N00024-16-R-4409_Amendment_0007_Released.docx.pdf

N0002416NR93003

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

See Attached.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 9

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 25-Oct-2016

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X N00024-16-R-4409

X 9B. DATED (SEE ITEM 11)

06-Sep-2016

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

24-Oct-2016

CODE

NAVAL SEA SYSTEMS COMMAND (HQ)

1333 ISAAC HULL AVE SE

WASHINGTON NAVY YARD DC 20376-2030

N00024 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

N00024-16-R-4409

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

The following items are applicable to this modification:

Summary of Changes:

1. Section C- Paragraph 3.4 Milestones for Certain Reports updated

2. Section J- List of Attachments updated

SECTION C - DESCRIPTIONS AND SPECIFICATIONS

The following have been modified:

SCOPE OF WORK

1. GENERAL REQUIREMENTS

1.1 The Contractor under the direction of the Regional Maintenance Center (RMC) and as an independent Contractor and not as an agent of the Government, shall furnish the material, support (electrical, crane, rigging, etc.) and facilities (except those furnished by the Government under express provisions of this contract) and provide the management, technical, procurement, production, testing and quality assurance necessary to prepare and accomplish the repair and alteration of the FY17 USS SAN ANTONIO (LPD 17) Dry-Docking Phased Maintenance Availability (DPMA) in accordance with the requirements stated in this Section, the Work Item Specifications and Work Item Plans, Drawings, and Other References, the Delivery Schedule, and all other terms and conditions set forth in this contract. Category I NAVSEA FY17 Standard Items through CHG 1 identified under Attachment J-1 are applicable to all items without further reference. Category II NAVSEA FY17 Standard Items through CHG 1 are applicable when invoked and/or referenced in individual work items specified in Attachment J-1.

NAVSEA Standard items may be found at:

http://www.navsea.navy.mil/Home/RMC/CNRMC/OurPrograms/SSRAC/NSI.aspx

1.2 The Contractor shall accomplish planning and scheduling to ensure a rational, integrated and timely plan for receipt, storage and installation of Government Furnished Material as identified in work item specifications, and for accomplishment of production work.

1.3 The Contractor shall provide an integrated milestone plan for the availability. These milestones will include a schedule of key events necessary to meet the contract delivery dates. A critical path analysis and a milestone schedule shall be used to measure schedule accomplishment of the functions and elements required to successfully complete the repair and alteration of FY17 USS SAN ANTONIO (LPD 17) DPMA within the availability dates herein.

1.4 INTEGRATED PRODUCTION SCHEDULE REVIEW MEETINGS - The Contractor shall formally present its Integrated Production Schedule to the Navy Supervisory Authority at the Work Package Execution Review (WPER), Start Availability, 25% Complete conference, 50% Complete conference and 75% complete conference. The Integrated Production Schedule shall include Alteration Installation Team (AIT), Government-Contracted Third Party Maintenance Providers, Ship's Force, Commercial Industrial Services (CIS), and Fleet Maintenance Activity (FMA) work to the maximum extent this information is available. At each meeting, the contractor shall present and explain, at minimum, the following information:

1.4.1 The Contractor's latest, Government approved, Integrated Production Schedule created in full compliance with Standard Item 009-60.

1.4.2 The Contractor's current progress in preparing for and/or executing the Availability in accordance with their Integrated Production Schedule. The Contractor shall provide an explanation and mitigation plan for any preparation or execution delays in comparison to their Integrated Production Schedule.

1.4.2.1 The Contractor's plan shall describe opportunities for schedule acceleration (at no cost to the Government unless directly related to a Government caused delay) and potential risks and mitigations to remaining schedule attainment.

1.5 Wherever the term “Job Order” is used in this solicitation/award, it also means “Contract.”

1.6 The Contractor shall report and recommend corrective action during contract performance for those deficiencies discovered which are not covered by the work specifications. As found conditions, needed repairs and corrective action reports will be submitted to the Government in the form of a Condition Found Report (CFR). The Contractor's conditions found reporting shall be in accordance with that set forth in Standard Item 009-01.

