Solicitation - FA700022Q0072.pdf

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, & 30

1. REQUISITION NUMBER PAGE 1 OF

2. CONTRACT NO. 3. AWARD/EFFECTIVE

DATE

4. ORDER NUMBER 5. SOLICITATION NUMBER 6. SOLICITATION ISSUE

DATE

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME b. TELEPHONE NUMBER (No collect calls)

8. OFFER DUE DATE/

LOCAL TIME

9. ISSUED BY

13b. RATING

14. METHOD OF SOLICITATION

CODE

15. DELIVER TO 16. ADMINISTERED BY CODE

18a. PAYMENT WILL BE MADE BY CODE17a. CONTRACTOR/

OFFEROR

CODE

FACILITY

CODE

CODE

TELEPHONE NO.

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN

OFFER

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK

BELOW IS CHECKED

RFQ IFB RFP

SEE ADDENDUM

19.

ITEM NO.

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

(Use Reverse and/or Attach Additional Sheets as Necessary)

25. ACCOUNTING AND APPROPRIATION DATA 26. TOTAL AWARD AMOUNT (For Govt. Use Only)

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED

29. AWARD OF CONTRACT: REF. OFFER

DATED . . YOUR OFFER ON SOLICITATION

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

30a. SIGNATURE OF OFFEROR/CONTRACTOR

30b. NAME AND TITLE OF SIGNER (Type or print) 30c. DATE SIGNED

31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

31b. NAME OF CONTRACTING OFFICER (Type or print) 31c. DATE SIGNED

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA - FAR (48 CFR) 53.212

10. THIS ACQUISITION IS UNRESTRICTED OR

NAICS:

SIZE STANDARD:

13a. THIS CONTRACT IS A

RATED ORDER UNDER

DPAS (15 CFR 700)

SET ASIDE: % FOR:

11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

12. DISCOUNT TERMS

ARE ARE NOT ATTACHED

ARE ARE NOT ATTACHED

27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1, 52.212-4. FAR 52.212-3 AND 52.212-5 ARE ATTACHED. ADDENDA

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA

8 (A)

EDWOSB

WOMEN-OWNED SMALL BUSINESS

(WOSB) ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

HUBZONE SMALL

BUSINESS

SMALL BUSINESS

Solicitation/Contract Form

Officer Dress and Mess Dress Uniforms IDC

Proposal Identifier: FA700022Q0072 Date: 23 Sep 2022

Supplies or Services & Prices or Costs

Additional Information/Notes

Item Supplies/Service Qty Unit Unit Price

Amount

Men’s Officer Service Uniform Coat

Manufactured in accordance with Purchase Description (PD) YAGC 93-3, dated 22 Jun 99 (Atch # 1), and USAFA Letter of Exception, dated 17 Mar 22 (Atch # 2).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401105 Product Service Code: 8405 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

750 Each

Women’s Officer Service Uniform Coat

Manufactured in accordance with PD YAGC 93-4, dated 31 Mar 00 (Atch # 3), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #4).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401486 Product Service Code: 8410 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

230 Each

Men’s Officer Service Uniform Trousers

Manufactured in accordance with PD YAGC 85-1B, Amendment 3, dated 3 Nov 93 (Atch #5), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #6).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401106 Product Service Code: 8405 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

1,475 Pair

Women’s Officer Service Uniform Slacks

Manufactured in accordance with PD 93-6 Revision 2, dated 21 Jul 97 (Atch #7), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #8).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401485 Product Service Code: 8410

435 Pair

Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

Men’s Mess Dress Uniform Jacket

Manufactured in accordance with PD AESC 82-6A, dated 5 Dec 85 (Atch #9), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #10).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001400833 Product Service Code: 8405 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

780 Each

Women’s Mess Dress Uniform Jacket

Manufactured in accordance with PD YAPC 04-5 Amendment 1, dated 30 Nov 05 (Atch #11) and USAFA Letter of Exception, dated 17 Mar 22 (Atch #12).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401398 Product Service Code: 8410 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

260 Each

Men’s Mess Dress Uniform Trousers

Manufactured in accordance with PD AESC 82-7A, dated 10 Jul 86 (Atch #13), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #14).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001400832 Product Service Code: 8405 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

815 Pair

Women’s Mess Dress Uniform Skirt

Manufactured in accordance with PD APC 05-06, revision dated 31 Jul 05 (Atch #15), USAFA Letter of Exception, Dated 17 Mar 22 (Atch #16).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401397 Product Service Code: 8410 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

260 Each

Men’s Officer Service Uniform Coat First Article Sample.

