HSCG85-17-R-P45213_Attachment_4_Solicitation_Provisions_(12.28.16).pdf

REQUEST FOR PROPOSAL ATTACHMENT 4

SOLICITATION NUMBER: HSCG85-17-R-P45213

SOLICITATION PROVISIONS

Addendum to FAR 52.212-1

The clause at Instructions to Offerors—Commercial Items (Oct 2016) incorporated by reference is amended as to supplement with the following terms and conditions:

(1) TECHNICAL PACKAGE REQUESTS

For references in the specification please email Jennifer.G.Sokolower@uscg.mil. The USCG intends to grant prospective offerors access to these documents via AMRDEC.

(2) INSTRUCTION FOR PROPOSAL CONTENT

Offeror’s proposals shall be submitted electronically in two password protected volumes.

When responding, please include “HSCG85-17-R-P45213 - Contractor Name” in the Subject Line. The electronic copy shall be compatible with Microsoft Office 2007, Adobe Acrobat XI Pro. Each volume must indicate: (1) the solicitation number: HSCG85-17-R-P45213 and (2) the name, email address, DUNS number, mailing address and telephone number of the Offeror. Please ask for a return e-mail confirming receipt of your electronic proposal. The password shall be submitted under a separate e-mail by the aforementioned date and time including “HSCG85-17-R-P45213 Proposal Password - Contractor Name” in Subject Line.

Please note: there is not a character length or mixed case requirement imposed on your password. Please note emails larger than ten megabytes will be rejected by the server.

Volume I: Offerors shall carefully articulate the following information:

(1) Ability to Absorb Growth: Ability to absorb up to 30% contract growth without impact to the overall completion. Assume that most of the additional work is identified in the first third of the availability, that the work per trade (Hull, Machinery, and Electrical) is proportional to the work in the specification, and that all material for such additional work is available within a reasonable amount of time. Provide strategy for mobilizing additional workforce both organically and subcontracted.

(2) Dry Dock Certification: Pre-award drydocking certification as required by SFLC Std Spec 8634 and pre-award calculations as required by SFLC Std Spec 8634, and, if applicable, an alternate blocking arrangement.

(3) Time Phase Sequencing of Work: Planning document in graphical format that shows:

(a) The overall period of performance for each CLIN, with start and stop dates of major sub-tasks.

(b) Due dates for critical inspection reports and any events requiring Coast Guard Inspector presence.

(c) All work item periods that require technical representative assistance.

(d) Critical paths with calculations for the number of days the critical paths can be delayed without affecting the delivery date.

(4) Staff Experience: For each work item in the specification, provide a list of completed projects that are similar in scope and magnitude that were performed by the Offeror's current staff or subcontractors resources that would provide services for CGC POLAR STAR.

Volume II: The Contractor shall submit proposals on a firm-fixed price basis. Volume II shall contain the following:

(1) The Schedule (SF 1449) and below information – The Schedule shall be filled out with the summation of the total contract price. Each CLIN must include a unit price and extended amount. The Rates for all Changes to the contract table shall be filled out. The Schedule shall also be signed and dated in block 30. The Offeror shall provide Attachment 2 excel sheets, “Schedule of Supplies/Service Continued” and “Rates of All Changes to the Contract”. The Offeror shall fill-in only the unit price on both sheets. The estimated quantities and extended amount in the excel sheet “Rates of All Changes to the Contract” are for evaluation of offers only. The proposed rate will apply to all changes involving additional work under this contract regardless of the actual total quantity required.

(2) Representations and Certifications (52.212.3), Certification Regarding Debarment, Suspension, Proposed Debarment, and Other Responsibility Matters (52.209-5) and Small Business Program Representations (52.219-1) shall be provided.

(3) Contractor shall fill out “LOCATION OF OFFEROR’S COMMERCIAL SHIPYARD”.

(4) Any amendments to the solicitation (signed SF-30). Offerors shall include a completed, signed copy of the entire solicitation with all appropriate “fill-in” sections completed. If any exceptions are taken to the terms and conditions of the solicitation, they shall be clearly set forth in a cover letter; and they shall be explained by the Offeror with the understanding that the exceptions may render the Offeror’s proposal unacceptable to the government.

(5) Past Performance Corrective Action Plan. Offerors who have received a marginal or unsatisfactory rating in any category for a past performance survey on a Government contract within the past three years shall submit a corrective action plan describing appropriate corrective action taken to ensure satisfactory performance on future contract awards. This information will be used as part of a responsibility determination for the prospective awardee.

