22r19-CDC AMR-Am-0001.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE

J

PAGE OF PAGES

1 2

2. AMENDMENT/MODIFICATION NO.

Am-0001

3. EFFECTIVE DATE

11-Jul-2022

4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY CODE W9128A 7. ADMINISTERED BY (If other than item 6) CODE

CONTRACTING DIVISION

BLDG 230 OTAKE ST.

FORT SHAFTER HI 96858

See Item 6

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X

9A. AMENDMENT OF SOLICITATION NO.

W9128A22R0019

X 9B. DATED (SEE ITEM 11)

22-Jun-2022

10A. MOD. OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE

RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

FY22 MCA PN 96540 Child Development Center, Aliamanu Military Reservation, Oahu, Hawaii

See Continuation Page.

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

TEL: EMAIL:

15B. CONT RACT OR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

BY

(Signature of Contracting Officer)

16C. DATE SIGNED

EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

30-105-04 STANDARD FORM 30 (Rev. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

W9128A22R0019 Am-0001

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

1. CHANGES TO SPECIFICATIONS. Attached hereto are revised pages/paragraphs to the specifications. The revision mark “(Am-0001)” is shown on each revised page.

a. REVISED SECTIONS. The following are revised pages to the solicitation. Changes are bold.

Standard Form 1442 – Page 1, Block 13A

Section 09 90 00, para 1.5.3

Section 23 30 00, para 2.6 and 2.9.1.f

Section 26 13 01, para 2.1.2

b. NEW SECTIONS. The following are new pages to the solicitation.

Section 00 22 16, Appendix A, Sample Subcontracting Plan

Section 00 60 00, Appendix A – Requests for Information (#1 through 21)

Section 00 60 00, Appendix B – Site Visit Attendees

c. REPLACED SECTION. The following section is replaced in its entirety:

Section 00 72 00, Appendix A, Davis Bacon Wage Determination dated 04/15/2022 with

07/08/2022

2. CHANGES TO DRAWINGS

a. REVISED DRAWINGS. The following revised drawings replace like-numbered drawings and are issued herewith:

Sheet ID Mark Revision Date

M-653 1 7/8/2022

3. Requests for Information are due by July 13, 2022, 2:00 PM, Hawaii Standard Time

4. The proposal due date and time has changed, see Am-0001, SF1442, Page 1, Block 13A.

FY22 Military Construction Army (MCA) PN96540 Child Development Center, Aliamanu Military Reservation, Oahu, Hawaii

DAYNA N MATSUMURA (808) 835-4379

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

22-Jun-2022

(RFP)

(IFB)

X

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______7 calendar days and complete it w ithin ________1047 calendar days after receiving aw ard, X notice to proceed. This performance period is mandatory, negotiable. (See _________________________52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by __ __ local time __28 Jul 2022___ (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______90 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

CONTRACTING DIVISION

BLDG 230 OTAKE ST.

FORT SHAFTER HI 96858

W9128A

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

(hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: TEL: FAX:

W9128A22R0019 105

1:00 PM

(Am-0001)

FY21 PN96540 CHILD DEVELOPMENT CENTER, AMR

Employer (if other than the Contractor)

Name of facility owner

Mailing address and telephone number of facility owner

Name of individual in facility owner's organization who can be contacted as a reference

Location, size and description of structure

Dates work was carried out

Description of work carried out on structure

1.5.3 SSPC QP 1 Certification

Contractors that perform surface preparation or coating application on steel substrates must be certified by the Society for Protective Coatings (formerly Steel Structures Painting Council) (SSPC) to the requirements of SSPC QP 1 prior to Contract award, and must remain certified while accomplishing any surface preparation or coating application. If a Contractor's certification expires, the firm will not be allowed to perform any work until the certification is reissued. Requests for extension of time for any delay to the completion of the project due to an inactive certification will not be considered. Notify the Contracting Officer of any change in Contractor certification status. Notify the Contracting Officer of all scheduled and unannounced on-site audits from SSPC and furnish a copy of all audit reports.

1.5.4 Approved Products List

The current MPI, "Approved Product List" which lists paint by brand, label, product name and product code as of the date of Contract award, will be used to determine compliance with the submittal requirements of this specification. The Contractor may choose to use a subsequent MPI "Approved Product List", however, only one list may be used for the entire Contract and each coating system is to be from a single manufacturer.

Provide all coats on a particular substrate from a single manufacturer.

No variation from the MPI Approved Products List is acceptable.

1.5.5 Paints and Coatings Indoor Air Quality Certifications

Provide paint and coating products certified to meet indoor air quality requirements by MPI GPS-1-14 , MPI GPS-2-14 or provide certification by other third-party programs. Provide current product certification documentation from certification body.

Provide certification of Indoor Air Quality for Paints and Primers.

Provide certification of Indoor Air Quality for Consolidated Latex Paints.

Submit required indoor air quality certifications in one submittal package.

