N0002425R4425_A0001.pdf

CODE

(Hour)

PAGE(S)

until local time

X

A

X B

X C X D

EX

X

G

F 163 - 177

178 - 205

X H 206 - 217 jourdan.e.jenkins.mil@us.navy .mil

RATING PAGE OF PAGES

7. ISSUED BY

(Date)

IMPORTANT - Award will be made on this Form, or on Standard Form 26, or by other authorized official written notice.

Previous Edition is Unusable 33-134 STANDARD FORM 33 (REV. 9-97)

Prescribed by GSA

FAR (48 CFR) 53.214(c)

DO 1 217

(If other than Item 7)

15A. NAME 16. NAME AND TITLE OF PERSON AUTHORIZED TO

AND

ADDRESS

SIGN OFFER (Type or print)

OF

OFFEROR

AMENDMENT NO. DATE

15B. TELEPHONE NO (Include area code) 17. SIGNATURE15C. CHECK IF REMITTANCE ADDRESS

IS DIFFERENT FROM ABOVE - ENTER

SUCH ADDRESS IN SCHEDULE.

18. OFFER DATE

1. THIS CONTRACT IS A RATED ORDER

UNDER DPAS (15 CFR 700)

2. CONTRACT NO.

N00024 8. ADDRESS OFFER TO

See Item 7

9. Sealed offers in original and copies for furnishing the supplies or services in the Schedule will be received at the place specified in Item 8, or if handcarried, in the depository located in

CAUTION - LATE Submissions, Modifications, and Withdrawals: See Section L, Provision No. 52.214-7 or 52.215-1. All offers are subject to all terms and conditions contained in this solicitation.

10. FOR INFORMATION

CALL:

A. NAME (NO COLLECT CALLS)

JOURDAN E JENKINS (202)781-1139

11. TABLE OF CONTENTS

SOLICITATION/ CONTRACT FORM

SUPPLIES OR SERVICES AND PRICES/ COSTS

2 - 77

X I CONTRACT CLAUSES

DESCRIPTION/ SPECS./ WORK STATEMENT X

PACKAGING AND MARKING

78 - 117

118 - 119

J LIST OF ATTACHMENTS

INSPECTION AND ACCEPTANCE

DELIVERIES OR PERFORMANCE

120 - 124

125 - 131 X K

REPRESENTATIONS, CERTIFICATIONS AND

OTHER STATEMENTS OF OFFERORS

CONTRACT ADMINISTRATION DATA 132 - 141 X

SPECIAL CONTRACT REQUIREMENTS

OFFER (Must be fully completed by offeror) 142 - 143 X M

L INSTRS., CONDS., AND NOTICES TO OFFERORS

EVALUATION FACTORS FOR AWARD

NOTE: Item 12 does not apply if the solicitation includes the provisions at 52.214-16, Minimum Bid Acceptance Period.

is inserted by the offeror) from the date for receipt of offers specified above, to furnish any or all items upon which prices are offered at the price set opposite each item, delivered at the designated point(s), within the time specified in the schedule.

13. DISCOUNT FOR PROMPT PAYMENT

(See Section I, Clause No. 52.232-8)

14. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments

AMENDMENT NO. DATE

to the SOLICITATION for offerors and related documents numbered and dated):

FACILITY

12. In compliance with the above, the undersigned agrees, if this offer is accepted within calendar days (60 calendar days unless a different period

SOLICITATION, OFFER AND AWARD

X

(X) SEC. DESCRIPTION (X) SEC. DESCRIPTION PAGE(S)

PART I - THE SCHEDULE

26. NAME OF CONTRACTING OFFICER (Type or print) 27. UNITED STATES OF AMERICA 28. AWARD DATE

EMAIL:TEL: (Signature of Contracting Officer)

CODE CODE

B. TELEPHONE (Include area code) C. E-MAIL ADDRESS

AWARD (To be completed by Government)

19. ACCEPTED AS TO ITEMS NUMBERED 20. AMOUNT 21. ACCOUNTING AND APPROPRIATION

22. AUTHORITY FOR USING OTHER THAN FULL AND OPEN COMPETITION:

10 U.S.C. 2304(c)( ) 41 U.S.C. 253(c)( ) (4 copies unless otherwise specified)

23. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

24. ADMINISTERED BY (If other than Item 7) CODE 25. PAYMENT WILL BE MADE BY CODE

PART IV - REPRESENTATIO NS AND INSTRUCTIO NS

PART III - LIST O F DO CUMENTS, EXHIBITS AND O THER ATTACHMENTS

144 - 161

PART II - CO NTRACT CLAUSES

NAVAL SEA SYSTEMS COMMAND (HQ)

1333 ISAAC HULL AVE SE

WASHINGTON NAVY YARD DC 20376-2030

FAX:

TEL:

FAX:

TEL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SOLICITATION

6. REQUISITION/PURCHASE NO.

N0002420FR62083

5. DATE ISSUED

08 Jul 2024

4. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

[ X ]

3. SOLICITATION NO.

N0002425R4425

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

CLIN

Number

1 Lot

RESERVED

FFP

FOB: Destination

PURCHASE REQUEST NUMBER: N0002420FR62083

PSC CD: J999

NET AMT

RESERVED

FFP

FOB: Destination

CDRLs

FFP

Contracts Data Requirements Lists (CDRLs)

FOB: Destination

TYCOM Base

FFP

PREPARE FOR AND ACCOMPLISH REPAIR AND ALTERATIONS

ONBOARD USS BOXER (LHD 4) DURING FY25 SELECTED RESTRICTED

AVAILABILITY (SRA) (Non-prorated WIs – See attachment J-4 for list)

The Contractor shall prepare for and accomplish repair and alterations during the

Selected Restricted Availability (SRA) onboard USS Boxer (LHD 4) as specified in the statement of work provided herein and in accordance with standard items, work item specification package drawings, test procedures, and other detailed data as included in Attachments J-1 and J-2.