(3) PROPOSAL PAGE LIMIT

There is no page limit for either volume of the proposal.

(4) PROPOSAL SUBMISSION

Proposals shall be submitted via email to Jennifer Sokolower at Jennifer.G.Sokolower@uscg.mil by the date in block 8 of the 1449. An Offeror that fails to meet any due date will be considered “late” in accordance with FAR 52.212-1(f).

(5) VALIDITY PERIOD OF PROPOSALS

The Offeror agrees to hold the prices in its proposal firm for 60 calendar days from the date specified for receipt of proposals, unless another time period is specified in an addendum to the solicitation.

(6) SOLICITATION QUESTIONS

Offerors are strongly encouraged to submit questions by 01/15/2016 1200 PT in order to provide the Government and Offerors adequate time to prepare for proposal submissions.

Questions received after the above cutoff date and time may not be answered. Submission of questions and any resulting answers from the Government will not require the Contracting Officer to extend the solicitation closing date. All Amendments to the solicitation will be posted via http://www.fedbizopps.gov. Note: The Government will not pay for costs incurred in the preparation and submission of proposals, or other costs incurred in response to this announcement.

Contractors doing business with the Government are required to register in the System for Award Management (SAM) database before they can be awarded a contract. A template containing the information for registration can be found at:

https://www.sam.gov/portal/public/SAM/#1

(7) DHS NOTICE TO OFFERORS

It is DHS policy that pricing for competitive negotiations should be based on adequate price competition. However, in the event only one responsible offer is obtained as a result of this solicitation, that offeror may be required to submit either Certified Cost or Pricing Data (FAR 15.403-4) or Data Other Than Certified Cost or Pricing Data (FAR 15-403-3) to support price negotiations.

(8) INSPECTION OF CUTTER PRIOR TO SUBMISSION OF PROPOSALS

The USCGC POLAR STAR is not in home port and will not be available for a domestic ship check during the solicitation period. While a physical ship check is not feasible, Offerors are encouraged to contact the Contracting Officer for any questions about physical features of the vessel. The Contracting Officer endeavor to resolve any questions, provide photos or videos where feasible, or possibly arrange information gathering either from a similar vessel or while USCGC POLAR STAR is in a foreign port.

(9) NOTICE OF PREAWARD SURVEY

The Government reserves the right to complete a pre-award survey prior to contract award.

Areas of interest on the survey may include: Performance Plans; Quality control or contractor quality assurance Plans; Personnel recruitment and training plans; Workload factors for manpower utilization; Management plan for handling peak workloads; Production capability;

Plant facilities and equipment; Purchasing and subcontracting; Labor resources; Performance record; Ability to meet delivery schedules; Ability to perform production work in accordance with the specifications; Environmental/energy considerations; Plant safety; Technical and/or professional abilities; Accounting systems; Security clearance; and Government property control.

(10) NOTICE FOR FILING AGENCY PROTESTS

United States Coast Guard Ombudsman Program

It is the policy of the United States Coast Guard (USCG) to issue solicitations and make contract awards in a fair and timely manner. The Ombudsman Program for Agency Protests (OPAP) was established to investigate agency protest issues and resolve them without expensive and time consuming litigation. OPAP is an independent reviewing authority that is empowered to grant a prevailing protester essentially the same relief as the Government Accountability Office (GAO). Interested parties are encouraged to seek resolution of their concerns within the USCG as an Alternative Dispute Resolution (ADR) forum rather than filing a protest with the GAO or some external forum. Interested parties may seek resolution of their concerns informally or opt to file a formal agency protest with the Contracting Officer or Ombudsman.

Informal Forum with the Ombudsman. Interested parties who believe a specific USCG procurement is unfair or otherwise defective should first direct their concerns to the applicable Contracting Officer. If the Contracting Officer is unable to satisfy their concerns, interested parties are encouraged to contact the U.S. Coast Guard Ombudsman for Agency Protests. Under this informal process the agency is not required to suspend contract award performance. Use of an informal forum does not suspend any time requirement for filing a protest with the agency or other forum. In order to ensure a timely response, interested parties should provide the following information to the Ombudsman: solicitation/contract number, contracting office, Contracting Officer, and solicitation closing date (if applicable).