1.5.6 Field Samples and Tests

The Contracting Officer may choose up to two coatings that have been delivered to the site to be tested at no cost to the Government. Take samples of each chosen product as specified in the paragraph SAMPLING PROCEDURE. Test each chosen product as specified in the paragraph TESTING PROCEDURE. Remove products from the job site which do not conform, and

SECTION 09 90 00 Page 12 (Am-0001) j3ec9jl8 Strikethrough

FY22 AMR Child Development Center PN96540

b. For single-phase motors, provide high-efficiency type, fractional-horsepower alternating-current motors, including motors that are part of a system, in accordance with NEMA MG 11. Provide premium efficiency type integral size motors in accordance with

NEMA MG 1.

c. For polyphase motors, provide squirrel-cage medium induction motors, including motors that are part of a system , and that meet the efficiency ratings for premium efficiency motors in accordance with NEMA MG 1. Select premium efficiency polyphase motors in accordance with NEMA MG 10.

d. Provide motors in accordance with NEMA MG 1 and of sufficient size to drive the load at the specified capacity without exceeding the nameplate rating of the motor. Provide motors rated for continuous duty with the enclosure specified. Provide motor duty that allows for maximum frequency start-stop operation and minimum encountered interval between start and stop. Provide motor torque capable of accelerating the connected load within 20 seconds with 80 percent of the rated voltage maintained at motor terminals during one starting period. Provide motor starters complete with thermal overload protection and other necessary appurtenances. Fit motor bearings with grease supply fittings and grease relief to outside of the enclosure.

e. Where two-speed or variable-speed motors are indicated, solid-state variable-speed controllers are allowed to accomplish the same function. Use solid-state variable-speed controllers for motors rated 10 hp or less and adjustable frequency drives for larger motors.

2.5 ANCHOR BOLTS

Provide anchor bolts for equipment placed on concrete equipment pads or on concrete slabs. Bolts to be of the size and number recommended by the equipment manufacturer and located by means of suitable templates.

Installation of anchor bolts must not degrade the surrounding concrete.

2.6 SEISMIC ANCHORAGE

Anchor equipment in accordance with Section 23 05 48.19- SEISMIC BRACING FOR HVAC. Install seismic anchorage in accordance with applicable seismic

2.7 PAINTING

Paint equipment units in accordance with approved equipment manufacturer's standards unless specified otherwise. Field retouch only if approved.

Otherwise, return equipment to the factory for refinishing.

2.8 INDOOR AIR QUALITY

Provide equipment and components that comply with the requirements of ASHRAE 62.1 unless more stringent requirements are specified herein.

2.9 DUCT SYSTEMS

2.9.1 Metal Ductwork

Provide metal ductwork construction, including all fittings and components, that complies with SMACNA 1966, as supplemented and modified

SECTION 23 30 00 Page 15 (Am-0001) criteria for the area and as defined in SMACNA 1981.

MKomo Cross-Out

MKomo Cross-Out

FY22 AMR Child Development Center PN96540 by this specification.

a. Provide radius type elbows with a centerline radius of 1.5 times the width or diameter of the duct where space permits. Otherwise, elbows having a minimum radius equal to the width or diameter of the duct or square elbows with factory fabricated turning vanes are allowed.

b. Provide ductwork that meets the requirements of Seal Class C. Provide ductwork in VAV systems upstream of the VAV boxes that meets the requirements of Seal Class A.

c. Provide sealants that conform to fire hazard classification specified in Section 23 07 00 THERMAL INSULATION FOR MECHANICAL SYSTEMS and are suitable for the range of air distribution and ambient temperatures to which it is exposed. Do not use pressure sensitive tape as a sealant. Provide duct sealant products that meet either emissions requirements of CDPH SECTION 01350 (limit requirements for either office or classroom spaces regardless of space type) or VOC content requirements of SCAQMD Rule 1168 (HVAC duct sealants are classified as "Other" within the SCAQMD Rule 1168 sealants table). Provide validation of indoor air quality for duct sealants.

d. Make spiral lock seam duct, and flat oval with duct sealant and lock with not less than 3 equally spaced drive screws or other approved methods indicated in SMACNA 1966. Apply the sealant to the exposed male part of the fitting collar so that the sealer is on the inside of the joint and fully protected by the metal of the duct fitting. Apply one brush coat of the sealant over the outside of the joint to at least 2 inch band width covering all screw heads and joint gap. Dents in the male portion of the slip fitting collar are not acceptable.

e. Fabricate outdoor air intake ducts and plenums with watertight soldered or brazed joints and seams.

f. It is acceptable to provide equivalent round ductwork in lieu of rectangular ductwork if space permits. Provide duct transitions between rectangular and round ductwork connections in accordance with SMACNA standards.

2.9.1.1 Metallic Flexible Duct

a. Provide duct that conforms to UL 181 and NFPA 90A with factory-applied insulation, vapor barrier, and end connections. Provide duct assembly that does not exceed 25 for flame spread and 50 for smoke developed.

Provide ducts designed for working pressures of 2 inches water gauge positive and 1.5 inches water gauge negative. Provide flexible round duct length that does not exceed 5 feet. Secure connections by applying adhesive for 2 inches over rigid duct, apply flexible duct 2 inches over rigid duct, apply metal clamp, and provide minimum of three No. 8 sheet metal screws through clamp and rigid duct.

b. Inner duct core: Provide interlocking spiral or helically corrugated flexible core constructed of zinc-coated steel, aluminum, or stainless steel; or constructed of inner liner of continuous galvanized spring steel wire helix fused to continuous, fire-retardant, flexible vapor barrier film, inner duct core.

c. Insulation: Provide inner duct core that is insulated with mineral fiber blanket type flexible insulation, minimum of 1 inch thick.

