Amendment 5 W50S8524B0001.pdf

127 MSC

STEVEN STOCKING

(586) 239-4881

43200 MAPLE ST.

SELFRIDGE ANGB MI 48045

F8Y36P3263A001-0001

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is to make the follow ing changes in accordance w ith the enclosed Summary of Changes:

1. Delete the Overtime Liquidated Damages Rates in the clause at FAR 52.211-12 Liquidated Damages-Construction

2. Contract Line items 2 and 3 are not to be priced--they are for informational purposes only. Subcontract line items 0002AA, 0002AB, 0002AC, 0003AA,0003B, and 0003AC shall be priced to include the unit price.

3. There are no other changes, and all other terms and conditions shall remain the same.

1. CONTRACT ID CODE PAGE OF PAGES

1 3

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 12-Jan-2024

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W50S8524B0001

X 9B. DATED (SEE ITEM 11)

14-Nov-2023

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

12-Jan-2024

CODE

USPFO MI 127 MISSION SUPPORT CONTRACTING

43200 MAPLE ST

SELFRIDGE ANGB MI 48045-5213

W50S85 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE W50S85

FACILITY CODECODE

EMAIL:TEL:

W50S8524B0001

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00 10 00 - SOLICITATION

CLIN 0002

The CLIN extended description has changed from:

Non personal services: Provide all plant, labor, new and current material, transportation, tools, equipment, appliances, supplies, services, permits, insurance and supervision necessary in support of crack repair in supprt of VGLZ172042 - Repair Runway Keel Repair Runway Keel in accordancewith drawings, plans, specifications, and all applicable terms and conditions.

To:

Non personal services: Provide all plant, labor, new and current material, transportation, tools, equipment, appliances, supplies, services, permits, insurance and supervision necessary in support of crack repair in supprt of VGLZ172042 - Repair Runway Keel Repair Runway Keel in accordancewith drawings, plans, specifications, and all applicable terms and conditions. DO NOT PRICE THIS LINE ITEM--IT IS INFORMATIONAL ONLY. PRICE

SUB LINE ITEMS 0002AA,0002AB, AND 0002AC

CLIN 0003

The CLIN extended description has changed from:

Non personal services: Provide all plant, labor, new and current material, transportation, tools, equipment, appliances, supplies, services, permits, insurance and supervision necessary in support of Asphalt repair in supprt of VGLZ172042 - Repair Runway Keel Repair Runway Keel in accordancewith drawings, plans, specifications, and all applicable terms and conditions.

To:

Non personal services: Provide all plant, labor, new and current material, transportation, tools, equipment, appliances, supplies, services, permits, insurance and supervision necessary in support of Asphalt repair in supprt of VGLZ172042 - Repair Runway Keel Repair Runway Keel in accordancewith drawings, plans, specifications, and all applicable terms and conditions.DO NOT PRICE THIS LINE ITEM--IT IS INFORMATIONAL ONLY. PRICE

BELOW SUB LINE ITEMS 0003AA,0003AB, AND 0003AC

SECTION 00 70 00 - CONDITIONS OF THE CONTRACT

The following have been modified:

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

W50S8524B0001

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of:

1. For the 84-calendar day runway shutdown Liquidated Damages will be assessed in the amount of $29,773.86 for each calendar day until the work is completed or accepted. In addition a one-time legal fee of $153.00 will apply.

2. After the runway shutdown is complete if the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,276.50 each calendar day of delay until the work is completed or accepted. In addition a onetime legal fee of $153.00 will apply.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

(End of Summary of Changes)