Solicitation_186118.pdf

Project specif ications and associated draw ings are attached to this solicitation.

See solicitation section 00100 for Instructions to Bidders. Competition is limited to small business concerns.

Bidders are advised that funding may not become available. If funds are not available, no aw ard w ill be made as a result of this solicitation.

Bidders w ill not be reimbursed for any effort or proposed cost resulting from the preparation of a bid in response to this solicitation.

Required Fill-In Information (To Be Completed By Bidder):

DUNS:

CAGE:

CONTRACTOR POC:

EMAIL:

PHONE:

X

BRENT W. ROWSE 910-451-2582 X 5237

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

05-Mar-2018

(RFP)

(IFB)

CALL:

Individual Training Course Team Training Facility

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

X

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______15 calendar days and complete it w ithin ________435 calendar days after receiving aw ard, notice to proceed. This performance period is X mandatory, negotiable. (See _________________________

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________0 copies to perform the w ork required are due at the place specified in Item 8 by ___________ local time ______________04 Apr 2018 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______120 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

NAVFAC MID ATLANTIC

ROICC CAMP LEJEUNE

1005 MICHAEL ROAD

CAMP LEJEUNE NC 28547-2521

N40085

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

10:30 AM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

P-1481

8. ADDRESS OFFER TO (If Other Than Item 7)

(910) 451-5629FAX:TEL: (910) 451-2582 TEL: FAX:

N4008518B6118 38

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specified below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

N4008518B6118

Section 00010 - Solicitation Contract Form

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Each

BASE BID

FFP

Price for the construction of Building D and associated site work, complete in accordance with the drawings and specifications. Refer to construction drawings CS-200 Overall Site Plan and CS201 Site Plan (Base Bid).

FOB: Destination

NET AMT

0002 1 Each Option Item No. 1

FFP

Price for the construction of Building C. Refer to construction drawings CS-200 Overall Site Plan and CS204 Site Plan (Bid Options). The price for this line item includes all applicable costs, overhead and profit for this work. The Government may unilaterally exercise the option within 120 calendar days of contract award without adjusting the price of the option or extending the contract completion date.

0003 1 Each Option Item No. 2

FFP

Price for the construction of Buildings A and B, and associated site work. Refer to construction drawings CS-200 Overall Site Plan and CS204 Site Plan (Bid Options). The price for this line item includes all applicable costs, overhead and profit for this work. The Government may unilaterally exercise the option within 120 calendar days of contract award without adjusting the price of the option or extending the contract completion date.

0004 1 Each Option Item No. 3

FFP

Price to design and provide the final, best valued Furniture, Fixtures and Equipment (FF&E) and Audio/Visual (A/V) package for the Project, complete.

Price for obtaining the services for an Interior Designer, certified by the National Council for Interior Design Qualification (NCIDQ), to prepare supporting plans and procurement data, in accordance with the design schedule. Tasks shall include but are not limited to: gathering the Activity’s project FF&E; execution of the FF&E Best Value Determination process; coordination of the building systems, and as-built conditions are identified and noted on the floor plans and construction drawings; development of Final FF&E Package to include furniture/equipment plans, procurement data sheets, cost summary, 8.5”x11” FF&E finish boards and any supplementary documentation; attend meetings with the Activity and NAVFAC MIDLANT; and perform final FF&E walk-through and punch list(s).

Refer to specification section 01 30 01.00 22 DESIGN, PROCUREMENT AND INSTALLATION OF FURNITURE, FIXTURES AND EQUIPMENT in Administrative Requirements. The price for this line item includes all applicable costs, overhead and profit for this work. The Government may unilaterally exercise the option within 120 calendar days of contract award without adjusting the price of the option or extending the contract completion date.

0005 1 Each Planned Modification Item 1

FFP

Procurement, installation, including all labor, material, equipment, transportation, and supervision required for the Furniture, Fixtures, and Equipment (FF&E) and Audio/Visual (A/V). If the Government awards the planned FF&E modification, it will be awarded at least 180 calendar days prior to the contract completion date without a schedule extension. The Government may also negotiate a bilateral time extension to issue the FF&E planned modification with fewer than 180 calendar days remaining. The price of this line item is comprised of the total cost of the Handling & Administrative Rate (HAR) plus the Government's estimated FF&E budget ($110,680.00). The total cost of the HAR shall be calculated as follows:

1. Estimated Budget: $110,680.00

2. HAR % (Not To Exceed 5%): _______% (Filled In By Bidder)

3. Total Cost of HAR (Line 1 x Line 2): $_______ (Filled In By Bidder)

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 N/A N/A N/A Government 0002 N/A N/A N/A Government 0003 N/A N/A N/A Government 0004 N/A N/A N/A Government 0005 N/A N/A N/A Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 N/A N/A N/A N/A

0002 N/A N/A N/A N/A

0003 N/A N/A N/A N/A

0004 N/A N/A N/A N/A

0005 N/A N/A N/A N/A

Section 00100 - Bidding Schedule/Instructions to Bidders

INSTRUCTIONS TO BIDDERS

Section 00100 - Bidding Schedule/Instructions to Bidders

INSTRUCTIONS TO BIDDERS

ATTACHMENTS (click the link next to “Documents” for attachments)

1. Specifications

2. Drawings

3. Erosion Control Permit

4. Stormwater Permit

5. Wastewater Permit

6. Water System Management Plan

GENERAL INFORMATION

One person may full the roles of the Superintendent and the Site Safety and Health Officer (SSHO), if duly qualified for these positions as defined in the project specifications.

However, the Quality Control (QC) Manager must be a stand-alone position.

The estimated price range is between $1,000,000 and $5,000,000.

A formal site visit will be scheduled via amendment.

REQUESTS FOR INFORMATION

All questions regarding this solicitation shall be addressed to Rachel Ashton via email at Brent.rowse@navy.mil no less than 10 working days prior to the bid opening date. Inquiries submitted after this deadline may not be answered. Pre-bid inquiries shall include an email subject line formatted as follows:

“Pre-Bid Inquiry Solicitation N40085-18-B-6118”

BID REQUIREMENTS

A complete bid submission consists of the following:

1. A completed Standard Form 1442 to include all of the required fill-in information.

2. Bid prices for all CLINs.

3. The signature of an authorized company representative on the Standard Form 1442.

4. A bid bond compliant with the requirements of FAR clause 52.228-1 Bid Guarantee.

A copy of the bid bond is acceptable at the bid opening; however, the original bid bond shall be supplied to the ROICC Camp Lejeune contracting office no later than 10 calendar days after the bid opening date.

5. Acknowledgement of solicitation amendments.

6. Completed representations and certifications in accordance with the solicitation clauses.

Incomplete bids will not be considered.

BID NOTES

1. Bids must be submitted on all line items. Failure to bid on all line items may result in the bid being rejected as non-responsive.

2. The bid for each CLIN shall include all markups (overheads, labor burden, and profit).

3. In accordance with FAR clause 52.217-5 Evaluation of Options, award will be made to the lowest responsive, responsible bidder based upon the total sum of CLINs 0001 through 0007.

4. The Government may reject a bid as nonresponsive if it is materially unbalanced. A bid is considered unbalanced when it is based upon prices significantly less than cost for some work and prices which are significantly overstated for other work.

5. The planned FF&E modification will be awarded only after Government review of the final FF&E package and will be funded separately. Requirements and details are provided in Specification Section 01 30 01.00 20 DESIGN, PROCUREMENT, AND

INSTALLATION OF FURNITURE, FIXTURES, AND EQUIPMENT.

6. The estimated value of FF&E has been supplied by the Government to provide offerors with the projected magnitude of effort. The estimated value includes the actual cost of the FF&E including freight and installation charges. The Government FF&E estimate is only an estimate; the actual value may be more or less at the time of modification award. Additional bonding is neither required nor will be compensated for the value associated with the FF&E planned modification.

7. Offerors may propose a Handling and Administration Rate (HAR) for the FF&E, which shall not exceed 5%. This fee shall account for all administrative costs, overhead, bonding fees, administration of subcontracts, profit, and all other costs associated and related to the coordination and processing of the procurement and installation of FF&E. The proposed HAR percentage will be incorporated into the contract award and will not be adjusted regardless of fluctuations from the estimated amount of FF&E. The proposed HAR is a fixed rate. The Contractor’s proposed HAR will be applied to all vendor/supplier costs for the FF&E.

8. The Contractor shall provide the final FF&E package to the Government within 90 calendar days after the option for interior design services is exercised. Should the Contractor not meet this deadline, the contract will not be extended based upon the date the FF&E modification is actually issued.

9. If awarded, the FF&E planned modification will be issued at least 180 calendar days prior to the contract completion date. The Contractor’s schedule shall take into account the award of FF&E as a modification within this timeframe. No schedule extensions will be granted if the modification is awarded at least 180 calendar days prior to the contract completion date.