(Am-0001)

Provide insulation covered on exterior with manufacturer's standard

SECTION 23 30 00 Page 16 fire retardant vapor barrier jacket for flexible round duct.

FY21 PN96540 CHILD DEVELOPMENT CENTER, AMR

Short-Circuit Current, kA rms Sym 14

Power Fuses, Amperes, Maximum Interrupting, kA rms Sym

200E or 200K

Provide switched ways rated for the required continuous and load interrupting current.

2.1.2 Switchgear Construction

Provide switchgear with the following construction and configuration:

a. Switch contacts and cable entrance terminations contained in an enclosed, 304 or 304L stainless steel compartment.

b. Configured with load interrupting and fused switched ways as indicated.

c. Accessible terminations suitable for cables entering from below.

d. Switch contact positions for switched ways visible through viewing windows in the switchgear termination compartment.

e. Each switched way with two position switch; Open, Closed and provisions for grounding.

2.1.2.1 Pad-mounting Provisions

Provide enclosed switchgear suitable for installation on a concrete pad, including the following:

a. Fabricate switchgear enclosure and enclosure base of ASTM A240/A240M type 304 or 304L stainless steel.

b. Enclosure base includes any part of the switchgear enclosure that is within 3 inches of concrete pad.

c. Paint enclosure including base ASTM D1535 Munsell 7GY3.29/1.5 green.

d. Comply with IEEE C57.12.29 for the paint coating system regardless of equipment material.

2.1.2.2 Pad/Vault-mounting Provisions

Provide enclosed switchgear suitable for installation on a concrete pad:

a. Fabricate switchgear enclosure and enclosure base of ASTM A240/A240M type 304 or 304L stainless steel.

b. Enclosure base includes any part of the switchgear enclosure that is within 3 inches of concrete pad.

c. Paint enclosure including base ASTM D1535 Munsell 7GY3.29/1.5 green.

d. Comply with IEEE C57.12.29 for the paint coating system regardless of equipment material.

SECTION 26 13 01 Page 6 (Am-0001) j3ec9mql Underline

Section 00 22 16, Appendix A

SAMPLE

SMALL BUSINESS SUBCONTRACTING PLAN

CONTRACTOR: ___________________________________

ADDRESS: ____________________________________

PHONE: (______) ____________________________

DUNS NO.: ____________________________________

SOLICITATION OR CONTRACT NUMBER: _______________________________

DESCRIPTION: ________________________________________________________

* Federal Acquisition Regulation (FAR), paragraph 19.708(b)(1)) prescribes the use of the clause at FAR

52.219-9 entitled "Small Business Subcontracting Plan." The following is a suggested model for use when formulating such subcontracting plan. While this model plan has been designed to be consistent with FAR

52.219-9, other formats of a subcontracting plan may be acceptable. However, failure to include the essential information as exemplified in this model may be cause for either a delay in acceptance or the rejection of a bid or offer where the clause is applicable. Further, the use of this model is not intended to waive other requirements that may be applicable under FAR 52.219-9 or that may appear in the

Government’s solicitation. "SUBCONTRACT," as used in this clause, means any agreement (other than one involving an employer-employee relationship) entered into by a federal government prime contractor or subcontractor calling for supplies or services required for performance of the contract or subcontract.

1. The information herein provided, together with any attachments and subsequent amendments, is submitted as a subcontracting plan to satisfy the applicable requirements of P.L. 99-661, Section 1207, P.L. 100-180, Section 806, and FAR 52.219-9, Alternate II (Nov 2016). Attached is a copy the company’s policy statement or internal guidance to company buyers recognizing understanding and commitment to the aforementioned public laws.

2. The following is a list of separate percentage goals for using small business (including Alaska Native

Corporations (ANCs) and Indian tribes), veteran-owned small business (VOSB), service-disabled veteran-owned small business (SDVOB), HUBZone small business (HUBZone), small disadvantaged business

(SDB)(including ANCs and Indian tribes), and women-owned small business (WOSB) concerns, and for

Defense Research Programs, historically black colleges and universities and minority serving institutions where applicable as subcontractors.

3. The following is a statement of the total dollars planned to be subcontracted and a statement of the total dollars planned to subcontracted to small business (including ANCs and Indian tribes), veteran-owned small business, service-disabled veteran-owned small business, HUBZone small business, small disadvantaged business (including ANCs and Indian tribes), and women-owned small business concerns, (Am-0001) as a percentage of total subcontract dollars. For individual subcontracting plans only, a contracting officer may require the goals referenced in item #2 of this section to be calculated as a percentage of total contract dollars, in addition to the goals established as a percentage of total subcontract dollars. (The following table is an example.)

Total Planned Subcontracting dollars under this contract estimated to go to SB Categories listed below:

Amount Percent

a. All types of business concerns under this contract (Large and small)

$100,000.00 50%

b. Total dollars planned to be subcontracted out $71,000.00 71%

c. Small Business Concerns [including American Native

Corporations (ANC) and Indian tribes]. (% of “a”)

$18,000.00 33.9%

d. Veteran-Owned Small Business Concerns (% of “a”) $4,000.00 5.9%

e. Service-Disabled Veteran-Owned Small Business Concerns.

