Solicitation_clauses.docx

TABLE OF CONTENTS

PART I – The Schedule

52.246-12 Inspection of Construction

52.211-10 Commencement, Prosecution, and Completion of Work

52.211-12 Liquidated Damages—Construction

52.211-13 Time Extensions

52.242-14 Suspension of Work

1452.201-70 Authorities and Delegations

1452.204-70 Release of Claims

DIAPR 2010-14 Contractor Performance Assessment Reporting System

DIAPR 2011-04 Electronic Invoicing and Payment Requirements – Internet Payment Platform (IPP)

Special Clause 1: Option for Additional Services—Separately Priced Line Items

Special Clause 2: Key Personnel

PART II – Contract Clauses

52.202-1 Definitions

52.203-3 Gratuities

52.203-5 Covenant Against Contingent Fees

52.203-7 Anti-Kickback Procedures

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity

52.203-10 Price or Fee Adjustment for Illegal or Improper Activity

52.203-12 Limitation on Payments to Influence Certain Federal Transactions

52.203-13 Contractor Code of Business Ethics and Conduct

52.203-14 Display of Hotline Poster(s)

52.203-17 Contractor Employee Whistleblower Rights and Requirement to Inform Employees of Whistleblower Rights

1452.203-70 Restriction on Endorsements—Department of the interior

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

52.204-9 Personal Identity Verification of Contractor Personnel

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards

52.204-13 System for Award Management Maintenance

52.204-14 Service Contract Reporting Requirements

52.209-6 Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters

52.209-10 Prohibition on Contracting with Inverted Domestic Corporations (Dec 2014)

52.210-1 Market Research

52.215-2 Audit and Records—Negotiation

1452.215-70 Examination of Records by the Department of the Interior

52.215-8 Order of Precedence—Uniform Contract Format

52.215-11 Price Reduction for Defective Certified Cost or Pricing Data—Modifications

52.215-13 Subcontractor Certified Cost or Pricing Data—Modifications

52.215-15 Pension Adjustments and Asset Reversions

52.215-17 Waiver of Facilities Capital Cost of Money

52.215-18 Reversion or Adjustment of Plans for Postretirement Benefits (PRB) Other Than Pensions

52.215-19 Notification of Ownership Changes

52.215-21 Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data—Modifications

52.219-8 Utilization of Small Business Concerns

52.219-28 Post-Award Small Business Program Rerepresentation

52.222-3 Convict Labor

52.222-4 Contract Work Hours and Safety Standards—Overtime Compensation

52.222-6 Construction Wage Rate Requirements

52.222-7 Withholding of Funds

52.222-8 Payrolls and Basic Records

52.222-9 Apprentices and Trainees

52.222-10 Compliance with Copeland Act Requirements

52.222-11 Subcontracts (Labor Standards)

52.222-12 Contract Termination—Debarment

52.222-13 Compliance with Construction Wage Rate Requirements and Related Regulations

52.222-14 Disputes Concerning Labor Standards

52.222-15 Certification of Eligibility

52.222-21 Prohibition of Segregated Facilities

52.222-26 Equal Opportunity

52.222-27 Affirmative Action Compliance Requirements for Construction

52.222-35 Equal Opportunity for Veterans

52.222-36 Equal Opportunity for Workers with Disabilities

52.222-37 Employment Reports on Veterans

52.222-40 Notification of Employee Rights Under the National Labor Relations Act

52.222-50 Combating Trafficking in Persons

52.222-54 Employment Eligibility Verification

52.222-55 Minimum Wages Under Executive order 13658 (Dec 2014)

52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts

52.223-3 Hazardous Material Identification and Material Safety Data—Alternate I

52.223-5 Pollution Prevention and Right-to-Know Information

52.223-6 Drug-Free Workplace

52.223-9 Estimate of Percentage of Recovered Material Content for EPA- Designated Products

52.223-15 Energy Efficiency in Energy-Consuming Products

52.223-17 Affirmative Procurement of EPA-designated Items in Service and Construction Contracts

