Attachment_5_Provisions_and_Clauses_Rev0.pdf

ATTACHMENT 5: RFQ NNA17599805Q-ACJ

MMARSS RFQ Provisions and Clauses Page 1 of 47

ALL APPLICABLE PROVISIONS/CLAUSES (COMMERCIAL AND CONSTRUCTION), Revision 0 Federal Acquisition Circular (FAC) 2005-95, dated January 19, 2017 (https://www.acquisition.gov/?q=browsefar) NASA FAR Supplement through May 4, 2017 (https://www.hq.nasa.gov/office/procurement/regs/nfstocA.htm)

FEDERAL ACQUISITION REGULATION (FAR) APPLICABLE PROVISIONS/CLAUSES – INCORPORATED BY REFERENCE:

Provision/Clause Number Date

FAR 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements Jan 2017

FAR 52.204-7, System for Award Management Oct 2016

FAR 52.204-13, System for Award Management Maintenance Oct 2016

FAR 52.204-16, Commercial and Government Entity Code Reporting Jul 2016

FAR 52.204-18, Commercial and Government Entity Code Maintenance Jul 2016

FAR 52.204-19, Incorporation by Reference of Representations and Certifications Jul 2016

FAR 52.204-22, Alternative Line Item Proposal Jan 2017

FAR 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations Nov 2015

FAR 52.212-1, Instructions to Offerors – Commercial Items Jan 2017

FAR 52.212-4, Contract Terms and Conditions – Commercial Items Jan 2017

FAR 52.214-34, Submission of Offers in the English Language Apr 1991

FAR 52.214-35, Submission of Offers in U.S. Currency Apr 1991

FAR 52.219-6, Notice of Total Small Business Set-Aside Nov 2011

FAR 52.219-28, Post-Award Small Business Program Representation Jul 2013

FAR 52.222-3, Convict Labor Jun 2003

FAR 52.222-6, Construction Wage Rate Requirements May 2014

FAR 52.222-7, Withholding of Funds May 2014

FAR 52.222-8, Payrolls and Basic Records May 2014

FAR 52.222-9, Apprentices and Trainees Jul 2005

FAR 52.222-10, Compliance with Copeland Act Requirements Feb 1988

FAR 52.222-11, Subcontracts (Labor Standards) May 2014

FAR 52.222-12, Contract Termination – Debarment May 2014

FAR 52.222-13, Compliance with Construction Wage Rate Requirements and Related Regulations May 2014

FAR 52.222-14, Disputes Concerning Labor Standards Feb 1988

FAR 52.222-15, Certification of Eligibility May 2014

FAR 52.222-21, Prohibition of Segregated Facilities Apr 2015

FAR 52.222-26, Equal Opportunity Sep 2016

FAR 52.222-27, Affirmative Action Compliance Requirements for Construction Apr 2015

FAR 52.222-41, Service Contract Labor Standards May 2014

FAR 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards – Price Adjustment May 2014

FAR 52.222-50, Combating Trafficking in Persons Mar 2015

FAR 52.222-55, Minimum Wages Under Executive Order 13658 Dec 2015

FAR 52.222-62, Paid Sick Leave Under Executive Order 13706 Jan 2017

FAR 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts Sep 2013

FAR 52.223-5, Pollution Prevention and Right-to-Know Information May 2011

FAR 52.223-6, Drug-Free Workplace May 2001

FAR 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons Jun 2016

FAR 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners Jun 2016

FAR 52.223-15, Energy Efficiency in Energy-Consuming Products Dec 2007

FAR 52.223-17, Affirmative Procurement of EPA-designated Items in Service and Construction Contracts May 2008

FAR 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving Aug 2011 https://www.acquisition.gov/?q=browsefar https://www.hq.nasa.gov/office/procurement/regs/nfstocA.htm

