Solicitation - FA485520B0006_Final.pdf

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NUMBER 5. REQUISITION/PURCHASE REQUEST NUMBER 6. PROJECT NUMBER

7. ISSUED BY CODE 8. ADDRESS OFFER TO

9. FOR INFORMATION

CALL:

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within calendar days and complete it within calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. (See ).

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and copies to perform the work required are due at the place specified in Item 8 by (hour) local time (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

b. An offer guarantee is, is not required.

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

STANDARD FORM 1442 (REV. 8/2014)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d)

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

12b. CALENDAR DAYS

YES NO

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NUMBER 2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED PAGE OF PAGES

AMOUNTS

OFFER (Must be fully completed by offeror)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED:

AWARD (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return copies to issuing office.) Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA

BY

31c. DATE

STANDARD FORM 1442 (REV. 8/2014) BACK

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) ( ) 41 U.S.C. 3304(a) ( )

26. ADMINISTERED BY 27. PAYMENT WILL BE MADE BY

FA485520B0006

Section A - Solicitation/Contract Form

Section B - Supplies or Services and Prices/Cost

Additional Information/Notes

Item Supplies/Service Quantity Unit Unit Price Amount

Construction - Replace the Primary and Secondary Electrical Distribution.The contractor shall furnish all services, labor, expertise, materials, supplies, equipment, site investigations, studies, supervision, and travel necessary to produce construction IAW supplied drawings and specifications. All material shall be approved and conform with the specifications. NOTE: CLIN shall include New Mexico Gross Receipts Tax at the current rate of 6.125% for the Remainder of Curry County, per Taxation & Revenue New Mexico.

Product Service Code: Y1NZ Standard Industry Classification (SIC) Code: 1623 Signal Code: A Weapon System Code: 000 Firm Fixed Price

1.0 Job

Section C - Description/Specifications/Statement of Work

Requirements Replace Primary and Secondary Electrical Distribution Phase 3 IAW provided SOW, specifications, and other associated attachments as identified in Section J.

Section D - Packaging and Marking

Not Applicable

Section E - Inspection and Acceptance

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.246-12 Inspection of Construction. 1996-08 52.246-13 Inspection-Dismantling, Demolition, or Removal of Improvements. 1996-08

0001 Inspection and Acceptance Location Both Destination Instructions: Inspect IAW contract specifications and accept if requirements are met.

DoDAAC: F1L3J2 Cage:

DunsNumber:

Duns4Number:

CountryCode: USA

27 SOCES CC

AF BPN NO MILSBILLS PROCESSES

506 N AIR COMMANDO WAY

CANNON AFB, NM 88103 5100

United States

OfficeCode:

Eric Wilcox Telephone: 575-784-6934 Email: eric.wilcox.5@us.af.mil

Section F - Deliveries or Performance

Delivery Schedule Ship To Address

Delivery Schedule From date of lead time event to completion of performance 210 Calendar Days Date of Notice to Proceed Receipt

Place of Performance DoDAAC: F1L3J2 Cage:

DunsNumber:

Duns4Number:

CountryCode: USA

27 SOCES CC

AF BPN NO MILSBILLS PROCESSES

506 N AIR COMMANDO WAY

CANNON AFB, NM 88103 5100

United States

OfficeCode:

Eric Wilcox Email: eric.wilcox.5@us.af.mil Telephone: 575-784-6934

Period of Performance From

01 OCT 2020

To

29 APR 2021

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.242-15 Stop-Work Order. 1989-08 52.247-34 F.o.b. Destination. 1991-11

Section G - Contract Administration Data

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.201-7000 Contracting Officer's Representative 1991-12 252.204-7006 Billing Instructions. 2005-10 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports. 2018-12 252.236-7000 Modification Proposals--Price Breakdown 1991-12

DFARS Clauses Incorporated by Full Text

252.232-7006 Wide Area WorkFlow Payment Instructions. 2018-12

WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (DEC 2018)

(a) Definitions. As used in this clause- "Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization.

"Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

"Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system.

"Payment request" and "receiving report" are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall-

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the WAWF home page at https://wawf.eb.mil/

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order:

(1) Document type. The Contractor shall submit payment requests using the following document type(s):

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items-

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer

"Construction" instead of "2-N-1" or “Combo”

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial item financing, submit a commercial item financing request.

