Sol_140P5226R0002.pdf

(See ).

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

SOLICITATION

1. SOLICITATION NO.

5. REQUISITION/PURCHASE REQUEST NO.

CODE

6. PROJECT NO.

8. ADDRESS OFFER TO

4. CONTRACT NO.

7. ISSUED BY

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and

b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than

STANDARD FORM 1442 (REV. 12/2022)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d) calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

is, is not required.

local time containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes copies to perform the work required are due at the place specified in Item 8 by (hour) award, YES NO notice to proceed. This performance period is mandatory negotiable.

calendar days and complete it within calendar days after receiving

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

12b. CALENDAR DAYS

2. TYPE OF SOLICITATION

NEGOTIATED (RFP) REQUEST FOR PROPOSAL

3. DATE ISSUED PAGE OF

SEALED BID (IFB) INVITATION FOR BID

9. FOR

INFORMATION CALL

PAGES

140P5226R0002

NPS, SER - West MABO 2680 Natchez Trace Parkway Tupelo MS 38804

NATIONAL PARK SERVICE, DOI

Contracting Operations (ConOps) East ATTN: West MABO Contracting Officer EMAIL: evans_ward@ios.doi.gov

0044035799 PMIS 323963A

PSW

Evans Ward 8502324630

04/03/2026

05/05/2026

10 240 Section F clause 52.211-10

PLANS DRAWING NO. G000 - A520, 69 Sheets, dated 2024.04.11

SPECS DIVISION 00 - 12, 179 Pages, dated 03/19/2024

PROJECT TITLE: Modernize Natchez Maintenance Facility

PROJECT LOCATION: Natchez National Historical Park, Natchez Mississippi

PROJECT SCOPE: The principal work consist of BLDG RENOVATION: Alteration of approximately 2,415 GSF of existing office and support spaces inside an existing, non-sprinklered one-story masonry building with a

997 SF mechanical mezzanine. Demo slab on grade to accommodate new plumbing layouts for the interior reconfiguration. Two overhead coil doors are to be removed and replaced with brick to match existing and windows. Selective demolition of partitions to accommodate new partition layout. Remove existing flooring and replace with new in half the building where renovations are taking place. New mechanical and electrical to replace existing systems.

ITEM 2 ROOFING: The existing 4850 SF maintenance building roof will be repaired/replaced to include new soffits, gutters, and siding trim.

ITEM 3 ABATEMENT SUITE: excluded by Owner (NOT PART OF THIS CONTRACT).

Continued...

1 17

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement by the Government in writing within stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

OFFER (Must be fully completed by offeror)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AWARD (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

CODE FACILITY CODE

15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

21. ITEMS ACCEPTED:

22. AMOUNT

26. ADMINISTERED BY

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31c. DATE

STANDARD FORM 1442 (REV. 12/2022) BACK

31b. UNITED STATES OF AMERICA

BY

31a. NAME OF CONTRACTING OFFICER (Type or print)

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30b. SIGNATURE 30c. DATE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

23. ACCOUNTING AND APPROPRIATION DATA

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO THE UNITED STATES CODE AT

27. PAYMENT WILL BE MADE BY

10 U.S.C. 3204(a) ( ) 41 U.S.C. 3304(a) ( )

20b. SIGNATURE 20c. OFFER DATE

Continued...

AMENDMENT

NUMBER

DATE.

DOI, NPS, SER - GUIS Admin. Office 1801 Gulf Breeze Parkway Gulf Breeze FL 32563

SW1

Evans Ward

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGES

NAME OF OFFEROR OR CONTRACTOR

SUPPLIES/SERVICES

(B)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

OPTIONAL FORM 336 (4-86)

Sponsored by GSA FAR (48 CFR) 53.110

ITEM NO.

(A)

QUANTITY

(C)

NSN 7540-01-152-8067

140P5226R0002

NAICS CODE: 236220

SIZE STANDARD: $45.0 Million of Dollars

SET-ASIDE: SDVOSB Program

PROJECT MAGNITUDE: Between $500,000 and

$1,000,000

CONTRACT TYPE: Firm-Fixed Price Construction.