52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving

52.224-1 Privacy Act Notification

52.224-2 Privacy Act

52.225-9 Buy American—Construction Materials

52.225-10 Notice of Buy American Requirement – Construction Materials

52.225-13 Restrictions on Certain Foreign Purchases

52.227-1 Authorization and Consent

52.227-2 Notice and Assistance Regarding Patent and Copyright Infringement

52.227-4 Patent Indemnity—Construction Contracts

52.227-17 Rights in Data – Special Works

52.228-1 Bid Guarantee

52.228-2 Additional Bond Security

52.228-5 Insurance—Work on a Government Installation

1452.228-70 Liability Insurance—Department of the Interior

52.228-11 Pledges of Assets

52.228-12 Prospective Subcontractor Requests for Bonds

52.228-14 Irrevocable Letter of Credit

52.228-15 Performance and Payment Bonds—Construction

52.229-3 Federal, State, and Local Taxes

52.232-5 Payments under Fixed-Price Construction Contracts

52.232-17 Interest

52.232-23 Assignment of Claims

52.232-27 Prompt Payment for Construction Contracts

52.232-33 Payment by Electronic Funds Transfer—System for Award Management

52.232-39 Unenforceability of Unauthorized Obligations

52.232-40 Providing Accelerated Payments to Small Business Subcontractors

52.233-1 Disputes—Alternate I

52.233-3 Protest after Award

52.233-4 Applicable Law for Breach of Contract Claim

52.236-1 Performance of Work by the Contractor

52.236-2 Differing Site Conditions

52.236-3 Site Investigation and Conditions Affecting the Work

52.236-4 Physical Data

52.236-5 Material and Workmanship

52.236-6 Superintendence by the Contractor

52.236-7 Permits and Responsibilities

52.236-8 Other Contracts

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

52.236-10 Operations and Storage Areas

52.236-11 Use and Possession Prior to Completion

52.236-12 Cleaning Up

52.236-13 Accident Prevention

52.236-14 Availability and Use of Utility Services

52.236-15 Schedules for Construction Contracts

52.236-21 Specifications and Drawings for Construction

52.236-26 Preconstruction Conference

1452.236-70 Prohibition Against Use of Lead-based Paint

52.242-13 Bankruptcy

52.243-4 Changes

52.244-6 Subcontracts for Commercial Items

52.246-21 Warranty of Construction

52.248-3 Value Engineering—Construction

52.249-2 Termination for Convenience of the Government (Fixed-Price)—Alternate I

52.249-10 Default (Fixed-Price Construction)

52.253-1 Computer Generated Forms

PART III – List of Documents, Exhibits, and Other Attachments

PART IV – Representations and Instructions

52.204-8 Annual Representations and Certifications

52.204-17 Ownership or Control of Offeror (Nov 2014) 52.204-19 Incorporation by Reference of Representations and Certifications (Dec 2014)

52.204-19 Incorporation by Reference of Representations and Certifications (Dec 2014)

52.209-2 Prohibition on Contracting with Inverted Domestic Corporations -- Representation

52.209-7 Information Regarding Responsibility Matters

52.236-28 Preparation of Proposals -- Construction

Instructions for the Submission of Offers and Other Information

52.204-7 System for Award Management

52.204-16 Commercial and Government Entity Code Reporting (Nov 2014)

52.204-18 Commercial and Government Entity Code Maintenance (Nov 2014)

52.211-6 Brand Name or Equal

52.215-1 Instructions to Offerors1—Competitive

52.215-16 Facilities Capital Cost of Money

52.215-20 Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data

1452.215-71 Use and Disclosure of Proposal Information—Department of the Interior

52.216-1 Type of Contract

52.222-5 Construction Wage Rate Requirements—Secondary Site of the Work

52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction

1452.233-2 Service of Protest Department of the Interior (JUL 1996) (Deviation)

52.236-26 – Preconstruction Conference

52.236-27 Site Visit (Construction

52.236-27 Site Visit (Construction)—Alternate I

52.252-5 Authorized Deviations in Provisions

Significant Factors and Subfactors

Special Provision 2: Evaluation of Options

SECTION B – SUPPLIES OR SERVICES AND PRICES

CONTRACT PRICE SCHEDULE

SOLICITATION NUMBER: P15PS00437

PARK - PMIS: YOSE - 154910C

DEVELOPED AREA: Yosemite Valley

PROJECT TITLE: Correct Critical Safety Hazards and Rehabilitate The Ahwahnee Hotel NHL