(2) ) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

(f) [Note: The Contractor may use a WAWF "combo" document type to create some combinations of invoice and receiving report in one step.]

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC: F87700 Issue By DoDAAC: FA4855 Admin DoDAAC: FA4855 Inspect By DoDAAC: F1L3J2 Ship To Code: F1L3J2 Ship From Code: N/A Mark For Code: N/A Service Approver (DoDAAC): FA4855 Service Acceptor (DoDAAC) FA4855 Accept at Other DoDAAC: N/A LPO DoDAAC: N/A DCAA Auditor DoDAAC: N/A Other DoDAAC(s): N/A

(4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) Receiving report. The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

Contract Administrator: jessica.baker.12@us.af.mil Customer: richard.helgeson.4@us.af.mil Contracting Officer: kasheka.codner@us.af.mil

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

(End of clause)

Section H - Special Contract Requirements

Not Applicable

Section I - Contract Clauses

52.215-1 Instructions to Offerors-Competitive Acquisition. 2017-01

Instructions to Offerors-Competitive Acquisition (Jan 2017)

(a) Definitions. As used in this provision- Discussions are negotiations that occur after establishment of the competitive range that may, at the Contracting Officer's discretion, result in the offeror being allowed to revise its proposal.

In writing, "writing," or "written" means any worded or numbered expression that can be read, reproduced, and later communicated, and includes electronically transmitted and stored information.

Proposal modification is a change made to a proposal before the solicitation's closing date and time, or made in response to an amendment, or made to correct a mistake at any time before award.

Proposal revision is a change to a proposal made after the solicitation closing date, at the request of or as allowed by a Contracting Officer as the result of negotiations.

Time, if stated as a number of days, is calculated using calendar days, unless otherwise specified, and will include Saturdays, Sundays, and legal holidays. However, if the last day falls on a Saturday, Sunday, or legal holiday, then the period shall include the next working day.

(b) Amendments to solicitations. If this solicitation is amended, all terms and conditions that are not amended remain unchanged. Offerors shall acknowledge receipt of any amendment to this solicitation by the date and time specified in the amendment(s).

(c) Submission, modification, revision, and withdrawal of proposals.

(1) Unless other methods (e.g., electronic commerce or facsimile) are permitted in the solicitation, proposals and modifications to proposals shall be submitted in paper media in sealed envelopes or packages (i) addressed to the office specified in the solicitation, and (ii) showing the time and date specified for receipt, the solicitation number, and the name and address of the offeror. Offerors using commercial carriers should ensure that the proposal is marked on the outermost wrapper with the information in paragraphs (c)(1)(i) and (c)(1)(ii) of this provision.

(2) The first page of the proposal must show-

(i) The solicitation number;

(ii) The name, address, and telephone and facsimile numbers of the offeror (and electronic address if available);

(iii) A statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation and agreement to furnish any or all items upon which prices are offered at the price set opposite each item;

(iv) Names, titles, and telephone and facsimile numbers (and electronic addresses if available) of persons authorized to negotiate on the offeror's behalf with the Government in connection with this solicitation; and

(v) Name, title, and signature of person authorized to sign the proposal. Proposals signed by an agent shall be accompanied by evidence of that agent's authority, unless that evidence has been previously furnished to the issuing office.

(3) Submission, modification, revision, and withdrawal of proposals.

(i) Offerors are responsible for submitting proposals, and any modifications or revisions, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that proposal or revision is due.

(ii)

(A) Any proposal, modification, or revision received at the Government office designated in the solicitation after the exact time specified for receipt of offers is "late" and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and-

(1) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of proposals; or

(2) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government's control prior to the time set for receipt of offers; or

(3) It is the only proposal received.

(B) However, a late modification of an otherwise successful proposal that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted.

(iii) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the proposal wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.

