E-OMS_RFP.pdf

SOLICITATION, OFFER AND AWARD

1. THIS CONTRACT IS A RATED ORDER

UNDER DPAS (15 CFR 350)

RATING

DO-C9

PAGE OF PAGES

1 74

2. CONTRACT NO. 3. SOLICITATION NO. 4. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

5. DATE ISSUED

09 JUL 2015

6. REQUISITION/PURCHASE NO.

FA2486-16-R-0002

7. ISSUED BY AFTC/PZZB CODE FA2487 8. ADDRESS OFFER TO (If other than Item 7)

AIR FORCE TEST CENTER

AFTC/PZZB

102 WEST D AVE, BLDG 11

EGLIN AFB, FL 32542-6890

LESLIE C. BAX 850-882-0175

LESLIE.BAX@US.AF.MIL

NOTE: In sealed bid solicitations “offer” and “offeror” mean “bid” and “bidder”.

SOLICITATION

9.

10. FOR

INFORMATION

CALL:

A. NAME

JOHN E. NALEZNY

B. TELEPHONE (Include area code)

(NO COLLECT CALLS)

850-883-0101

C. E-MAIL ADDRESS

john.nalezny@us.af.mil

11. TABLE OF CONTENTS

() SEC. DESCRIPTION PAGE(S) () SEC DESCRIPTION PAGE(S)

PART I - THE SCHEDULE PART II - CONTRACT CLAUSES

A SOLICITATION/CONTRACT FORM 1 I CONTRACT CLAUSES 61

B SUPPLIES OR SERVICES AND PRICES/COSTS 2 PART III - LIST OF DOCUMENTS, EXHIBITS, AND OTHER ATTACH.

C DESCRIPTION/SPECS./WORK STATEMENT 43 J LIST OF ATTACHMENTS 74

D PACKAGING AND MARKING 44 PART IV - REPRESENTATIONS AND INSTRUCTIONS

E INSPECTION AND ACCEPTANCE 45 K REPRESENTATIONS, CERTIFICATIONS, K - 1

F DELIVERIES OR PERFORMANCE 46 AND OTHER STATEMENTS OF OFFERORS

G CONTRACT ADMINISTRATION DATA 50 L INSTRS, CONDS, AND NOTICES TO OFFERORS L - 1

H SPECIAL CONTRACT REQUIREMENTS 53 M EVALUATION FACTORS FOR AWARD M - 1

OFFER (Must be fully completed by offeror) NOTE: Item 12 does not apply if the solicitation includes the provisions at 52.214-16, Minimum Bid Acceptance Period.

12. In compliance with the above, the undersigned agrees, if this offer is accepted within ____210____ calendar days (60 calendar days unless a different period is inserted by the offeror) from the date of receipt of offers specified above, to furnish any or all items upon which prices are offered at the price set opposite each item, delivered at the designated point(s), within the time specified in the schedule.

13. DISCOUNT FOR PROMPT PAYMENT

(See Section I, Clause No. 52.232-8)

10 CALENDAR DAYS

20 CALENDAR DAYS

30 CALENDAR DAYS

CALENDAR DAYS

14. ACKNOWLEDGEMENTS OF AMENDMENTS

(The offeror acknowledges receipt of amend-

AMENDMENT NO. DATE AMENDMENT NO. DATE

ments to the SOLICITATION for offerors and related documents numbered and dated:

15A. NAME

AND

CODE FACILITY 16. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

ADDRESS

OF

OFFEROR

15B. TELEPHONE NO. (Include area code)

15C. CHECK IF REMITTANCE ADDRESS

IS DIFFERENT FROM ABOVE - ENTER

SUCH ADDRESS IN SCHEDULE.

17. SIGNATURE 18. OFFER DATE

AWARD (To be completed by Government)

19. ACCEPTED AS TO ITEMS NUMBERED 20. AMOUNT 21. ACCOUNTING AND APPROPRIATION

22. AUTHORITY FOR USING OTHER THAN FULL AND OPEN COMPETI-

TION: 23. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM

10 U.S.C. 2304(c) ( ) 41 U.S.C. 253(c) ( )

24. ADMINISTERED BY (If other than Item 7) CODE 25. PAYMENT WILL BE MADE BY CODE

26. NAME OF CONTRACTING OFFICER (Type or print) 27. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

28. AWARD DATE

IMPORTANT - Award will be made on this Form, or on Standard Form 26, or by other authorized official written notice.

AUTHORIZED FOR LOCAL REPRODUCTION STANDARD FORM 33 (REV. 9-97)

PREVIOUS EDITION IS UNUSABLE Prescribed by GSA ConWrite Version 6.14.1 FAR (48 CFR) 53.21(c) Created 09 Jul 2015 9:40 AM

PART I - THE SCHEDULE

SECTION B - SUPPLIES OR SERVICES AND PRICES/COSTS

SECTION B FA2486-16-R-0002

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

CONTRACT BASE

0001 __________ Noun: EGLIN RANGE OPERATION & MAINTENANCE -

CONTRACT BASE

DD1423 is Exhibit: A Contract type: R - COST PLUS AWARD FEE Start Date: 01 OCT 2016 Completion Date: 31 MAR 2018 Descriptive Data:

The Contractor shall provide Operation and Maintenance (O&M) of the Eglin Range IAW the Performance Work Statement for the contract base period. Period of Performance is 18 Months. Actual Start and Completion Dates will be filled in accordingly at time of award.

Estimated Cost: $

0002 __________ Noun: NRTF OPERATION & MAINTENANCE - CONTRACT BASE DD1423 is Exhibit: A Contract type: R - COST PLUS AWARD FEE Start Date: 01 OCT 2016 Completion Date: 31 MAR 2018 Descriptive Data:

The Contractor shall provide O&M of the National Radar Cross-Section Test Facility (NRTF) IAW the Performance Work Statement for the contract base period. Period of Performance is 18 Months. Actual Start and Completion Dates will be filled in accordingly at time of award.