Notice: Refer to FAR Clause 52.217-5, Evaluation of Options, as prescribed in FAR 17. Offerors are required to submit, at a minimum, an offer that conforms to the solicitation documents with pricing for Base line items and all option line items. Failure to do so may render the proposal unacceptable. On lump-sum line items, provide the total price only. For all unit-priced line items, provide the unit price and the extended total price. If no specific line item exists for a portion of the work, include the costs in a related item. In case of error in calculation of extended prices, the unit price governs. In case of error in summation, the total of the corrected amounts govern. Round totals and extended prices to whole dollars. The Government reserves the right to award any or no options at or after the time of award. At the option of the Government, the period for exercise of options at the proposed prices shall extend 60 calendar days from the date of award. Pricing will be evaluated based on what is determined to be the best value to the Government. Options may be exercised in any, order deemed in the judgment of the Contracting Officer to offer the best value to the Government.

TOTAL BASE PRICE (Contract Line Item Number 1 through 4) ------------------------------------

TOTAL PRICE FOR ALL OPTIONS (Contract Line Item Number 5 through 6) ------------------------------------

TOTAL PROPOSED PRICE - BASE PLUS ALL OPTIONS (Contract Line Item Numbers 1 through 6) -----------

All measurement and payment information is included in the project specifications, Section 012700.

SECTION C – DESCRIPTIONS/SPECIFICATIONS/STATEMENT OF WORK

A. Project Location: Yosemite Valley, Yosemite National Park, California.

B. The Work consists of the following: The Work includes correction of accessibility and fire safety egress issues at The Ahwahnee. The project is comprised of the following measures:

1. Replacement of the existing non-code compliant exit stairway serving the East Wing of the hotel.

2. Remodeling of four guest rooms on the First Floor and Second Floor East Wing to add two (2) accessible guest suites, one (1) with accessible outdoor balcony.

3. Provision of an elevator providing accessibility from the Ground Floor to the Mezzanine Level meeting rooms.

4. Rehabilitation and remodeling of the Ahwahnee Bar and its existing non-original service additions at the east end of the Ground Floor, including construction of a new Bar Kitchen.

Specifications and Drawings are included as attachments and becomes part of this project. All work on this project shall be in compliance with the Specifications and Drawings. See Section J for list of attachments .

SECTION D – PACKAGING AND MARKING

P15PS00437

Document Title YOSE-154910C-Correct Critical Safety Hazards & Rehabilitate the Ahwahnee Hotel NHL

SECTION E – INSPECTION AND ACCEPTANCE

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

(a) Definition. “Work” includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not—

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer’s written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may—

(1) By contract or otherwise, replace or correct the work and charge the cost to the Contractor; or

(2) Terminate for default the Contractor’s right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government’s rights under any warranty or guarantee.

SECTION F – DELIVERIES OR PERFORMANCE

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 15 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than July 29, 2016. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 LIQUIDATED DAMAGES—CONSTRUCTION (SEPT 2000)

If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government for each calendar day of delay until the work is completed or accepted.

Liquidated damages shall be assessed in the following amounts:

1. LU/LA Elevator Installation (South Wing): The Colonial Room, Tudor Lounge, Tresidder Room and Solarium will be closed for installation of the LU/LA Elevator, beginning February 8, 2016. A closure of 14 weeks is anticipated with Beneficial Occupancy by May 20, 2016. Liquidated Damages for this work is $500/day.

2. Ahwahnee Bar (East Wing): The Ahwahnee Bar will be closed for demolition and construction of improvements to the bar and seating area, beginning January 4, 2016. A closure of 14 weeks is anticipated with Beneficial Occupancy by April 15, 2016. The bar will then reopen for limited service until the bar kitchen is complete. Liquidated Damages for this work is $1,000/day.

