this requirement into the contract, whichever is applicable. Upon request, the Contractor shall submit certificates of completion for each affected Contractor employee and subcontractor employee, to the COR or to the contracting officer (if a COR is not assigned), within 5 calendar days after completion of training by all employees and subcontractor personnel. AT Level I awareness training is available at the following website:

http://jko.jten.mil/courses/atl1/launch.html; or it can be provided by the RA ATO in presentation form which will be documented via memorandum.

2. Access and General Protection/Security Policy and Procedures

All contractor and all associated sub-contractors employees shall comply with applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative). The contractor shall also provide all information required for background checks to meet installation/facility access requirements to be accomplished by installation Provost Marshal Office, Director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements (FAR clause 52.204-9, Personal Identity Verification of Contractor Personnel) as directed by DOD, HQDA and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any installation or facility change, the Government may require

SECTION 01 30 00.24 Page 6 changes in contractor security matters or processes.

2b. for Contractors Who Do Not Require CAC, But Require Access To A Dod Facility Or Installation

Contractor and all associated sub-contractors employees shall comply with adjudication standards and procedures using the National Crime Information Center Interstate Identification Index (NCIC-III) and Terrorist Screening Database (TSDB) (Army Directive 2014-05 / AR 190-13), applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative, as NCIC and TSDB are available), or, at OCONUS locations, in accordance with status of forces agreements and other theater regulations.

3. Not Used

4. Suspicious Activity Reporting Training (e.g. iWATCH, CorpsWatch, or See Something, Say Something)

The contractor and all associated sub-contractors shall receive a brief/training (provided by the RA) on the local suspicious activity reporting program. This locally developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the project manager, security representative or law enforcement entity. This training shall be completed within 30 calendar days of contract award and within 30 calendar days of new employees commencing performance with the results reported to the COR NLT 5 calendar days after the completion of the training.

5. Contractor Employees Who Require Access to Government Information Systems.

Not Applicable

6. OPSEC Standing Operating Procedure/Plan

Not Applicable

7. OPSEC Training

All new contractor employees will complete Level I OPSEC Training within 30 calendar days of their reporting for duty. Additionally, all contractor employees must complete annual OPSEC awareness training. The contractor shall submit certificates of completion for each affected contractor and subcontractor employee, to the COR or to the contracting officer (if a COR is not assigned), within 5 calendar days after completion of training.

OPSEC awareness training is available at the following websites:

https://www.iad.gov/ioss/ or http://www.cdse.edu/catalog/operations-security.html; or it can be provided by the RA OPSEC Officer in presentation form which will be documented via memorandum.

8. Information Assurance (IA)/Information Technology (IT) Training

Not Applicable

9. Information Assurance (IA)/Information Technology (IT) Certification

SECTION 01 30 00.24 Page 7

Not Applicable

10. Not Used

11. Not Used

12. Handling or Access to Classified Information.

Not Applicable

13. Will be Escorted in Areas Where They May be Exposed to Classified and/or Sensitive Materials and/or Sensitive or Restricted Areas

If applicable, all contract employees, including subcontractor employees who are not in possession of the appropriate security clearance or access privileges, will be escorted in areas where they may be exposed to classified and/or sensitive materials and/or sensitive or restricted areas.

14. Contractor Company to Obtain a Facility Clearance and Individual Clearances at the Appropriate Level

The Prime Contractor Company must have (or will have) a Facility Clearance (FCL) at the appropriate level (IAW the NISPOM DOD 5220.22-M and AR 380-49) prior to the start of the contract awarded period of performance.

Contractor personnel performing work under this contract must have the required security clearance, per AR 380-67, at the appropriate level at the start of the period of performance. Security Clearances and FCL requirements are required to be maintained for the life of the contract IAW the DD254 attached to the contract. If no FCL, the supporting Government Contracting Activity will sponsor the prime contract company in obtaining the FCL.

15. Pre-Screen Candidates using E-Verify Program

The Contractor must pre-screen Candidates using the E-verify Program (http://www.uscis.gov/e-verify) website to meet the established employment eligibility requirements. The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to enrollment to ensure the correct information is entered into the E-verify system. An initial list of verified/eligible Candidates must be provided to the COR no later than 3 business days after the initial contract award.

