Revised Attachment 3 Supplemental Contract Requirements 4 March 2022 .pdf
PDF 217 KB Posted
- Attached to
- Flight Test Apron Hill Air Force Base Federal contract opportunity
- Solicitation number
- W9123822R0015
About this file
This document outlines requirements for a federal construction contract opportunity. The contractor will be responsible for replacing and reconstructing several sections of existing Portland cement concrete slabs that comprise the flight test apron at Hill Air Force Base, along with demolishing adjacent drainage infrastructure. Scope of work includes installation of a coarse aggregate base, underdrain pipes, stormwater structures, grounding points, and replacement of aircraft sunshade structures. The selected contractor must design and construct all new facilities in accordance with Department of Defense and Air Force construction standards for permanent structures. The solicitation was issued by the Department of the Army Corps of Engineers Sacramento District for this design-bid-build construction contract.
View the file
Other files for this federal contract opportunity
| File | Type | Posted |
|---|---|---|
| Cut Sheet 2381 AM0002 2022-03-07.pdf | ||
| Cut Sheet 180-25-0982C-121-C-121.pdf | ||
| Cut Sheet 180-25-0982C-122-C-122.pdf | ||
| W9123822R0015 AMENDMENT 0002.pdf | ||
| Revised Attachment 4 UT20220091 Feb 25 2022.pdf | ||
| W9123822R0015 AMENDMENT 0001.pdf | ||
| B07 W9123822R0015 Sign In Roster Site Walk.pdf | ||
| W9123822R0015 Flight Apron Repairs v2.pdf | ||
| Attachment 6 Flight Apron Site Walk.pdf | ||
| Attachment 7_Utah Resident Office Map.pdf | ||
| Attachment 9 Past Performance Questionnaire.pdf | ||
| Attachment 4 DBW Rates.pdf | ||
| Attachment 2 Test Apron Drawings.pdf | ||
| Attachment 1 Specifications.pdf | ||
| Attachment 8 Project Information Form.pdf | ||
| Attachment 5 Pre Award Survey.pdf | ||
| Attachment 3 Supplemental Contract Requirements.pdf |
Show all 17
On GovTribe
Work with this file on GovTribe
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Attachment 3
SUPPLEMENTAL CONTRACT REQUIREMENTS
1. Performance Period: Refer to contract section 00700, FAR 52.211-10. The performance period for the work stated above shall be 18 months.
2. Liquidated Damages: Refer to contract section 00700, FAR 52.211-12, Liquidated Damages-
Construction. Liquidated damages for this work are $1,995.05 for each day of delay.
3. Authorities: “Only a warranted Contracting Officer (either PCO or ACO) acting within their delegated limits has the authority to issue modifications or otherwise change the terms and conditions of this contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this contract you shall not proceed with the change and shall immediately notify the
Contracting Officer.”
Wage Determination: General Decision No: UT20220091 02/25/2022, or its most current modification atthe time of award is hereby applicable to work performed under this task order. The most current decision or its modification can be found at:
6. Time Extensions For Unusually Severe Weather: Refer to FAR 52.249-10, Default (Fixed- Priced
Construction). All weather delay will need to be submitted and approved by the Contracting Officer
Representative.
MONTHLY ANTICIPATED ADVERSE WEATHER DELAY
WORK DAYS BASED ON (5) DAY WORK WEEK-HILL AFB
JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC
(22) (19) (15) (07) (04) (03) (01) (02) (02) (05) (15) (22) https://sam.gov/wage-determination/UT20220091/1 https://sam.gov/wage-determination/UT20210083/5
File details come from the government source that posted it. Updated .