3. Ahwahnee Bar Kitchen (East Wing): The Ahwahnee Bar Kitchen will be closed for demolition and construction of a new kitchen, beginning January 4, 2016. A closure of 29 weeks is anticipated with Beneficial Occupancy by July 29, 2016. Liquidated damages for this work is $1,000/day.

4. Accessible Guest Rooms (East Wing): Guest Rooms at the east end of the East Wing will be closed for demolition and construction of two new guest suites and an interior egress stair, beginning January 4, 2016. A closure of 21 weeks is anticipated with Beneficial Occupancy by May 27, 2016. Liquidated damages for this work is $500/day.

(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.211-13 TIME EXTENSIONS (SEPT 2000)

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule. (End of clause)

52.242-14 SUSPENSION OF WORK (APR 1984)

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting Officer’s failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed—

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

(End of clause)

SECTION G – CONTRACT ADMINISTRATION DATA

1452.201-70 AUTHORITIES AND DELEGATIONS (SEPT 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award. The COR will be responsible for technical monitoring of the contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor. Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum. The Contractor need not proceed with direction that it considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's appointment, within 3 days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30 days to any notice made under paragraph (d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor's risk. (End of clause)

1452.204-70 RELEASE OF CLAIMS—DEPARTMENT OF THE INTERIOR (JUL 1996)

After completion of work and prior to final payment, the Contractor shall furnish the Contracting Officer with a release of claims against the United States relating to this contract. The Release of Claims form (DI–137) shall be used for this purpose. The form provides for exception of specified claims from operation of the release. (End of clause)

DIAPR 2010-14 CONTRACTOR PERFORMANCE ASSESSMENT REPORTING SYSTEM (JUL 2010)

(a) FAR 42.1502 directs all Federal agencies to collect past performance information on contracts. The Department of the Interior (DOI) has implemented the Contractor Performance Assessment Reporting System (CPARS) to comply with this regulation. One or more past performance evaluations will be conducted in order to record your contract performance as required by FAR 42.15.

(b) The past performance evaluation process is a totally paperless process using CPARS. CPARS is a web-based system that allows for electronic processing of the performance evaluation report. Once the report is processed, it is available in the Past Performance Information Retrieval System (PPIRS) for Government use in evaluating past performance as part of a source selection action.

(c) We request that you furnish the Contracting Officer with the name, position title, phone number, and email address for each person designated to have access to your firm's past performance evaluation(s) for the contract no later than 30 days after award. Each person granted access will have the ability to provide comments in the Contractor portion of the report and state whether or not the Contractor agrees with the evaluation, before returning the report to the Assessing Official. The report information must be protected as source selection sensitive information not releasable to the public.

(d) When your Contractor Representative(s) (Past Performance Points of Contact) are registered in CPARS, they will receive an automatically-generated email with detailed login instructions. Further details, systems requirements, and training information for CPARS is available at http://www.cpars.gov. The CPARS User Manual, registration for On Line Training for Contractor Representatives, and a practice application may be found at this site.

(e) Within 60 days after the end of a performance period, the Contracting Officer will complete an interim or final past performance evaluation and the report will be accessible at http://www.cpars.gov. Contractor Representatives may then provide comments in response to the evaluation, or return the evaluation without comment. Comments are limited to the space provided in Block 22. Your comments should focus on objective facts in the Assessing Official's narrative and should provide your views on the causes and ramifications of the assessed performance. In addition to the ratings and supporting narratives, blocks 1 - 17 should be reviewed for accuracy, as these include key fields that will be used by the Government to identify your firm in future source selection actions. If you elect not to provide comments, please acknowledge receipt of the evaluation by indicating "No comment" in Block 22, and then signing and dating Block 23 of the form. Without a statement in Block 22, you will be unable to sign and submit the evaluation back to the Government. If you do not sign and submit the CPAR within 30 days, it will automatically be returned to the Government and will be annotated: "The report was delivered/received by the contractor on (date). The contractor neither signed nor offered comment in response to this assessment." Your response is due within 30 calendar days after receipt of the CPAR.

(f) The following guidelines apply concerning your use of the past performance evaluation:

(g) If you wish to discuss a past performance evaluation, you should request a meeting in writing to the Contracting Officer no later than seven days following your receipt of the evaluation. The meeting will be held in person or via telephone or other means during your 30-day review period.