BID DELIVERY INSTRUCTIONS

Bidders and/or interested parties requiring sponsorship to access Camp Lejeune to deliver bids and/or attend the bid opening shall submit the full name of the individual(s) requiring sponsorship as it appears on a valid driver’s license or state-issued identification card compliant with the 2005 Real ID Act. Should the driver’s license or state-issued identification card not be compliant with the 2005 Real ID Act, one of the following forms of identification can be presented in conjunction with the driver’s license of the vehicle operator:

1. U.S. Passport

2. U.S. Passport Card

3. U.S. Coast Guard Merchant Mariner Card

4. Personal Identity Verification (PIV) Card

5. Personal Identity Verification - Interoperable (PIV-I)

6. U.S. State Department Driver's License

7. Veteran's Health Identification Card (Issued by the U.S.Department of Veterans

Affairs)

8. U.S. Permanent Resident Card (Form I-551)

9. U.S. Certificate of Naturalization or Certificate of Citizenship (Form N-550)

10. Department of Homeland Security Employment Authorization Document (Form I-

766)

The following states have been granted an extension to the Real ID Act. Should an individual’s identification be issued from one of the following states, the preceding Real ID requirements are waived:

Alaska, American Samoa, California, Guam, Idaho, Illinois, Kentucky, Louisiana, Maine, Massachusetts, Michigan, Minnesota, Missouri, Montana, New Jersey, North Dakota, Northern Mariana Islands, New Hampshire, New York, Oklahoma, Oregon, Pennsylvania, Puerto Rico, Rhode Island, South Carolina, Virginia, US Virgin Islands, Washington

If an acceptable form of identification is not available to an individual wishing to deliver a bid and/or attend the bid opening, this must be identified in the request for sponsorship. If properly identified within five (5) working days prior to the bid opening date, the Government will coordinate an escort for the identified individual(s) to Building 1005.

The name of all individual(s) requiring sponsorship shall be submitted to Brent Rowse via email at brent.rowse@navy.mil no later than five (5) working days prior to the bid opening date. If a bidder desires sponsorship for a date prior to the bid opening date, this shall be identified in the request.

Sponsorship is required for all individuals not possessing RapidGate or DoD identification to access to Camp Lejeune.

The request for sponsorship email shall contain a subject line formatted as follows:

“Request Sponsorship for Bid Delivery, Solicitation N40085-18-B-6118”

Upon delivery, bids shall promptly be timestamped at the front desk and deposited into the bid box at the following location:

ROICC Camp Lejeune 1005 Michael Road Camp Lejeune, NC 28547

Bids shall be sealed and clearly marked with the following statement on the front of the package:

“Bid for Solicitation N40085-18-B-6118”

Bids may be delivered via the US Postal Service, UPS, FedEx, or other delivery service;

however, the responsibility lies with the bidder to ensure timely delivery.

To allow for mail delivery of bids, amendments revising the scope of work will not be posted by the Government with less than two (2) working remaining until the bid opening. If the Government determines the scope of work needs to be changed within the two (2) working days remaining until the bid opening, the bid opening date will be extended to allow prospective bidders to mail amendment acknowledgement and/or bid revisions.

POST-AWARD MINIMUM INSURANCE REQUIREMENTS (SUCCESSFUL BIDDER)

If awarded the contract, the Contractor shall procure and maintain during the entire performance under this contract the following minimum insurance coverage:

1. Comprehensive General Liability: $500,000 per occurrence.

2. Automobile Liability: $200,000 per person, $500,000 per occurrence for bodily injury, and $20,000 per occurrence for property damage.

3. Worker’s Compensation: As required by Federal, State, and Occupational Disease laws.

4. Employer’s Liability Coverage: $100,000 except in states where Worker’s

Compensation may not be written by private carriers.

5. Any other insurance policy required by the laws of the state of North Carolina.

Prior to commencement of work, the Contractor shall furnish to the ROICC Camp Lejeune contracting office a certificate of written statement demonstrating the above required insurance coverage. The policies evidencing the required insurance shall contain the cancellation language required by FAR Clause 52.228-5 Insurance – Work on a Government Installation. This required language shall address the following section:

“(b) Before commencing work under this contract, the Contractor shall notify the Contracting Officer in writing that the required insurance has been obtained. The policies evidencing required insurance shall contain an endorsement to the effect that any cancellation or any material change adversely affecting the Government’s interest shall not be effective –

(1) For such period as the laws of the State in which this contract is to be performed prescribe; or

(2) Until 30 days after the insurer or the Contractor gives written notice to the Contracting Officer, whichever period is longer.”