See Notes A, B, & D-F

FOB: Destination

TYCOM Alts

FFP

PREPARE FOR AND ACCOMPLISH REPAIR AND ALTERATIONS

in the statement of work provided herein and in accordance with standard items, TYCOM - Habitability

FFP

PREPARE FOR AND ACCOMPLISH REPAIR AND ALTERATIONS

in the statement of work provided herein and in accordance with standard items, Prorates

FFP

PREPARE FOR AND ACCOMPLISH REPAIR AND ALTERATIONS

AVAILABILITY (SRA) (Prorated WIs – See attachment J-4 for list) in the statement of work provided herein and in accordance with standard items, NAVSEA OPN

FFP

PREPARE FOR AND ACCOMPLISH REPAIR AND ALTERATIONS

in the statement of work provided herein and in accordance with standard items, NAVSEA OMN

FFP

PREPARE FOR AND ACCOMPLISH REPAIR AND ALTERATIONS

in the statement of work provided herein and in accordance with standard items, OPTION Bargelant

FFP

PREPARE FOR AND ACCOMPLISH REPAIR AND ALTERATIONS

in the statement of work provided herein and in accordance with standard items, See Notes A - F

OPTION Fuel Assistance & Tow

FFP

PREPARE FOR AND ACCOMPLISH REPAIR AND ALTERATIONS

in the statement of work provided herein and in accordance with standard items, OPTION SA 80156K, AN/SLQ-32(V)6 Hardware Upgd

FFP

ShipAlt LHD1-80156K, AN/SLQ-32(V)6 Hardware Upgrade; accomplish

(OPTION ITEM)

PREPARE FOR AND ACCOMPLISH REPAIR AND ALTERATIONS

in the statement of work provided herein and in accordance with standard items, OPTION SA 95520K & 95532K, CASS RF-A & RF-B Ins

FFP

ShipAlt 95520K and 95532K, Consolidated Automated Support System (CASS)

RF-A and RF-B Installation, Alteration Installation Team (AIT) Support Service;

provide (OPTION ITEM) in the statement of work provided herein and in accordance with standard items, OPTION SA 96483K, CAC2S Afloat Hardware, AIT

FFP

ShipAlt 96483K, CAC2S Afloat Hardware, Alteration Installation Team (AIT)

Support Service; provide (OPTION ITEM) in the statement of work provided herein and in accordance with standard items, OPTION SA 88635K, CIWS Blk 1B Overhaul, AIT

FFP

ShipAlt 88635K, Close In Weapons System (CIWS) Block 1B Overhaul, Alteration Installation Team (AIT) Support Service; provide (OPTION ITEM) in the statement of work provided herein and in accordance with standard items, OPTION SA 86222K, NFG Backfit Phase I, AIT

FFP

ShipAlt LHD4-86222K, Next Generation Fathometer (NGF) Backfit Phase I, Alteration Installation Team AIT) Support Service; provide (OPTION ITEM) in the statement of work provided herein and in accordance with standard items, OPTION SA 93698K, EPLRS Tri-Band Antenna Mod

FFP

ShipAlt LHD4-93698K, EPLRS Tri-Band Antenna Modification, Alteration

Installation Team (AIT) Support Service; provide (OPTION ITEM) in the statement of work provided herein and in accordance with standard items, OPTION SA 94058K, EMUT MUOS Rep Ant, AIT

FFP

ShipAlt LHD4-94058K, Enhanced Manpack UHF Terminal (EMUT) Mobile User

Objective System (MUOS) Replacement Antenna, Alteration Installation Team

(AIT) Support Service; provide (OPTION ITEM) in the statement of work provided herein and in accordance with standard items, OPTION SA 93584K, AIS V1 Cyber Hardening, AIT

FFP

ShipAlt LHD4-93584K, AIS V1 Cyber Hardening, Alteration Installation Team in the statement of work provided herein and in accordance with standard items, OPTION SA 93526K, GPNTS(V)8 Alteration, AIT

FFP

ShipAlt LHD4-93526K, GPNTS(V)8 Alteration, Alteration Installation Team in the statement of work provided herein and in accordance with standard items, OPTION SA 99094K, Navy Cash 2.0, Hardware, AIT

FFP

ShipAlt LHD1-99094K, Navy Cash 2.0, Hardware, Alteration Installation Team in the statement of work provided herein and in accordance with standard items, OPTION SA 95037K, NFSA Hardware Refresh, AIT

FFP

ShipAlt LHD1-95037K, NAVAIR Fleet System Array (NFSA) HARDWARE

REFRESH, Alteration Installation Team (AIT) Support Service; provide (OPTION

ITEM)

in the statement of work provided herein and in accordance with standard items, OPTION SA 93785K, SWD 93786, Upgd to SYY-1 HW

FFP

ShipAlt LHD4-93785K, SWD 93786, Upgrade to SYY-1 HW, Alteration

Installation Team (AIT) Support Service; provide (OPTION ITEM) in the statement of work provided herein and in accordance with standard items, OPTION SA 93868K, I-STALKER HW, AIT Spt Svc

FFP

ShipAlt 93868K, I-STALKER HW, Alteration Installation Team (AIT) Support

Service; provide (OPTION ITEM) in the statement of work provided herein and in accordance with standard items, OPTION SA 94282K, RAM MK 31 Mod 5, AIT Spt Svc

FFP

ShipAlt LHD1-94282K, RAM MK 31 Mod 5, Alteration Installation Team (AIT) in the statement of work provided herein and in accordance with standard items, OPTION SA 95267K, Moriah AAS AIT Spt Svc

FFP

ShipAlt LHD1-95267K, Moriah Aviation Land and Launch Enclave (AAS), Alteration Installation Team (AIT) Support Service; provide (OPTION ITEM) in the statement of work provided herein and in accordance with standard items, OPTION SA FC81023, URN-32 Shipboard TACAN, AIT

FFP

ShipAlt LHD1-FC81023, URN-32 Shipboard TACAN, Alteration Installation

Team (AIT) Support Service; provide (OPTION ITEM) in the statement of work provided herein and in accordance with standard items, OPTION SA 97962K, ShipAlt Title, AIT Spt Svc