(% of “a”)

$4,000.00 5.9%

f. HUBZone Business Concerns. (% of “a”) $10,000.00 16.3%

g. Small Disadvantaged Business Concerns (including ANCs and

Indian tribes). (% of “a”)

$17,000.00 31.4%

h. Women-owned Small Business Concerns. (% of “a”) $18,000.00 33.9%

Option Years: (State the goals for the option years. If the same percentages will be used, state, “Same percentages as noted above will be used for each option year.” If there are no option years, leave this portion out of your plan.)

4. The following is a statement of the principal types of supplies and services to be subcontracted and the types planned for subcontracting to small business (including ANCs and Indian tribes), veteran-owned small business, service-disabled veteran-owned small business, HUBZone small business, small disadvantaged business (including ANCs and Indian tribes), and women-owned small business concerns, as a percentage of total subcontract dollars. (The following table is an example.)

Provide listing of subcontractors, contact information such as phone number or email address, their business size, type of work, and amount to be subcontracted. For example:

Contractor Contract info Size Type of Work Amount Percent

S&S Sampling (999)555-5555 SB Soil Drilling $5,000 5%

ABC Testing abc@dot.com SDB Material testing $15,000 15%

XYZ Consultants (999)444-4444 WOSB Civil Engineering $7,500 7.5%

John Doe Surveying (000)333-3333 HUBZone Survey $15,000 15%

ACME Plumbing acme@dot.com SDB and

VOSB

Plumbing $8,250 8.2%

Ace Equipment ace@dot.com SDVOSB and VOSB

Equipment Rental $5,000 5%

AAA Electrical

Supplier aaa@dot.net VOSB Electrical Supplies $12,000 12%

5. The method used to develop the subcontracting goals. (FAR 19.704(a)(4)). Provide information on how the subcontracting goals were developed. i.e., vendor listing, General Contractors’ Association, past experience with subcontractors, etc.

(Am-0001)

6. The method used to identify potential sources for solicitation purposes involve (FAR 19.704(a)(5)):

List sources of potential subcontractors. For example: SBA’s PRO-Net database, Corps of Engineers’ vendor listing, General Contractors’ Association, past experience and/or familiarity with specific subcontractors, etc.

7. Within the goals specified in paragraph 2 above, indirect costs are or are not included.

(A statement as to whether or not indirect costs are included in establishing subcontracting goals, and if indirect costs are included, a description of the method used to determine the proportionate share of indirect costs to be incurred with (i) small business (including ANCs and Indian tribes), (ii) Veteran-owned; (iii) Service-disabled veteran owned; (iv) HUBZone; (v) Small disadvantaged (including ANCs and Indian tribes); (vi) women-owned business concerns).

NOTE: COMMERCIAL PLANS MUST INCLUDE INDIRECT COSTS.

8. The following individual will administer the subcontracting program:

Name: __________________________________

Title: __________________________________

Address: __________________________________

Telephone: (_______)_________________________

FAX: (_______)_________________________

The duties of the above named person(s) involve:

a. Assist small business, veteran-owned small business, service-disabled veteran-owned small business, HUBZone small business, small disadvantaged business, and women-owned small business concerns by arranging solicitations, time for the preparation of bids, quantities, specifications, and delivery schedules so as to facilitate the participation by such concerns.

b. Provide adequate and timely consideration of the potentialities of small business, veteran-owned small business, service-disabled veteran-owned small business, HUBZone small business, small disadvantaged business, and women-owned small business concerns in all “make-or-buy” decisions.

c. Counsel and discuss subcontracting opportunities with representatives of small business, veteran-owned small business, service-disabled veteran-owned small business, HUBZone small business, small disadvantaged business, and women-owned small business firms.

d. Confirm that a subcontractor representing itself as a HUBZone small business concern is certified by SBA as a HUBZone small business concern in accordance with 52.219-8(d)(2).

e. Provide notice to subcontractors concerning penalties and remedies for misrepresentations of business status as small, veteran-owned small business, HUBZone small, small disadvantaged or women-owned small business for the purpose of obtaining a subcontract that is to be included as part or all of a goal contained in the Contractor’s subcontracting plan.

f. For all competitive subcontracts over the simplified acquisition threshold in which a small business concern received a small business preference, upon determination of the successful subcontract Offeror, prior to award of the subcontract the Contractor must inform each

(Am-0001) unsuccessful small business subcontract Offeror in writing of the name and location of the apparent successful Offeror and if the successful subcontract Offeror is a small business, veteran-owned small business, service-disabled veteran-owned small business, HUBZone small business, small disadvantaged business, or women-owned small business concern.

g. Assign each subcontract the NAICS code and corresponding size standard that best describes the principal purpose of the subcontract.

h. Develop and maintain subcontractor and supplier lists of small (including ANCs and Indian tribes), veteran-owned small, service-disabled veteran-owned small, HUBZone small, small disadvantaged (including ANCs and Indian tribes), and women-owned small business concerns.

i. Monitor the progress toward proposed subcontracting goals, and if necessary, makes adjustments to achieve the subcontracting goals.

j. Prepare and submit periodic subcontracting reports to include the Individual Subcontract

Report (ISR) and the Summary Subcontract Report (SSR) using the Electronic Subcontracting

Reporting System (eSRS) at www.esrs.gov following the instructions in the eSRS and FAR clause 52.219-9.