Formal Agency Protest with the Ombudsman. Prior to submitting a formal agency protest, protesters must first use their best efforts to resolve their concerns with the Contracting Officer through open and frank discussions. If the protester’s concerns are unresolved, an Independent Review is available by the Ombudsman. The protester may file a formal agency protest to either the Contracting Officer or, as an alternative to that, the Ombudsman under the OPAP program. Contract award or performance will be suspended during the protest period unless contract award or performance is justified in writing for urgent and compelling reasons, or is determined in writing to be in the best interest of the Government. The agency’s goal is to resolve protests in less than 35 calendar days from the date of filing.

Protests shall include the information set forth in FAR 33.103(d) (2). If the protester fails to submit the required information, resolution of the protest may be delayed or the protest may be dismissed. To be timely, protests must be filed within the period specified in FAR 33.103(e). Formal protests filed under the OPAP program should be submitted electronically to OPAP@uscg.mil and the Contracting Officer, or by hand delivery to the Contracting Officer.

Election of Forum. After an interested party protests a Coast Guard procurement to the Contracting Officer or the Ombudsman, and while the protest is pending, the protester agrees not to file a protest with the GAO or other external forum. If the protest is filed with an external forum, the agency protest will be dismissed.

The Ombudsman Hotline telephone number is 202.372.3695.

(11) FAR 52.252-1 SOLICITATION PROVISIONS INCORPORATED BY

REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The Offeror is cautioned that the listed provisions may include blocks that must be completed by the Offeror and submitted with its offer. In lieu of submitting the full text of those provisions, the Offeror may identify the provision by paragraph identifier and provide the appropriate information with its offer. Also, the full text of a clause may be accessed electronically at these addresses:

www.acquisition.gov/far/ http://www.dhs.gov/publication/hsar

PROVISION INCLUDED BY REFERENCE

NUMBER TITLE/DATE

FAR 52.203-11 Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions (Sept 2007)

FAR 52.225-25 Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certifications (Dec 2012)

(12) FAR 52.209-5 CERTIFICATION REGARDING RESPONSIBILITY

MATTERS (OCT 2015)

(a)(1) The Offeror certifies, to the best of its knowledge and belief, that-

(i) The Offeror and/or any of its Principals-

(A) Are are not presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency;

(B) Have have not , within a three-year period preceding this offer, been convicted of, or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State, or local) contract or subcontract; violation of Federal or State antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property (if offeror checks “have”, the offeror shall also see 52.209-7, if included in this solicitation);

(C) Are are not presently indicted for, or otherwise criminally or civilly charged by, a governmental entity with commission of any of the offenses enumerated in paragraph (a)(1)(i)(B) of this provision;

(D) Have , have not , within a three-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds $3,500 for which the liability remains unsatisfied.

(1) Federal taxes are considered delinquent if both of the following criteria apply:

(i) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted.

(ii) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded.

(2) Examples.

(i) The taxpayer has received a statutory notice of deficiency, under I.R.C. § 6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability.

Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(ii) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. § 6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(iii) The taxpayer has entered into an installment agreement pursuant to I.R.C.

§ 6159. The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment.

(iv) The taxpayer has filed for bankruptcy protection. The taxpayer is not delinquent because enforced collection action is stayed under 11 U.S.C. 362 (the Bankruptcy Code).

(ii) The Offeror has has not , within a three-year period preceding this offer, had one or more contracts terminated for default by any Federal agency.

(2) “Principal,” for the purposes of this certification, means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment;

and similar positions).

This Certification Concerns a Matter Within the Jurisdiction of an Agency of the United States and the Making of a False, Fictitious, or Fraudulent Certification May Render the Maker Subject to Prosecution Under Section 1001, Title 18, United States Code.

(b) The Offeror shall provide immediate written notice to the Contracting Officer if, at any time prior to contract award, the Offeror learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances.

(c) A certification that any of the items in paragraph (a) of this provision exists will not necessarily result in withholding of an award under this solicitation. However, the certification will be considered in connection with a determination of the Offeror’s responsibility. Failure of the Offeror to furnish a certification or provide such additional information as requested by the Contracting Officer may render the Offeror nonresponsible.

(d) Nothing contained in the foregoing shall be construed to require establishment of a system of records in order to render, in good faith, the certification required by paragraph (a) of this provision. The knowledge and information of an Offeror is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings.