FFP

ShipAlt 97962K, ShipAlt Title, Alteration Installation Team (AIT) Support

Service; provide (OPTION ITEM) in the statement of work provided herein and in accordance with standard items, OPTION SA 92525K, MF-TDMA MODEM SUPPOR, AIT

FFP

ShipAlt 92525K, MF-TDMA MODEM SUPPOR, Alteration Installation Team in the statement of work provided herein and in accordance with standard items, OPTION SA 93699K, IRIDIUM ANTENNA, AIT

FFP

ShipAlt 93699K, IRIDIUM ANTENNA, Alteration Installation Team (AIT) in the statement of work provided herein and in accordance with standard items, OPTION SA 92881K, NMT MODEM SPIRAL ONE, AIT

FFP

ShipAlt 92881K, NMT MODEM SPIRAL ONE, Alteration Installation Team in the statement of work provided herein and in accordance with standard items, OPTION SAs 96363K & 96363K AIT Spts Svc

FFP

ShipAlt LHD1-96363K, Electric Plant Control and Monitoring System Installation;

accomplish & ShipAlt LHD1-96363K, EP PMP Installation, Alteration Installation

Team (AIT) Support Service; provide in the statement of work provided herein and in accordance with standard items, OPTION SA 96362K, Circuit Breaker Upgrade, AIT

FFP

ShipAlt LHD1-96362K, Circuit Breaker Upgrade, Alteration Installation Team

(AIT) Support Service; provide in the statement of work provided herein and in accordance with standard items, OPTION TYCOM Option

FFP

PREPARE FOR AND ACCOMPLISH REPAIR AND ALTERATIONS

in the statement of work provided herein and in accordance with standard items, OPTION Growth Reservation for CLIN 0004

FFP

Growth Reservation Associated with CLIN 0004. See attachment J-4.

Growth Reservation for CLIN 0004

See Notes A, B and D - F

Growth Reservation for CLIN 0004

Growth Reservation for CLIN 0005

Growth Reservation Associated with CLIN 0005. See attachment J-4.

Growth Reservation for CLIN 0005

OPTION Growth Reservation for CLIN 0005

Growth Reservation for CLIN 0006

Growth Reservation Associated with CLIN 0006. See attachment J-4.

Growth Reservation for CLIN 0007

Growth Reservation Associated with CLIN 0007. See attachment J-4.

Growth Reservation for CLIN 0008

Growth Reservation Associated with CLIN 0008. See attachment J-4.

Growth Reservation for CLIN 0009

Growth Reservation Associated with CLIN 0009. See attachment J-4.

OPTION Growth Reservation for CLIN 0010

Growth Reservation Associated with CLIN 0010. See attachment J-4.

OPTION Growth Reservation for CLIN 0011

Growth Reservation Associated with CLIN 0011. See attachment J-4.

OPTION Growth Reservation for CLIN 0012

Growth Reservation Associated with CLIN 0012. See attachment J-4.

OPTION Growth Reservation for CLIN 0013

Growth Reservation Associated with CLIN 0013. See attachment J-4.

OPTION Growth Reservation for CLIN 0014

Growth Reservation Associated with CLIN 0014. See attachment J-4.

OPTION Growth Reservation for CLIN 0015

Growth Reservation Associated with CLIN 0015. See attachment J-4.

OPTION Growth Reservation for CLIN 0016

Growth Reservation Associated with CLIN 0016. See attachment J-4.

OPTION Growth Reservation for CLIN 0017

Growth Reservation Associated with CLIN 0017. See attachment J-4.

OPTION Growth Reservation for CLIN 0018

Growth Reservation Associated with CLIN 0018. See attachment J-4.

OPTION Growth Reservation for CLIN 0019

Growth Reservation Associated with CLIN 0019. See attachment J-4.

OPTION Growth Reservation for CLIN 0020

Growth Reservation Associated with CLIN 0020. See attachment J-4.

OPTION Growth Reservation for CLIN 0021

Growth Reservation Associated with CLIN 0021. See attachment J-4.

OPTION Growth Reservation for CLIN 0022

Growth Reservation Associated with CLIN 0022. See attachment J-4.

OPTION Growth Reservation for CLIN 0023

Growth Reservation Associated with CLIN 0023. See attachment J-4.

OPTION Growth Reservation for CLIN 0024

Growth Reservation Associated with CLIN 0024. See attachment J-4.

OPTION Growth Reservation for CLIN 0025

Growth Reservation Associated with CLIN 0025. See attachment J-4.

OPTION Growth Reservation for CLIN 0026

Growth Reservation Associated with CLIN 0026. See attachment J-4.

OPTION Growth Reservation for CLIN 0027

Growth Reservation Associated with CLIN 0027. See attachment J-4.

OPTION Growth Reservation for CLIN 0028

Growth Reservation Associated with CLIN 0028. See attachment J-4.

OPTION Growth Reservation for CLIN 0029

Growth Reservation Associated with CLIN 0029. See attachment J-4.

OPTION Growth Reservation for CLIN 0030

Growth Reservation Associated with CLIN 0030. See attachment J-4.

OPTION Growth Reservation for CLIN 0031

Growth Reservation Associated with CLIN 0031. See attachment J-4.

OPTION Growth Reservation for CLIN 0032

Growth Reservation Associated with CLIN 0032. See attachment J-4.

OPTION Growth Reservation for CLIN 0033

Growth Reservation Associated with CLIN 0033. See attachment J-4.

OPTION Growth Reservation for CLIN 0034

Growth Reservation Associated with CLIN 0034. See attachment J-4.

OPTION Incentive Reservation for CLIN 0035

Incentive Reservation Associated with CLIN 0035. See attachment J-4.

OPTION Incentive Reservation for CLIN 0036

Incentive Reservation Associated with CLIN 0036. See attachment J-4.

OPTION Incentive Reservation for CLIN 0037

Incentive Reservation Associated with CLIN 0037. See attachment J-4.

Incentive Reservation for CLIN 0038

Incentive Reservation Associated with CLIN 0038. See attachment J-4.

Incentive Reservation for CLIN 0039

Incentive Reservation Associated with CLIN 0039. See attachment J-4.