Manufactured in accordance with Purchase Description (PD) YAGC 93-3, dated 22 Jun 99 (Atch # 1), and USAFA Letter of Exception, dated 17 Mar 22 (Atch # 2).

See FAR Clause 52.209-4 First Article Approval-Government Testing with Alternate I.

Locally Assigned Control Number: 30TB0000000000001401105 Product Service Code: 8405 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

1 Each

Women’s Officer Service Uniform Coat First Article Sample.

Manufactured in accordance with PD YAGC 93-4, dated 31 Mar 00 (Atch # 3), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #4).

See FAR Clause 52.209-4 First Article Approval-Government Testing with Alternate I.

Locally Assigned Control Number: 30TB0000000000001401486 Product Service Code: 8410 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

1 Each

Men’s Officer Service Uniform Trousers First Article Sample.

Manufactured in accordance with PD YAGC 85-1B, Amendment 3, dated 3 Nov 93 (Atch #5), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #6).

See FAR Clause 52.209-4 First Article Approval-Government Testing with Alternate I.

Locally Assigned Control Number: 30TB0000000000001401106 Product Service Code: 8405 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

1 Pair

Women’s Officer Service Uniform Slacks First Article Sample.

Manufactured in accordance with PD 93-6 Revision 2, dated 21 Jul 97 (Atch #7), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #8).

See FAR Clause 52.209-4 First Article Approval-Government Testing with Alternate I.

Locally Assigned Control Number: 30TB0000000000001401485 Product Service Code: 8410 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

1 Pair

Men’s Mess Dress Uniform Jacket First Article Sample.

Manufactured in accordance with PD AESC 82-6A, dated 5 Dec 85 (Atch #9), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #10).

See FAR Clause 52.209-4 First Article Approval-Government Testing with Alternate I.

Locally Assigned Control Number: 30TB0000000000001400833 Product Service Code: 8405 Weapon System Code: 000

1 Each

Pricing Arrangement: Firm Fixed Price

Women’s Mess Dress Uniform Jacket First Article Sample.

Manufactured in accordance with PD YAPC 04-5 Amendment 1, dated 30 Nov 05 (Atch #11) and USAFA Letter of Exception, dated 17 Mar 22 (Atch #12).

See FAR Clause 52.209-4 First Article Approval-Government Testing with Alternate I.

Locally Assigned Control Number: 30TB0000000000001401398 Product Service Code: 8410 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

1 Each

Men’s Mess Dress Uniform Trousers First Article Sample.

Manufactured in accordance with PD AESC 82-7A, dated 10 Jul 86 (Atch #13), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #14).

See FAR Clause 52.209-4 First Article Approval-Government Testing with Alternate I.

Locally Assigned Control Number: 30TB0000000000001400832 Product Service Code: 8405 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

1 Pair

Women’s Mess Dress Uniform Skirt First Article Sample.

Manufactured in accordance with PD APC 05-06, revision dated 31 Jul 05 (Atch #15), USAFA Letter of Exception, Dated 17 Mar 22 (Atch #16).

See FAR Clause 52.209-4 First Article Approval-Government Testing with Alternate I.

Locally Assigned Control Number: 30TB0000000000001401397 Product Service Code: 8410 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

Men’s Officer Service Uniform Coat

Manufactured in accordance with Purchase Description (PD) YAGC 93-3, dated 22 Jun 99 (Atch # 1), and USAFA Letter of Exception, dated 17 Mar 22 (Atch # 2).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401105 Product Service Code: 8405 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

750 Each

Women’s Officer Service Uniform Coat

Manufactured in accordance with PD YAGC 93-4, dated 31 Mar 00 (Atch # 3), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #4).