MMARSS RFQ Provisions and Clauses Page 2 of 47

FAR 52.223-20, Aerosols Jun 2016

FAR 52.223-21, Foams Jun 2016

FAR 52.225-1, Buy American – Supplies May 2014

FAR 52.225-10, Notice of Buy American Requirement – Construction Materials May 2014

FAR 52.225-13, Restrictions on Certain Foreign Purchases Jun 2008

FAR 52.227-4, Patent Indemnity – Construction Contracts Dec 2007

FAR 52.228-5, Insurance - Work on a Government Installation Jan 1997

FAR 52.232-5, Payments under Fixed-Price Construction Contracts May 2014

FAR 52.232-11, Extras Apr 1984

FAR 52.232-27, Prompt Payment for Construction Contracts Jan 2017

FAR 52.232-36, Payment by Third Party May 2014

FAR 52.232-39, Unenforceability of Unauthorized Obligations Jun 2013

FAR 52.232-40, Providing Accelerated Payments to Small Business Subcontractors Dec 2013

FAR 52.233-3, Protest after Award Aug 1996

FAR 52.233-4, Applicable Law for Breach of Contract Claim Oct 2004

FAR 52.236-2, Differing Site Conditions Apr 1984

FAR 52.236-3, Site Investigation and Conditions Affecting the Work Apr 1984

FAR 52.236-5, Material and Workmanship Apr 1984

FAR 52.236-6, Superintendence by the Contractor Apr 1984

FAR 52.236-7, Permits and Responsibilities Nov 1991

FAR 52.236-8, Other Contracts Apr 1984

FAR 52.236-9, Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements Apr 1984

FAR 52.236-10, Operations and Storage Areas Apr 1984

FAR 52.236-11, Use and Possession Prior to Completion Apr 1984

FAR 52.236-12, Cleaning Up Apr 1984

FAR 52.236-13, Accident Prevention Nov 1991

FAR 52.236-13, Accident Prevention, Alternate I Nov 1991

FAR 52.236-14, Availability and Use of Utility Services Apr 1984

FAR 52.236-17, Layout of Work Apr 1984

FAR 52.236-21, Specifications and Drawings for Construction Feb 1997

FAR 52.242-14, Suspension of Work Apr 1984

FAR 52.242-15, Stop-Work Order Aug 1989

FAR 52.242-17, Government Delay of Work Apr 1984

FAR 52.243-1, Changes – Fixed Price Aug 1987

FAR 52.243-1, Changes – Fixed Price, Alternate I Apr 1984

FAR 52.243-5, Changes and Changed Conditions Apr 1984

FAR 52.245-1, Government Property Jan 2017

FAR 52.246-4, Inspection of Services – Fixed Price Aug 1996

FAR 52.246-12, Inspection of Construction Aug 1996

FAR 52.246-13, Inspection – Dismantling, Demolition, or Removal of Improvements Aug 1996

FAR 52.246-16, Responsibility of Supplies Aug 1984

FAR 52.247-34, F.O.B. Destination Nov 1991

FAR 52.249-1, Termination for Convenience of the Government (Fixed-Price)(Short Form) Apr 1984

FAR 52.249-1, Termination for Convenience of the Government (Fixed-Price)(Short Form), Alternate I Apr 1984

FAR 52.249-10, Default (Fixed-Price Construction) Apr 1984

FAR 52.249-10, Default (Fixed-Price Construction), Alternate I Apr 1984

MMARSS RFQ Provisions and Clauses Page 3 of 47

FAR 52.250-2, SAFETY Act Coverage Not Applicable Feb 2009

FAR 52.251-1, Government Supply Sources Apr 2012

FAR 52.252-5, Authorized Deviations in Provisions Apr 1984

FAR 52.252-6, Authorized Deviations in Clauses Apr 1984

FAR 52.253-1, Computer Generated Forms Jan 1991

FEDERAL ACQUISITION REGULATION (FAR) APPLICABLE PROVISIONS/CLAUSES – INCORPORATED BY FULL TEXT:

FAR 52.204-9, Personal Identity Verification of Contractor Personnel Jan 2011

FAR 52.211-10, Commencement, Prosecution, and Completion of Work Apr 1984

FAR 52.212-2, Evaluation -- Commercial Items (ADDENDUM) Oct 2014

FAR 52.212-3, Offeror Representations and Certifications – Commercial Items Jan 2017

FAR 52.212-3, Offeror Representations and Certifications – Commercial Items, Alternate I Jan 2017

FAR 52.212-5, Contract Terms and Conditions Required to Implement Statutes or Executive Orders – Commercial Items

Jan 2017

FAR 52.222-5, Construction Wage Rate Requirements—Secondary Site of the Work May 2014

FAR 52.222-23, Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction

Feb 1999

FAR 52.225-9, Buy American – Construction Materials May 2014

FAR 52.236-27, Site Visit (Construction) Feb 1995

FAR 52.252-1, Solicitation Provisions Incorporated by Reference Feb 1998

FAR 52.252-2, Clauses Incorporated by Reference Feb 1998

FAR 52.252-3, Alterations in Solicitation Apr 1984

NASA FEDERAL ACQUISITION REGULATION SUPPLEMENT (NFS) APPLICABLE PROVISIONS/CLAUSES – INCORPORATED

BY REFERENCE:

NFS 1852.203-71, Requirement to Inform Employees of Whistleblower Rights Aug 2014

NFS 1852.215-84, Ombudsman Nov 2011

NFS 1852.223-75, Major Breach of Safety or Security, Alternate I Feb 2006

NFS 1852.228-75, Minimum Insurance Coverage Oct 1988

NFS 1852.233-70, Protest to NASA Dec 2015

NFS 1852.237-70, Emergency Evacuation Procedures Dec 1988

NFS 1852.237-73, Release of Sensitive Information Jun 2005

NFS 1852.242-72, Denied Access to NASA Facilities Oct 2015

NFS 1852.245-72, Liability for Government Property Furnished for Repair or Other Services Jan 2011

NFS 1852.245-79, Records and Disposition Reports for Government Property With Potential Historic or Significant Real Value Jan 2011

NASA FEDERAL ACQUISITION REGULATION SUPPLEMENT (NFS) APPLICABLE PROVISIONS/CLAUSES – INCORPORATED

BY FULL TEXT:

NFS 1852.216-78, Firm Fixed Price Dec 1988

1852.225-70, Export Licenses Feb 2000

1852.236-74, Magnitude of Requirement Dec 1988

1852.245-83, Real Property Management Requirements Jan 2011

AMES RESEARCH CENTER (ARC) APPLICABLE PROVISIONS/CLAUSES INCORPORATED BY FULL TEXT:

PLACE OF PERFORMANCE - SERVICES Mar 2016

ARC 52.223-90 EMERGENCY PREPAREDNESS AND RESPONSE Jan 2012

ARC 52.223-91 DISASTER ASSISTANCE AND RESCUE TEAM (DART) PARTICIPATION Jan 2012

ARC 52.230-90 CONTRACTOR PURCHASING Jan 2012

ARC 52.237-99 NON-PERSONAL SERVICES May 2012

MMARSS RFQ Provisions and Clauses Page 4 of 47

FEDERAL ACQUISITION REGULATION (FAR) APPLICABLE PROVISIONS/CLAUSES – INCORPORATED BY FULL TEXT:

52.204-9 -- Personal Identity Verification of Contractor Personnel.

As prescribed in 4.1303, insert the following clause:

Personal Identity Verification of Contractor Personnel (Jan 2011)

(a) The Contractor shall comply with agency personal identity verification procedures identified in the contract that implement Homeland Security Presidential Directive-12 (HSPD-12), Office of Management and Budget (OMB) guidance M-05-24, and Federal Information Processing Standards Publication (FIPS

PUB) Number 201.