Incentive Reservation for CLIN 0040

Incentive Reservation Associated with CLIN 0040. See attachment J-4.

Incentive Reservation for CLIN 0041

Incentive Reservation Associated with CLIN 0041. See attachment J-4.

OPTION Incentive Reservation for CLIN 0042

Incentive Reservation Associated with CLIN 0042. See attachment J-4.

Incentive Reservation for CLIN 0043

Incentive Reservation Associated with CLIN 0043. See attachment J-4.

Incentive Reservation for CLIN 0045

Incentive Reservation Associated with CLIN 0045. See attachment J-4.

Incentive Reservation for CLIN 0046

Incentive Reservation Associated with CLIN 0046. See attachment J-4.

OPTION Incentive Reservation for CLIN 0048

Incentive Reservation Associated with CLIN 0048. See attachment J-4.

OPTION Incentive Reservation for CLIN 0069

Incentive Reservation Associated with CLIN 0069. See attachment J-4.

OPTION Incentive Reservation for CLIN 0071

Incentive Reservation Associated with CLIN 0071. See attachment J-4.

OPTION SA 85154k, Int Ship Control Install

FFP

PREPARE FOR AND ACCOMPLISH REPAIR AND ALTERATIONS

in the statement of work provided herein and in accordance with standard items, OPTION Growth Reservation for CLIN 0086

Growth Reservation Associated with CLIN 0086. See attachment J-4.

OPTION Incentive Reservation for CLIN 0087

Incentive Reservation Associated with CLIN 0087. See attachment J-4.

OPTION SA 85154K, LHD SCS Mod, AIT Spt Svc

FFP

PREPARE FOR AND ACCOMPLISH REPAIR AND ALTERATIONS

in the statement of work provided herein and in accordance with standard items, See Notes A-F

OPTION Growth Reservation for CLIN 0089

Growth Reservation Associated with CLIN 0086. See attachment J-4.

OPTION Delivery Incentive

FFP

The amount of any incentive payable to the contractor, pursuant to the Section B

Special Incentive clause, shall be evaluated and determined in accordance with the procedures set forth in Tables 1 & 2. The total maximum amount available pursuant to this incentive is $15,000,000.

A. General

The USS BOXER’s (LHD 4) maintenance and modernization is required at prescribed intervals within its life cycle to sustain its safety and tactical integrity for extended periods of deployment. The goal of this availability is to complete the work required within the USS BOXER’s FY25 Selected Restricted Availability on time and return the ship back to the Fleet as scheduled so that the vessel can perform assigned missions and continue to be an operating asset to the Navy.

The ability to maintain the USS BOXER FY25 Selected Restricted Availability within its solicited schedule is paramount to maintaining the Navy’s operating fleet. In order to attain this goal, it is in the Government’s best interest to incentivize contractor performance, and to reward contractor efforts that substantially contribute to obtaining superior performance and overcoming execution delays and challenges within schedule. Therefore, the

Government is interested in incentivizing the completion of the availability in a manner reasonably expected to lead to this outcome.

The delivery of USS BOXER on or before 5 August 2026 is of paramount importance to the Navy. In order to attain this goal, it is in the Navy’s best interest to incentivize Contractor delivery, as follows, by rewarding the Contractor, under CLIN 0004-0034, 0086, 0089 for achieving the following milestones:

Table 1: Incentive Earned Calculation

CLIN/

SLIN

Event #

Milestone Event/ Achievement

Milestone

Date

Maximum

Incentive

Available

Schedule

Adjustment

Factor

Incentive

Earned

0004-

0034/0086

/0089

Complete Availability

5 August 2026

$15,000,000 xSchedule

Adjustment

Factor

TBD

Total Maximum Incentive Available $15,000,000 TBD

B. Incentive Available

The amount of any incentive payable to the Contractor, pursuant to this clause, shall be determined in accordance with Table 2. The total maximum incentive available pursuant to this note is $15,000,000.

C. Incentive Evaluation

To be eligible for any incentive herein, the Contractor shall deliver the USS BOXER on or before 5 August 2026.

The incentive available will not change as a result of growth and new work.

Table 2: Schedule Adjustment Factor

MILESTONE: Complete Availability SCHEDULE ADJUSTMENT FACTOR

Achieve Milestone Schedule Date 100%

1 to 7 day delay (within 1 weeks) 90%

8 to 14 day delay (between 1 and 2 weeks) 80%

15 to 21 day delay (between 2 and 3 weeks) 70%

22 to 28 day delay (between 3 and 4 weeks) 60%

29 to 35 day delay (between 4 and 5 weeks) 50%

36 to 42 day delay (between 5 and 6 weeks) 40%

43 and 49 day delay (between 6 and 7 weeks) 30%

50 to 56 day delay (between 7 and 8 weeks) 20%

57 to 63 delay (between 8 and 9 weeks) 10%

Greater than a 67 day delay (greater than 9 weeks) 0%

D. Finality Determination of the Performance Incentive

The determination of the amount of the Performance Incentive, if any, to be paid to the Contractor is a unilateral decision made solely at the discretion of the PCO.

E. Changes to the DETERMINATION OF SPECIAL INCENTIVE language

Any changes to the language, terms or conditions associated with this incentive shall only be authorized by the PCO.

NOTE A: LEVEL OF EFFORT TO COMPLETION –SHIP REPAIR

1. The Contractor agrees to provide the level of effort to completion (LOE to Completion) in the performance of growth CLINs in the execution of the USS BOXER FY25 SRA:

a. 140, 891 direct labor hours (labor hours) and $5,099,356 ($TBD fully burdened) materials to complete expected, within scope growth work on the USS BOXER FY25 SRA work package under CLINs 0035 – 0071, 0087, & 0090.

2. The total LOE to Completion for the performance of the above growth CLINs shall be comprised of labor hours and the associated material required to support the expected, within scope growth. The mix of labor hours and material may be adjusted. Adjustments to the labor hour and material mix will be documented via weekly

Technical Direction Letter (TDL) and subsequently unilaterally adjusted via contract modification. The

Government reserves the right to reconcile the weekly TDLs via unilateral modification at the Administrative

Contracting Officer’s (ACO) discretion.