k. Notify the Contracting Officer of any deviation from this subcontracting plan.

l. Attend or arrange for the attendance of company counselors at Business Opportunity

Workshops, Minority Business Enterprise Seminars, Trade Fairs, Procurement Conferences, etc.

m. Oversee the establishment and maintenance of contract and subcontract award records.

n. Prepare and submit timely, required subcontract reports.

o. Coordinate the company’s activities during the conduct of compliance reviews by Federal agencies.

p. Other duties: ________________________________________________________________

9. The following outreach efforts will be taken to assure small business (including ANCs and Indian tribes), veteran-owned small business, service-disabled veteran-owned small business, HUBZone small business, small disadvantaged business (including ANCs and Indian tribes), and women-owned small business concerns will have an equitable opportunity to compete for subcontracts:

Provide description of your outreach efforts. For example:

a. Sources will be identified from the Small Business Administration’s PRO-Net database.

b. Sources will be requested from business development organizations such as the Chamber of Commerce and Regional Minority Development Councils.

c. Participation in small business trade fairs

10. The Offeror agrees that the clause in this contract entitled “Utilization of Small Business Concerns” will be included in all subcontracts which offer further subcontracting opportunities, and all subcontractors (except small business concerns) who receive subcontracts in excess of $750,000 for supplies or services or greater than $1,500,000 for construction will be required to adopt and comply with a subcontracting plan similar to this one as required by FAR 52.219-9, “Small Business Subcontracting

Plan.” The acceptability of percentage goals shall be determined on a case-by-case basis depending on the supplies or services involved, the availability of potential small business (including ANCs and Indian tribes), veteran-owned small business, service-disabled veteran-owned small business, HUBZone small business, small disadvantaged business (including ANCs and Indian tribes), and women-owned small business subcontractors, and prior experience. (Flow-down of the subcontracting plan requirement is not applicable to subcontracts for commercial items in contracts that contain either FAR 52.212-5(e) or FAR 52.244-6(c).)

11. The Offeror agrees to:

a. Cooperate in any studies or surveys as may be required.

b. Submit periodic reports in order to allow the Government to determine the extent of compliance by the Offeror with the subcontracting plan.

http://www.esrs.gov/

(Am-0001)

c. Include subcontracting data for each order when reporting subcontracting achievements for indefinite-delivery, indefinite-quantity contract intended for use by multiple agencies;

d. Submit on a semi-annual basis for the periods ending March 31 and September 30, within 30 days after the close of each reporting period the Individual Subcontract Report (ISR) and the

Summary Subcontract Report (SSR) using the Electronic Subcontracting Reporting System

(eSRS) at www.esrs.gov following the instructions in eSRS and FAR Clause 52.219-9 in accordance with the instructions of the administering contracting office, or provide other ancillary reports as requested by the Contracting Officer or Small Business Office Submit a completed report within 30 days after contract completion.

e. Ensure that its subcontractors agree to submit ISR and/or SSR using eSRS, if applicable.

f. Provide its prime contract number and DUNS number, and e-mail address of the official responsible for acknowledging receipt of or rejecting the ISRs, to all first-tier subcontractors with subcontracting plans in order to enter the information into the eSRS when submitting ISRs; and

g. Require each subcontractor with a subcontracting plan provide the administer of this subcontracting plan, the prime contract number, its DUNS number, and e-mail address of the subcontractor’s official responsible for acknowledging receipt of or rejecting the ISRs, to its subcontractors with subcontracting plans.

12. The Offeror agrees to maintain the following types of records to demonstrate compliance with this subcontracting plan and its goals, including:

a. Description of the types of records that will be maintained concerning procedures that have been adopted to comply with the requirements and goals in the plan including establishing source lists, guides, and other data that describe the Offeror’s efforts to locate small business

(including ANCs and Indian tribes), veteran-owned small business, service-disabled veteran-owned small business, HUBZone small business, small disadvantaged business (including

ANCs and Indian tribes), and women-owned small business concerns.

b. Source lists (e.g., SAM), guides, and other data that identify small business, veteran-owned small business, service-disabled veteran-owned small business, HUBZone small business, small disadvantaged business, and women-owned small business concerns.

c. Organizations contacted in attempt to location sources that are small business, veteran-owned small business, service-disabled veteran-owned small business, HUBZone small business, small disadvantaged business, and women-owned small business concerns.

d. Records on each subcontract resulting in award of more than $150,000, indicating:

(1) Records on each subcontract solicitation resulting in an award of more than the simplified acquisition threshold, indicating

A. Whether a small business concerns were solicited and if not, why not;

B. Whether a veteran-owned small business concerns were solicited and if not, why not;

C. Whether a service-disabled veteran-owned small business concerns were solicited and if not, why not;

D. Whether a HUBZone small business concerns were solicited and if not, why not;

E. Whether a small disadvantaged business concerns were solicited and if not, why not;

F. Whether a women-owned small business concerns were solicited and, if not, why not.

G. If applicable, the reason award was not made to a small business concern.

e. Records of any outreach effort to contact

(1) Trade associations;

(2) Business development organizations;

http://www.esrs.gov/

(Am-0001)

(3) Conferences and trade fairs to locate small, HUBZone, small business, small disadvantaged, service-disabled veteran-owned, and women-owned small business sources; and

(4) Veterans service organizations.

f. Records of internal guidance and encouragement provided to buyers through:

(1) Workshops, seminars, training, etc., and

(2) Monitoring performance to evaluate compliance with the program’s requirements.

g. On a contract-by-contract basis, records to support award data submitted by the Offeror to the

Government, including the name, address, and business size of each subcontractor.