(h) A copy of the completed past performance evaluation will be available in CPARS for your viewing and for Government use supporting source selection actions after it has been finalized. (End of Local Clause) DIAPR 2011-04 Electronic Invoicing and Payment Requirements – Internet Payment Platform (IPP) (APR 2013) Payment requests must be submitted electronically through the U.S. Department of the Treasury’s Internet Payment Platform System (IPP).

“Payment request” means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions – Commercial Items included in commercial item contracts, The IPP website address is: https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice:

Pay Estimate Form and Current Schedule of Values)

The Contractor must use the IPP website to register, access, and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM) will receive enrollment instructions via email from the Federal Reserve Bank of Boston (FRBB) within 3 – 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

(End of Local Clause)

SECTION H – SPECIAL CONTRACT REQUIREMENTS

SPECIAL CLAUSE 1: OPTION FOR ADDITIONAL SERVICES—SEPARATELY PRICED LINE ITEMS

The Government may require the delivery of the numbered line items identified in the Schedule as option items at the price stated in the Schedule. The Contracting Officer may unilaterally exercise the option by written notice to the Contractor within 60 days after contract award. Performance of added line item tasks shall be at the price negotiated in the contract Schedule. (End of clause)

SPECIAL CLAUSE 2: KEY PERSONNEL

(a) The Contractor shall assign to this contract the following key personnel:

Project Managers Superintendent (Prime Contractor) Quality Control Managers Safety Managers / Site Safety and Health officer

(b) During the first 120 days of performance, the Contractor shall make no substitutions of key personnel unless the substitution is necessitated by illness, death, or termination of employment. The Contractor shall notify the Contracting Officer within 15 calendar days after the occurrence of any of these events and provide the information required by paragraph (c) below. After the initial 120 day period, the Contractor shall submit the information required by paragraph (c) to the Contracting Officer at least 15 days prior to making any permanent substitutions.

(c) The Contractor shall provide a detailed explanation of the circumstances necessitating the proposed substitutions, complete resumes for the proposed substitutes, and any additional information requested by the Contracting Officer. Proposed substitutes should have comparable qualifications to those of the persons being replaced. The Contracting Officer will notify the Contractor within 15 calendar days after receipt of all required information of the decision on substitutions. This clause will be modified to reflect any approved changes of key personnel. (End of clause)

SECTION I – CONTRACT CLAUSES

52.202-1 DEFINITIONS (NOV 2013)

When a solicitation provision or contract clause uses a word or term that is defined in the Federal Acquisition Regulation (FAR), the word or term has the same meaning as the definition in FAR 2.101 in effect at the time the solicitation was issued, unless—

(a) The solicitation, or amended solicitation, provides a different definition;

(b) The contracting parties agree to a different definition;

(c) The part, subpart, or section of the FAR where the provision or clause is prescribed provides a different meaning; or

(d) The word or term is defined in FAR Part 31, for use in the cost principles and procedures. (End of clause)

52.203-3 GRATUITIES (APR 1984)

(a) The right of the Contractor to proceed may be terminated by written notice if, after notice and hearing, the agency head or a designee determines that the Contractor, its agent, or another representative—

(1) Offered or gave a gratuity (e.g., an entertainment or gift) to an officer, official, or employee of the Government; and

(2) Intended, by the gratuity, to obtain a contract or favorable treatment under a contract.

(b) The facts supporting this determination may be reviewed by any court having lawful jurisdiction.

(c) If this contract is terminated under paragraph (a) of this clause, the Government is entitled—

(1) To pursue the same remedies as in a breach of the contract; and

(2) In addition to any other damages provided by law, to exemplary damages of not less than 3 nor more than 10 times the cost incurred by the Contractor in giving gratuities to the person concerned, as determined by the agency head or a designee. (This paragraph (c)(2) is applicable only if this contract uses money appropriated to the Department of Defense.)