16. Required Armed Security Guards

Not Applicable

17. Threat Awareness Reporting Program (TARP) Training

All new contractor employees will complete annual Threat Awareness and Reporting Program (TARP) Training provided by a Counterintelligence Agent, IAW AR 381-12 . The contractor shall submit certificates of completion for each affected contractor and subcontractor employee(s) or a memorandum for the record, to the COR or to the contracting officer (if a COR is not assigned), within 5 calendar days after completion of training. Authorized webbased TARP training for CAC card holders is available at the following website: https://www.us.army.mil/suite/page/655474

1.9 MISSION DELAY DAYS

The Contractor shall anticipate a work delay of up to 10 days during the

SECTION 01 30 00.24 Page 8 contract period due to Using Service operations. The Contractor will be notified one week in advance of these interruptions. This time is included in the overall completion time stated. In addition to the 10 days noted above, there will be approximately one hundred convoy movements in and around the WSA each year. For each convoy movement, there will be two 30-minute periods (in and out) during which tower crane use and use of Cheyenne Road (site access) will be prohibited. During this time, work may continue in the contractor staging area and on the construction site, but vehicles will not be allowed to enter or leave the site. This time is included in the overall completion time stated.

1.10 CONTRACT DRAWINGS AND SPECIFICATIONS

1.10.1 SETS FURNISHED

Utilize the bid drawings and specifications as amended in the performance of the work until the electronic Adobe Acrobat.pdf conformed specifications and contract drawings (i.e., bid drawings that have been posted with all amendment changes) are sent electronically to the Contractor. See paragraph below for contract drawing distribution requirements. The work must conform to the contract drawings, set out in the drawing index, all of which form a part of these specifications. The work must also conform to any of the standard details bound or referenced herein.

1.10.2 REPRODUCTION AND DISTRIBUTION

The Government will process no progress payments prior to distribution of electronic contract drawings and conformed specification sets by the Government. The Government will provide the Contractor with a CD-ROM or DVD-ROM or sent electronically containing Adobe Acrobat .pdf contract drawings and conformed specification sets and editable CAD file drawings (format defined in Section 01 33 39.00 10 ADVANCED MODELING (BIM/CIM/GIS/CAD) REQUIREMENTS. Prepare final record or as-built drawings as defined in Section 01 33 39.00 10 ADVANCED MODELING

(BIM/CIM/GIS/CAD) REQUIREMENTS.

1.10.3 NOTIFICATION OF DISCREPANCIES

Check all electronically sent drawing files furnished by the government immediately upon their receipt and promptly notify the Contracting Officer of any discrepancies. Follow dimensions marked on drawings in lieu of scale measurements. Enlarged plans and details govern where the same work is shown at smaller scales. All scales shown are based on a standard drawing size of 22" x 34". If any other size drawings are furnished or plotted adjust the scales accordingly. The Contractor must also advise his sub-contractors of the above. The Contractor must compare all drawings and verify the figures before laying out the work and will be responsible for any errors which might have been avoided thereby.

1.10.4 OMISSIONS

Omissions from the drawings or specifications or the misdescription of details of work which are manifestly necessary to carry out the intent of the drawings and specifications, or which are customarily performed, does not relieve the Contractor from performing such omitted or misdescribed details of the work but work must be performed as if fully and correctly

SECTION 01 30 00.24 Page 9 set forth and described in the drawings and specifications.

1.11 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit items below in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-02 Shop Drawings

Equipment Room Drawings; G-RO.

1.12 CONCURRENT CONSTRUCTION

Construction work closely related to and/or located at the site of the work under a concurrent contract may be in progress simultaneously with work under this contract. Cooperate with others as necessary in the interest of timely completion of all work. In the event of interference, notify the Contracting Officer (CO) immediately for resolution and the CO decision is final.

1.13 PAYMENT

1.13.1 PROMPT PAYMENT ACT

Pay requests authorized in GENERAL CONDITIONS (CONTRACT CLAUSES) clause:

"Payments Under Fixed-Price Construction Contracts", will be paid pursuant to the clause, "Prompt Payment for Construction Contracts". Submit pay requests on ENG Form 93 and 93a, "Payment Estimate-Contract Performance" and "Continuation". All information and substantiation required by the identified contract clauses must be submitted with the ENG Form 93, and the required certification included on the last page of the ENG Form 93a, signed by an authorized contractor official and dated when signed. The designated billing office is the Office of the Area Engineer.

