Atch_2_Supplemental_Contract_Requirements.docx

W91238-18-R-0021 Attachment 2

SUPPLEMENTAL CONTRACT REQUIREMENTS

1. Performance Period. Refer to contract Section 00700, FAR 52.211-10. The performance period for the work stated above shall be 635 calendar days from Notice to Proceed date.

2. Liquidated Damages. Refer to FAR 52.211-12, Liquidated Damages-Construction. Liquidated damages for this work are $2,124.00 for each day of delay.

3. Authorities. No person other than the Government Contracting Officer/Administrative Contracting Officer has the authority to make any changes to this contract action that impact cost or schedule. Authority from the Contracting Officer/Administrative Contracting Officer to the contractor to make changes that impact cost or schedule will be in the form of an official, signed modification.

4. Wage Determination. General Decision No. CA20160009 dated 1/26/2018, or its most current modification at the time of award is hereby applicable to work performed under this task order. The most current decision or its modification can be found at http://www.wdol.gov/wdol/scafiles/davisbacon/CA9.dvb

5. Time Extensions For Unusually Severe Weather. Refer to Default (Fixed-Priced Construction). All weather delay will need to be submitted and approved by the Contracting Officer Representative.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK-BEALE AFB

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

(07) (06) (05) (04) (01) (00) (00) (00) (01) (02) (05) (07)