3. LOE to Completion obligations specified above shall only include effort performed in direct support of this contract and shall not include time and effort expended on such things as local travel to and from an employee's usual work location, uncompensated effort while on travel status, truncated lunch periods, work (actual or inferred) at an employee's residence or other non-work locations.

4. LOE to Completion labor hours and material are within the scope and pricing of this contract and are not subject to an equitable adjustment under FAR 52.243-1 ‘Changes – Fixed Price’. The utilization of LOE to Completion is at the discretion of the Contracting Officer and subject to the schedule phasing identified in Note F.

5. If, in the opinion of the Contractor, any effort directed in the Growth Management Request Form (GMR) calls for effort outside the scope of the contract, the Contractor shall notify the Administrative Contracting Officer

(ACO) in writing within two (2) working days after the receipt of any such direction. In the event of a cost dispute, the ACO may unilaterally authorize hours and material against LOE work. The Contractor shall not proceed with the work directed by the GMR unless and until the Contractor is notified by the ACO to proceed with the directed work. The Contractor is required to proceed with the directed work as directed by the ACO.

Thereafter, any remaining disagreement shall be addressed in accordance with FAR 52.233-1(Alt. 1) ‘Disputes.’

Additionally, if the cost of performing the disputed direction exceeds $100,000, the Contractor is required to comply with FAR 52.243-6 ‘Change Order Accounting.’

6. The labor hours and material requirements listed in Section B, Note A, paragraph 1 above are part of this contract. Prime contractor efforts shall be deducted from the labor hours allocated. Subcontractor efforts and materials shall be deducted from the materials allocated. The balance of labor hours and materials remaining in the LOE to Completion CLINs will be recouped by the Government via final contract modification at the end of the availability.

7. Only authorized direct production labor hours shall be deducted from the LOE to Completion direct labor hour ceiling set forth in Section B, Note A, paragraph 1 above. Per Note B paragraph 2 below, all non-production labor shall be included in the Contractor’s fully burdened labor rate. Non-production hours shall not be included in pricing submitted in support of growth issued under the LOE to Completion CLINs. Additionally, Contractor

LOE to Completion pricing shall not include any allowance for technical representatives or for any other

Government directed source unless specifically directed by the Contracting Officer.

8. Only authorized material dollars shall be deducted from LOE to Completion material reservation set forth in

Section B, Note A, paragraph 1 above. This material reservation consists of the total cost of materials and subcontractor efforts proposed. All subcontractor quotes shall be included in the Change Order Price Analysis

(COPA) as per Section C, paragraph 1.13. Material dollars may include freight or duties if specifically itemized on the invoice for the material. The Contractor shall not be allowed to add material handling charges, overhead

(including G&A), or profit into the settled cost of materials deducted from the material reservation.

9. The information received in the consolidated final report required by Section C paragraph 6.6 will be used by the ACO in the issuance of one contract modification based on the information received in the final report identified in Section C below, which will be a final settlement for all LOE to Completion labor hours and material dollars. Once the number of labor hours and materials for directed work has been settled, neither party shall be entitled to an adjustment because the expended labor hours and materials differ from the settled price.

This shall not preclude an adjustment otherwise permitted by law and regulation; e.g. fraud, product substitution, defective workmanship or materials. Each directed work shall receive approval by the

SUPERVISOR and the ACO. “SUPERVISOR” as defined in NAVSEA Standard Item (NSI) 009-01, paragraph

4.3, refers to the local Government activity responsible for the execution and contract administration of Navy maintenance and modernization work.

NOTE B: FIXED SHIP REPAIR LABOR AND MATERIAL BURDEN RATES FOR GROWTH AND

NEW WORK

SCHEDULE OF PRICES / RATES: SHIP REPAIR LABOR RATE (FULLY BURDENED)

1. The Contractor’s fully burdened ship repair labor rate will be used for negotiating growth; and new work to be performed under this contract. The contractor agrees that the number of hours included in its price proposal submitted in response to Requests for Contract Changes (RCCs), Growth Management Requests (GMRs) and

Reservation Task Requests (RTRs) shall include only direct production hours. For these purposes, direct production hours are for skilled labor at the journeyman level expended in direct production including but not limited to the following functions:

Abrasive cleaning/blasting

Fire Watch

Welding

Burning

Brazing

Carpentry

Machinists (inside and outside)

Electrical Work

Electronic Work

Engineering

Design Support

Lagging

Ship-fitting

Boiler-making

Painting

Sheet-metal Work

Pipefitting

Rigging

General Labor

Staging/Scaffolding

Diesel Mechanics

2. The fully burdened ship repair labor rate proposed by the contractor listed in paragraph 7 below shall include all costs associated with support functions (whether charged directly or indirectly by the offeror’s accounting systems) provided in support of the direct production functions listed in paragraph 1 above. Support functions shall be considered to be included in the offeror’s fully burdened ship repair labor rate for direct production hours. Labor hours for the below support functions shall not be separately proposed, including in support of subcontractors. Support functions include, and are not limited to, those types listed below:

Testing

Quality Assurance

Execution Planning

Cleaning (except tank cleaning)

Supervision (all types, including, but not limited to supervision of trades, support personnel and subcontractors)

Security

Surveying

Administration

Transportation

Purchasing

Staff

Lofting

Other indirect support

Handling & Warehousing

Safety/Environmental

Program Management

3. The fully burdened ship repair labor rate is a fixed hourly rate that includes all wages, (i.e. straight time, overtime, shift differential, holiday time, etc.), overhead, all other indirect costs, general and administrative expenses, Facilities Capital Cost of Money (FCCOM) and profit. The fully burdened ship repair labor rate represents a blended rate including labor transferred between divisions, subsidiaries, or affiliates of the contractor under a common control.

