10 Bid Schedule_amendment 5.pdf
PDF 195 KB Posted
- Attached to
- Child Development Center Renovation Solicitation
- Solicitation number
- FA452824R0001
About this file
This document is an Amendment #5 to the Bid Schedule for the renovation of Child Development Center (CDC) B164 at Minot AFB, Project Number AFPID 1007645. The revised Bid Schedule adds a new item (0005) for removal and disposal of asbestos-containing vermiculite insulation at new exterior wall openings, with a quantity of 85 SF.
The overall project is to renovate Building 164 into a Child Development Center for children aged 1 to 5 years, in accordance with facility criteria and Air Force requirements. The scope includes repairing and providing new civil, mechanical, plumbing, electrical, and communication systems. Options are included for removal and disposal of additional asbestos and lead-based paint, as well as access delays. The total estimated project magnitude is between $1,000,000 and $5,000,000. This is a 100% Small Business Set-Aside acquisition.
View the file
Other files
Show all 33
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
AMENDMENT #5
RENOVATE CHILD DEVELOPMENT CENTER CDC B164
PROJECT NUMBER AFPID 1007645
11 APRIL 2024
AMENDMENT ITEMS LIST:
1. Replace current Bid schedule with revised bid schedule. The revised bid schedule adds in Item 0005 ‐ Entire work complete for removal and disposal of acm vermiculite insulation at new exterior wall openings.
It also states a quantity of 85 SF. The revised bid schedule has the revised date of 4‐11‐2024 in the header.
Renovate CDC B164 (1007645) Revised on 4-11-2024
BID SCHEDULE
The contractor shall furnish the design, specification, and all facilities, labor, materials, equipment and other incidentals necessary to perform the following work items in strict accordance with applicable federal acquisition regulations.
BID ITEM 0001: The purpose of this project is to renovate Building 164 into a Child Development Center for children 1 to 5 years old. It shall meet the criteria of FC 4-740- 14F, Design: Air Force Child Development Centers, and AFI 34-144, Child and Youth Programs. Work includes repair/ provide new civil, mechanical, plumbing, electrical and communication systems for the facility. (CLIN 0001)
ITEM DESCRIPTION: QUANITY UNIT
PRICE
TOTAL
AMOUNT
0001 Renovation Child Development Center B164
Renovate and convert existing Housing Office B164 into a Child Development Center (CDC) in order to alleviate child care shortages currently available at Minot AFB.
(1) LS ---
Options
0002 Entire work complete for removal and disposal of additional asbestos not included in the basic amount.
500 SF ---
0003 Entire work complete for removal and disposal of lead-based paint
500 SF ---
0004 Access delays. Estimated quantity is 75 hours. See Note 5 below.
(1) LS ---
0005 Entire work complete for removal and disposal of acm vermiculite insulation at new exterior wall openings.
85 SF ---
1) If a modification to a bid based on unit prices is submitted, which provides for a lump sum adjustment to the total cost, the application to each unit price in the bid schedule must be stated. If it is not stated, the bidder agrees that the lump sum adjustment shall be applied on a pro-rated basis to every unit price in the bid schedule.
NOTES:
1.See 00 21 00, INSTRUCTIONS TO OFFERORS (RFP) for evaluation of options. The Government reserves the right to exercise Option Item No. 0002, 0003, 0004, and 0005 anytime during construction.
2. Prices must be entered for all items of the schedule. Total amounts submitted without prices being entered on individual items will be rejected. Additions will be subject to verification by the Government. In case of variation between the lump-sum prices and the total amount, the lump-sum prices will be considered the price submitted.
3. Quantities for unit priced items are estimated only and the respective unit price will prevail in the event of an overrun or underrun subject to Section FAR 52.211-18 “Variation in Estimated Quantities”.
Renovate CDC B164 (1007645) Revised on 4-11-2024
4. Access Delays. Measure and pay for each half hour that the entire workforce is delayed, or prevented from accessing the project site. The Contractor’s superintendent shall notify the Contracting Officer’s on-site representative within twenty-four hours (24) of any delay restricting access to the jobsite. This item will be paid based on a half-hour of work basis. All partial half hours for a notified delay will be rounded up to the next half-hour increment.
BY:
COMPANY:
TITLE:
DATE:
File details come from the government source that posted it. Updated .