(b) The Contractor shall account for all forms of Government-provided identification issued to the

Contractor employees in connection with performance under this contract. The Contractor shall return such identification to the issuing agency at the earliest of any of the following, unless otherwise determined by the Government;

(1) When no longer needed for contract performance.

(2) Upon completion of the Contractor employee’s employment.

(3) Upon contract completion or termination.

(c) The Contracting Officer may delay final payment under a contract if the Contractor fails to comply with these requirements.

(d) The Contractor shall insert the substance of clause, including this paragraph (d), in all subcontracts when the subcontractor’s employees are required to have routine physical access to a Federally-controlled facility and/or routine access to a Federally-controlled information system. It shall be the responsibility of the prime Contractor to return such identification to the issuing agency in accordance with the terms set forth in paragraph (b) of this section, unless otherwise approved in writing by the Contracting Officer.

(End of Clause)

52.211-10 -- Commencement, Prosecution, and Completion of Work.

As prescribed in 11.404(b), insert the following clause in solicitations and contracts when a fixed-price construction contract is contemplated. The clause may be changed to accommodate the issuance of orders under indefinite-delivery contracts for construction.

Commencement, Prosecution, and Completion of Work (Apr 1984)

The Contractor shall be required to

(a) commence work under this contract within [specified on individual BPA call schedules] calendar days after the date the Contractor receives the notice to proceed, http://farsite.hill.af.mil/reghtml/regs/far2afmcfars/fardfars/far/04.htm#P703_88210 http://farsite.hill.af.mil/reghtml/regs/far2afmcfars/fardfars/far/11.htm#P198_30162

MMARSS RFQ Provisions and Clauses Page 5 of 47

(b) prosecute the work diligently, and

(c) complete the entire work ready for use not later than [specified on individual BPA call schedules].*

The time stated for completion shall include final cleanup of the premises.

(End of Clause)

ADDENDUM to 52.212-2 -- Evaluation -- Commercial Items.

In accordance with FAR 12.301(c)(2), included is a similar provision containing all evaluation factors required by FAR 13.106-2, Evaluation of Quotations or Offers.

As prescribed in 12.301(c), the Contracting Officer may insert a provision substantially as follows:

Evaluation -- Commercial Items (Oct 2014)

(a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers:

Qualifications [see FAR 13.106-2(b)(3)]________________

Price [see FAR 13.106-2(b)(3)]_______________________

Past Performance [see FAR 13.106-2(b)(3)(ii)(D)]________

Technical and past performance, when combined, are [FAR 15.304 is not applicable to this streamlined acquisition; evaluation will be conducted in accordance with FAR 13.106-2. Reference combined solicitation/synopsis “Attachment 7_Evaluation of Quotations_Rev0” for detailed evaluation procedures.]

(b) Options. The Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. The Government may determine that an offer is unacceptable if the option prices are significantly unbalanced. Evaluation of options shall not obligate the

Government to exercise the option(s).

(c) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer’s specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

(End of Provision)

52.212-3 -- Offeror Representations and Certifications -- Commercial Items.

As prescribed in 12.301(b)(2), insert the following provision:

Offeror Representations and Certifications -- Commercial Items (Jan 2017) http://farsite.hill.af.mil/reghtml/regs/far2afmcfars/fardfars/far/12.htm#P120_20016

MMARSS RFQ Provisions and Clauses Page 6 of 47

The offeror shall complete only paragraphs (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at http://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision.

(a) Definitions. As used in this provision--

“Administrative merits determination” means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Arbitral award or decision” means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Civil judgment” means--

(1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction.

(2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“DOL Guidance” means the Department of Labor (DOL) Guidance entitled: “Guidance for Executive

Order 13673, ‘Fair Pay and Safe Workplaces’ “. The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces.

