07 Bid Schedule.pdf
PDF 145 KB Posted
- Attached to
- Child Development Center Renovation Solicitation
- Solicitation number
- FA452824R0001
About this file
This bid schedule outlines the requirements for renovating a Child Development Center at Minot Air Force Base. The contractor shall renovate Building 164 to meet standards for an Air Force Child Development Center, including repairing or replacing civil, mechanical, plumbing, electrical and communication systems. The base bid item is for renovating the existing Housing Office into a Child Development Center for a lump sum price. There are also options for removing additional asbestos or lead paint not included in the base work. The bid schedule includes estimated quantities, unit pricing, and notes on pricing requirements, quantity adjustments, access delays, and notifying the contracting officer of delays. The related federal contract opportunity is a solicitation from the Department of the Air Force Global Strike Command for the Child Development Center renovation.
View the file
Other files
Show all 33
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Renovate CDC B164 (1007645)
BID SCHEDULE
The contractor shall furnish the design, specification, and all facilities, labor, materials, equipment and other incidentals necessary to perform the following work items in strict accordance with applicable federal acquisition regulations.
BID ITEM 0001: The purpose of this project is to renovate Building 164 into a Child Development Center for children 1 to 5 years old. It shall meet the criteria of FC 4-740- 14F, Design: Air Force Child Development Centers, and AFI 34-144, Child and Youth Programs. Work includes repair/ provide new civil, mechanical, plumbing, electrical and communication systems for the facility. (CLIN 0001)
ITEM DESCRIPTION: QUANITY UNIT
PRICE
TOTAL
AMOUNT
0001 Renovation Child Development Center B164
Renovate and convert existing Housing Office B164 into a Child Development Center (CDC) in order to alleviate child care shortages currently available at Minot AFB.
(1) LS ---
Options
0002 Entire work complete for removal and disposal of additional asbestos not included in the basic amount.
500 SF ---
0003 Entire work complete for removal and disposal of lead-based paint
500 SF ---
0004 Access delays. Estimated quantity is 75 hours. See Note 5 below.
(1) LS ---
1) If a modification to a bid based on unit prices is submitted, which provides for a lump sum adjustment to the total cost, the application to each unit price in the bid schedule must be stated. If it is not stated, the bidder agrees that the lump sum adjustment shall be applied on a pro-rated basis to every unit price in the bid schedule.
NOTES:
1.See 00 21 00, INSTRUCTIONS TO OFFERORS (RFP) for evaluation of options. The Government reserves the right to exercise Option Item No. 0002, 0003, and 0004 anytime during construction.
2. Prices must be entered for all items of the schedule. Total amounts submitted without prices being entered on individual items will be rejected. Additions will be subject to verification by the Government. In case of variation between the lump-sum prices and the total amount, the lump-sum prices will be considered the price submitted.
3. Quantities for unit priced items are estimated only and the respective unit price will prevail in the event of an overrun or underrun subject to Section FAR 52.211-18 “Variation in Estimated Quantities”.
4. Access Delays. Measure and pay for each half hour that the entire workforce is delayed, or prevented from accessing the project site. The Contractor’s superintendent shall notify the Contracting Officer’s on-site representative within twenty-four hours (24) of any delay
Renovate CDC B164 (1007645) restricting access to the jobsite. This item will be paid based on a half-hour of work basis. All partial half hours for a notified delay will be rounded up to the next half-hour increment.
BY:
COMPANY:
TITLE:
DATE:
File details come from the government source that posted it. Updated .