Option Line Item

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401486 Product Service Code: 8410 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

230 Each

Option Line Item

Men’s Officer Service Uniform Trousers

Manufactured in accordance with PD YAGC 85-1B, Amendment 3, dated 3 Nov 93 (Atch #5), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #6).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401106 Product Service Code: 8405 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

1,475 Pair

Option Line Item

Women’s Officer Service Uniform Slacks

Manufactured in accordance with PD 93-6 Revision 2, dated 21 Jul 97 (Atch #7), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #8).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401485 Product Service Code: 8410 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

435 Pair

Option Line Item

Men’s Mess Dress Uniform Jacket

Manufactured in accordance with PD AESC 82-6A, dated 5 Dec 85 (Atch #9), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #10).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001400833 Product Service Code: 8405 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

780 Each

Option Line Item

Women’s Mess Dress Uniform Jacket

Manufactured in accordance with PD YAPC 04-5 Amendment 1, dated 30 Nov 05 (Atch #11) and USAFA Letter of Exception, dated 17 Mar 22 (Atch #12).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401398 Product Service Code: 8410

260 Each

Pricing Arrangement: Firm Fixed Price

Option Line Item

Men’s Mess Dress Uniform Trousers

Manufactured in accordance with PD AESC 82-7A, dated 10 Jul 86 (Atch #13), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #14).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001400832 Product Service Code: 8405 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

815 Pair

Option Line Item

Women’s Mess Dress Uniform Skirt

Manufactured in accordance with PD APC 05-06, revision dated 31 Jul 05 (Atch #15), USAFA Letter of Exception, Dated 17 Mar 22 (Atch #16).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401397 Product Service Code: 8410 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

260 Each

Option Line Item

Men’s Officer Service Uniform Coat

Manufactured in accordance with Purchase Description (PD) YAGC 93-3, dated 22 Jun 99 (Atch # 1), and USAFA Letter of Exception, dated 17 Mar 22 (Atch # 2).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401105 Product Service Code: 8405 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

750 Each

Option Line Item

Women’s Officer Service Uniform Coat

Manufactured in accordance with PD YAGC 93-4, dated 31 Mar 00 (Atch # 3), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #4).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401486 Product Service Code: 8410 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

230 Each

Men’s Officer Service Uniform Trousers

Manufactured in accordance with PD YAGC 85-1B, Amendment 3, dated 3 Nov 93 (Atch #5), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #6).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401106 Product Service Code: 8405 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

1,475 Pair

Option Line Item

Women’s Officer Service Uniform Slacks

Manufactured in accordance with PD 93-6 Revision 2, dated 21 Jul 97 (Atch #7), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #8).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401485 Product Service Code: 8410 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

435 Pair

Option Line Item

Men’s Mess Dress Uniform Jacket

Manufactured in accordance with PD AESC 82-6A, dated 5 Dec 85 (Atch #9), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #10).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001400833 Product Service Code: 8405 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

780 Each

Option Line Item

Women’s Mess Dress Uniform Jacket

Manufactured in accordance with PD YAPC 04-5 Amendment 1, dated 30 Nov 05 (Atch #11) and USAFA Letter of Exception, dated 17 Mar 22 (Atch #12).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401398 Product Service Code: 8410 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

260 Each

Option Line Item

Men’s Mess Dress Uniform Trousers

Manufactured in accordance with PD AESC 82-7A, dated 10 Jul 86 (Atch #13), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #14).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

815 Pair

Locally Assigned Control Number: 30TB0000000000001400832 Product Service Code: 8405 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

Option Line Item

Women’s Mess Dress Uniform Skirt

Manufactured in accordance with PD APC 05-06, revision dated 31 Jul 05 (Atch #15), USAFA Letter of Exception, Dated 17 Mar 22 (Atch #16).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401397 Product Service Code: 8410 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

260 Each

Option Line Item

Men’s Officer Service Uniform Coat

Manufactured in accordance with Purchase Description (PD) YAGC 93-3, dated 22 Jun 99 (Atch # 1), and USAFA Letter of Exception, dated 17 Mar 22 (Atch # 2).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401105 Product Service Code: 8405 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

750 Each

Option Line Item

Women’s Officer Service Uniform Coat

Manufactured in accordance with PD YAGC 93-4, dated 31 Mar 00 (Atch # 3), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #4).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401486 Product Service Code: 8410 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

230 Each

Option Line Item

Men’s Officer Service Uniform Trousers

Manufactured in accordance with PD YAGC 85-1B, Amendment 3, dated 3 Nov 93 (Atch #5), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #6).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401106 Product Service Code: 8405 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

1,475 Pair

Women’s Officer Service Uniform Slacks

Manufactured in accordance with PD 93-6 Revision 2, dated 21 Jul 97 (Atch #7), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #8).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401485 Product Service Code: 8410 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