“Economically disadvantaged women-owned small business (EDWOSB) concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the

United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

“Enforcement agency” means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance

Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity

Commission, the Occupational Safety and Health Review Commission, and the National Labor Relations

Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are--

(1) Department of Labor Wage and Hour Division (WHD) for--http://www.sam.gov/portal http://www.dol.gov/fairpayandsafeworkplaces

MMARSS RFQ Provisions and Clauses Page 7 of 47

(i) The Fair Labor Standards Act;

(ii) The Migrant and Seasonal Agricultural Worker Protection Act;

(iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act;

(v) 41 U.S.C. chapter 67, formerly known as the Service Contract Act;

(vi) The Family and Medical Leave Act; and

(vii) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors);

(2) Department of Labor Occupational Safety and Health Administration (OSHA) for--

(i) The Occupational Safety and Health Act of 1970; and

(ii) OSHA-approved State Plans;

(4) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for--

(i) Section 503 of the Rehabilitation Act of 1973;

(ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam

Era Veterans' Readjustment Assistance Act of 1974; and

(iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity);

(5) National Labor Relations Board (NLRB) for the National Labor Relations Act; and

(6) Equal Employment Opportunity Commission (EEOC) for--

(i) Title VII of the Civil Rights Act of 1964;

(ii) The Americans with Disabilities Act of 1990;

(iii) The Age Discrimination in Employment Act of 1967; and

(iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act).

“Forced or indentured child labor” means all work or service—

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

MMARSS RFQ Provisions and Clauses Page 8 of 47

“Highest-level owner” means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

“Immediate owner” means an entity, other than the offeror, that has direct control of the offeror.

Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

“Inverted domestic corporation,” means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

“Labor compliance agreement” means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters.

“Labor laws” means the following labor laws and E.O.s:

(1) The Fair Labor Standards Act.

(2) The Occupational Safety and Health Act (OSHA) of 1970.

(3) The Migrant and Seasonal Agricultural Worker Protection Act.

(4) The National Labor Relations Act.

(5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act.

(6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act.

(7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity).

(8) Section 503 of the Rehabilitation Act of 1973.

(9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era

Veterans' Readjustment Assistance Act of 1974.

(10) The Family and Medical Leave Act.

(11) Title VII of the Civil Rights Act of 1964.

(12) The Americans with Disabilities Act of 1990.

(13) The Age Discrimination in Employment Act of 1967.

(14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors).

MMARSS RFQ Provisions and Clauses Page 9 of 47

(15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html).

“Labor law decision” means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of “labor laws”.

“Manufactured end product” means any end product in product and service codes (PSCs) 1000-9999, except—

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

“Place of manufacture” means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the

Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

“Predecessor” means an entity that is replaced by a successor and includes any predecessors of the predecessor.

“Restricted business operations” means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174).

Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate—

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

http://www.osha.gov/dcsp/osp/approved_state_plans.html

MMARSS RFQ Provisions and Clauses Page 10 of 47

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

Sensitive technology—

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically—

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the

International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

“Service-disabled veteran-owned small business concern”—

(1) Means a small business concern—

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

“Small business concern” means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

“Small disadvantaged business concern, consistent with 13 CFR 124.1002,” means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

MMARSS RFQ Provisions and Clauses Page 11 of 47

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United

States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding

$750,000 after taking into account the applicable exclusions set forth at 13 CFR

124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR

124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Subsidiary” means an entity in which more than 50 percent of the entity is owned—

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

“Successor” means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term “successor” does not include new offices/divisions of the same company or a company that only changes its name.

The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances.

“Veteran-owned small business concern” means a small business concern—

(1) Not less than 51 percent of which is owned by one or more veterans(as defined at 38 U.S.C.