1.13.2 PAYMENT FOR MATERIALS DELIVERED OFFSITE

a. Pursuant to Federal Acquisition Regulation (FAR) 52.232-5, Payments Under Fixed Price Construction Contracts, materials delivered to the contractor at locations other than the site of the work may be taken into consideration in making payments, if included in payment estimates and if all the conditions of the General Provisions are fulfilled. Payment for items delivered to locations other than the work site are limited to:

(1) Materials required by the technical provisions; or

(2) Materials that have been fabricated to the point where they are identifiable to an item of work required under this contract; or

(3) Items specifically listed below in paragraph b.

b. Payment for materials delivered off-site must be made only after receipt of paid invoices listing the value of material and labor incorporated in the items along with a canceled check showing the prime contractor's title to the items delivered off site. Payment for materials delivered off-site must be limited to the following items: [List specific material items to be considered for payment when off-site delivery is

SECTION 01 30 00.24 Page 10 made].

1.13.3 CONTRACTOR PAYROLL RECORD

Contractor is required to log payrolls for all their own employees and subcontractors utilizing ENG Form 3180. Each subcontractor requires a separate ENG 3180 for their payrolls. The Contractor must maintain the ENG 3180, along with the payrolls, on site and available for review by the Contracting Officer's Representative. Update the ENG 3180's weekly as payrolls are submitted. After making copies for their files, the Contractor is required to submit the originals of each week’s payrolls to the Resident Office. Before final payment, provide the completed ENG 3180’s to the Contracting Officer's Representatives. If the Contractor has elected to use an electronic payroll system, as described in paragraph

CONTRACTOR SUPPLY AND USE OF ELECTRONIC SOFTWARE FOR PROCESSING

CONSTRUCTION WAGE RATE REQUIREMENTS STATUTE CERTIFIED LABOR PAYROLLS, the payroll inventory produced by the electronic payroll system will satisfy the requirements in this paragraph and FAR 52.222-8, Payrolls and Basic Records.

1.14 AVAILABILITY OF UTILITY SERVICES

All reasonably required amounts of domestic water and electricity will be made available to the Contractor by the Government from existing system outlets and supplies. The Contractor is responsible to , at their own expense, make all temporary connections and install distribution lines.

Furnish to the Contracting Officer a complete system layout drawing showing type of materials to be used and method of installation for all temporary electrical systems. All temporary lines must be maintainedin a workmanlike manner satisfactory to the Contracting Officer and removed by the Contractor in like manner prior to final acceptance of the construction. Normal quantities of electricity and water used to make final tests of completely installed systems will be furnished by the Government.

1.15 UTILITY SERVICE INTERRUPTIONS

Submit written notification not less than 15 calendar days in advance of each interruption of each utility and communication service to or within existing buildings and facilities being used by others. No single outage will exceed 4 hours unless approved in writing. The time and duration of all outages will be coordinated and approved with the Using Agency by the Contracting Officer.

1.16 DIGGING PERMITS AND ROAD CLOSINGS

The Contractor must allow 14 calendar days from date of written application to receive permission to dig and to close roads. Only close roads one lane at a time and allow vehicular traffic to pass through the construction area. Flag work on or near roadways in accordance with the safety requirements in Safety and Health Requirements Manual EM 385-1-1, which forms a part of these specifications. Do not cause blockage of work located along the alert force route and maintain unobstructed access for alert force traffic at all times.

1.17 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

a. This provision specifies the procedure for the determination of

SECTION 01 30 00.24 Page 11 time extensions for unusually severe weather in accordance with the GENERAL CONDITIONS (CONTRACT CLAUSES) clause entitled "Default:

(Fixed-Price Construction)." In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor.

b. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

Jan 6 Feb 7 Mar 6 Apr 4 May 4 Jun 4 Jul 4 Aug 3 Sep 2 Oct 3 Nov 5 Dec 9

c. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the contractor will record on the RMS daily CQC report, any occurrence of adverse weather and resultant impact to normally scheduled work, within 24 hours of the event. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the contractor's scheduled work day. Describe in the RMS daily CQC reports the critical path item that is being affected and provide the critical path activity number(s) from the current schedule. The COR must acknowledge and accept the agreed upon occurrence of each adverse weather delay in RMS for the delays to be considered as adverse weather delays.

At the end of each month, identify the number of actual adverse weather delay days that includes days impacted by actual adverse weather (even if adverse weather occurred in previous month), calculated chronologically from the first to the last day of each month, and recorded as full days.