(e) The certification in paragraph (a) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly rendered an erroneous certification, in addition to other remedies available to the Government, the Contracting Officer may terminate the contract resulting from this solicitation for default.

(End of provision)

(13) FAR 52.209-7 INFORMATION REGARDING RESPONSIBILITY

MATTERS (JUL 2013)

(a) Definitions. As used in this provision—

“Administrative proceeding” means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

“Federal contracts and grants with total value greater than $10,000,000” means—

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

“Principal” means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager;

plant manager; head of a division or business segment; and similar positions).

(b) The offeror has does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in—

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

(End of provision)

(14) FAR 52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm-Fixed Price contract resulting from this solicitation.

(End of provision)

(15) 52.217-5 EVALUATION OF OPTIONS (July 1990)

Except when it is determined in accordance with FAR 17.206(b) not to be in the Government’s best interests, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

(End of provision)

(16) FAR 52.233-2 SERVICE OF PROTEST. (SEPT 2006)

(a) Protests, as defined in section 31.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from Jennifer Sokolower at Jennifer.G.Sokolower@uscg.mil.

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

(17) LOCATION OF OFFEROR’S COMMERCIAL SHIPYARD

In order for the Contracting Officer to evaluate certain foreseeable costs to the Coast Guard that will vary with the location of the commercial shipyard to be used by the offeror as further defined in Evaluation Factors for Award, the offeror is required to provide, in the space below, the exact location of the shipyard to be used to perform the services required under this solicitation. The offeror is cautioned that its failure to provide the location of its commercial shipyard in the space provided may result in its bid being declared nonresponsive under the provisions of an Invitation for Bids or its proposal being declared deficient under the terms of a Request for Proposal.

Name and location Shipyard: ___________________________________________

(End of provision)

(18) FORESEEABLE COST FACTORS PERTAINING TO DIFFERENT

SHIPYARD LOCATIONS

(1) If the Contractor's offered place of performance is more than fifty (50) driving miles from USCG Base Seattle, there will be a transportation cost for one (1) U.S. Coast Guard Representative(s) for four (4) round trip(s) between the Contractor's offered place of performance and USCG Base Seattle at the cost of coach-type airfare.

(2) If the Contractor's offered place of performance is more than fifty (50) driving miles from USCG Base Seattle, "Per Diem" expenses for one hundred and ten (110) days to support three (3) U.S. Coast Guard Representative(s) while in the city of the place of contract performance determined in accordance with the Joint Federal Travel Regulations (JFTR).

(3) Facility costs to navigate vessel between its homeport and the Contractor's offered place of performance (round trip) is $411.73 per nautical mile.

(4) Family separation allowance for 38 personnel with dependents on board at $8.33 per day for each personnel for 110 days each when the place of performance is more than fifty (50) driving miles from the home pier of the vessel. The entitlement is calculated from the date the vessel leaves homeport and ends upon return to homeport. All travel dates will be included in this calculation. See U.S. Coast Guard Pay Manual, COMDTINST M7220.29, Chapter 3-F.

(5) Crew's transportation during overhaul away from home port. As required by 37 USC 406 b. and Chapter 7, Part F1 of the Joint Federal Travel Regulations (JFTR), on the thirty-first (31) day of a ship being away from home port, and every sixty (60) days thereafter, all personnel with dependents will be provided round trip coach type airfare to the ship's home pier. There will be 2 home port visit(s) during the performance of this contract. The vessel has 38 personnel with dependents onboard. The cost of this airfare will be determined from the official airline guide. The calculation of trips does not include travel time to and from the overhaul place of performance. See Joint Travel Regulations (JTR), Chapter 7, Part X, paragraph U7615.

52.212-2 EVALUATION—COMMERCIAL ITEMS. (OCT 2014)

(a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers:

(i) Technical Capability: Each sub-factor will be assigned a rating of technically acceptable (meets the minimum requirements of the solicitation) or technically unacceptable (proposal does not meet the minimum requirements of the solicitation). Any sub-factor technically unacceptable rating will result in a technically unacceptable proposal. Sub-factors are:

(1) Sub-factor 1 – Ability to Absorb Growth: The evaluation will assess the Offeror's ability to absorb contract growth work of up to 30% identified during the first 1/3 of the base contract period without extending the base contract period.