435 Pair

Option Line Item

Men’s Mess Dress Uniform Jacket

Manufactured in accordance with PD AESC 82-6A, dated 5 Dec 85 (Atch #9), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #10).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001400833 Product Service Code: 8405 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

780 Each

Option Line Item

Women’s Mess Dress Uniform Jacket

Manufactured in accordance with PD YAPC 04-5 Amendment 1, dated 30 Nov 05 (Atch #11) and USAFA Letter of Exception, dated 17 Mar 22 (Atch #12).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401398 Product Service Code: 8410 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

260 Each

Option Line Item

Men’s Mess Dress Uniform Trousers

Manufactured in accordance with PD AESC 82-7A, dated 10 Jul 86 (Atch #13), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #14).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001400832 Product Service Code: 8405 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

815 Pair

Women’s Mess Dress Uniform Skirt

Manufactured in accordance with PD APC 05-06, revision dated 31 Jul 05 (Atch #15), USAFA Letter of Exception, Dated 17 Mar 22 (Atch #16).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401397 Product Service Code: 8410 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

260 Each

Option Line Item

Men’s Officer Service Uniform Coat

Manufactured in accordance with Purchase Description (PD) YAGC 93-3, dated 22 Jun 99 (Atch # 1), and USAFA Letter of Exception, dated 17 Mar 22 (Atch # 2).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401105 Product Service Code: 8405 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

750 Each

Option Line Item

Women’s Officer Service Uniform Coat

Manufactured in accordance with PD YAGC 93-4, dated 31 Mar 00 (Atch # 3), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #4).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401486 Product Service Code: 8410 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

230 Each

Option Line Item

Men’s Officer Service Uniform Trousers

Manufactured in accordance with PD YAGC 85-1B, Amendment 3, dated 3 Nov 93 (Atch #5), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #6).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401106 Product Service Code: 8405 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

1,475 Pair

Option Line Item

Women’s Officer Service Uniform Slacks

Manufactured in accordance with PD 93-6 Revision 2, dated 21 Jul 97 (Atch #7), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #8).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401485 Product Service Code: 8410

435 Pair

Pricing Arrangement: Firm Fixed Price

Option Line Item

Men’s Mess Dress Uniform Jacket

Manufactured in accordance with PD AESC 82-6A, dated 5 Dec 85 (Atch #9), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #10).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001400833 Product Service Code: 8405 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

780 Each

Option Line Item

Women’s Mess Dress Uniform Jacket

Manufactured in accordance with PD YAPC 04-5 Amendment 1, dated 30 Nov 05 (Atch #11) and USAFA Letter of Exception, dated 17 Mar 22 (Atch #12).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401398 Product Service Code: 8410 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

260 Each

Option Line Item

Men’s Mess Dress Uniform Trousers

Manufactured in accordance with PD AESC 82-7A, dated 10 Jul 86 (Atch #13), and USAFA Letter of Exception, dated 17 Mar 22 (Atch #14).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001400832 Product Service Code: 8405 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

815 Pair

Option Line Item

Women’s Mess Dress Uniform Skirt

Manufactured in accordance with PD APC 05-06, revision dated 31 Jul 05 (Atch #15), USAFA Letter of Exception, Dated 17 Mar 22 (Atch #16).

The quantity is an estimated quantity only. Required quantities will be provided by issuance of delivery orders. Reference Clause 52.216-18 for ordering period details.

Locally Assigned Control Number: 30TB0000000000001401397 Product Service Code: 8410 Weapon System Code: 000 Claimant Program Code: A9 Pricing Arrangement: Firm Fixed Price

260 Each

Description/Specifications/Statement of Work

Requirements The Officer Uniform consists of the following garments: Mens Officer Coat, Womens Officer Coat, Mens Officer Trousers, and Womens Officer Slacks. The Mess Dress Uniform consists of the following garments:

Mens Mess Dress Coat, Womens Mess Dress Coat, Mens Mess Dress Trousers, Womens Mess Dress Skirt, and Womens Mess Dress Slacks (currently under development).

Packaging and Marking

Inspection and Acceptance

Overall Contract Inspection/Acceptance Locations

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore

Email: Eric.Moore@usafa.edu

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31

10 MSG LGRCU

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu Telephone: 719-333-8041

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Please contact Eric Moore for additional delivery requirements.