4. Consumable materials are goods used in the ordinary course of work performance such as office supplies, paper, rags, vehicle or equipment fuel costs, cleaning chemicals, disposable tools, welding rods, paint buckets, paint brushes, protective clothing, etc., that are consumed/used in the process of repair and do not become an integral part of the repaired vessel. Consumable material shall be included in the contractor’s fully burdened ship repair labor rate and not separately priced.

5. Physical materials are goods that become incorporated into the repaired vessel in the course of the repair, such as replacement steel, pipes, paint, and fasteners. The material burden rate applies to physical materials but not to consumable materials. The material burden rate will be applied to the actual cost of the physical material. Actual cost does not include handling charges, general and administrative cost, overhead, profit, or any other indirect cost.

6. For growth and new work contract changes involving subcontractors, subcontractor quotes will be treated as

Other Direct Costs (ODCs) and will be subject to the contract material burden rate shown in paragraph (7) below. Subcontractor (competitive quotes if required by the ACO) quotes must be submitted with the contractor’s COPA in response to RCCs, GMRs and RTRs issued by the Contracting Officer. For new work only, these subcontractor quotes must be competitively acquired. At no time will the proposed total to be performed by the prime contractor combined with subcontractor quote, material quote, and applicable burdens be allowed to cost more than it would have, had the prime contractor directly provided all material and labor. The proposed total pricing restriction addressed in the preceding sentence does not apply in any case where the work is required to be performed by Original Equipment Manufacturers (OEMs), Government directed subcontractors, and/or Government authorized vendors. RCCs and RTRs that are subcontracted for material only (no associated labor required within the RCC) shall not be subject to the

Material Burden Rate. Any material burden rate applied to new work shall be approved by the ACO, upon receipt of supporting documentation in accordance with FAR 15.404-3, Subcontract Pricing Considerations.

7. The contract fixed fully burdened ship repair labor rate and material burden rate are shown below. These fixed rates shall be used for negotiating growth, and new work during the availability and up to three (3) months after the Attachment J-3 ‘Contract Complete’ date:

USS BOXER FY25 SRA

Fully Burdened Ship Repair Labor Rate TBD

Material Burden Rate TBD

8. In the event of a one-bid or directed availability, the Contracting Officer may negotiate the Fully Burdened

Ship Repair Labor Rate and Material Burden Rate (not to exceed the ceiling rate(s) identified above) with the offeror in accordance with FAR 15.4, Contract Pricing. The rates herein are not considered a Forward Pricing

Rate Agreement (FPRA) and are identified solely for the purpose of establishing a ceiling.

9. In the event of an extension due to excusable delay to the delivery date for the USS BOXER FY25 SRA, the

Contractor’s fully burdened ship repair labor rate shall be escalated by 0.41 % commencing 3 months after the

Attachment J-3 “Contract Complete” date. Following the “Contract Complete” date identified in Attachment J-

3 (Milestones), this rate shall be escalated quarterly through the 24th month, if necessary, and shall be used to negotiate all growth, and new work. Note, in the event of an excusable delay, this escalation rate shall be applied only to growth and new work not previously identified in Attachment J-4 (Pricing Worksheet). The material burden rate shall not increase.

NOTE C: OPTION ITEMS

Option item to which the option clause FAR 52.217-7 (NAVSEA Variation II) applies and which is to be supplied only if and to the extent said option is exercised.

NOTE D: SCHEDULE OF DAILY RATES FOR PIERSIDE AND DRY-DOCKING (FULLY BURDENED)

FOR PURPOSES OF A COMPENSABLE EXTENSION TO THE DRY-DOCKING OR DELIVERY DATE

1. In the event of a compensable extension to the dry-docking or delivery date, the Contractor’s fully burdened daily rates for additional dry-dock and/or pierside performance period at the Contractor’s facility will be evaluated by the ACO upon receipt of the Contractor’s certified or other than certified cost or pricing data

(certification requirements are subject to FAR 15.403).

2. The Contractor agrees that the daily rates shall include all costs that run with time associated with additional performance days in accordance with the work package specification requirements of this availability. The daily rates shall include all costs associated with additional performance days (whether charged directly or indirectly by the offeror’s accounting systems) including but not limited to:

Temporary Services, including but not limited to:

o Decking services o Pumping services o Electricity

Internet Connectivity

Air Conditioning

Support Services for the Navy, its agents and Contractors

Facilities, including but not limited to:

o Piers o Dry-docks o Office spaces o Trailers o Parking o Flammable Liquid Storage and Hazardous Material Storage o Material Warehousing and Lay-down space

Project Management and other labor costs that run with time including but not limited to:

o Program Management o Supervision o Integration & Scheduling o Cleaning (except tank cleaning) o Quality Assurance o Execution Planning o Security o Administration o Contracts o Purchasing o Other indirect support o Safety/Environmental

Transportation

3. The fully burdened daily rates are fixed rates that include all wages, overhead, other indirect costs, general and administrative expenses, Facilities Capital Cost of Money (FCCOM) and profit.

4. The proposed, fully burdened daily rates for pierside and dry-docking may be used during the availability’s extension period, up to 24 months after the “Contract Complete” date identified in Attachment J-3 (Milestones).

If the use of these extension rates is determined to be warranted by the ACO during execution, the Contractor shall submit certified or other than certified cost or pricing data to support the rates (certification requirements are subject to FAR 15.403).

USS BOXER FY25 AVAIL Additional Day Requiring

Availability Extension

Additional Day Does Not Require

Availability Extension

Additional Dry-Docking Day TBD TBD

Additional Pierside Day TBD

5. The Contractor bears the burden of proving the requested extension is compensable in accordance with this contract, and establish the duration of compensability through schedule analysis utilizing the Production Schedule establishing impact to critical path and/or controlling work items. The Contractor agrees that, in the event of such an extension, a bilateral modification will be executed with the price of the extension calculated as follows:

Total Price of Extension = D(e) * (P/D)

D(e) = Agreed Extension Days to the Delivery Date

(P/D) = Price/Day

6. The (P/D) will be utilized for any modifications to extend the contract in the event of compensable delay impacting the pierside and dry-docking period, regardless of the number of modifications or the number of days required to meet the Schedule Milestone ‘Contract Complete’ within 24 months of the ‘Contract Complete’ date. If the Contracting Officer determines a delay in meeting the Schedule Milestone is not compensable, no modification will be executed and the Contractor will be directed to continue work until certified ‘Contract

Complete’ by the RMC.