FACILITY: The existing Melrose maintenance facility (late 90's construction) consists of a large carpentry shop, training room, office space, break room, shower/restroom, and storage areas. This renovation project will provide ancillary space(s) for dual use by NATC FM division and Maintenance Action Team (MAT) part of the Historic Preservation Training Center

(HPTC).

REQUESTS FOR QUOTATIONS (RFQ) solicitation prepared in accordance with FAR PART 12 and

PART 36 - CONSTRUCTION policies and procedures.

The project Specifications and Drawings are incorporated by attachment in Section J and made part of the RFP packaged posted online at

SAM.gov.

SITE VISIT: An organized site visit has been scheduled for APR 9, 2026 10 AM (CDT)

Participants will meet at site of work site (45

Melrose Montebello Parkway Natchez MS)

INSTRUCTIONS (Section L) and Evaluation Factors for Award (Section M). At a minimum, quotation must include:

1. Executed SF-1442

2. Executed Bid Bond, SF-24

3. Price Schedule (Section B)

4. Executed Reps and Certs (Section K)

5. Past Performance Information on projects with similar scope and magnitude

Delivery: 240 Days After Notice to Proceed

Delivery Location Code: 0011283061

NPS, Natchez NHP

45 Melrose/Montebello Parkway

Natchez MS 39120-3801 US

00010 Natchez Maintenance Facility Renovation

Period of Performance: 06/01/2026 to

02/01/2027

A - Solicitation/Contract Form B - Supplies or Services/Prices C - Description/Specifications D - Packaging and Marking E - Inspection and Acceptance F - Deliveries or Performance G - Contract Administration Data H - Special Contract Requirements I - Contract Clauses J - List of Documents, Exhibits and Other Attachments K - Representations, Certifications, and Other Statements of Bidders L - Instructions,Conditions, and Notices to Bidders M - Evaluation Factors for Award

A - Solicitation/Contract Form

B - Supplies or Services/Prices

C - Description/Specifications

D - Packaging and Marking

E - Inspection and Acceptance

52.246-12 Inspection of Construction. (AUG 1996)

(a) Definition. Work includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not -

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) below.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer's written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The

Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may (1) by contract or otherwise, replace or correct the work and charge the cost to the Contractor or (2) terminate for default the Contractor's right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government's rights under any warranty or guarantee.

(End of clause)

F - Deliveries or Performance

52.236-15 Schedules for Construction Contracts. (APR 1984) (Deviation JAN 2026)

(a)(1) Within five days after the work commences on the contract or another period of time determined by the Contracting Officer, the Contractor shall prepare and submit to the Contracting Officer for approval a practicable schedule showing the order in which the Contractor proposes to perform the work, and the dates on which the Contractor contemplates starting and completing the work (including acquiring materials, plant, and equipment).

(2) The schedule shall be in the form of a progress chart of suitable scale to indicate appropriately the percentage of work scheduled for completion by any given date during the period.

(3) If the Contractor fails to submit a schedule within the time prescribed, the Contracting Officer may withhold approval of progress payments until the Contractor submits the required schedule.

(b) The Contractor shall continually update the actual progress in the schedule and shall submit it to the Contracting Officer by the means prescribed in the contract for transmittals or as directed by the Contracting Officer.

(c)(1) If the Contractor falls behind the approved schedule, the Contractor shall take steps necessary to recover lost time and execute in accordance with the approved schedule, without additional cost to the Government.

(2) Such steps may include increasing the number of shifts, overtime operations, days of work, and/or the amount of construction plant.

(3) The Contractor shall submit, for approval, supplementary schedule(s) that demonstrate how the lost time will be recovered.

(d) If the Contractor does not recover the lost time, the Contracting Officer may determine that the Contractor is not prosecuting the work with sufficient diligence to ensure completion within the time specified in the contract. Upon making this determination, the Contracting Officer may terminate the Contractor's right to proceed with the work, or any separable part of it, in accordance with the default terms of this contract.

(End of clause)

G - Contract Administration Data

DOI ELECTRONIC INVOICING Electronic Invoicing and Payment Requirements - Invoice Processing Platform (IPP) (February 2021)

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor.