101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

“Women-owned business concern” means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of the its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

“Women-owned small business concern” means a small business concern --

(1) That is at least 51 percent owned by one or more women or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with

13 CFR part 127),” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

MMARSS RFQ Provisions and Clauses Page 12 of 47

Note to paragraph (a): By a court order issued on October 24, 2016, the following definitions in this paragraph (a) are enjoined indefinitely as of the date of the order: “Administrative merits determination”, “Arbitral award or decision”, paragraph (2) of “Civil judgment”, “DOL Guidance”, “Enforcement agency”, “Labor compliance agreement”, “Labor laws”, and “Labor law decision”. The enjoined definitions will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(b)

(1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph

(b)(2) of this provision do not automatically change the representations and certifications posted on the SAM website.

(2) The offeror has completed the annual representations and certifications electronically via the

SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representation and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and

Certifications—Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs

____________. [Offeror to identify the applicable paragraphs at (c) through (u) of this provision that the offeror has completed for the purposes of this solicitation only, if any. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer. Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on SAM.]

(c) Offerors must complete the following representations when the resulting contract is to be performed in the United States or its outlying areas. Check all that apply.

(1) Small business concern. The offeror represents as part of its offer that it [_] is, [_] is not a small business concern.

(2) Veteran-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [_] is, [_] is not a veteran-owned small business concern.

(3) Service-disabled veteran-owned small business concern. [Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(2) of this provision.] The offeror represents as part of its offer that it [_] is, [_] is not a service-disabled veteran-owned small business concern.

(4) Small disadvantaged business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [_] is, [_] is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.

https://www.acquisition.gov/

MMARSS RFQ Provisions and Clauses Page 13 of 47

(5) Women-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [_] is, [_] is not a women-owned small business concern.

Note: Complete paragraphs (c)(8) and (c)(9) only if this solicitation is expected to exceed the simplified acquisition threshold.

(6) WOSB concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(5) of this provision.] The offeror represents that—

(i) It [_] is, [_] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [_] is, [_] is not a joint venture that complies with the requirements of 13 CFR part

127, and the representation in paragraph (c)(6)(i) of this provision is accurate for each

WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB

Program and other small businesses that are participating in the joint venture:

_________.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(7) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a WOSB concern eligible under the WOSB Program in

(c)(6) of this provision.] The offeror represents that—

(i) It [_] is, [_] is not an EDWOSB concern, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [_] is, [_] is not a joint venture that complies with the requirements of 13 CFR part

127, and the representation in paragraph (c)(7)(i) of this provision is accurate for each

EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: _____________.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

(8) Women-owned business concern (other than small business concern). [Complete only if the offeror is a women-owned business concern and did not represent itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [_] is, a women-owned business concern.

(9) Tie bid priority for labor surplus area concerns. If this is an invitation for bid, small business offerors may identify the labor surplus areas in which costs to be incurred on account of manufacturing or production (by offeror or first-tier subcontractors) amount to more than 50 percent of the contract price:

MMARSS RFQ Provisions and Clauses Page 14 of 47

(10) HUBZone small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, as part of its offer, that--

(i) It [_] is, [_] is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR part 126; and

(ii) It [_] is, [_] is not a HUBZone joint venture that complies with the requirements of 13

CFR part 126, and the representation in paragraph (c)(10)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture.

[The offeror shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: __________.] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

(d) Representations required to implement provisions of Executive Order 11246 --

(1) Previous contracts and compliance. The offeror represents that --

(i) It [_] has, [_] has not, participated in a previous contract or subcontract subject to the

Equal Opportunity clause of this solicitation; and

(ii) It [_] has, [_] has not, filed all required compliance reports.

(2) Affirmative Action Compliance. The offeror represents that --

(i) It [_] has developed and has on file, [_] has not developed and does not have on file, at each establishment, affirmative action programs required by rules and regulations of the

Secretary of Labor (41 CFR parts 60-1 and 60-2), or

(ii) It [_] has not previously had contracts subject to the written affirmative action programs requirement of the rules and regulations of the Secretary of Labor.