1.7 The Navy may send a site inspection team to perform an inspection of the contractor's facility prior to arrival of the vessel

1.8 GOVERNMENT FURNISHED MATERIAL: Government Furnished Material (GFM) cited in the solicitation (Attachment J-1, Specification Package) will be shipped to the contractor’s facility.

The successful offeror is to coordinate delivery of Government Furnished Material with the Project Manager. Government property permanently removed from a vessel that requires a Property Administrator's disposition instructions shall be properly prepared for shipment and be delivered as directed by the Property Administrator. GFM will be listed in paragraph 5 of the Work Item(s).

1.9 QUALITY ASSURANCE

1.9.1 QUALITY ASSURANCE PROGRAM - The Contractor shall provide and maintain a quality assurance program acceptable to the Government, and shall perform or have performed the inspections and tests pursuant to that program to substantiate that the material and workmanship provided pursuant to the job order conform to the drawings, specifications, job orders, and contract requirements listed herein. The Contractor's quality assurance program shall be in accordance with that set forth in Standard Item 009-

04. In addition to its rights under Clause 252.217-7005, the Government shall have the right to deem work or material furnished by the Contractor to be incomplete and not in accordance with the requirements of the job order by reason of the Contractor's failure to comply with the requirements of its quality assurance program and, as such, the Contractor shall not be entitled to progress payments for said work and material.

1.9.2 Quality Assurance Surveillance Plan (QASP) - The Contractor shall meet the performance/acceptable quality level requirements for each deliverable/assessment area in the QASP, Attachment J-5. There will be monetary deductions based on unfavorable contractor performance as stated in the QASP. There is no maximum dollar limit to the deductions which can be assessed against the Contractor for failing to meet the performance/acceptable quality level requirements.

1.10 REQUEST FOR CONTRACT CHANGES (RCC) TIMELINE - The contractor shall provide all

Change Order Price Analysis (COPA) proposals in response to Request for Contract Changes (RCC) within three business days. If circumstances arise where the contractor is unable to submit a COPA within three business days, the contractor shall notify the Government in writing of the specific circumstances and provide a date on which a COPA will be submitted. The contractor’s timeliness in submitting COPAs in response to RCCs will be evaluated in CPARS and utilized for past performance ratings on future proposal evaluations. Notification of late submission of COPA does not exempt the contractor from meeting the three business day requirement, but will be considered by the Government when conducting a CPARS evaluation.

1.11 AUTHORIZED CHANGES ONLY BY THE CONTRACTING OFFICER – No order, statement, or conduct of Government personnel who visit the Contractor's facilities or in any other manner communicates with Contractor personnel during the performance of this contract shall constitute a change under the "Changes" clause of this contract. The Contractor shall not comply with any order, direction or request of Government personnel unless it is issued in writing and signed by the Contracting Officer, or is pursuant to specific authority otherwise included as a part of this contract.

The Contracting Officer is the only person authorized to approve changes in any of the requirements of this contract and, notwithstanding provisions contained elsewhere in this contract, the said authority remains solely the Contracting Officer's. In the event the contractor effects any change at the direction of any person other than the Contracting Officer, the change will be considered to have been made without authority and no adjustment will be made in the contract price to cover any increase in charges incurred as a result thereof.

1.12 NAVY MAINTENANCE DATABASE (NMD): The Contractor shall use NMD for the submission of Condition Found Reports throughout the administration of this contract.

1.13 ORGANIZATION CHART AND EMPLOYEE ROSTER:

1.13.1 ORGANIZATION CHART - Within 30 days of contract award, submit a chart detailing each management, technical, engineering and production position from the highest company level to the lowest supervisory level. Include descriptions of each position describing the duties, responsibilities, authority and names of the individuals filling the positions. The organizational chart must represent the facility that will perform the work.

1.13.2 EMPLOYEE ROSTER: After receipt of award and prior to starting work aboard the vessel, the contractor must submit a list of employees who will work aboard ship to the Commanding Officer of the ship via the NSA Security Office. The list should be on company letterhead, include each employee's name and security clearance when required, and bear the signature of a company official.

2. LOCATION: Government facilities are not available for this requirement. All work shall be completed at the contractor’s facilities.

2.1 DRYDOCK CERTIFICATION - The dry-docking of all vessels shall be accomplished in dry docks certified in accordance with MIL-STD-1625D(SH) dated 27 August 2009.