(2) Sub-factor 2 – Ability to Dock the Vessel: The evaluation will assess the Offeror's proposed dry-dock facility, pre-award calculations and docking arrangements to confirm it has the capability to support a safe docking evolution.

(3) Sub-factor 3 – Time Phase Sequencing of Work: The evaluation will assess the Offeror's ability to plan the availability with milestones and a clearly identified critical path at each point in the availability.

(4) Sub-factor 4 – Staff Experience: The evaluation will assess the Offeror’s staff experience in the performance of projects that are similar in nature to the work outlined in this solicitation. To be technically acceptable, the Offeror’s must demonstrate that it's staff (or subcontractor resources) are capable of performing each Work Item. This shall be accomplished by documenting completed projects that are similar in scope and magnitude.

In evaluating experience, the Government will consider only the information in the Offeror’s proposal, and may also elect to consider information from other reliable sources.

(ii) Total Evaluated Price

The total evaluated price shall consist of the following: definite items in the schedule, optional items in the schedule, foreseeable cost factors applicable to different shipyard locations, and the total of all extended amounts in Attachment 2, Sheet 2, Rates for Contract Changes.

Evaluation will be based upon the receipt of competitive offers, comparison to published commercial and historical prices, and to the Independent Government Cost Estimate (IGCE). Offerors are encouraged to provide their most favored customer pricing and discounts with their initial proposal.

Basis for award will be to the responsible Offeror whose proposal has the lowest evaluated price meeting or exceeding the acceptability standards for non-cost factors using the guidance in FAR 15.101-2 and the guidance for evaluation of Commercial Items at FAR 12.602(c).

(b) Options. The Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. The Government may determine that an offer is unacceptable if the option prices are significantly unbalanced.

Evaluation of options shall not obligate the Government to exercise the option(s).

(c) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer’s specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

(End of provision)

52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS—

COMMERCIAL ITEMS. (OCT 2016), ALTERNATIVE I (OCT 2014)

The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Website located at https://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (r) of this provision.

(a) Definitions. As used in this provision—

“Economically disadvantaged women-owned small business (EDWOSB) concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

“Forced or indentured child labor” means all work or service—

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

“Highest-level owner” means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

“Immediate owner” means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following:

ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

“Inverted domestic corporation”, means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

“Manufactured end product” means any end product in product and service codes (PSCs) 1000-9999, except—

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

“Place of manufacture” means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

“Predecessor” means an entity that is replaced by a successor and includes any predecessors of the predecessor.

“Restricted business operations” means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate—

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

“Sensitive technology”—

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically—

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

“Service-disabled veteran-owned small business concern”—

(1) Means a small business concern—

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

“Small business concern” means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

“Small disadvantaged business concern”, consistent with 13 CFR 124.1002, means a small business concern under the size standard applicable to the acquisition, that—

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by—

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Subsidiary” means an entity in which more than 50 percent of the entity is owned—

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

“Veteran-owned small business concern” means a small business concern—

(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

“Successor” means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term “successor” does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances.

“Women-owned business concern” means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

“Women-owned small business concern” means a small business concern—

(1) That is at least 51 percent owned by one or more women; or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program” (in accordance with 13 CFR part 127), means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

(b)(1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted on the SAM website.

(2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through http://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representations and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and Certifications—Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs ______________.

[Offeror to identify the applicable paragraphs at (c) through (r) of this provision that the offeror has completed for the purposes of this solicitation only, if any.

These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on

SAM.]

(c) Offerors must complete the following representations when the resulting contract will be performed in the United States or its outlying areas. Check all that apply.

(1) Small business concern. The offeror represents as part of its offer that it is, is not a small business concern.

(2) Veteran-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it is, is not a veteran-owned small business concern.

(3) Service-disabled veteran-owned small business concern. [Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(2) of this provision.] The offeror represents as part of its offer that it is, is not a service-disabled veteran-owned small business concern.

(4) Small disadvantaged business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, that it is, is not a small disadvantaged business concern as defined in 13 CFR 124.1002.

(5) Women-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it is, is not a women-owned small business concern.

(6) WOSB concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(5) of this provision.] The offeror represents that—

(i) It is is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It is, is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(6)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture:

__________.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(7) Economically disadvantaged women-owned small business (EDWOSB) concern.

[Complete only if the offeror represented itself as a WOSB concern eligible under the WOSB Program in (c)(6) of this provision.] The offeror represents that—

(i) It is, is not an EDWOSB concern, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It is, is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(7)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: __________.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

Note: Complete paragraphs (c)(8) and (c)(9) only if this solicitation is expected to exceed the simplified acquisition threshold.