(e) Certification Regarding Payments to Influence Federal Transactions (31 U.S.C. 1352). (Applies only if the contract is expected to exceed $150,000.) By submission of its offer, the offeror certifies to the best of its knowledge and belief that no Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of

Congress, an officer or employee of Congress or an employee of a Member of Congress on his or her behalf in connection with the award of any resultant contract. If any registrants under the Lobbying

Disclosure Act of 1995 have made a lobbying contact on behalf of the offeror with respect to this contract, the offeror shall complete and submit, with its offer, OMB Standard Form LLL, Disclosure of

Lobbying Activities, to provide the name of the registrants. The offeror need not report regularly employed officers or employees of the offeror to whom payments of reasonable compensation were made.

(f) Buy American Certificate. (Applies only if the clause at Federal Acquisition Regulation (FAR) 52.225-

1, Buy American – Supplies, is included in this solicitation.)

MMARSS RFQ Provisions and Clauses Page 15 of 47

(1) The offeror certifies that each end product, except those listed in paragraph (f)(2) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The offeror shall list as foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of “domestic end product.” The terms “commercially available off-the-shelf (COTS) item,” “component,” “domestic end product,” “end product,” “foreign end product,” and “United

States” are defined in the clause of this solicitation entitled “Buy American—Supplies.”

(2) Foreign End Products:

LINE ITEM NO. COUNTRY OF ORIGIN

[List as necessary]

(3) The Government will evaluate offers in accordance with the policies and procedures of FAR

Part 25.

(g)

(1) Buy American -- Free Trade Agreements -- Israeli Trade Act Certificate. (Applies only if the clause at FAR 52.225-3, Buy American -- Free Trade Agreements -- Israeli Trade Act, is included in this solicitation.)

(i) The offeror certifies that each end product, except those listed in paragraph (g)(1)(ii) or (g)(1)(iii) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The terms “Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end product,” “commercially available off-the-shelf

(COTS) item,” “component,” “domestic end product,” “end product,” “foreign end product,” “Free Trade Agreement country,” “Free Trade Agreement country end product,” “Israeli end product,” and “United States” are defined in the clause of this solicitation entitled “Buy American--Free Trade Agreements--Israeli Trade Act.”

(ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled “Buy

American—Free Trade Agreements—Israeli Trade Act”:

Free Trade Agreement Country End Products (Other than Bahrainian, Moroccan, Omani, Panamanian, or

Peruvian End Products) or Israeli End Products:

LINE ITEM NO. COUNTRY OF ORIGIN

[List as necessary]

MMARSS RFQ Provisions and Clauses Page 16 of 47

(iii) The offeror shall list those supplies that are foreign end products (other than those listed in paragraph (g)(1)(ii) or this provision) as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act.” The offeror shall list as other foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of “domestic end product.”

Other Foreign End Products:

LINE ITEM NO. COUNTRY OF ORIGIN

[List as necessary]

(iv) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25.

(2) Buy American—Free Trade Agreements—Israeli Trade Act Certificate, Alternate I. If

Alternate I to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

(g)(1)(ii) The offeror certifies that the following supplies are Canadian end products as defined in the clause of this solicitation entitled “Buy American—

Free Trade Agreements—Israeli Trade Act”:

Canadian End Products:

Line Item No.:

[List as necessary]

(3) Buy American—Free Trade Agreements—Israeli Trade Act Certificate, Alternate II. If

Alternate II to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

(g)(1)(ii) The offeror certifies that the following supplies are Canadian end products or Israeli end products as defined in the clause of this solicitation entitled “Buy American--Free Trade Agreements--Israeli Trade Act'':

Canadian or Israeli End Products:

Line Item No.: Country of Origin:

[List as necessary]

MMARSS RFQ Provisions and Clauses Page 17 of 47

(4) Buy American—Free Trade Agreements—Israeli Trade Act Certificate, Alternate III. If

Alternate III to the clause at 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

(g)(1)(ii) The offeror certifies that the following supplies are Free Trade

Agreement country end products (other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled “Buy American—Free Trade

Agreements—Israeli Trade Act”:

Free Trade Agreement Country End Products (Other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products:

Line Item No.: Country of Origin:

[List as necessary]

(5) Trade Agreements Certificate. (Applies only if the clause at FAR 52.225-5, Trade

Agreements, is included in this solicitation.)