3. SCHEDULE: USS SAN ANTONIO must be delivered, mission-ready, no later than 27 April 2018.

3.1: MILESTONES: In addition to the contract completion date of 27 April 2018, the Government has established execution dates for the milestones identified in Attachment J-3.

3.1.1 - ***Offerors (Prime Contractors) shall contact the Procuring Contracting Officer, Sheila

Utz at sheila.utz1@navy.mil and the Contract Specialist, Lisa Carll at lisa.carll@navy.mil to receive the established dates, included as Attachment J-3. These milestones will not be distributed publicly on FBO.

3.1.2 - If any milestone event is not accomplished by the date provided, and the failure to accomplish any such milestone event does not arise from a cause beyond the control and without fault or negligence of the Contractor, such failure may be deemed to constitute a failure to perform this contract in accordance with its terms within the meaning of subparagraph (a)(1)(ii) of the clause of this contract entitled "DEFAULT” (DFARS 252.217-7009).

3.1.3 - Reserved.

3.1.4- The Contractor shall schedule the performance of all items in the USS SAN ANTONIO

DPMA work package, including work items included as both Base and Option items, so as to permit a contract scope increase up to 150,448 “hours” and $2,410,188 in “material” to be performed as "Additional Requirements" (including growth and new work). “Material,” as defined for the application of this paragraph, is defined as physical deliverable materials, exclusive of prime and subcontractor labor. “Hours,” as defined for the application of this paragraph is to include both prime and subcontract labor hours. The contractor agrees that these Additional Requirements, if ordered, shall be performed concurrently with the aforementioned work items, during the contract period of performance, without impacting the Key Events/Milestones included in Attachment J-3 Execution Milestones, or impacting, accelerating, or causing delay or disruption to the work required by the aforementioned work items, to any other Government contract, and/or to any other work in progress for the Government.

The "Additional Requirements," if required, shall be ordered during the contract period of performance, as may be modified, on the following schedule:

No more than 75% of the hours or material following the 25% schedule point the availability (as measured in days between the “Start Availability” and “End of Availability” milestones in Attachment J-3).

No more than 50% of the hours or material following the 50% schedule point the availability (as measured in days between the “Start Availability” and “End of Availability” milestones in Attachment J-3).

No more than 25% of the hours or material following the 75% schedule point the availability (as measured in days between the “Start Availability” and “End of Availability” milestones in Attachment J-3).

3.2. DELAYS / DISRUPTIONS: The contractor shall coordinate the work effort with the Naval Supervising Activity (NSA) Project Manager on a daily basis to prevent changing situations from causing delays and disruptions. Disruption due to minor delays in obtaining access to spaces and operation of equipment are to be expected. A minor delay is defined as eight (8) hours or less. These disruptions are considered normal rather than unusual occurrences during the performance of tasks ordered under this contract. If, during contract performance, delays greater than those indicated above are encountered, the Contractor shall immediately verbally notify the Project Manager and Contracting Officer, followed by a written statement within 24 hours after occurrence of delay, stating time of impact, reason for delay, duration of impact, number of people affected, action taken to properly schedule the work, action taken to minimize impact, and the names of the Government person(s) contacted.

3.3 - SCHEDULE AND ASSOCIATED REPORTS: The proposed scheduling of work, resources, key events and milestones submitted by the Contractor in accordance with Standard Item 009-60 during the course of contract performance shall not be materially different from the Schedule and Associated Reports provided in the Contractor’s technical proposal.

3.4 MILESTONES FOR CERTAIN REPORTS: The contractor shall complete the necessary work associated with the following reports and submit to the Government the required reports in the necessary format and containing the required information as specified in the Work Item no later than A+79 or be subject to the deductions provided in Attachment J-5 Quality Assurance Surveillance Plan.