(iv) If an emergency or unanticipated event interrupts normal Government processes so that proposals cannot be received at the office designated for receipt of proposals by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation, the time specified for receipt of proposals will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(v) Proposals may be withdrawn by written notice received at any time before award. Oral proposals in response to oral solicitations may be withdrawn orally. If the solicitation authorizes facsimile proposals, proposals may be withdrawn via facsimile received at any time before award, subject to the conditions specified in the provision at 52.215-5, Facsimile Proposals. Proposals may be withdrawn in person by an offeror or an authorized representative, if the identity of the person requesting withdrawal is established and the person signs a receipt for the proposal before award.

(4) Unless otherwise specified in the solicitation, the offeror may propose to provide any item or combination of items.

(5) Offerors shall submit proposals in response to this solicitation in English, unless otherwise permitted by the solicitation, and in U.S. dollars, unless the provision at FAR 52.225-17, Evaluation of Foreign Currency Offers, is included in the solicitation.

(6) Offerors may submit modifications to their proposals at any time before the solicitation closing date and time, and may submit modifications in response to an amendment, or to correct a mistake at any time before award.

(7) Offerors may submit revised proposals only if requested or allowed by the Contracting Officer.

(8) Proposals may be withdrawn at any time before award. Withdrawals are effective upon receipt of notice by the Contracting Officer.

(d) Offer expiration date. Proposals in response to this solicitation will be valid for the number of days specified on the solicitation cover sheet (unless a different period is proposed by the offeror).

(e) Restriction on disclosure and use of data. Offerors that include in their proposals data that they do not want disclosed to the public for any purpose, or used by the Government except for evaluation purposes, shall-

(1) Mark the title page with the following legend:

This proposal includes data that shall not be disclosed outside the Government and shall not be duplicated, used, or disclosed-in whole or in part-for any purpose other than to evaluate this proposal. If, however, a contract is awarded to this offeror as a result of-or in connection with-the submission of this data, the Government shall have the right to duplicate, use, or disclose the data to the extent provided in the resulting contract. This restriction does not limit the Government's right to use information contained in this data if it is obtained from another source without restriction. The data subject to this restriction are contained in sheets [insert numbers or other identification of sheets]; and

(2) Mark each sheet of data it wishes to restrict with the following legend:

Use or disclosure of data contained on this sheet is subject to the restriction on the title page of this proposal.

(f) Contract award.

(1) The Government intends to award a contract or contracts resulting from this solicitation to the responsible offeror(s) whose proposal(s) represents the best value after evaluation in accordance with the factors and subfactors in the solicitation.

(2) The Government may reject any or all proposals if such action is in the Government's interest.

(3) The Government may waive informalities and minor irregularities in proposals received.

(4) The Government intends to evaluate proposals and award a contract without discussions with offerors (except clarifications as described in FAR 15.306(a)). Therefore, the offeror's initial proposal should contain the offeror's best terms from a cost or price and technical standpoint. The Government reserves the right to conduct discussions if the Contracting Officer later determines them to be necessary. If the Contracting Officer determines that the number of proposals that would otherwise be in the competitive range exceeds the number at which an efficient competition can be conducted, the Contracting Officer may limit the number of proposals in the competitive range to the greatest number that will permit an efficient competition among the most highly rated proposals.

(5) The Government reserves the right to make an award on any item for a quantity less than the quantity offered, at the unit cost or prices offered, unless the offeror specifies otherwise in the proposal.

(6) The Government reserves the right to make multiple awards if, after considering the additional administrative costs, it is in the Government's best interest to do so.

(7) Exchanges with offerors after receipt of a proposal do not constitute a rejection or counteroffer by the Government.

(8) The Government may determine that a proposal is unacceptable if the prices proposed are materially unbalanced between line items or subline items. Unbalanced pricing exists when, despite an acceptable total evaluated price, the price of one or more line items is significantly overstated or understated as indicated by the application of cost or price analysis techniques. A proposal may be rejected if the Contracting Officer determines that the lack of balance poses an unacceptable risk to the Government.

(9) If a cost realism analysis is performed, cost realism may be considered by the source selection authority in evaluating performance or schedule risk.

(10) A written award or acceptance of proposal mailed or otherwise furnished to the successful offeror within the time specified in the proposal shall result in a binding contract without further action by either party.

(11) If a post-award debriefing is given to requesting offerors, the Government shall disclose the following information, if applicable:

(i) The agency's evaluation of the significant weak or deficient factors in the debriefed offeror's offer.