(d) The rights and remedies of the Government provided in this clause shall not be exclusive and are in addition to any other rights and remedies provided by law or under this contract. (End of clause)

52.203-5 COVENANT AGAINST CONTINGENT FEES (MAY 2014)

(a) The Contractor warrants that no person or agency has been employed or retained to solicit or obtain this contract upon an agreement or understanding for a contingent fee, except a bona fide employee or agency. For breach or violation of this warranty, the Government shall have the right to annul this contract without liability or, to deduct from the contract price or consideration, or otherwise recover, the full amount of the contingent fee.

(b) “Bona fide agency,” as used in this clause, means an established commercial or selling agency, maintained by a contractor for the purpose of securing business, that neither exerts nor proposes to exert improper influence to solicit or obtain Government contracts nor holds itself out as being able to obtain any Government contract or contracts through improper influence.

“Bona fide employee,” as used in this clause, means a person, employed by a contractor and subject to the contractor’s supervision and control as to time, place, and manner of performance, who neither exerts nor proposes to exert improper influence to solicit or obtain Government contracts nor holds out as being able to obtain any Government contract or contracts through improper influence.

“Contingent fee,” as used in this clause, means any commission, percentage, brokerage, or other fee that is contingent upon the success that a person or concern has in securing a Government contract.

“Improper influence,” as used in this clause, means any influence that induces or tends to induce a Government employee or officer to give consideration or to act regarding a Government contract on any basis other than the merits of the matter. (End of clause)

52.203-7 ANTI-KICKBACK PROCEDURES (MAY 2014)

(a) Definitions.

“Kickback,” as used in this clause, means any money, fee, commission, credit, gift, gratuity, thing of value, or compensation of any kind which is provided to any prime Contractor, prime Contractor employee, subcontractor, or subcontractor employee for the purpose of improperly obtaining or rewarding favorable treatment in connection with a prime contract or in connection with a subcontract relating to a prime contract.

“Person,” as used in this clause, means a corporation, partnership, business association of any kind, trust, joint-stock company, or individual.

“Prime contract,” as used in this clause, means a contract or contractual action entered into by the United States for the purpose of obtaining supplies, materials, equipment, or services of any kind.

“Prime Contractor” as used in this clause, means a person who has entered into a prime contract with the United States.

“Prime Contractor employee,” as used in this clause, means any officer, partner, employee, or agent of a prime Contractor.

“Subcontract,” as used in this clause, means a contract or contractual action entered into by a prime Contractor or subcontractor for the purpose of obtaining supplies, materials, equipment, or services of any kind under a prime contract.

“Subcontractor,” as used in this clause, (1) means any person, other than the prime Contractor, who offers to furnish or furnishes any supplies, materials, equipment, or services of any kind under a prime contract or a subcontract entered into in connection with such prime contract, and (2) includes any person who offers to furnish or furnishes general supplies to the prime Contractor or a higher tier subcontractor.

“Subcontractor employee,” as used in this clause, means any officer, partner, employee, or agent of a subcontractor.

(b) 41 U.S.C. chapter 87, Kickbacks, prohibits any person from—

(1) Providing or attempting to provide or offering to provide any kickback;

(2) Soliciting, accepting, or attempting to accept any kickback; or

(3) Including, directly or indirectly, the amount of any kickback in the contract price charged by a prime Contractor to the United States or in the contract price charged by a subcontractor to a prime Contractor or higher tier subcontractor.

(c)(1) The Contractor shall have in place and follow reasonable procedures designed to prevent and detect possible violations described in paragraph (b) of this clause in its own operations and direct business relationships.

(2) When the Contractor has reasonable grounds to believe that a violation described in paragraph (b) of this clause may have occurred, the Contractor shall promptly report in writing the possible violation. Such reports shall be made to the inspector general of the contracting agency, the head of the contracting agency if the agency does not have an inspector general, or the Attorney General.

(3) The Contractor shall cooperate fully with any Federal agency investigating a possible violation described in paragraph (b) of this clause.

(4) The Contracting Officer may (i) offset the amount of the kickback against any monies owed by the United States under the prime contract and/or (ii) direct that the Prime Contractor withhold from sums owed a subcontractor under the prime contract the amount of the kickback. The Contracting Officer may order that monies withheld under subdivision (c)(4)(ii) of this clause be paid over to the Government unless the Government has already offset those monies under subdivision (c)(4)(i) of this clause. In either case, the Prime Contractor shall notify the Contracting Officer when the monies are withheld.