If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph b. above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the GENERAL CONDITIONS (CONTRACT CLAUSES) clause entitled "Default (Fixed Price Construction)". (ER 415-1-15)

1.18 INSURANCE REQUIRED

In accordance with GENERAL CONDITIONS (CONTRACT CLAUSES) clause:

"Insurance Work on a Government Installation," procure the following minimum insurance:

Type Amount

Workmen's Compensation and Employer's Liability Insurance $100,000

SECTION 01 30 00.24 Page 12

General Liability Insurance $500,000 per occurrence

Automobile Liability Insurance Bodily injury $200,000 per person and $500,000 per occurrence Property damage $ 20,000 per occurrence

(Coverages per FAR 28.307-2)

1.19 SECURITY REQUIREMENTS

1.19.1 Contractor's Employee Identification

The Contractor is responsible for furnishing to each employee and for requiring each employee engaged on the work to display such identification as may be approved and directed by the Contracting Officer. Deliver all prescribed identification immediately be delivered to the Contracting Officer, for cancellation upon release of any employees. When the contract involves work in restricted security areas, only employees who are U.S. citizens will be permitted to enter. Proof of U.S. citizenship is required prior to entry. When required by the Contracting Officer, obtain and submit fingerprints of all persons employed or to be employed on the project. (Based on FAR 52.204-2)

1.19.2 Entry Requirements

Base access is currently more limited than usual due to COVID-19.

Contractors will need to coordinate access with Resident Office personnel.

1.19.3 F.E. Warren AFB Entry Requirements

Submit the information shown on the attached ID Card Application on Contractor letterhead for each prime or subcontractor employee requesting access to F.E. Warren AFB, Wyoming. The information must be delivered to the F.E. Warren project office.

1.19.4 F.E. Warren AFB DBIDS Sponsor Privileges

A maximum of two prime contractor employees may be granted DBIDS sponsor privileges after submitting the appropriate information to Security Forces via the COR. This will allow those individuals to sponsor contractor personnel on the premises of F.E. Warren AFB without accompanying government personnel.

1.20 CONTRACTOR QUALITY CONTROL (CQC)

See Section 01 45 00.00 10 QUALITY CONTROL.

1.21 NONDOMESTIC CONSTRUCTION MATERIALS

The list of excepted nondomestic construction materials or their components referenced in the Buy American Construction Material Contract Clauses includes the list set forth in paragraph 25.104 of the Federal Acquisition Regulation.

1.22 DAILY WORK SCHEDULES AND WEEKLY COORDINATION MEETINGS

In order to closely coordinate work under this contract, prepare a

SECTION 01 30 00.24 Page 13 written agenda/meeting minutes and attend a weekly coordination meeting with the Contracting Officer and Using Service at which time the Contractor must submit for coordination and approval, their proposed daily work schedule for the next two week period. The Provide a copy of modifications (MODs), Serial Letters, Requests for Information (RFIs)and any other information that is needed in the minutes of the meeting.

Include required temporary utility services, time and duration of interruptions, and protection of adjoining areas with the Contractor's proposed 2-week work schedule. At this meeting, the Contractor must also submit their schedule of proposed dates and times of all preparatory inspections to be performed during the next 2 weeks. The items of work listed on the proposed 2-week schedule are to be keyed to the NAS by activity number and description for each activity anticipated to be performed during the next 2-week period. Coordination action by the Contracting Officer relative to these schedules will be accomplished during these weekly meetings. Daily reports must be completed and given to the Contracting Officer or Representative within 24 hours of work. All official correspondence such as serial letters and RFIs, with attachments are to be provided in one hardcopy original with original signatures and one electronic (Adobe pdf format) copy by email. The Government will consider the correspondence to be received when the official hardcopy or electronic copy is received by the designated office.

1.23 AS-BUILT DRAWINGS

See 01 33 39.00 10 ADVANCED MODELING (BIM/CIM/CAD) REQUIREMENTS.

1.24 SIGN

On commencement of work on this project, furnish and erect the temporary sign in the location selected by the Contracting Officer near the project site. Maintain the sign in good condition through the project construction period. Upon completion of the project remove the sign from the premises. The project sign must conform to standard drawing bound herein. A decal of the "Engineer Castle" and the U. S. Air Force emblem will be furnished the Contractor upon request.

1.25 EQUIPMENT ROOM DRAWINGS

Prior to construction, prepare and submit room plans for all mechanical, electrical, and communication rooms or similar areas. The plans must be consolidated for all trades, be to scale, and show all pertinent structural features.