(ii) The overall evaluated cost or price and technical rating of the successful and the debriefed offeror and past performance information on the debriefed offeror.

(iii) The overall ranking of all offerors, when any ranking was developed by the agency during source selection.

(iv) A summary of the rationale for award.

(v) For acquisitions of commercial items, the make and model of the item to be delivered by the successful offeror.

(vi) Reasonable responses to relevant questions posed by the debriefed offeror as to whether source selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities were followed by the agency.

(End of provision)

52.236-27 Alternate I Site Visit (Construction). - (Alternate I) 1995-02

Alternate I (Feb1995). If an organized site visit will be conducted, substitute a paragraph substantially the same as the following for paragraph (b) of the basic provision:

(b) An organized site visit has been scheduled for- _______9 July 2020 at 2pm (MT)

(c) Participants will meet at- _____Cannon AFB Visitors Center

52.242-17 Government Delay of Work Government Delay of Work (Apr 1984)

(a) If the performance of all or any part of the work of this contract is delayed or interrupted (1)by an act of the

Contracting Officer in the administration of this contract that is not expressly or impliedly authorized by this contract, or (2)by a failure of the Contracting Officer to act within the time specified in this contract, or within a reasonable time if not specified, an adjustment (excluding profit) shall be made for any increase in the cost of performance of this contract caused by the delay or interruption and the contract shall be modified in writing accordingly. Adjustment shall also be made in the delivery or performance dates and any other contractual term or condition affected by the delay or interruption. However, no adjustment shall be made under this clause for any delay or interruption to the extent that performance would have been delayed or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an adjustment is provided or excluded under any other term or condition of this contract.

(b) A claim under this clause shall not be allowed-

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved; and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the delay or interruption, but not later than the day of final payment under the contract.

(End of clause)

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.202-1 Definitions. 2013-11 52.203-3 Gratuities. 1984-04 52.203-5 Covenant Against Contingent Fees. 2014-05 52.203-6 Restrictions on Subcontractor Sales to the Government. 2006-09 52.203-7 Anti-Kickback Procedures. 2014-05 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity. 2014-05 52.203-10 Price or Fee Adjustment for Illegal or Improper Activity. 2014-05

52.203-11 Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions.

2007-09

52.203-12 Limitation on Payments to Influence Certain Federal Transactions. 2010-10

52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights.

2014-04

52.203-18 Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements-Representation.

2017-01

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements. 2017-01 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper. 2011-05 52.204-9 Personal Identity Verification of Contractor Personnel. 2011-01 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards. 2018-10 52.204-13 System for Award Management Maintenance. 2018-10 52.204-18 Commercial and Government Entity Code Maintenance. 2016-07

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities.

2018-07

52.207-1 Notice of Standard Competition. 2006-05

52.209-6 Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment.

2015-10

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters. 2018-10 52.209-10 Prohibition on Contracting with Inverted Domestic Corporations. 2015-11 52.211-13 Time Extensions. 2000-09 52.214-26 Audit and Records-Sealed Bidding. 2010-10

52.214-27 Price Reduction for Defective Certified Cost or Pricing Data-Modifications-Sealed Bidding.

2011-08

52.214-28 Subcontractor Certified Cost or Pricing Data-Modifications-Sealed Bidding. 2010-10 52.214-29 Order of Precedence-Sealed Bidding. 1986-01 52.215-8 Order of Precedence-Uniform Contract Format. 1997-10 52.219-6 Notice of Total Small Business Set-Aside. 2020-03 52.219-8 Utilization of Small Business Concerns. 2018-10 52.219-9 Small Business Subcontracting Plan. 2020-03 52.219-13 Notice of Set-Aside of Orders. 2020-03 52.219-16 Liquidated Damages-Subcontracting Plan. 1999-01 52.219-27 Notice of Service-Disabled Veteran-Owned Small Business Set-Aside. 2020-03 52.219-33 Nonmanufacturer Rule. 2020-03 52.222-1 Notice to the Government of Labor Disputes. 1997-02