7. In the event the Contracting Officer determines the delay is concurrent, but clearly apportioned, a bilateral modification will be executed with the price calculated as follows:

Total Price of Extension = (D(g) - (D(c)) * (P/D)

D(g) = Government Responsible Delay (measured in days)

D(c) = Contractor Responsible Delay (measured in days)

(P/D) = Price/Day

The values for D(g) and D(c) will be determined by the Contracting Officer.

8. If the Contracting Officer determines the delay is excusable, a modification will be executed to extend the

Delivery Date, however, the Contractor shall not be entitled to recover a Daily Extension Rates.

9. All terms and conditions under the contract apply to all modifications extending the delivery date. If the

Contracting Officer and Contractor are unable to reach agreement regarding duration or compensability, the

Government reserves the right to execute a unilateral modification utilizing the parameters outlined in paragraphs 5 through 8 above. Failure to agree on whether a compensable extension is appropriate or the duration of any delivery date extension shall be a dispute subject to the requirements of FAR 52.233-1(Alt. 1)

‘Disputes.’

NOTE E: SPECIAL AGREEMENT FOR GROWTH WITH A PRICE OF $15,000 OR LESS

1. To make administration of small dollar value growth more efficient and less costly, both parties (Government and Contractor) agree to a pre-priced value for individual growth items with an estimated price of $15,000 or less. The Contract will include a firm fixed price for growth valued at $15,000 or less. Zero-dollar changes and administrative contract changes (for example, drawing revision change where no additional work is required) shall not be executed using the Small Dollar Value Growth procedures, but will follow the change process.

2. The amount included in this Contract for the growth described above shall be equal to a maximum quantity of:

a. 479 occurrences for growth work computed at a firm fixed price of $6,264 per occurrence, as associated with CLINS 0035 – 0071, 0087, & 0090 for the USS BOXER (LHD 4) FY25 SRA.

3. A Waterfront Circuit Team comprised of a small group of Contractor and Government representatives shall administer the Special Agreement for Growth with a value of $15,000 or less. The Contractor shall establish a group of empowered representatives who will be located in proximity to the ship during the availability period and who will interact with a similar group of Government representatives (also to be located in close proximity to the ship and to be identified by the NSA). Specific arrangements for the Waterfront Circuit Team shall be mutually agreed between the Contractor and NSA.

4. The Contractor shall report proposed growth work through the normal CFR process in accordance with Contract terms. The Government may also independently identify growth work. No later than 24 hours after the final approval of the CFR, the Waterfront Circuit Team shall use best efforts to determine if the proposed growth is

$15,000 or less, and document the agreed to technical scope of work. The Contracting Officer or the authorizing official shall direct the commencement of all growth work. Directed growth will be followed by documentation to appropriately reflect specification changes.

5. If the Waterfront Circuit Team is not able to reach agreement that the price of the growth work is $15,000, or less, then it will be adjudicated through the LOE to Completion process identified in Section B, Note A.

However, if LOE to Completion negotiations reveal the value of growth work is $15,000, or less, the task will be settled in accordance with the Small Dollar Value Growth procedure at the pre-priced value per occurrence identified in Section B, Note E, Paragraph 2, above.

6. If the Contractor and Government (Contracting Officer) reach settlement in three (3) business days an incentive of $1,236 will be applied to the standard price per change of $6,264. The result in these instances would be a

SDVG price per change of $7,500.

7. The Contractor and Government (Contracting Officer) shall develop a growth tracker to identify and record the number of directed occurrences under this Note. All growth meeting the criteria of paragraph 1 above shall be accepted under this clause without delay and disruption in ship redelivery.

8. When the quantity of occurrences for Small Dollar Growth is depleted, the Small Dollar Growth process shall revert to the LOE to Completion process for remaining growth.

Within 30 days after the end of the contract period of performance, the Contractor and Contracting Officer, utilizing the growth work tracker, shall determine the number of pre-priced occurrences not directed under this contract.

Accordingly, the Contracting Officer will decrease the contract price by an amount calculated by multiplying the remaining number of occurrences by the pre-established firm fixed price per occurrence.

NOTE F: AVAILABILITY SCHEDULE PERFORMANCE

1. The Contractor shall schedule the performance of all Base and Option items in the work package, so as to permit a contract scope increase up to the:

Total contract number of labor hours and material dollars to complete growth work as described in NOTE

A: LEVEL OF EFFORT TO COMPLETION –SHIP REPAIR, paragraph 1.

Total contract number of Small Value Dollar Growth occurrences as described in NOTE E: SPECIAL

AGREEMENT FOR GROWTH WITH A PRICE OF $15,000 OR LESS, paragraph 2.

2. The Contractor agrees that the growth work identified in Section B, Note F, Paragraph 1, above, if tasked, shall be performed, purchased and installed concurrently with the work items, without impacting, accelerating, or causing delay or disruption to the work required by the base and option work items, to any other Government contract, or to any other work in progress for the Government.

3. The growth work described above, if required, shall be tasked during the contract period of performance, as may be modified, on the following schedule phasing:

No more than 50% of the hours or material following the 50% schedule point of the availability (as measured in days between the “Availability Start” and “Contract Complete” milestones in Attachment J-3), adjusted for delay to delivery date.

No more than 25% of the hours or material following the 75% schedule point of the availability (as measured in days between the “Availability Start” and “Contract Complete” milestones in Attachment J-3), adjusted for delay to delivery date.

NOTE G: SUPPLEMENTAL WORK PACKAGE

1. Within seven (7) days of award, the Government intends to issue a supplemental work package to be potentially incorporated into the availability. The total dollar value of the supplemental work package is expected to be no greater than $2 Million.

2. Within 10 days of receiving the supplemental package Request for Proposal (RFP), the contractor shall notify the Government, in writing, as to whether the work package can be completed within the schedule milestones listed in Attachment J-3. The Contractor agrees to provide objective evidence of any work that cannot be completed to include direct impact to the critical path.

