N0042117R0018_DRAFT_RFP_Section_F.pdf

N00421-17-R-0018

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 N/A N/A N/A N/A

0002 N/A N/A N/A N/A

0003 N/A N/A N/A N/A

0101 N/A N/A N/A N/A

CLAUSES INCORPORATED BY REFERENCE

52.242-15 Alt I Stop-Work Order (Aug 1989) - Alternate I APR 1984

52.242-17 Government Delay Of Work APR 1984

52.247-34 F.O.B. Destination NOV 1991

252.247-7023 Transportation of Supplies by Sea APR 2014

CLAUSES INCORPORATED BY FULL TEXT

52.215-6 PLACE OF PERFORMANCE (OCT 1997)

(a) The offeror or respondent, in the performance of any contract resulting from this solicitation, [ ] intends, [

] does not intend [check applicable block] to use one or more plants or facilities located at a different address from the address of the offeror or respondent as indicated in this proposal or response to request for information.

(b) If the offeror or respondent checks ``intends'' in paragraph (a) of this provision, it shall insert in the following spaces the required information:

Place of performance (street address, city, state,county, zip code)

Name and address of owner and operator of the plant or facility if other than offeror or respondent

N00421-17-R-0018

5252.211-9507 PERIOD OF PERFORMANCE (NAVAIR)(SEP 2013)

(a) The contract shall commence on [insert effective date TBD at award ] and shall continue for a period of sixty months]. However, the period of performance may be extended in accordance with the option provisions contained herein.

(b) If DFAR Clause 252.216-7006, "Ordering", is incorporated into this contract, then the period in which the

Government can issue orders under the contract will be extended at the exercise of an option, and extended to the end of that option period.

minim5252.216-9506 MINIMUM AND MAXIMUM QUANTITIES (NAVAIR)(MAR 1999)

As referred to in paragraph (b) of FAR 52.216-22 " Indefinite Quantity" of this contract, the contract minimum quantity is $10,000.00 IAW Para. 3.6.2 Sec. C of the Performance Work Statement (PWS); the maximum quantity is the ceiling value of the contract.

5252.247-9505 TECHNICAL DATA AND INFORMATION (NAVAIR)(FEB 1995)

Technical Data and Information shall be delivered in accordance with the requirements of the Contract Data

Requirements List, DD Form 1423, Exhibit A attached hereto, and the following:

(a) The contractor shall concurrently deliver technical data and information per DD Form 1423, Blocks 12 and 13

(date of first/subsequent submission) to all activities listed in Block 14 of the DD Form 1423 (distribution and addresses) for each item. Complete addresses for the abbreviations in Block 14 are shown in paragraph (g) below.

Additionally, the technical data shall be delivered to the following cognizant codes, who are listed in Block 6 of the

DD Form 1423.

(1) PCO, Code 2.5.1.13

(2) ACO, Code, TBD at contract award

(b) Partial delivery of data is not acceptable unless specifically authorized on the DD Form 1423, or unless approved in writing by the PCO.

(c) The Government review period provided on the DD Form 1423 for each item commences upon receipt of all required data by the technical activity designated in Block 6.

(d) A copy of all other correspondence addressed to the Contracting Officer relating to data item requirements

(i.e., status of delivery) shall also be provided to the codes reflected above and the technical activity responsible for the data item per Block 6, if not one of the activities listed above.

(e) The PCO reserves the right to issue unilateral modifications to change the destination codes and addresses for all technical data and information at no additional cost to the Government.

(f) Unless otherwise specified in writing, rejected data items shall be resubmitted within thirty (30) days after receipt of notice of rejection.

(g) DD Form 1423, Block 14 Mailing Addresses: 21983 Bundy Rd. BLDG 441 Patuxent River MD 20670