52.222-4 Contract Work Hours and Safety Standards -Overtime Compensation. 2018-03 52.222-6 Construction Wage Rate Requirements. 2018-08 52.222-7 Withholding of Funds. 2014-05 52.222-8 Payrolls and Basic Records. 2018-08 52.222-9 Apprentices and Trainees. 2005-07 52.222-10 Compliance with Copeland Act Requirements. 1988-02 52.222-11 Subcontracts (Labor Standards). 2014-05 52.222-12 Contract Termination-Debarment. 2014-05 52.222-13 Compliance with Construction Wage Rate Requirements and Related Regulations. 2014-05 52.222-14 Disputes Concerning Labor Standards. 1988-02 52.222-15 Certification of Eligibility. 2014-05 52.222-21 Prohibition of Segregated Facilities. 2015-04 52.222-27 Affirmative Action Compliance Requirements for Construction. 2015-04 52.222-34 Project Labor Agreement. 2010-05 52.222-37 Employment Reports on Veterans. 2016-02 52.222-40 Notification of Employee Rights Under the National Labor Relations Act. 2010-12 52.222-50 Combating Trafficking in Persons. 2019-01 52.222-54 Employment Eligibility Verification. 2015-10 52.222-55 Minimum Wages Under Executive Order 13658. 2015-12 52.222-62 Paid Sick Leave Under Executive Order 13706. 2017-01 52.223-5 Pollution Prevention and Right-to-Know Information. 2011-05 52.223-6 Drug-Free Workplace. 2001-05 52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving. 2011-08 52.223-21 Foams. 2016-06 52.225-13 Restrictions on Certain Foreign Purchases. 2008-06 52.228-2 Additional Bond Security. 1997-10 52.228-3 Workers' Compensation Insurance (Defense Base Act). 2014-07 52.228-5 Insurance-Work on a Government Installation. 1997-01 52.228-11 Pledges of Assets. 2018-08 52.228-12 Prospective Subcontractor Requests for Bonds. 2014-05 52.228-14 Irrevocable Letter of Credit. 2014-11 52.228-15 Performance and Payment Bonds-Construction. 2010-10 52.229-3 Federal, State, and Local Taxes. 2013-02 52.232-8 Discounts for Prompt Payment. 2002-02 52.232-11 Extras. 1984-04 52.232-17 Interest. 2014-05 52.232-23 Assignment of Claims. 2014-05 52.232-27 Prompt Payment for Construction Contracts. 2017-01 52.232-39 Unenforceability of Unauthorized Obligations. 2013-06 52.232-40 Providing Accelerated Payments to Small Business Subcontractors. 2013-12 52.233-1 Disputes. 2014-05 52.233-3 Protest after Award. 1996-08 52.233-4 Applicable Law for Breach of Contract Claim. 2004-10 52.236-2 Differing Site Conditions. 1984-04 52.236-3 Site Investigation and Conditions Affecting the Work. 1984-04 52.236-5 Material and Workmanship. 1984-04 52.236-6 Superintendence by the Contractor. 1984-04 52.236-7 Permits and Responsibilities. 1991-11 52.236-8 Other Contracts. 1984-04

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements.

1984-04

52.236-10 Operations and Storage Areas. 1984-04 52.236-11 Use and Possession Prior to Completion. 1984-04 52.236-12 Cleaning Up. 1984-04 52.236-13 Accident Prevention. 1991-11 52.236-15 Schedules for Construction Contracts. 1984-04 52.236-17 Layout of Work. 1984-04 52.236-21 Specifications and Drawings for Construction. 1997-02 52.236-26 Preconstruction Conference. 1995-02 52.242-13 Bankruptcy. 1995-07 52.242-14 Suspension of Work. 1984-04 52.243-1 Alternate I Changes-Fixed-Price. - (Alternate I) 1987-08 52.243-4 Changes. 2007-06 52.244-6 Subcontracts for Commercial Items. 2019-08 52.246-21 Warranty of Construction. 1994-03 52.247-5 Familiarization with Conditions. 1984-04 52.247-12 Supervision, Labor, or Materials. 1984-04 52.248-3 Alternate I Value Engineering-Construction. - (Alternate I) 2015-10 52.249-2 Termination for Convenience of the Government (Fixed-Price). 2012-04 52.249-4 Termination for Convenience of the Government (Services) (Short Form). 1984-04 52.249-10 Default (Fixed-Price Construction). 1984-04 52.253-1 Computer Generated Forms. 1991-01

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.203-7000 Requirements Relating to Compensation of Former DoD Officials 2011-09

252.203-7001 Prohibition on Persons Convicted of Fraud or Other Defense-Contract-Related Felonies.