To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions - Commercial Items included in commercial item contracts. The IPP website address is:

https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice [Payment Application and Schedule of Values documentation required under this contract]:

The Contractor must use the IPP website to register access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM) will receive enrollment instructions via email from the Federal Reserve Bank of St. Louis (FRBSTL) within 3 - 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email IPPCustomerSupport@fiscal.treasury.gov or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

(End of Local Clause)

H - Special Contract Requirements

I - Contract Clauses

52.203-6 Restrictions on Subcontractor Sales to the Government. (JUN 2020) - Alternate I (NOV 2021)

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, Proposed for Debarment, or Voluntarily Excluded. (JAN 2025)

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters. (OCT 2018)

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations. (NOV 2015)

52.222-3 Convict Labor. (JUN 2003)

52.222-4 Contract Work Hours and Safety Standards - Overtime Compensation. (MAY 2018)

52.222-7 Withholding of Funds. (MAY 2014)

52.222-8 Payrolls and Basic Records. (JUL 2021)

52.222-9 Apprentices and Trainees. (JUL 2005)

52.222-10 Compliance With Copeland Act Requirements. (FEB 1988)

52.222-13 Compliance With Construction Wage Rate Requirements and Related Regulations. (MAY 2014)

52.222-14 Disputes Concerning Labor Standards. (FEB 1988)

52.222-15 Certification of Eligibility. (MAY 2014)

52.222-35 Equal Opportunity for Veterans. (JUN 2020)

52.222-36 Equal Opportunity for Workers with Disabilities. (JUN 2020)

52.222-37 Employment Reports on Veterans. (JUN 2020)

52.222-40 Notification of Employee Rights Under the National Labor Relations Act. (DEC 2010)

52.222-50 Combating Trafficking in Persons. (OCT 2025)

52.222-54 Employment Eligibility Verification. (JAN 2025)

52.222-62 Paid Sick Leave Under Executive Order 13706. (JAN 2022)

52.223-9 Estimate of Percentage of Recovered Material Content for EPA-Designated Items. (MAY 2008)

(a) Definitions. As used in this clause-

Postconsumer material means a material or finished product that has served its intended use and has been discarded for disposal or recovery, having completed its life as a consumer item.

Postconsumer material is a part of the broader category of "recovered material."

Recovered material means waste materials and by-products recovered or diverted from solid waste, but the term does not include those materials and by-products generated from, and commonly reused within, an original manufacturing process.

(b) The Contractor, on completion of this contract, shall-

(1) Estimate the percentage of the total recovered material content for EPA-designated item(s) delivered and/or used in contract performance, including, if applicable, the percentage of post-consumer material content; and

(2) Submit this estimate to [Contracting Officer complete in accordance with agency procedures].

(End of clause)

52.223-11 Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons.

(MAY 2024)

52.223-12 Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners. (MAY 2024)

52.223-21 Foams. (MAY 2024)

52.225-5 Trade Agreements. (NOV 2023)

52.228-2 Additional Bond Security. (OCT 1997)

52.228-5 Insurance - Work on a Government Installation. (JAN 1997)

52.228-12 Prospective Subcontractor Requests for Bonds. (DEC 2022)

52.228-15 Performance and Payment Bonds - Construction. (JUN 2020)

(a) Definitions. As used in this clause -

Original contract price means the award price of the contract; or, for requirements contracts, the price payable for the estimated total quantity; or, for indefinite-quantity contracts, the price payable for the specified minimum quantity. Original contract price does not include the price of any options, except those options exercised at the time of contract award.

(b) Amount of required bonds. Unless the resulting contract price is valued at or below the threshold specified in Federal Acquisition Regulation 28.102-1(a) on the date of award of this contract, the successful offeror shall furnish performance and payment bonds to the Contracting Officer as follows:

(1) Performance bonds (Standard Form 25). The penal amount of performance bonds at the time of contract award shall be 100 percent of the original contract price.

(2) Payment Bonds (Standard Form 25-A). The penal amount of payment bonds at the time of contract award shall be 100 percent of the original contract price.

(3) Additional bond protection. (i) The Government may require additional performance and payment bond protection if the contract price is increased. The increase in protection generally will equal 100 percent of the increase in contract price.

(ii) The Government may secure the additional protection by directing the Contractor to increase the penal amount of the existing bond or to obtain an additional bond.