CLAUSES INCORPORATED BY REFERENCE

52.204-22 Alternative Line Item Proposal JAN 2017 52.214-3 Amendments To Invitations For Bids DEC 2016 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.214-34 Submission Of Offers In The English Language APR 1991 52.214-35 Submission Of Offers In U.S. Currency APR 1991 52.222-5 Construction Wage Rate Requirements--Secondary Site of the

Work

MAY 2014

52.236-27 Alt I Site Visit (Construction) (Feb 1995) - Alternate I FEB 1995

CLAUSES INCORPORATED BY FULL TEXT

52.211-14 NOTICE OF PRIORITY RATING FOR NATIONAL DEFENSE, EMERGENCY PREPAREDNESS, AND ENERGY PROGRAM USE (APR 2008)

Any contract awarded as a result of this solicitation will be DO rated order certified for national defense, emergency preparedness, and energy program use under the Defense Priorities and Allocations System (DPAS) (15 CFR 700), and the Contractor will be required to follow all of the requirements of this regulation.

(End of provision)

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a contract resulting from this solicitation.

52.217-5 EVALUATION OF OPTIONS (JUL 1990)

Except when it is determined in accordance with FAR 17.206(b) not to be in the Government's best interests, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

23.5% 6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from

Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Marine Corp Base, Camp Lejeune.

52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT--CONSTRUCTION MATERIALS (MAY 2014)

ALTERNATE I (MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American --Construction Materials” (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute shall submit the request with its offer, including the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American Act, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR

52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested--

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

52.225-12 NOTICE OF BUY AMERICAN REQUIREMENT-- CONSTRUCTION MATERIALS UNDER

TRADE AGREEMENTS (MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “designated country construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American -- Construction Materials Under Trade Agreements” (Federal Acquisition Regulation (FAR) clause 52.225-11).

(b) Requests for determination of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of FAR clause 52.225-11 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction materials, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(4)(i) of FAR clause 52.225-11.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers. (1) When an offer includes foreign construction material, other than designated country construction material, that is not listed by the Government in this solicitation in paragraph (b)(3) of FAR clause 52.225-11, the offeror also may submit an alternate offer based on use of equivalent domestic or designated country construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of FAR clause 52.225-11 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of FAR clause 52.225-11 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic or designated country construction material, and the offeror shall be required to furnish such domestic or designated country construction material. An offer based on use of the foreign construction material for which an exception was requested-- (i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be 20 percent of the bid price or $3,000,000.00, whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from:

ROICC Lejeune 1005 Micheal Road Camp Lejeune, NC 28547

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

[Insert one or more Internet addresses]

252.215-7008 ONLY ONE OFFER (OCT 2013)

(a) After initial submission of offers, the Offeror agrees to submit any subsequently requested additional cost or pricing data if the Contracting Officer notifies the Offeror that--

(1) Only one offer was received; and

(2) Additional cost or pricing data is required in order to determine whether the price is fair and reasonable or to comply with the statutory requirement for certified cost or pricing data (10 U.S.C. 2306a and FAR 15.403-3).

(b) Requirement for submission of additional cost or pricing data. Except as provided in paragraph (c) of this provision, the Offeror shall submit additional cost or pricing data as follows:

(1) If the Contracting Officer notifies the Offeror that additional cost or pricing data are required in accordance with paragraph (a) of this clause, the data shall be certified unless an exception applies (FAR 15.403-1(b)).

(2) Exceptions from certified cost or pricing data. In lieu of submitting certified cost or pricing data, the Offeror may submit a written request for exception by submitting the information described in the following paragraphs. The Contracting Officer may require additional supporting information, but only to the extent necessary to determine whether an exception should be granted, and whether the price is fair and reasonable.

(i) Identification of the law or regulation establishing the price offered. If the price is controlled under law by periodic rulings, reviews, or similar actions of a governmental body, attach a copy of the controlling document, unless it was previously submitted to the contracting office.