2008-12

252.203-7002 Requirement to Inform Employees of Whistleblower Rights. 2013-09 252.204-7003 Control of Government Personnel Work Product. 1992-04 252.204-7004 Antiterrorism Awareness Training for Contractors. 2019-02 252.204-7008 Compliance with Safeguarding Covered Defense Information Controls. 2016-10 252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting. 2019-12 252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support. 2016-05

252.209-7004 Subcontracting with Firms that are Owned or Controlled by the Government of a Country that is a State Sponsor of Terrorism.

2019-05

252.223-7004 Drug-Free Work Force. 1988-09 252.223-7006 Prohibition on Storage, Treatment, and Disposal of Toxic or Hazardous Materials. 2014-09 252.223-7008 Prohibition of Hexavalent Chromium. 2013-06 252.225-7001 Buy American and Balance of Payments Program. 2017-12 252.225-7002 Qualifying Country Sources as Subcontractors. 2017-12 252.225-7012 Preference for Certain Domestic Commodities. 2017-12 252.225-7016 Restriction on Acquisition of Ball and Roller Bearings. 2011-06 252.225-7048 Export-Controlled Items. 2013-06

252.226-7001 Utilization of Indian Organizations, Indian-Owned Economic Enterprises, and Native Hawaiian Small Business Concerns.

2019-04

252.232-7010 Levies on Contract Payments. 2006-12 252.237-7010 Prohibition on Interrogation of Detainees by Contractor Personnel. 2013-06 252.243-7001 Pricing of Contract Modifications. 1991-12 252.243-7002 Requests for Equitable Adjustment. 2012-12 252.244-7000 Subcontracts for Commercial Items 2013-06 252.246-7004 Safety of Facilities, Infrastructure, and Equipment for Military Operations. 2010-10

FAR Clauses Incorporated by Full Text

52.204-1 Approval of Contract. 1989-12

As prescribed in 4.103 , insert the following clause:

APPROVAL OF CONTRACT (DEC 1989)

This contract is subject to the written approval of [ ] and shall not be binding until Lt Kasheka Codner identify title of designated agency official here so approved.

(End of clause)

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

2019-08

As prescribed in 4.2105(b), insert the following clause:

PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS AND VIDEO SURVEILLANCE SERVICES OR

EQUIPMENT (AUG 2019)

As used in this clause-(a) Definitions.

means The People's Republic of China.Covered foreign country means-Covered telecommunications equipment or services

Telecommunications equipment produced by Huawei Technologies Company or ZTE Corporation (or any subsidiary or affiliate of such (1) entities);

For the purpose of public safety, security of Government facilities, physical security surveillance of critical infrastructure, and other (2) national security purposes, video surveillance and telecommunications equipment produced by Hytera Communications Corporation, Hangzhou Hikvision Digital Technology Company, or Dahua Technology Company (or any subsidiary or affiliate of such entities);

Telecommunications or video surveillance services provided by such entities or using such equipment; or(3)

Telecommunications or video surveillance equipment or services produced or provided by an entity that the Secretary of Defense, in (4) consultation with the Director of National Intelligence or the Director of the Federal Bureau of Investigation, reasonably believes to be an entity owned or controlled by, or otherwise connected to, the government of a covered foreign country.

means-Critical technology

Defense articles or defense services included on the United States Munitions List set forth in the International Traffic in Arms (1) Regulations under subchapter M of chapter I of title 22, Code of Federal Regulations;

Items included on the Commerce Control List set forth in Supplement No. 1 to part 774 of the Export Administration Regulations under (2) subchapter C of chapter VII of title 15, Code of Federal Regulations, and controlled-

Pursuant to multilateral regimes, including for reasons relating to national security, chemical and biological weapons proliferation, (i) nuclear nonproliferation, or missile technology; or

For reasons relating to regional stability or surreptitious listening;(ii)