13. Assurances that the Offeror will make a good faith effort to acquire articles, equipment, supplies, services, or materials, or obtain the performance of construction work from the small business concerns that the Offeror used in preparing the bid or proposal, in the same or greater scope, amount, and quality used in preparing and submitting the bid or proposal. Responding to a request for a quote does not constitute use in preparing a bid or proposal. An Offeror used a small business concern in preparing the bid or proposal if--

(i) The Offeror identifies the small business concern as a subcontractor in the bid or proposal or associated small business subcontracting plan, to furnish certain supplies or perform a portion of the contract; or

(ii) The Offeror used the small business concern's pricing or cost information or technical expertise in preparing the bid or proposal, where there is written evidence of an intent or understanding that the small business concern will be awarded a subcontract for the related work if the Offeror is awarded the contract;

14. Assurances that the contractor will provide the contracting officer with a written explanation if the contractor fails to acquire articles, equipment, supplies, services or materials or obtain the performance of construction work as described in items 3 and 4 of this section. This written explanation will be submitted to the contracting officer within 30 days of contract completion.

15. Assurances that the contractor will not prohibit a subcontractor from discussing with the contracting officer any material matter pertaining to payment to or utilization of a subcontractor; and;

16. Assurances that the Offeror will pay its small business subcontractors on time and in accordance with the terms and conditions of the subcontract, and notify the contracting officer if the Offeror pays a reduced or an untimely payment to a small business subcontractor (see 52.242-5).

http://farsite.hill.af.mil/reghtml/regs/far2afmcfars/fardfars/far/52_237.htm#P308_50712

(Am-0001)

This subcontracting plan was submitted by:

(Must be a company official with authority to contractually obligate the company.)

Signed: ___________________________________

Date: ___________________________________

Typed Name: ___________________________________

Title: ___________________________________

Phone Number: ___________________________________

Agency Small Business Review:

Typed Name: ___________________________________

Signed: ___________________________________ Date Reviewed: ________________

Deputy for Small Business

U. S. Small Business Administration1

Signed: ___________________________________ Date Reviewed: ________________

Procurement Center Representative

Small Business Administration

Contracting Officer Approval:

Signed: _________________________________ Date Approved: ________________

Contracting Officer

1 By statute, SBA does not approve or disapprove a subcontracting plan; rather, SBA’s comments are advisory, and the contracting officer approves or disapproves the plan.

FY22 PN 096540 Child Development Center, Aliamanu Military Reservation

W9128A22R0019

RFI # Question Response

The first set of project requirements for this solicitation (4.1.2 a-e | pg.

24/130) are highly specific in regards to having experience building/renovating not only a child development center/primary school but also having this build be in an area that is logistically similar to construction on the Hawaiian Islands, if not on the Hawaiian islands.

Because of the unique nature of this request, would the USACE consider relaxing the project time frames to include projects completed as far back as 2002? This might allow firms like ours to better present examples of relevant projects that show experience in both areas. Likewise, if the project was completed prior to 2012, would the USACE consider allowing projects as low as $5 Million? In inflation adjust dollars, this amount correlates to almost double in present day value. By relaxing the guidelines on this RFP, we feel more firms would have a chance to be competitive and truly allow the USACE to choose from a variety of qualified contractors.

Request denied.

Does this project require that all materials need to be DOMESTIC?

Especially for the DI FITTINGS on waterline scope.

See Section 00 72 00, clause 52.225-11 Buy American-Construction Materials Under Trade Agreement (Nov 2021)

If yes, can we get you a quote of C153 FITTINGS instead of C110 FITTINGS (Section 33 11 00 - Ductile-Iron Piping)? We might not be able to provide quote for Domestic C110 but we can if it can Import

C153 fittings are not acceptable.

This RFP was issued on June 22, 2022. The RFP states that RFIs are due on June 28, 2022, which gives only 4 business days to review the entire project. In addition, the RFI deadline is prior to the scheduled job walk of July 6, 2022. Can the RFI deadline be adjusted to something more typical such as 10 business day prior to bid due date?

See Am-0001, SF30.

Is it possible to adjust the box sizes on Attachment A? As there are only two pages allotted for each project, we will need more space for scope of work, etc.

Yes

Section 00 60 00, Appendix A, Requests for Information - 1

W9128A22R0019

RFI # Question Response

Section 00 22 16 – Supplementary Instructions to Proposers, 7.0 Volume 2: Price Proposal, 7.1.10 Volume 2, TAB 7: Subcontracting Plan (only required from Large Business Concerns (page 30 of 128), states that a subcontracting plan must be submitted in accordance with FAR 52.219-9 no later than five (5) calendar days after a notification request from the Contracting Officer or Contract Specialist. The table included on page 29 of 128 of the RPF also lists the contents of the price proposal (volume 2) and make it seem like the subcontracting plan would be due at the same time as the price proposal (for large business concerns). Please verify if/when a subcontracting plan is due. Please also provide a template of the subcontracting plan because although the RFP references to the template being Appendix A, a template was not included.