(5) The Contractor agrees to incorporate the substance of this clause, including paragraph (c)(5) but excepting paragraph (c)(1), in all subcontracts under this contract which exceed $150,000.

(End of clause) 52.203-8 CANCELLATION, RESCISSION, AND RECOVERY OF FUNDS FOR ILLEGAL OR IMPROPER ACTIVITY (MAY 2014)

(a) If the Government receives information that a contractor or a person has violated 41 U.S.C. 2102-2104, Restrictions on Obtaining and Disclosing Certain Information, the Government may—

(1) Cancel the solicitation, if the contract has not yet been awarded or issued; or

(2) Rescind the contract with respect to which—

(i) The Contractor or someone acting for the Contractor has been convicted for an offense where the conduct violates 41 U.S.C. 2102 for the purpose of either—

(A) Exchanging the information covered by such subsections for anything of value; or

(B) Obtaining or giving anyone a competitive advantage in the award of a Federal agency procurement contract; or

(ii) The head of the contracting activity has determined, based upon a preponderance of the evidence, that the Contractor or someone acting for the Contractor has engaged in conduct punishable under 41 U.S.C. 2105(a).

(b) If the Government rescinds the contract under paragraph (a) of this clause, the Government is entitled to recover, in addition to any penalty prescribed by law, the amount expended under the contract.

(c) The rights and remedies of the Government specified herein are not exclusive, and are in addition to any other rights and remedies provided by law, regulation, or under this contract. (End of clause)

52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (MAY 2014)

(a) The Government, at its election, may reduce the price of a fixed-price type contract and the total cost and fee under a cost-type contract by the amount of profit or fee determined as set forth in paragraph (b) of this clause if the head of the contracting activity or designee determines that there was a violation of 41 U.S.C. 2102 or 2103, as implemented in section 3.104 of the Federal Acquisition Regulation.

(b) The price or fee reduction referred to in paragraph (a) of this clause shall be—

(1) For cost-plus-fixed-fee contracts, the amount of the fee specified in the contract at the time of award;

(2) For cost-plus-incentive-fee contracts, the target fee specified in the contract at the time of award, notwithstanding any minimum fee or “fee floor” specified in the contract;

(3) For cost-plus-award-fee contracts—

(i) The base fee established in the contract at the time of contract award;

(ii) If no base fee is specified in the contract, 30 percent of the amount of each award fee otherwise payable to the Contractor for each award fee evaluation period or at each award fee determination point.

(4) For fixed-price-incentive contracts, the Government may—

(i) Reduce the contract target price and contract target profit both by an amount equal to the initial target profit specified in the contract at the time of contract award; or

(ii) If an immediate adjustment to the contract target price and contract target profit would have a significant adverse impact on the incentive price revision relationship under the contract, or adversely affect the contract financing provisions, the Contracting Officer may defer such adjustment until establishment of the total final price of the contract. The total final price established in accordance with the incentive price revision provisions of the contract shall be reduced by an amount equal to the initial target profit specified in the contract at the time of contract award and such reduced price shall be the total final contract price.

(5) For firm-fixed-price contracts, by 10 percent of the initial contract price or a profit amount determined by the Contracting Officer from records or documents in existence prior to the date of the contract award.

(c) The Government may, at its election, reduce a prime contractor’s price or fee in accordance with the procedures of paragraph (b) of this clause for violations of the statute by its subcontractors by an amount not to exceed the amount of profit or fee reflected in the subcontract at the time the subcontract was first definitively priced.

(d) In addition to the remedies in paragraphs (a) and (c) of this clause, the Government may terminate this contract for default. The rights and remedies of the Government specified herein are not exclusive, and are in addition to any other rights and remedies provided by law or under this contract. (End of clause)

52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE CERTAIN FEDERAL TRANSACTIONS (OCT 2010)

(a) Definitions. As used in this clause— “Agency” means “executive agency” as defined in Federal Acquisition Regulation (FAR) 2.101.