Work Item Description Report Paragraph Number

Report Type

110-11-001 Underwater Hull; inspect and repair 3.2.2,3.3.3 Visual

123-11-001 Freeboard Structure Inspection; accomplish 3.2.1 Visual

123-14-001 Potable Water Tank; Inspect and Preserve 3.2.1 Visual

123-14-002 Fresh Water Tank; Preserve 3.2 Visual

123-14-003 Fresh Water Tank; inspect and preserve 3.2.1 Visual

233-11-021 Main Propulsion Diesel Engine (MPDE) Fuel Oil Leak-off 3.3.3.1 Visual

123-16-007 Ballast tank Manhole Cover; Install new 3.1.1 Visual

123-17-003 JP-5 Fual Drain tank; Preserve 3.2.1 Visual

123-14-004 Potable Water Tanks; repair 3.8.1 Labor report

233-11-003 Main Propulsion Diesel Engine (MPDE) Camshaft Timing Gear Assemblies; repair

3.1 PCP

233-11-004 Main Propulsion Diesel Engine (MPDE) Intercooler;

replace

3.8.1 Labor report

233-11-005 Main Propulsion Diesel Engine (MPDE) Flexible Coupling;

repair

3.3.1 Pre-alignment inspection

631-13-001 Chain Locker; preserve 3.2.1 Visual

233-12-003 1B Main Propulsion Diesel Engine (MPDE) Left And Right Exhaust Manifold Assembly And Exhaust Gas Inlet Bellows Gasket Leak; repair

3.1.1 OEM report IAW 009-90

233-14-003 2B Main Propulsion Diesel Engine (MPDE), Governor and Fuel Oil Pump and Drive Assembly; repair

3.1 PCP

243-11-001 Propulsion Shafting; inspect and repair 3.2.1.1, 3.3.2.1, 3.4.3.1, 3.7.1, 3.7.2.1, 3.8.3.2

Measure, NDT

634-11-011 Well Deck Preserve 3.8.1 LOE Report

245-11-001 Controllable Pitch Propeller (CPP) Hub; replace 3.2.1, 3.4.1.1, 3.4.2.1 Pre-Operational, NDT, Inspection

245-11-004 Controllable Pitch Propeller (CPP) Valve Rod Assembly;

repair

3.2.2, 3.2.3.4, 3.2.4.1, 3.2.5.1, 3.2.6.1

Matchmark Verification, Visual, NDT, Measurement

245-12-001 Controllable Pitch Propeller (CPP) Hub; replace 3.2.1, 3.4.1.1, 3.4.2.1 Pre-Operational, NDT, Inspection

245-12-004 Controllable Pitch Propeller (CPP) Valve Rod Assembly;

repair

3.2.3.4, 3.2.4.1, 3.2.5.1, 3.2.6.1

Visual, NDT, Measurement

562-11-001 Rudder Bearing Seal and Rudderstock Seal; repair 3.2.3.1 Inspection

4. SAFETY:

4.1 SAFETY INSPECTOR / FIRE MARSHALL: In addition to the safety standards provided in the specifications, the contractor is responsible for providing an experienced Safety Inspector/Fire Marshall who will accomplish daily inspections of the Contractor's entire work area on the ship, together with the Contracting Office’s Safety Representative. This Inspector or Fire Marshall shall not be one of the Contractor's supervisors or superintendents normally assigned to the ship and shall be identified in the contractor’s approved Safety Plan.

4.2 PERSONAL PROTECTIVE EQUIPMENT: Whenever work is performed aboard U.S. Naval Ships or vessels at piers or dry docks of a Naval Shipyard or Naval Station, Contractor employees (including management personnel) shall have and use at all times the following personal protective equipment:

(a) Protective hard hats that meet the following specifications:

(1) Protective helmets purchased after July 5, 1994 shall comply with ANSI Z89.1-1986, "American National Standard for Personnel Protection-Protective Headwear for Industrial Workers-Requirements," or shall be demonstrated to be equally effective.

(2) Protective helmets purchased before July 5, 1995 shall comply with ANSI Standard "American National Standard Safety requirements for Industrial Head Protection," Z89.1- 1969, or shall be demonstrated by the employer to be equally effective. [Ref. 29 CFR

1910.135 Head Protection]

(b) Approved type Plano or prescription glasses meeting the following specifications:

(1) Protective eye and face devices purchased after July 5, 1994 shall comply with ANSI standard Z87.1-1989, "American National Standard Practice for Occupational and Educational Eye and Face Protection", or shall be demonstrated by the employer to be equally effective.

