25R0070 Amendment 0007.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE

PAGE OF PAGES

1 3

2. AMENDMENT/MODIFICATION NO.

3. EFFECTIVE DATE

09-SEPT-2025

4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than item 6) CODE

NAVFACSYSCOM MID-ATLANTIC

CONTRACTING CORE

9324 VIRGINIA AVENUE

NORFOLK VA 23511-3095

See Item 6

8. NAME AND ADDRESS OF CONT RACTOR (No., Street, County, State and Zip Code) X 9A. AMENDMENT OF SOLICITATION NO.

N40085-25-R-0070

X 9B. DATED (SEE ITEM 11)

08/12/25

10A. MOD. OF CONT RACT /ORDER NO.

10B. DAT ED (SEE ITEM 13)

CODE FACILITY CODE

11. THIS ITEM ONLY APPLIES TO AMENDMENT S OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, x is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15 and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT

TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNT ING AND APPROPRIAT ION DAT A (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICAT IONS OF CONT RACTS/ORDERS.

IT MODIFIES THE CONT RACT /ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONT RACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONT RACT /ORDER IS MODIFIED TO REFLECT THE ADMINIST RAT IVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORT ANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

N4008525R0070 Design-Build (DB) Repair CVN Bulkhead Q8 at Naval Station Norfolk, Norfolk, Virginia

Contract POC: Catharine Keeling, catharine.a.keeling.civ@us.navy.mil

SEE SF 30 BLOCK 14 CONTINUATION PAGE

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONT RACTING OFFICER (Type or print)

TEL: EMAIL:

15B. CONT RACT OR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNIT ED STATES OF AMERICA

BY

(Signature of Contracting Officer)

16C. DATE SIGNED

EXCEPTION TO SF 30

STANDARD FORM 30 (Rev. 11/16) APPROVED BY OIRM 11-84 Prescribed by GSA

FAR (48 CFR) 53.243

N40085-25-R-0070

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

The following have been added by full text:

AMENDMENT 0007

The purpose of this amendment is to incorporate the following:

1. To Update General Requirements

1. Updated General Requirements

Changes to the General Requirements are as follows:

From:

Factor 1 – Technical Solution:

(i) Solicitation Submittal Requirements:

Submit a narrative work plan and summary level schedule to describe your approach to managing the project and ensuring adherence to the project schedule. Both the schedule and narrative must address the execution of the base work as identified in the RFP. The narrative shall not exceed eight (8) 8-1/2” x 11” pages, 12-point font size. Up to four (4) drawings on 11”x17” paper can be provided to supplement the narrative and will not count towards the page limit. Provide the summary level schedule, in 11” x 17” pages in the Adobe PDF file. There is no page limit on the summary level schedule.

The narrative work plan shall address major elements of work and demonstrate understanding of the scope, all phases and major milestones, technical complexities, and construction schedule required to achieve the work as identified in the solicitation. Identify activities that may affect the project timeline, including other/off site work activities. In addition, the plan shall address the following technical complexities:

a. Overall management and coordination of simultaneous construction activities;

b. Contractor’s intended design approach for the project;

c. Minimizing footprint of contractor’s operations and laydown in the Pier Area during construction;

d. Approach to avoid project schedule slippage due to material/equipment procurement and delivery delays;

e. Open-water construction methods, including installation via equipment mounted on barges;

f. Subcontractors for both design and construction and their ability to provide skilled labor;

g. Maintaining the workforce as needed;

h. Management of this workforce

The project schedule shall illustrate the Offeror’s ability to achieve or improve on the contract completion date set out in the RFP (1440 calendar days, including 15 days for bond approval). Identify the overall completion time for this project as well as interim completion times (including each phase of work as identified in the RFP) and key milestones for sequences as required to complete construction. The schedule shall demonstrate an understanding of the work, a logical sequence of events to accomplish the work, and contain enough information to identify all of the major milestones, as defined in the RFP.

The schedule shall be based on a contract award date of 30 September 2025. This date is for proposal purposes only and is not intended to indicate an anticipated/planned award date. NOTE: If a realistic duration shorter than specified in the RFP is proposed, the proposed duration will be incorporated into the resultant contract.

N40085-25-R-0070

To:

Factor 1 – Technical Solution:

(ii) Solicitation Submittal Requirements:

Submit a narrative work plan and summary level schedule to describe your approach to managing the project and ensuring adherence to the project schedule. Both the schedule and narrative must address the execution of the base work as identified in the RFP. The narrative shall not exceed eight (8) 8-1/2” x 11” pages, 12-point font size. Up to four (4) drawings on 11”x17” paper can be provided to supplement the narrative and will not count towards the page limit. Provide the summary level schedule, in 11” x 17” pages in the Adobe PDF file. There is no page limit on the summary level schedule.

The narrative work plan shall address major elements of work and demonstrate understanding of the scope, all phases and major milestones, technical complexities, and construction schedule required to achieve the work as identified in the solicitation. Identify activities that may affect the project timeline, including other/off site work activities. In addition, the plan shall address the following technical complexities:

i. Overall management and coordination of simultaneous construction activities;

j. Contractor’s intended design approach for the project;

k. Minimizing footprint of contractor’s operations and laydown in the Pier Area during construction;

l. Approach to avoid project schedule slippage due to material/equipment procurement and delivery delays;

m. Open-water construction methods, including installation via equipment mounted on barges;

n. Subcontractors for both design and construction and their ability to provide skilled labor;

o. Maintaining the workforce as needed;

p. Management of this workforce

The project schedule shall illustrate the Offeror’s ability to achieve or improve on the contract completion date set out in the RFP (1800 calendar days, including 15 days for bond approval). Identify the overall completion time for this project as well as interim completion times (including each phase of work as identified in the RFP) and key milestones for sequences as required to complete construction. The schedule shall demonstrate an understanding of the work, a logical sequence of events to accomplish the work, and contain enough information to identify all of the major milestones, as defined in the RFP.

The schedule shall be based on a contract award date of 30 September 2025. This date is for proposal purposes only and is not intended to indicate an anticipated/planned award date. NOTE: If a realistic duration shorter than specified in the RFP is proposed, the proposed duration will be incorporated into the resultant contract.

(End of Summary of Changes)