(c) Furnishing executed bonds. The Contractor shall furnish all executed bonds, including any necessary reinsurance agreements, to the Contracting Officer, within the time period specified in the Bid Guarantee provision of the solicitation, or otherwise specified by the Contracting Officer, but in any event, before starting work.

(d) Surety or other security for bonds. The bonds shall be in the form of firm commitment, supported by corporate sureties whose names appear on the list contained in Treasury Department Circular 570, individual sureties, or by other acceptable security such as postal money order, certified check, cashier's check, irrevocable letter of credit, or, in accordance with Treasury Department regulations, certain bonds or notes of the United States. Treasury Circular 570 is published in the Federal Register or may be obtained from the U.S. Department of the Treasury, Financial Management Service, Surety Bond Branch, 3700 East West Highway, Room 6F01, Hyattsville, MD 20782. Or via the internet at http://www.fms.treas.gov/c570/.

(e) Notice of subcontractor waiver of protection (40 U.S.C. 3133(c)). Any waiver of the right to sue on the payment bond is void unless it is in writing, signed by the person whose right is waived, and executed after such person has first furnished labor or material for use in the performance of the contract.

(End of clause)

52.233-3 Protest After Award. (AUG 1996)

52.233-4 Applicable Law for Breach of Contract Claim. (OCT 2004)

1452.228-70 Liability Insurance (JUL 1996)

(a) The Contractor shall procure and maintain during the term of this contract and any extension thereof liability insurance in form satisfactory to the Contracting Officer by an insurance company which is acceptable to the Contracting Officer. The named insured parties under the policy shall be the Contractor and the United States of America. The amounts of the insurance shall be not less than as follows:

$750,000.00 each person*

$1,000,000.00 each occurrence*

$500,000.00 property damage*

(b) Each policy shall have a certificate evidencing the insurance coverage. The insurance company shall provide an endorsement to notify the Contracting Officer 30 days prior to the effective date of cancellation or termination of the policy or certificate; or modification of the policy or certificate which may adversely affect the interest of the Government in such insurance. The certificate shall identify the contract number, the name and address of the Contracting Officer, as well as the insured, the policy number and a brief description of contract services to be performed.

The contractor shall furnish the Contracting Officer with a copy of an acceptable insurance certificate prior to beginning the work.

*These amounts to be set by the Contracting Officer.

(End of clause)

52.223-23 52.223-23, Sustainable Products and Services (MAY 2024) (DEVIATION FEB 2025)

52.244-6 Subcontracts for Commercial Products and Commercial Services (Jan 2025) (DEVIATION

FEB 2025)

52.203-12 Limitation on Payments to Influence Certain Federal Transactions. (JUN 2020)

52.204-13 System for Award Management-Maintenance. (OCT 2018) (Deviation Effective Date)

52.204-14 Service Contract Reporting Requirements. (OCT 2016) (Deviation Effective Date)

52.204-19 Incorporation by Reference of Representations and Certifications. (DEC 2014)

52.212-4 Terms and Conditions-Commercial Products and Commercial Services. (NOV 2023) (Deviation Effective Date)

52.219-14 Limitations on Subcontracting. (OCT 2022) (Deviation JAN 2026)

(a) This clause does not apply to the unrestricted portion of a partial set-aside.

(b) Definition. Similarly situated entity, as used in this clause, means a first-tier subcontractor, including an independent contractor, that-

(1) Has the same small business program status as that which qualified the prime contractor for the award (e.g., for a small business set-aside contract, any small business concern, without regard to its socioeconomic status); and

(2) Is considered small for the size standard under the North American Industry Classification System (NAICS) code the prime contractor assigned to the subcontract.

(c) Applicability. This clause applies only to-

(1) Contracts that have been set aside for any of the small business concerns identified in 19.000(a)(3);

(2) Part or parts of a multiple-award contract that have been set aside for any of the small business concerns identified in 19.000(a)(3);

(3) Contracts that have been awarded on a sole-source basis in accordance with sections 19.105, 19.106, 19.107, and 19.108;

(4) Orders expected to exceed the simplified acquisition threshold and that are set aside for small business concerns under multiple-award contracts, as described in 8.4 and 16.5;

(5) Orders, regardless of dollar value, that are set aside in accordance with sections 19.105, 19.106, 19.107, and 19.108 under multiple-award contracts, as described in 8.4 and 16.5; and

(6) Contracts using the HUBZone price evaluation preference to award to a HUBZone small business concern unless the concern waived the evaluation preference.