3. The Contractor can submit requests for clarification up to 14 days after receiving the RFP. The proposal is due no later than 30 days after receiving the RFP. If the proposal is equal to or greater than the certified cost and pricing threshold (currently $2 Million) the proposal meets the requirement for certified cost and pricing data of FAR 15.403 and will be submitted in the format required by FAR 15.408, Table 15-2. If the proposal is less than the certified cost and pricing threshold, the Contractor agrees to provide the data other than certified cost and pricing data as requested by the contracting officer. The data other than certified cost and pricing includes, but is not limited to:

Prime labor hours broken down by trade and paragraph level with a basis of estimate for each work item.

Detailed material list with the source, part number, description, unit cost, quantity, total cost, and vendor quotes

Subcontractor quotes including labor hours broken down by paragraph and task, labor rate, full material quote including part number, description, unit cost, quantity, total cost, and vendor quotes.

4. The Contractor shall develop and provide an Integrated Production Schedule, created in full compliance with Standard Item 009-60, in support of the WPER and updated prior to the finalization of the solicited work package revisions and the supplemental work package, reflecting the schedule constraints proposed in the contractor’s schedule.

The Integrated Production Schedule shall integrate Alteration Installation Teams (AIT), Government-Contracted Third Party Maintenance Providers, Ship's Force, Commercial

Industrial Services (CIS), and Fleet Maintenance Activity (FMA) work to the maximum extent this information is available.

5. This post award supplemental package is considered to be new work to which the rates stated in Note B are applicable.

CLAUSES INCORPORATED BY FULL TEXT

B-215-H002 REFUNDS (SPARES AND SUPPORT EQUIPMENT) (NAVSEA) (OCT 2018)

(a) In the event that the price of a spare part or item of support equipment delivered under this contract significantly exceeds its intrinsic value, the Contractor agrees to refund the difference. Refunds will not be made to recoup the amount of cost decreases that occur over time due to productivity gains (excluding economic purchase quantity considerations) or changes in market conditions.

(b) For purposes of this requirement, the intrinsic value of an item is defined as follows:

(1) If the item is one which is sold or is substantially similar or functionally equivalent to one that is sold in substantial quantities to the general public, intrinsic value is the established catalog or market price, plus the value of any unique requirements, including delivery terms, inspection, packaging, or labeling.

(2) If there is no comparable item sold in substantial quantities to the general public, intrinsic value is defined as the price an individual would expect to pay for the item based upon an economic purchase quantity as defined in FAR

52.207-4, plus the value of any unique requirements, including delivery terms, inspection, packaging or labeling.

(c) At any time up to two years after delivery of a spare part or item of support equipment, the Contracting Officer may notify the Contractor that based on all information available at the time of the notice, the price of the part or item apparently exceeds its intrinsic value.

(d) If notified in accordance with paragraph (c) above, the Contractor agrees to enter into good faith negotiations with the Government to determine if, and in what amount, the Government is entitled to a refund.

(e) If agreement pursuant to paragraph (d) above cannot be reached, and the Navy's return of the new or unused item to the Contractor is practical, the Navy, subject to the Contractor's agreement, may elect to return the item to the Contractor.

Upon return of the item to its original point of Government acceptance, the Contractor shall refund in full the price paid.

If no agreement pursuant to paragraph (d) above is reached, and return of the item by the Navy is impractical, the

Contracting Officer may, with the approval of the Head of the Contracting Activity, issue a Contracting Officer's final decision on the matter, subject to Contractor appeal as provided in the "Disputes" clause (FAR 52.233-1).

(f) The Contractor shall make refunds, as required under this requirement, in accordance with instructions from the

Contracting Officer.

(g) The Contractor shall not be liable for a refund if the Contractor advised the Contracting Officer in a timely manner that the price it would propose for a spare part or item of support equipment exceeded its intrinsic value, and with such advice, specified the estimated proposed price, the estimated intrinsic value and known alternative sources or item, if any, that can meet the requirement.

(h) This requirement does not apply to any spare parts or items of support equipment whose price is determined through adequate price competition. This requirement also does not apply to any spare part or item of support equipment if the

Contractor submitted, and certified the currency, accuracy and completeness of, cost or pricing data applicable to the item.

(End of text)

B-227-H001 PROVISIONING TECHNICAL DOCUMENTATION – WITHHOLDING OF PAYMENT

(NAVSEA) (OCT 2018)

The PTD is considered to be a part of the "Technical Data" specified to be delivered under this contract for the purposes of the "Technical Data--Withholding of Payment" (DFARS 252.227-7030) clause. The terms and conditions of the clause entitled "Limitation On Withholding of Payments (FAR 52.232-9), if included in this contract, shall not apply to withholding of payment for failure to make timely delivery of the PTD or delivery of deficient PTD.

B-231-H002 WORKSITE TRAVEL COSTS (NAVSEA) (OCT 2018)

(a) The contractor shall not charge, and the Government shall not pay, as an allowable cost under this contract, any manhour costs (whether straight-time or overtime) for contractor personnel or subcontractor personnel traveling to or from worksites, including travel to worksites other than the contractor's facility for performance of contract work.

(b) Workers being paid under this contract, as prime contractor personnel or subcontractor personnel, will complete a full shift at the worksite, and no compensation will be paid for travel time before or after the shift.

(c) This requirement pertains only to payments for travel time before or after these workers' regular shifts

(commuting costs), and does not apply to legitimate travel costs incurred during normal working hours, provided that those costs are otherwise reasonable, allocable and allowable and approved in writing by the Government. This requirement does not apply to manufacturer's representatives or Original Equipment Manufacturer (OEM) representatives when specifically required by the Government work specifications.

(d) Additionally, the contractor shall not charge, and the Government shall not pay, any transportation costs under this contract associated with transporting contractor or subcontractor personnel between the contractor's facility (or subcontractor's facility), and any other worksite to perform ship repair, maintenance or modernization.

Transportation costs include, but are not limited to, bus fare, car fare, train fare, or boat…