Specially designed and prepared nuclear equipment, parts and components, materials, software, and technology covered by part 810 of (3) title 10, Code of Federal Regulations (relating to assistance to foreign atomic energy activities);

Nuclear facilities, equipment, and material covered by part 110 of title 10, Code of Federal Regulations (relating to export and import of (4) nuclear equipment and material);

Select agents and toxins covered by part 331 of title 7, Code of Federal Regulations, part 121 of title 9 of such Code, or part 73 of title (5) 42 of such Code; or

Emerging and foundational technologies controlled pursuant to section 1758 of the Export Control Reform Act of 2018 (50 U.S.C. (6) 4817).

means any component necessary for the proper function or performance of a piece of equipment, system, or Substantial or essential component service.

Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) (b) Prohibition.

prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. The Contractor is prohibited from providing to the Government any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in Federal Acquisition Regulation 4.2104.

This clause does not prohibit contractors from providing-(c) Exceptions.

A service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or(1)

Telecommunications equipment that cannot route or redirect user data traffic or permit visibility into any user data or packets that such (2) equipment transmits or otherwise handles.

Reporting requirement. (d) In the event the Contractor identifies covered telecommunications equipment or services used as a substantial or (1) essential component of any system, or as critical technology as part of any system, during contract performance, or the Contractor is notified of such by a subcontractor at any tier or by any other source, the Contractor shall report the information in paragraph (d)(2) of this clause to the Contracting

Officer, unless elsewhere in this contract are established procedures for reporting the information; in the case of the Department of Defense, the

Contractor shall report to the website at https://dibnet.dod.mil. For indefinite delivery contracts, the Contractor shall report to the Contracting Officer for the indefinite delivery contract and the Contracting Officer(s) for any affected order or, in the case of the Department of Defense, identify both the indefinite delivery contract and any affected orders in the report provided at https://dibnet.dod.mil.

The Contractor shall report the following information pursuant to paragraph (d)(1) of this clause(2)

Within one business day from the date of such identification or notification: the contract number; the order number(s), if applicable; (i) supplier name; supplier unique entity identifier (if known); supplier Commercial and Government Entity (CAGE) code (if known); brand; model number (original equipment manufacturer number, manufacturer part number, or wholesaler number); item description; and any readily available information about mitigation actions undertaken or recommended.

Within 10 business days of submitting the information in paragraph (d)(2)(i) of this clause: any further available information about (ii) mitigation actions undertaken or recommended. In addition, the Contractor shall describe the efforts it undertook to prevent use or submission of covered telecommunications equipment or services, and any additional efforts that will be incorporated to prevent future use or submission of covered telecommunications equipment or services.

The Contractor shall insert the substance of this clause, including this paragraph (e), in all subcontracts and other contractual (e) Subcontracts.

instruments, including subcontracts for the acquisition of commercial items.

(End of clause)

52.209-1 Qualification Requirements. 1995-02

As prescribed in 9.206-2, insert the following clause:

QUALIFICATION REQUIREMENTS (FEB 1995)

. "Qualification requirement," as used in this clause, means a Government requirement for testing or other quality assurance (a) Definition demonstration that must be completed before award.

One or more qualification requirements apply to the supplies or services covered by this contract. For those supplies or services requiring (b) qualification, whether the covered product or service is an end item under this contract or simply a component of an end item, the product, manufacturer, or source must have demonstrated that it meets the standards prescribed for qualification before award of this contract. The product, manufacturer, or source must be qualified at the time of award whether or not the name of the product, manufacturer, or source is actually included on a qualified products list, qualified manufacturers list, or qualified bidders list. Offerors should contact the agency activity designated below to obtain all requirements that they or their products or services, or their subcontractors or their products or services, must satisfy to become qualified and to arrange for an opportunity to demonstrate their abilities to meet the standards specified for qualification.

(Name) ____

(Address) ____

If an offeror, manufacturer, source, product or service covered by a qualification requirement has already met the standards specified, the (c) relevant information noted below should be provided.