(d) Independent contractors. An independent contractor shall be considered a subcontractor.

(e) By submission of an offer and execution of a contract, the Contractor agrees that in performance of a contract assigned a North American Industry Classification System (NAICS) code for-

(1) Services (except construction), it will not pay more than 50 percent of the amount paid by the Government for contract performance to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor's 50 percent subcontract amount that cannot be exceeded.

When a contract includes both services and supplies, the 50 percent limitation shall apply only to the service portion of the contract;

(2) Supplies (other than procurement from a nonmanufacturer of such supplies), it will not pay more than 50 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor's 50 percent subcontract amount that cannot be exceeded.

When a contract includes both supplies and services, the 50 percent limitation shall apply only to the supply portion of the contract;

(3) General construction, it will not pay more than 85 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor's 85 percent subcontract amount that cannot be exceeded; or

(4) Construction by special trade contractors, it will not pay more than 75 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor's 75 percent subcontract amount that cannot be exceeded.

(f) The Contractor shall comply with the limitations on subcontracting as follows:

(1) For contracts, in accordance with paragraphs (c)(1), (2), (3) and (6) of this clause-

[Contracting Officer check as appropriate.]

[X] By the end of the base term of the contract and then by the end of each subsequent option period; or

[ ] By the end of the performance period for each order issued under the contract.

(2) For orders, in accordance with paragraphs (c)(4) and (5) of this clause, by the end of the performance period for the order.

(g) A joint venture agrees that, in the performance of the contract, the applicable percentage specified in paragraph (e) of this clause will be performed by the aggregate of the joint venture participants.

(1) In a joint venture comprised of a small business protégé and its mentor approved by the Small Business Administration, the small business protégé shall perform at least 40 percent of the work performed by the joint venture. Work performed by the small business protégé in the joint venture must be more than administrative functions.

(2) In an 8(a) joint venture, the 8(a) participant(s) shall perform at least 40 percent of the work performed by the joint venture. Work performed by the 8(a) participants in the joint venture must be more than administrative functions.

(End of clause)

52.219-27 Notice of Set-Aside for, or Sole-Source Award to, Service-Disabled Veteran-Owned Small Business (SDVOSB) Concerns Eligible Under the SDVOSB Program. (FEB 2024) (Deviation JAN 2026)

52.222-12 Contract Termination - Debarment. (MAY 2014)

52.222-13 Compliance With Construction Wage Rate Requirements and Related Regulations. (MAY 2014)

52.222-14 Disputes Concerning Labor Standards. (FEB 1988)

52.222-15 Certification of Eligibility. (MAY 2014)

52.226-8 Encouraging Contractor Policies To Ban Text Messaging While Driving. (MAY 2024)

52.232-5 Payments Under Fixed-Price Construction Contracts. (MAY 2014)

52.232-33 Payment by Electronic Funds Transfer - System for Award Management. (OCT 2018)

52.232-40 Providing Accelerated Payments to Small Business Subcontractors. (MAR 2023)

52.236-2 Differing Site Conditions. (APR 1984) (Deviation JAN 2026)

52.236-3 Site Investigation and Conditions Affecting the Work. (APR 1984) (Deviation JAN 2026)

52.236-5 Material and Workmanship. (APR 1984) (Deviation JAN 2026)

52.236-6 Superintendence by the Contractor. (APR 1984) (Deviation JAN 2026)

52.236-7 Permits and Responsibilities. (NOV 1991) (Deviation JAN 2026)

52.236-8 Other Contracts. (APR 1984) (Deviation JAN 2026)

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements.

(APR 1984) (Deviation JAN 2026)

52.236-10 Operations and Storage Areas. (APR 1984) (Deviation JAN 2026)

52.236-11 Use and Possession Prior to Completion. (APR 1984) (Deviation JAN 2026)

52.236-12 Cleaning Up. (APR 1984) (Deviation JAN 2026)

52.236-13 Accident Prevention. (NOV 1991) (Deviation JAN 2026) - Alternate I (NOV 1991)

(a) The Contractor shall provide and maintain work environments and procedures that-

(1) Safeguard the public and Government personnel, property, materials, supplies, and equipment exposed to Contractor operations and activities;

(2) Avoid interruptions of Government operations and delays in project completion dates;

and

(3) Control costs in the performance of this contract.