(2) Protective eye and face devices purchased before July 5, 1994 shall comply with ANSI "USA standard for Occupational and Educational Eye and Face Protection", Z87.1- 1968, or shall be demonstrated by the employer to be equally effective. [Ref. 29 CRF

1910.133 Protective eye and face devices.]

(c) Safety toe shoes, with built-in protective toe box that meet the following specifications:

(1) Protective footwear purchased after July 5, 1994 shall comply with ANSI Standard Z41-1991, "American National Standard for Personal Protection-Protective Footwear", or shall be demonstrated by the employer to be equally effective.

(2) Protective footwear purchased before July 5, 1994 shall comply with the ANSI standard "USA Standard for Men's Safety Toe Footwear", Z41.1 1967, or shall be demonstrated by the employer to be equally effective [Ref. 29 CFR 1910.136 Protective eye and face devices.]

4.3 BLACK OXIDE COATED THREADED FASTENERS (BOCTFs): Due to safety concerns, use of BOCTFs is not authorized when installing or replacing threaded fasteners in the accomplishment of any work required by any Work Item in this contract.

5. OTHER REQUIREMENTS

5.1 USE/POSSESSION OF PERSONAL ELECTRONIC DEVICES (PED'S) - The possession and use of portable electronic devices (PED's) within the confines of any naval vessel, or in the contractor's facility where equipment removed from the vessel is being worked, is strictly controlled. Cellular phones with digital imaging capabilities are strictly prohibited. PED's may not be connected to any Navy-owned or controlled network. PED's may not be used to store or process any digital information associated with the conduct of the contract without written authorization from the NSA. PED's include:

mobile computing devices such as personal digital assistants (PDA's);

hand-held or laptop computers;

mobile telephone devices such as data-enabled cellular telephones;

two-way pagers, including those with e-mail capability;

analog and digital sound recorders; and digital cameras, including cellular phones with digital imaging capabilities.

5.2 NON SMOKING POLICY - For bidding purposes, contractors are advised that in light of the Navy's policy regarding smoke-free facilities, the entire vessel, topside and below decks, is to be considered a "No Smoking Area" unless otherwise indicated by shipboard policy.

5.3. CITIZENSHIP REQUIREMENTS - The contractor shall comply with the Department of Defense Industrial Security Manual (DoD 5220.22), and any revisions to that manual as of the Bid Opening Date prescribed, for verification of all U. S. Citizens. Prospective offerors shall refer all questions pertaining to the above to MARMC, Security Manager.

SECTION J - LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS

The following have been modified:

DOCUMENTS/EXHIBITS/ATTACHMENTS

The following document(s), exhibit(s), and other attachment(s) form a part of this solicitation:

No. Document

Attachment S-1 Technical Capabilities Data Sheet Attachment S-2 Past Performance Questionnaire Attachment S-3 Pre-Proposal Information (PPI) Form Attachment S-4 Past Performance References Attachment S-5 Eligibility Criteria Data Sheet (Updated via Amendment 0004)

The following document(s), exhibit(s), and other attachment(s) also form a part of this solicitation and will form a part of the contract resulting from this solicitation:

No. Document Attachment J-1 Specification Package No. SSPTPPC-LPD17-NSSA16-CNO1 (Errata 1, Errata 2, Errata 3, Errata 4, Addendum 1) Updated via Amendment 0007 Attachment J-2 Work Item Plans, Drawings, and Other References (Updated CD available) Attachment J-3 Execution Milestones and Key Event Dates (Updated via Amendment 0004) To be incorporated at contract award Attachment J-4 Pricing Workbook (Updated via Amendment 0006) Attachment J-5 Quality Assurance Surveillance Plan (Updated via Amendment 0002) Attachment J-6 Subcontracting Plan (to be incorporated upon award)

Exhibit A Contract Data Requirements List (CDRL) (DD Form 1423) A001-A003; A005-A009; A011; A012; A014 (Does not include A004, A0010, or A0013) Exhibit B Contract Data Requirements List (CDRL) (DD Form 1423) B001-B009 Exhibit C Contract Data Requirements List (CDRL) (DD Form 1423) C001-C002

(End of Summary of Changes)