Attachment 3 Supplemental Contract Requirements.pdf
PDF 50 KB Posted
- Attached to
- Flight Test Apron Hill Air Force Base Federal contract opportunity
- Solicitation number
- W9123822R0015
About this file
This solicitation is for replacement and reconstruction of existing Portland cement concrete slabs and structural base materials at sections A36B, A45Bl, A45B2, and A52B of the flight test apron at Hill Air Force Base. The selected contractor will demolish and remove existing concrete slabs and drainage structures, design and install new anchored aircraft tie-downs and pavement markings in accordance with DoD and Air Force facility criteria. Additional requirements include installing underdrain piping and stormwater structures, providing grounding points, and replacing existing aircraft sunshade structures. The Department of the Army Corps of Engineers Engineering District Sacramento is the contracting agency. The acquisition will utilize sealed bidding procedures.
View the file
Other files for this federal contract opportunity
| File | Type | Posted |
|---|---|---|
| W9123822R0015 AMENDMENT 0002.pdf | ||
| Cut Sheet 180-25-0982C-121-C-121.pdf | ||
| Cut Sheet 180-25-0982C-122-C-122.pdf | ||
| Cut Sheet 2381 AM0002 2022-03-07.pdf | ||
| W9123822R0015 AMENDMENT 0001.pdf | ||
| Revised Attachment 3 Supplemental Contract Requirements 4 March 2022 .pdf | ||
| Revised Attachment 4 UT20220091 Feb 25 2022.pdf | ||
| B07 W9123822R0015 Sign In Roster Site Walk.pdf | ||
| Attachment 7_Utah Resident Office Map.pdf | ||
| Attachment 9 Past Performance Questionnaire.pdf | ||
| Attachment 4 DBW Rates.pdf | ||
| Attachment 2 Test Apron Drawings.pdf | ||
| Attachment 1 Specifications.pdf | ||
| Attachment 8 Project Information Form.pdf | ||
| Attachment 5 Pre Award Survey.pdf | ||
| W9123822R0015 Flight Apron Repairs v2.pdf | ||
| Attachment 6 Flight Apron Site Walk.pdf |
Show all 17
On GovTribe
Work with this file on GovTribe
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Attachment 3
SUPPLEMENTAL CONTRACT REQUIREMENTS
1. Performance Period: Refer to contract section 00700, FAR 52.211-10. The performance period for the work stated above shall be 365 calendar days.
2. Liquidated Damages: Refer to contract section 00700, FAR 52.211-12, Liquidated Damages-
Construction. Liquidated damages for this work are $2,974.34 for each day of delay.
3. Authorities: “Only a warranted Contracting Officer (either PCO or ACO) acting within their delegated limits has the authority to issue modifications or otherwise change the terms and conditions of this contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this contract you shall not proceed with the change and shall immediately notify the
Contracting Officer.”
Wage Determination: General Decision No: UT20220091 01/07/2022, or its most current modification atthe time of award is hereby applicable to work performed under this task order. The most current decision or its modification can be found at:
SAM.gov
6. Time Extensions For Unusually Severe Weather: Refer to FAR 52.249-10, Default (Fixed- Priced
Construction). All weather delay will need to be submitted and approved by the Contracting Officer
Representative.
MONTHLY ANTICIPATED ADVERSE WEATHER DELAY
WORK DAYS BASED ON (5) DAY WORK WEEK-HILL AFB
JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC
(22) (19) (15) (07) (04) (03) (01) (02) (02) (05) (15) (22) https://sam.gov/wage-determination/UT20210083/5
File details come from the government source that posted it. Updated .