“Covered Federal action” means any of the following actions:

(1) Awarding any Federal contract.

(2) Making any Federal grant.

(3) Making any Federal loan.

(4) Entering into any cooperative agreement.

(5) Extending, continuing, renewing, amending, or modifying any Federal contract, grant, loan, or cooperative agreement.

“Indian tribe” and “tribal organization” have the meaning provided in section 4 of the Indian Self-Determination and Education Assistance Act (25 U.S.C. 450b) and include Alaskan Natives.

“Influencing or attempting to influence” means making, with the intent to influence, any communication to or appearance before an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with any covered Federal action.

“Local government” means a unit of government in a State and, if chartered, established, or otherwise recognized by a State for the performance of a governmental duty, including a local public authority, a special district, an intrastate district, a council of governments, a sponsor group representative organization, and any other instrumentality of a local government.

“Officer or employee of an agency” includes the following individuals who are employed by an agency:

(1) An individual who is appointed to a position in the Government under Title 5, United States Code, including a position under a temporary appointment.

(2) A member of the uniformed services, as defined in subsection 101(3), Title 37, United States Code.

(3) A special Government employee, as defined in section 202, Title 18, United States Code.

(4) An individual who is a member of a Federal advisory committee, as defined by the Federal Advisory Committee Act, Title 5, United States Code, appendix 2.

“Person” means an individual, corporation, company, association, authority, firm, partnership, society, State, and local government, regardless of whether such entity is operated for profit, or not for profit. This term excludes an Indian tribe, tribal organization, or any other Indian organization eligible to receive Federal contracts, grants, cooperative agreements, or loans from an agency, but only with respect to expenditures by such tribe or organization that are made for purposes specified in paragraph (b) of this clause and are permitted by other Federal law.

“Reasonable compensation” means, with respect to a regularly employed officer or employee of any person, compensation that is consistent with the normal compensation for such officer or employee for work that is not furnished to, not funded by, or not furnished in cooperation with the Federal Government.

“Reasonable payment” means, with respect to professional and other technical services, a payment in an amount that is consistent with the amount normally paid for such services in the private sector.

“Recipient” includes the Contractor and all subcontractors. This term excludes an Indian tribe, tribal organization, or any other Indian organization eligible to receive Federal contracts, grants, cooperative agreements, or loans from an agency, but only with respect to expenditures by such tribe or organization that are made for purposes specified in paragraph (b) of this clause and are permitted by other Federal law.

“Regularly employed” means, with respect to an officer or employee of a person requesting or receiving a Federal contract, an officer or employee who is employed by such person for at least 130 working days within 1 year immediately preceding the date of the submission that initiates agency consideration of such person for receipt of such contract. An officer or employee who is employed by such person for less than 130 working days within 1 year immediately preceding the date of the submission that initiates agency consideration of such person shall be considered to be regularly employed as soon as he or she is employed by such person for 130 working days.

“State” means a State of the United States, the District of Columbia, or an outlying area of the United States, an agency or instrumentality of a State, and multi-State, regional, or interstate entity having governmental duties and powers.

(b) Prohibition. 31 U.S.C. 1352 prohibits a recipient of a Federal contract, grant, loan, or cooperative agreement from using appropriated funds to pay any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with any covered Federal actions. In accordance with 31 U.S.C. 1352 the Contractor shall not use appropriated funds to pay any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with the award of this contractor the extension, continuation, renewal, amendment, or modification of this contract.

(1) The term appropriated funds does not include profit or fee from a covered Federal action.

(2) To the extent the Contractor can demonstrate that the Contractor has sufficient monies, other than Federal appropriated funds, the Government will assume that these other monies were spent for any influencing activities that would be unallowable if paid for with Federal appropriated funds.

(c) Exceptions. The prohibition in paragraph (b) of this clause does not apply under the following conditions:

(1) Agency and legislative liaison by Contractor employees.

(i) Payment of reasonable compensation made to an officer or employee of the Contractor if the payment is for agency and legislative liaison activities not directly related to this contract. For purposes of this paragraph, providing any information specifically requested by an agency or Congress is permitted at any time.

(ii) Participating with an agency in…