(i) The offeror certifies that each end product, except those listed in paragraph (g)(5)(ii) of this provision, is a U.S.-made or designated country end product as defined in the clause of this solicitation entitled “Trade Agreements.”

(ii) The offeror shall list as other end products those end products that are not U.S.-made or designated country end products.

Other End Products

Line Item No.: Country of Origin:

[List as necessary]

(iii) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. For line items covered by the WTO GPA, the Government will evaluate offers of U.S.-made or designated country end products without regard to the restrictions of the Buy American statute. The Government will consider for award only offers of

U.S.-made or designated country end products unless the Contracting Officer determines that there are no offers for such products or that the offers for such products are insufficient to fulfill the requirements of the solicitation.

(h) Certification Regarding Responsibility Matters (Executive Order 12689). (Applies only if the contract value is expected to exceed the simplified acquisition threshold.) The offeror certifies, to the best of its knowledge and belief, that the offeror and/or any of its principals--

MMARSS RFQ Provisions and Clauses Page 18 of 47

(1) [_] Are, [_] are not presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency;

(2) [_] Have, [_] have not, within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a Federal, state or local government contract or subcontract; violation of Federal or state antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property; and

(3) [_] Are, [_] are not presently indicted for, or otherwise criminally or civilly charged by a

Government entity with, commission of any of these offenses enumerated in paragraph (h)(2) of this clause; and

(4) [_] Have, [_] have not, within a three-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds $3,500 for which the liability remains unsatisfied.

(i) Taxes are considered delinquent if both of the following criteria apply:

(A) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted.

(B) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded.

(ii) Examples.

(A) The taxpayer has received a statutory notice of deficiency, under I.R.C.

§6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability.

Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appear rights.

(B) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. §6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals Contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

MMARSS RFQ Provisions and Clauses Page 19 of 47

(C) The taxpayer has entered into an installment agreement pursuant to I.R.C.

§6159. The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment.

(D) The taxpayer has filed for bankruptcy protection. The taxpayer is not delinquent because enforced collection action is stayed under 11 U.S.C. §362

(the Bankruptcy Code).

(i) Certification Regarding Knowledge of Child Labor for Listed End Products (Executive Order 13126).

[The Contracting Officer must list in paragraph (i)(1) any end products being acquired under this solicitation that are included in the List of Products Requiring Contractor Certification as to Forced or

Indentured Child Labor, unless excluded at 22.1503(b).]

(1) Listed End Product

Listed End Product: Listed Countries of Origin:

(2) Certification. [If the Contracting Officer has identified end products and countries of origin in paragraph (i)(1) of this provision, then the offeror must certify to either (i)(2)(i) or (i)(2)(ii) by checking the appropriate block.]

[_] (i) The offeror will not supply any end product listed in paragraph (i)(1) of this provision that was mined, produced, or manufactured in the corresponding country as listed for that product.

[_] (ii) The offeror may supply an end product listed in paragraph (i)(1) of this provision that was mined, produced, or manufactured in the corresponding country as listed for that product. The offeror certifies that is has made a good faith effort to determine whether forced or indentured child labor was used to mine, produce, or manufacture any such end product furnished under this contract. On the basis of those efforts, the offeror certifies that it is not aware of any such use of child labor.

(j) Place of manufacture. (Does not apply unless the solicitation is predominantly for the acquisition of manufactured end products.) For statistical purposes only, the offeror shall indicate whether the place of manufacture of the end products it expects to provide in response to this solicitation is predominantly—

(1) [_] In the United…