Offeror's Name ____

Manufacturer's Name ____ ____

Source's Name ____

Item Name ____

Service Identification ____

Test Number (to the extent known)____

Even though a product or service subject to a qualification requirement is not itself an end item under this contract, the product, (d) manufacturer, or source must nevertheless be qualified at the time of award of this contract. This is necessary whether the Contractor or a subcontractor will ultimately provide the product or service in question. If, after award, the Contracting Officer discovers that an applicable qualification requirement was not in fact met at the time of award, the Contracting Officer may either terminate this contract for default or allow performance to continue if adequate consideration is offered and the action is determined to be otherwise in the Government's best interests.

If an offeror, manufacturer, source, product or service has met the qualification requirement but is not yet on a qualified products list, (e) qualified manufacturers list, or qualified bidders list, the offeror must submit evidence of qualification prior to award of this contract. Unless determined to be in the Government's interest, award of this contract shall not be delayed to permit an offeror to submit evidence of qualification.

Any change in location or ownership of the plant where a previously qualified product or service was manufactured or performed requires (f) reevaluation of the qualification. Similarly, any change in location or ownership of a previously qualified manufacturer or source requires reevaluation of the qualification. The reevaluation must be accomplished before the date of award.

(End of provision)

52.209-11 Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. 2016-02

As prescribed in (d), insert the following provision:9.104-7

REPRESENTATION BY CORPORATIONS REGARDING DELINQUENT TAX LIABILITY OR A FELONY CONVICTION UNDER ANY

FEDERAL LAW (FEB 2016)

As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), (a) and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that-

Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or (1) have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or

Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is (2) aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.

The Offeror represents that-(b)

It is is not a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative (1) remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and

It is is not a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.(2)

(End of provision)

52.209-13 Violation of Arms Control Treaties or Agreements-Certification. 2018-06

As prescribed in 9.109-5 , insert the following provision:

VIOLATION OF ARMS CONTROL TREATIES OR AGREEMENTS-CERTIFICATION (JUN 2018)

This provision does not apply to acquisitions below the simplified acquisition threshold or to acquisitions of commercial items as defined at (a)

FAR 2.101.

. [ ](b) Certification Offeror shall check either (1) or (2).

The Offeror certifies that- ____ (1)

It does not engage and has not engaged in any activity that contributed to or was a significant factor in the President's or Secretary of (i) State's determination that a foreign country is in violation of its obligations undertaken in any arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. The determinations are described in the most recent unclassified annual report provided to Congress pursuant to section 403 of the Arms Control and Disarmament Act (22 U.S.C. 2593a). The report is available via the Internet at https://www.state.gov/t/avc/rls /rpt/; and

No entity owned or controlled by the Offeror has engaged in any activity that contributed to or was a significant factor in the (ii) President's or Secretary of State's determination that a foreign country is in violation of its obligations undertaken in any arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. The determinations are described in the most recent unclassified annual report provided to Congress pursuant to section 403 of the Arms Control and Disarmament Act (22 U.S.C. 2593a). The report is available via the Internet at https://www.state.gov/t/avc/rls/rpt/; or

The Offeror is providing separate information with its offer in accordance with paragraph (d)(2) of this provision. ____ (2)

Procedures for reviewing the annual unclassified report (see paragraph (b)(1) of this provision). For clarity, references to the report in this (c) section refer to the entirety of the annual unclassified report, including any separate reports that are incorporated by reference into the annual unclassified report.

Check the table of contents of the annual unclassified report and the country section headings of the reports incorporated by reference to (1) identify the foreign countries listed there. Determine whether the Offeror or any person owned or controlled by the Offeror may have engaged in any activity related to one or more of such foreign countries.

If there may have been such activity, review all findings in the report associated with those foreign countries to determine whether or not (2) each such foreign country was determined to be in violation of its obligations undertaken in an arms control, nonproliferation, or disarmament agreement to which the United States is a party, or to be not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. For clarity, in the annual report an explicit certification of non-compliance is equivalent to a determination of violation. However, the following statements in the annual report are not equivalent to a determination of violation:

An inability to certify compliance.(i)

An inability to conclude compliance.(ii)

A statement about compliance concerns.(iii)

If so, determine whether the Offeror or any person owned or controlled by the Offeror has engaged in any activity that contributed to or (3) is a significant factor in the determination in the report that one or more of these foreign countries is in violation of its obligations undertaken in an arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in…