See Section 00 22 16, para 7.1.10 for when a subcontrating plan would be due.

See Am-0001 for a sample subcontracting plan.

On Painting Spec 09 90 00 1.5.3 calls for SSPC QP 1 prior to award.

According to SSPC a company must have a project on going before they can perform their audit. Can we hire a NACE Certified Coating Inspector Level 3 until we get our QP1.

See Am-0001, Section 09 90 00, para 1.5.3

Reference S-504, Detail A4. The detail calls out (2) #8 x 12 long A706 (4 total).

1.Please clarify if there are 2 or 4 items?

2.Is this designation indicating a piece of #8 rebar that is to be threaded and bolted to the steel beam or does it indicate another threaded type of product?

Please provide required torque specifications for bolts to threaded member.

1.There are 4 total bars. Refer to details A1 and A4/S-504.

2.The rebar does not get bolted.

Please confirm soap dispenser is not desired at Preschool/Pre-K/Kinder Toilet Room nor in the active play toilet

Confirmed.

10 No cable tray is shown on the telecom drawings. Please advise. See Sheet T-101 to T-105, and Key Note 1 for cable trays.

Spec Section 26 13 01 – 2.1.2 – Indicates switchgear to be made of steel but 2.1.2.1 indicates stainless steel. Please advise if the switchgear in

2.1.2 is to be made of stainless steel.

See Am-0001, Section 26 13 01, para 2.1.2

Section 00 60 00, Appendix A, Requests for Information - 2

W9128A22R0019

RFI # Question Response

Please confirm all indoor equipment such as switchgear, transformers, panel boards, and disconnects can be Nema 1 Standard Steel Construction and all outdoor equipment is NEMA 4X Stainless Steel 304.

Confirmed.

Please confirm all branch wiring for receptacles, lighting, and mechanical equipment is to be XHHW per specifications.

THHN wire is acceptable.

Spec Section 28 31 76 – Please confirm complete design drawings are the responsibility of the contractor including a stamp by a registered fire protection engineer.

Confirmed.

Where space permits, at contractor’s choice equivalent round ductwork may be used in lieu of rectangular ductwork. Please advise

See Am-0001, Section 23 30 00, para 2.9.1.f

Note 7 on Sheet M-653 states “coordinate connection of building DDC system to existing central HVAC DDC system. Ensure systems are compatible and correctly calibrated as required to connect to central HVAC DDC system.” Please clarify the scope of work required by this project. Define the term “coordinate” as it relates to this projects scope of work. Please provide what system is the “existing central HVAC DDC system.” Please clarify who is to provide the cost and perform the work to integrate into the existing base UMCS.

See Am-0001, sheet M-635

There are limited details on the mechanical and plumbing drawings for upper attachment details. Please refer to detail C1&C4/M-501 and P-502 as examples. Please confirm if the overhead mechanical systems can attach to the metal deck for support of if alternate details are required for upper attachments?

No. See note 1 on detail A1/S-605.

Section 00 60 00, Appendix A, Requests for Information - 3

W9128A22R0019

RFI # Question Response

There is conflicting information in the documents with regards to seismic requirements for mechanical systems. The mechanical specification Section 23 05 48.19 Seismic Bracing for HVAC indicates to provide bracing and seismic support. Section HVAC Air Distribution 23 30 00 paragraph 2.6 Seismic Anchorage states “Anchor equipment in accordance with applicable seismic criteria for the area…” On the structural drawings Sheet S-001 under the Earthquake Design Data, the project is listed as a Risk Category III and Seismic Design Category C.

Based on the criteria provided, per ACCE 7-16 Chapter 13 that no seismic bracing is requirement for mechanical and plumbing systems and equipment. Please confirm no seismic bracing is requirement based on the structural design criteria.

See Am-0001, Section 23 30 00, para 2.6

Contractor assumed that there is NO Attic wet-type sprinkler for the Project. Please confirm

Confirmed.

Spec 25 05 11 is requiring to provide an Ethernet Switch, “2.1 ETHERNET SWITCH Provide Open Systems Interconnection (OSI) Layer 2 Ethernet switches with the following capabilities”, with an interface to support switch configuration for these capabilities. Please clarify why is the requirement under 25 05 11 and not Division 27 Communications. Please provide brand and port density.

The switches mentioned in Section 25 05 11 are not for the telecom, it is for the building industrial control systems. The section is not requesting that a device be installed, it is stating that If a switch is installed it must comply with the 25 05 11 spec.

Section 32 31 13, para 2.3.1B. Please confirm if it is acceptable to use fittings that meet ASTM F626 in lieu of ASTM A153.

Confirmed.

Spec Section 088100, Part 2.3.1 – “Color must be bronze.” Please confirm that this is in reference to the hue of the low emissivity coating and not the outboard glass substrate itself.

Confirmed.

Section 00 60 00, Appendix A, Requests for Information - 4

Section 00 60 00, Appendix B, Site Visit Attendees (Am-0001) - Page 1

(Am-0001) - Page 2

(Am-0001) - Page 3

Section 00 72 00, Appendix A - 1

General Decision Number: HI20220001 07/08/2022

Superseded General Decision Number: HI20210001

State: Hawaii

Construction Types: Building, Heavy (Heavy and Dredging), Highway and Residential

Counties: Hawaii Statewide.