(b) In addition, for contracts for construction or dismantling, demolition, or removal of improvements, the Contractor shall-

(1) Provide appropriate safety barricades, signs, and signal lights;

(2) Comply with the standards issued by the Secretary of Labor at 29 CFR part 1926 and 29 CFR part 1910; and

(3) Ensure that any additional measures the Contracting Officer determines to be reasonably necessary for the purposes are taken.

(c) If this contract is for construction or dismantling, demolition or removal of improvements with any Department of Defense agency or component, the Contractor shall comply with all pertinent provisions of the latest version of U.S. Army Corps of Engineers Safety and Health Requirements Manual, EM 385-1-1, in effect on the date of the solicitation.

(d)(1) If the Contracting Officer becomes aware of any noncompliance with these requirements or any condition that poses a serious or imminent danger to the health or safety of the public or Government personnel, the Contracting Officer will notify the Contractor orally, with written confirmation, and request immediate initiation of corrective action.

(2) This notice, when delivered to the Contractor or the Contractor's representative at the work site, shall be deemed sufficient notice of the noncompliance and that corrective action is required.

(3) After receiving the notice, the Contractor shall immediately take corrective action.

(4) If the Contractor fails or refuses to promptly take corrective action, the Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken.

(5) The Contractor shall not be entitled to any equitable adjustment of the contract price or extension of the performance schedule on any stop-work order issued under this clause.

(e) The Contractor shall insert the substance of this clause, including this paragraph (e), in subcontracts.

(f) Before commencing the work, the Contractor shall-

(1) Submit a written proposed plan for implementing this clause. The plan shall include an analysis of the significant hazards to life, limb, and property inherent in contract work performance and a plan for controlling these hazards; and

(2) Meet with representatives of the Contracting Officer to discuss and develop a mutual understanding relative to administration of the overall safety program.

(End of clause)

52.236-14 Availability and Use of Utility Services. (APR 1984) (Deviation JAN 2026)

J - List of Documents, Exhibits and Other Attachments

Attachment Number Title Date

01 DWG GENERAL 03/14/2024

02 DWG - ARCHITECTURAL 03/14/2024

03 DWG - STRUCTURAL 03/14/2024

04 DWG - MECHANICAL 03/14/2024

05 DWG - PLUMBING 03/14/2024

06 DWG - ELECTRICAL 03/14/2024

07 DWG - FIRE ALARM 03/14/2024

08 DWG - COMPLETE SET 03/14/2024

09 SPECS 03/14/2024

10 WAGE DETERMINATIONS 01/02/2026

11 CONTRACT PRICE SCHEDULE 03/07/2024

K - Representations, Certifications, and Other Statements of Bidders

52.225-6 Trade Agreements Certificate. (FEB 2021)

52.225-25 Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-Representation and Certifications. (JUN 2020)

52.203-11 Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. (SEP 2024)

52.223-4 Recovered Material Certification. (MAY 2008)

L - Instructions,Conditions, and Notices to Bidders

52.222-5 Construction Wage Rate Requirements-Secondary Site of the Work. (MAY 2014)

52.225-7 Waiver of Buy American Statute for Civil Aircraft and Related Articles. (FEB 2016)

52.228-1 Bid Guarantee. (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

(c) The amount of the bid guarantee shall be 20 percent of the bid price or 3,000,000.00, whichever is less.

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

(End of provision)

52.236-27 Site Visit (Construction). (FEB 1995) - Alternate I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigation and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for -

APR 9. 2026

(c) Participants will meet at -

SITE OF WORK at 45 Melrose Montebello Parkway Natchez MS

(End of provision)

52.204-7 System for Award Management-Registration. (NOV 2024) (Deviation Effective Date)

52.212-1 Instructions to Offerors-Commercial Products and Commercial Services. (SEP 2023) (Deviation Effective Date)

(a) Submission of offers. Submit signed and dated offers to the office specified in this solicitation at or before the exact time specified in this solicitation. As a minimum, offers shall include-

(1) The solicitation number;

(2) The name, address, telephone number of the Offeror;

(3) The Offeror's Unique Entity Identifier (UEI) and, if applicable, Electronic Funds Transfer (EFT) indicator;

(4) Information necessary to evaluate the factors contained in the provision at 52.212-2 or as described in the solicitation;

(5) Responses to provisions that require Offeror completion of information, representations, and certifications (other than those collected via the System for Award Management (SAM)); and

(6) A statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation and any solicitation amendments.