(8) Women-owned business concern (other than small business concern). [Complete only if the offeror is a women-owned business concern and did not represent itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it is a women-owned business concern.

(9) Tie bid priority for labor surplus area concerns. If this is an invitation for bid, small business offerors may identify the labor surplus areas in which costs to be incurred on account of manufacturing or production (by offeror or first-tier subcontractors) amount to more than 50 percent of the contract price:____________________________________

(10) HUBZone small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, as part of its offer, that—

(i) It is, is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR Part 126; and

(ii) It is, is not a HUBZone joint venture that complies with the requirements of 13 CFR Part 126, and the representation in paragraph (c)(10)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture.

[The offeror shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: __________.] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

(11) (Complete if the offeror has represented itself as disadvantaged in paragraph (c)(4) of this provision.)

Black American.

Hispanic American.

Native American (American Indians, Eskimos, Aleuts, or Native Hawaiians).

Asian-Pacific American (persons with origins from Burma, Thailand, Malaysia, Indonesia, Singapore, Brunei, Japan, China, Taiwan, Laos, Cambodia (Kampuchea), Vietnam, Korea, The Philippines, Republic of Palau, Republic of the Marshall Islands, Federated States of Micronesia, the Commonwealth of the Northern Mariana Islands, Guam, Samoa, Macao, Hong Kong, Fiji, Tonga, Kiribati, Tuvalu, or Nauru).

Subcontinent Asian (Asian-Indian) American (persons with origins from India, Pakistan, Bangladesh, Sri Lanka, Bhutan, the Maldives Islands, or Nepal).

Individual/concern, other than one of the preceding.

(d) Representations required to implement provisions of Executive Order 11246—

(1) Previous contracts and compliance. The offeror represents that—

(i) It has, has not participated in a previous contract or subcontract subject to the Equal Opportunity clause of this solicitation; and

(ii) It has, has not filed all required compliance reports.

(2) Affirmative Action Compliance. The offeror represents that—

(i) It has developed and has on file, has not developed and does not have on file, at each establishment, affirmative action programs required by rules and regulations of the Secretary of Labor (41 cfr parts 60-1 and 60-2), or

(ii) It has not previously had contracts subject to the written affirmative action programs requirement of the rules and regulations of the Secretary of Labor.

(e) Certification Regarding Payments to Influence Federal Transactions (31 U.S.C. 1352).

(Applies only if the contract is expected to exceed $150,000.) By submission of its offer, the offeror certifies to the best of its knowledge and belief that no Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress or an employee of a Member of Congress on his or her behalf in connection with the award of any resultant contract. If any registrants under the Lobbying Disclosure Act of 1995 have made a lobbying contact on behalf of the offeror with respect to this contract, the offeror shall complete and submit, with its offer, OMB Standard Form LLL, Disclosure of Lobbying Activities, to provide the name of the registrants. The offeror need not report regularly employed officers or employees of the offeror to whom payments of reasonable compensation were made.

(f) Buy American Certificate. (Applies only if the clause at Federal Acquisition Regulation (FAR) 52.225-1, Buy American—Supplies, is included in this solicitation.)

(1) The offeror certifies that each end product, except those listed in paragraph (f)(2) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The offeror shall list as foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of “domestic end product.” The terms “commercially available off-the-shelf (COTS) item” “component,” “domestic end product,” “end product,” “foreign end product,” and “United States” are defined in the clause of this solicitation entitled “Buy American—Supplies.”

(2) Foreign End Products:

Line Item No. Country of Origin

[List as necessary]

(3) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25.

(g)(1) Buy American—Free Trade Agreements—Israeli Trade Act Certificate. (Applies only if the clause at FAR 52.225-3, Buy American—Free Trade Agreements—Israeli Trade Act, is included in this solicitation.)

(i) The offeror certifies that each end product, except those listed in paragraph (g)(1)(ii) or (g)(1)(iii) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The terms “Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end product,” “commercially available off-the-shelf (COTS) item,” “component,” “domestic end product,” “end product,” “foreign end product,” “Free Trade Agreement country,” “Free Trade Agreement country end product,” “Israeli end product,” and “United States” are defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements–Israeli Trade Act.”

(ii) The…