BUILDING CONSTRUCTION PROJECTS; RESIDENTIAL CONSTRUCTION

PROJECTS (consisting of single family homes and apartments up to and including 4 stories); HEAVY AND HIGHWAY CONSTRUCTION

PROJECTS AND DREDGING

Note: Contracts subject to the Davis-Bacon Act are generally required to pay at least the applicable minimum wage rate required under Executive Order 14026 or Executive Order 13658.

Please note that these Executive Orders apply to covered contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but do not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60).

|If the contract is entered |. Executive Order 14026 |

|into on or after January 30, | generally applies to the |

|2022, or the contract is | contract. |

|renewed or extended (e.g., an |. The contractor must pay |

|option is exercised) on or | all covered workers at |

|after January 30, 2022: | least $15.00 per hour (or |

| | the applicable wage rate |

| | listed on this wage |

| | determination, if it is |

| | higher) for all hours |

| | spent performing on the |

| | contract in 2022. |

|If the contract was awarded on|. Executive Order 13658 |

|or between January 1, 2015 and| generally applies to the |

|January 29, 2022, and the | contract. |

|contract is not renewed or |. The contractor must pay all|

|extended on or after January | covered workers at least |

|30, 2022: | $11.25 per hour (or the |

| | applicable wage rate listed|

| | on this wage determination,|

| | if it is higher) for all |

| | hours spent performing on |

| | that contract in 2022. |

The applicable Executive Order minimum wage rate will be adjusted annually. If this contract is covered by one of the

Executive Orders and a classification considered necessary for performance of work on the contract does not appear on this

Section 00 72 00, Appendix A - 2

(Am-0001) wage determination, the contractor must still submit a conformance request.

Additional information on contractor requirements and worker protections under the Executive Orders is available at https://www.dol.gov/agencies/whd/government-contracts.

Modification Number Publication Date

0 01/07/2022

1 01/14/2022

2 02/18/2022

3 02/25/2022

4 03/04/2022

5 03/11/2022

6 03/18/2022

7 03/25/2022

8 04/15/2022

9 07/08/2022

ASBE0132-001 09/05/2021

Rates Fringes

Asbestos Workers/Insulator

Includes application of all insulating materials, protective coverings, coatings and finishes to all types of mechanical systems. Also the application of firestopping material for wall openings and penetrations in walls, floors, ceilings and curtain walls...............$ 42.80 26.25

BOIL0627-005 01/01/2021

BOILERMAKER......................$ 37.25 31.25

BRHI0001-001 08/30/2021

BRICKLAYER

Bricklayers and Stonemasons.$ 46.46 30.43

Pointers, Caulkers and

Weatherproofers.............$ 46.71 30.43

BRHI0001-002 08/30/2021

Section 00 72 00, Appendix A - 3

(Am-0001)

Tile, Marble & Terrazzo Worker

Terrazzo Base Grinders......$ 42.59 32.57

Terrazzo Floor Grinders and Tenders.................$ 41.04 32.57

Tile, Marble and Terrazzo

Workers.....................$ 44.40 32.57

CARP0745-001 10/01/2021

Carpenters:

Carpenters; Hardwood Floor

Layers; Patent Scaffold

Erectors (14 ft. and over); Piledrivers;

Pneumatic Nailers; Wood

Shinglers and Transit and/or Layout Man...........$ 51.25 24.84

Millwrights and Machine

Erectors....................$ 51.50 24.84

Power Saw Operators (2 h.p. and over)..............$ 51.40 24.84

CARP0745-002 10/01/2021

Drywall and Acoustical

Workers and Lathers..............$ 51.50 24.84

ELEC1186-001 09/05/2021

Electricians:

Cable Splicers..............$ 59.38 30.34

Electricians................$ 52.55 30.14

Telecommunication worker....$ 33.69 13.13

ELEC1186-002 09/05/2021

Line Construction:

Cable Splicers..............$ 59.38 30.34

Groundmen/Truck Drivers.....$ 39.41 26.12

Heavy Equipment Operators...$ 47.30 28.53

Linemen.....................$ 52.55 30.14

Telecommunication worker....$ 33.69 13.13

ELEV0126-001 01/01/2022

ELEVATOR MECHANIC................$ 65.33 36.885+a+b

Section 00 72 00, Appendix A - 4

(Am-0001)

a. VACATION: Employer contributes 8% of basic hourly rate for

5 years service and 6% of basic hourly rate for 6 months to

5 years service as vacation pay credit.

b. PAID HOLIDAYS: New Year's Day, Memorial Day, Independence

Day, Labor Day, Veterans' Day, Thanksgiving Day, the Friday after Thanksgiving Day and Christmas Day.

ENGI0003-002 09/03/2018

Diver (Aqua Lung) (Scuba))

Diver (Aqua Lung) (Scuba)

(over a depth of 30 feet)...$ 66.00 31.26

Diver (Aqua Lung) (Scuba)

(up to a depth of 30 feet)..$ 56.63 31.26

Stand-by Diver (Aqua Lung)

(Scuba)....................$ 47.25 31.26

Diver (Other than Aqua Lung)

Diver (Other than Aqua

Lung).......................$ 66.00…