(ii) Commercial item exception. For a commercial item exception, the Offeror shall submit, at a minimum, information on prices at which the same item or/similar items have previously been sold in the commercial market that is adequate for evaluating the reasonableness of the price for this acquisition. Such information may include—

(A) For catalog items, a copy of or identification of the catalog and its date, or the appropriate pages for the offered items, or a statement that the catalog is on file in the buying office to which the proposal is being submitted. Provide a copy or describe current discount policies and price lists (published or unpublished), e.g., wholesale, original equipment manufacturer, or reseller. Also explain the basis of each offered price and its relationship to the established catalog price, including how the proposed price relates to the price of recent sales in quantities similar to the proposed quantities;

(B) For market-priced items, the source and date or period of the market quotation or other basis for market price, the base amount, and applicable discounts. In addition, describe the nature of the market; or

(C) For items included on an active Federal Supply Service Multiple Award Schedule contract, proof that an exception has been granted for the schedule item.

(3) The Offeror grants the Contracting Officer or an authorized representative the right to examine, at any time before award, books, records, documents, or other directly pertinent records to verify any request for an exception under this provision, and the reasonableness of price. For items priced using catalog or market prices, or law or regulation, access does not extend to cost or profit information or other data relevant solely to the Offeror's determination of the prices to be offered in the catalog or marketplace.

(4) Requirements for certified cost or pricing data. If the Offeror is not granted an exception from the requirement to submit certified cost or pricing data, the following applies:

(i) The Offeror shall prepare and submit certified cost or pricing data and supporting attachments in accordance with the instructions contained in Table 15-2 of FAR 15.408, which is incorporated by reference with the same force and effect as though it were inserted here in full text. The instructions in Table 15-2 are incorporated as a mandatory format to be used, unless the Contracting Officer and the Offeror agree to a different format.

(ii) As soon as practicable after agreement on price, but before contract award (except for unpriced actions such as letter contracts), the offeror shall submit a Certificate of Current Cost or Pricing Data, as prescribed by FAR 15.406- 2.

(c) If the Offeror is the Canadian Commercial Corporation, certified cost or pricing data are not required. If the Contracting Officer notifies the Canadian Commercial Corporation that additional data other than certified cost or pricing data are required in accordance with 225.870-4(c), the Canadian Commercial Corporation shall obtain and provide the following:

(1) Profit rate or fee (as applicable).

(2) Analysis provided by Public Works and Government Services Canada to the Canadian Commercial Corporation to determine a fair and reasonable price (comparable to the analysis required at FAR 15.404-1).

(3) Data other than certified cost or pricing data necessary to permit a determination by the U.S. Contracting Officer that the proposed price is fair and reasonable [U.S. Contracting Officer to provide description of the data required in accordance with FAR 15.403-3(a)(1) with the notification].

(4) As specified in FAR 15.403-3(a)(4), an offeror who does not comply with a requirement to submit data that the U.S. Contracting Officer has deemed necessary to determine price reasonableness or cost realism is ineligible for award unless the head of the contracting activity determines that it is in the best interest of the Government to make the award to that offeror.

(d) If negotiations are conducted, the negotiated price should not exceed the offered price.

5252.214-9301 NOTICE TO BIDDERS (JUN 1994)

(a) Under the bidding items furnished on Standard Form 1442 (Solicitation, Offer, and Award) the bidder shall state prices for each basis for bid given hereinafter: (check if applicable)

X (i) Base Bid Item 0001 shall be the entire work complete in accordance with the drawings and specifications, but not including work indicated or specified to be provided under any of the other bid items.

(ii) Additive Bid Items shall be for the work identified in and not included in any other bid item.

BIDS MUST BE SUBMITTED ON ALL ITEMS. FAILURE TO PROPOSE ON ALL ITEMS MAY RESULT IN

THE BID BEING REJECTED AS NON-RESPONSIVE.

(b) All hand delivered bids must be deposited in the bid box by the reception desk at

ROICC Lejeune 1005 Michael Road Camp Lejeune, NC 28547 prior to the time and date set for bid opening. Any bids submitted by hand after the time set for receipt will be stamped with the date and hour of receipt and held unopened until after award. The file shall be documented in accordance with FAR 14.304-4.

Section 00600 - Representations & Certifications

52.204-7 System for Award Management OCT 2016 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

252.204-7007 Alternate A, Annual Representations and Certifications JAN 2015 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting

OCT 2016

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (NOV 2017)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 236220.

(2) The small business size standard is $36,500,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2; Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(vii) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xvii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xviii) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xix) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xx) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $77,533, the provision with its Alternate II applies.

(D) If the acquisition value is $77,533 or more but is less than $100,000, the provision with its Alternate III applies.

(xxi) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225- 5.

(xxii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiii) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxiv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( )…