DoDAAC: F4BR31 CountryCode: USA

10 MSG LGRCU

AF NO MILSBILLS PROC CP 7193333218

2351 SIJAN DR

USAF ACADEMY, CO 80840-8202

UNITED STATES

Eric Moore Email: Eric.Moore@usafa.edu

Deliveries or Performance

Overall Contract Delivery Period

Contractor Destination

Line Item Delivery Schedule QTY Address and POC Special Handling/Notes

750 Each FoB Details

Contractor Destination

230 Each FoB Details

Contractor Destination

1,475 Pair FoB Details

Contractor Destination

435 Pair FoB Details

Contractor Destination

780 Each FoB Details

Contractor Destination

260 Each FoB Details

Contractor Destination

815 Pair FoB Details

Contractor Destination

260 Each FoB Details

Contractor Destination

1 Each FoB Details

Contractor Destination

1 Each FoB Details

0010 Contractor

1 Pair FoB Details

Contractor Destination

1 Pair FoB Details

Contractor Destination

1 Each FoB Details

Contractor Destination

1 Each FoB Details

Contractor Destination

1 Pair FoB Details

Contractor Destination

1 Each FoB Details

Contractor Destination

Option Line Item

750 Each FoB Details Contractor Destination

Option Line Item

230 Each FoB Details Contractor Destination

Option Line Item

1,475 Pair FoB Details Contractor Destination

Option Line Item

435 Pair FoB Details Contractor Destination

Option Line Item

780 Each FoB Details Contractor

260 Each FoB Details Contractor Destination

Option Line Item

815 Pair FoB Details Contractor Destination

Option Line Item

260 Each FoB Details Contractor Destination

Option Line Item

750 Each FoB Details Contractor Destination

Option Line Item

230 Each FoB Details Contractor Destination

Option Line Item

1,475 Pair FoB Details Contractor Destination

Option Line Item

435 Pair FoB Details Contractor Destination

Option Line Item

780 Each FoB Details Contractor Destination

Option Line Item

260 Each FoB Details Contractor Destination

Option Line Item

815 Pair FoB Details Contractor Destination

260 Each FoB Details

Contractor Destination

Option Line Item

750 Each FoB Details Contractor Destination

Option Line Item

230 Each FoB Details Contractor Destination

Option Line Item

1,475 Pair FoB Details Contractor Destination

Option Line Item

435 Pair FoB Details Contractor Destination

Option Line Item

780 Each FoB Details Contractor Destination

Option Line Item

260 Each FoB Details Contractor Destination

Option Line Item

815 Pair FoB Details Contractor Destination

Option Line Item

260 Each FoB Details Contractor Destination

Option Line Item

750 Each FoB Details Contractor Destination

Option Line Item

230 Each FoB Details Contractor

1,475 Pair FoB Details Contractor Destination

Option Line Item

435 Pair FoB Details Contractor Destination

Option Line Item

780 Each FoB Details Contractor Destination

Option Line Item

260 Each FoB Details Contractor Destination

Option Line Item

815 Pair FoB Details Contractor Destination

Option Line Item

260 Each FoB Details Contractor Destination

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.247-7023 Transportation of Supplies by Sea. Feb 2019

Contract Administration Data

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports. Dec 2018

DFARS Clauses Incorporated by Full Text

252.232-7006 Wide Area WorkFlow Payment Instructions. Dec 2018

As prescribed in 232.7004(b), use the following clause:

WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (DEC 2018)

(a) Definitions. As used in this clause-

"Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization.

"Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

"Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system.

"Payment request" and "receiving report" are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall-

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the WAWF home page at https://wawf.eb.mil/

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order:

(1) Document type. The Contractor shall submit payment requests using the following document type(s):

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items-

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

Combo Invoice and Receiving Report

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

N/A

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial item financing, submit a commercial item financing request.

(2) ) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

(f) [Note: The Contractor may use a WAWF "combo" document type to create some combinations of invoice and receiving report in one step.]

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF Pay Official DoDAAC F67100 Issue By DoDAAC FA7000 Admin DoDAAC FA7000 Inspect By DoDAAC F4BR31 Ship To Code F4BR31 Ship From Code ____ Mark For Code ____ Service Approver (DoDAAC) ____ Service Acceptor (DoDAAC) ____ Accept at Other DoDAAC ____ LPO DoDAAC ____ DCAA Auditor DoDAAC ____ Other DoDAAC(s) ____

(4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) Receiving report.