(b) Period for acceptance of offers. The Offeror agrees to hold the prices in its offer firm for 60 calendar days from the date specified for receipt of offers, unless another time period is specified in an addendum to the solicitation.

(c) Late submissions, modifications, revisions, and withdrawals of offers.

(1) Offerors are responsible for submitting offers and any modifications or revisions to the Government office designated in the solicitation by the time specified in the solicitation.

(2) Any offer, modification, or revision received after the time specified for receipt of offers is "late" and will not be considered unless it is received before award is made and the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition. However, a late modification of an otherwise successful offer that makes its terms more favorable to the Government will be considered at any time it is received and may be accepted.

(3) If an emergency or unanticipated event interrupts normal Government processes so that offers cannot be received at the Government office designated for receipt of offers by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation or other notice of an extension of the closing date, the time specified for receipt of offers will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(4) Offerors may withdraw their offers by written notice to the Government received at any time before award.

(d) Contract award (not applicable to Invitation for Bids). The Government intends to evaluate offers and award a contract without discussions with Offerors. Therefore, the Offeror's initial offer should contain the Offeror's best terms. However, the Government reserves the right to conduct discussions, if necessary. The Government may reject any or all offers if such action is in the public interest, accept other than the lowest offer, and waive informalities and minor irregularities in offers received.

(e) Debriefings. If a postaward debriefing is given to requesting Offerors, the Government will disclose the following information, if applicable:

(1) The agency's evaluation of the significant weak or deficient factors in the debriefed Offeror's offer.

(2) The overall evaluated cost or price and technical rating of the successful Offeror and the debriefed Offeror and past performance information on the debriefed Offeror.

(3) The overall ranking of all Offerors when any ranking was developed by the agency during source selection.

(4) A summary of the rationale for award.

(5) For acquisitions of commercial products, the make and model of the product to be delivered by the successful Offeror.

(6) Reasonable responses to relevant questions posed by the debriefed Offeror as to whether the agency followed source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities.

(End of provision)

M - Evaluation Factors for Award

52.212-2 Evaluation-Commercial Products and Commercial Services. (NOV 2021) (Deviation Effective Date)

(a) Evaluation factors. The Government will award a contract resulting from this solicitation to the responsible Offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors will be used to evaluate offers:

FACTOR 1 - PAST PERFORMANCE

FACTOR 2 - PRICE

(b) Options (if applicable). The Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. The Government may determine that an offer is unacceptable if the option prices are significantly unbalanced. The evaluation of options does not obligate the Government to exercise the option(s).

(c) Notice of award. A written notice of award or acceptance of an offer furnished to the successful Offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer's specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

(End of provision)

EVALUATION FACTORS

Factor 1: Past Performance Subfactor 1: Relevant Experience Relevant experience is defined as successful performance on projects involving:

• Building renovation, modernization, or rehabilitation

• Comparable scope, complexity, and operational impact

• Work in occupied or operational facilities

• Coordination of multiple construction trades

• Implementation of effective quality control systems

• Schedule management and on-time completion

• Minimization of disruption to ongoing operations

Relevancy Standards:

• Highly Relevant: Projects closely matching scope, complexity, and operational constraints (e.g., occupied renovations with multiple trades and strict scheduling)

• Relevant: Similar renovation/construction projects with some comparable elements

• Somewhat Relevant: General construction projects with limited similarity

• Not Relevant: Projects lacking similarity in scope or complexity

Factor 2: Price Price proposals will be evaluated for:

• Reasonableness

• Completeness

The contracting officer must determine the price to be fair and reasonable. Price analysis techniques may include.

Comparison of proposed prices received in response to the solicitation Comparison of proposed prices with independent Government cost estimates Analysis of data other than certified cost or pricing data provided by the offeror

Offeror phone number

Standard form 1442 backside

Sponsored by GSA FAR (48 CFR) 53.110