0003 __________

Noun: USATR OPERATION & MAINTENANCE - CONTRACT BASE DD1423 is Exhibit: A Contract type: R - COST PLUS AWARD FEE Start Date: 01 OCT 2016 Completion Date: 31 MAR 2018 Descriptive Data:

The Contractor shall provide O&M of the US Army Training Ranges (USATR) IAW the Performance Work Statement for the contract base period. Period of Performance is 18 Months. Actual Start and Completion Dates will be filled in accordingly at time of award.

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

0004 __________ Noun: MAJOR GROUND TEST FACILITIES - CONTRACT BASE DD1423 is Exhibit: A Contract type: U - COST PLUS FIXED FEE Start Date: 01 OCT 2016 Completion Date: 31 MAR 2018 Descriptive Data:

The Contractor shall provide test and test support services in the Major Ground Test Facilities (MGTF) IAW the Performance Work Statement and Section B Clause B01, Contract Type: Cost Plus Fixed Fee, for the contract base period. This CLIN includes performing MGTF directive requirements IAW PWS Section 6, and performing overtime within the MGTFs as required. Period of Performance is 18 Months. Actual Start and Completion Dates will be filled in accordingly at time of award.

The contract's most highly specialized positions are identified in paragraph (d)(2) of Clause B01 Contract Type: Cost Plus Fixed Fee. The subset of the estimated costs below for these highly specialized positions is $6,206,300.

Estimated Cost (if all six months are exercised): $28,717,500 Fixed Fee % % Estimated Fee (if all six months are exercised): $ Total Estimated Cost (if all six months are exercised): $

0005 __________

Noun: EGLIN RANGE & MGTF CONTRACTOR ACQUIRED

PROPERTY - CONTRACT BASE

Contract type: S - COST Start Date: 01 OCT 2016 Completion Date: 31 MAR 2018 Descriptive Data:

IAW Section H Clause H03 Contractor Acquired Property and the Performance Work Statement, the Contractor shall acquire property in support of O&M of the Eglin Range and for MGTF requirements for the contract base period. This is a Cost-Reimbursement CLIN in which the Contractor receives no fee. Period of Performance is 18 months.

Actual Start and Completion Dates will be filled in accordingly at time of award.

Estimated Total Item Amount: $37,830,000

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

0006 __________ Noun: NRTF CONTRACTOR ACQUIRED PROPERTY - CONTRACT

BASE

Contract type: S - COST Start Date: 01 OCT 2016 Completion Date: 31 MAR 2018 Descriptive Data:

IAW Section H Clause H03 Contractor Acquired Property and the Performance Work Statement, the Contractor shall acquire property in support of O&M of the NRTF for the contract base period. This is a Cost-Reimbursement CLIN in which the Contractor receives no fee. Period of Performance is 18 months. Actual Start and Completion Dates will be filled in accordingly at time of award.

Estimated Total Item Amount: $1,605,000

0007 __________

Noun: USATR CONTRACTOR ACQUIRED PROPERTY -

CONTRACT BASE

Contract type: S - COST Start Date: 01 OCT 2016 Completion Date: 31 MAR 2018 Descriptive Data:

IAW Section H Clause H03 Contractor Acquired Property and the Performance Work Statement, the Contractor shall acquire property in support of O&M of the USATR for the contract base period. This is a Cost-Reimbursement CLIN in which the Contractor receives no fee. Period of Performance is 18 months. Actual Start and Completion

Estimated Total Item Amount: $270,000

0008 __________

Noun: EGLIN RANGE & MGTF TRAVEL - CONTRACT BASE Contract type: S - COST Start Date: 01 OCT 2016 Completion Date: 31 MAR 2018 Descriptive Data:

When directed by the Government, the Contractor shall travel in support of O&M of the Eglin Range and in support of the MGTF requirements for the contract base period IAW the Performance Work Statement and Section H Clause H06 Travel. This is a Cost- Reimbursement CLIN in which the Contractor receives no fee. The Government shall reimburse the Contractor for travel costs in accordance with the applicable Federal Acquisition Regulation and its supplements. Period of Performance is 18 months. Actual Start and Completion Dates will be filled in accordingly at time of award.

Estimated Total Item Amount: $3,750,000

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

0009 __________ Noun: NRTF TRAVEL - CONTRACT BASE Contract type: S - COST Start Date: 01 OCT 2016 Completion Date: 31 MAR 2018 Descriptive Data:

When directed by the Government, the Contractor shall travel in support of O&M of the NRTF requirements for the contract base period IAW the Performance Work Statement and Section H Clause H06 Travel. This is a Cost-Reimbursement CLIN in which the Contractor receives no fee. The Government shall reimburse the Contractor for travel costs in accordance with the applicable Federal Acquisition Regulation and its supplements. Period of Performance is 18 months. Actual Start and Completion Dates will be filled in accordingly at time of award.

Estimated Total Item Amount: $91,950

0010 __________

Noun: USATR TRAVEL - CONTRACT BASE Contract type: S - COST Start Date: 01 OCT 2016 Completion Date: 31 MAR 2018 Descriptive Data:

When directed by the Government, the Contractor shall travel in support of O&M of the USATR requirements for the contract base period IAW the Performance Work Statement and Section H Clause H06 Travel. This is a Cost-Reimbursement CLIN in which the Contractor receives no fee. The Government shall reimburse the Contractor for travel costs in accordance with the applicable Federal Acquisition Regulation and its supplements. Period of Performance is 18 months. Actual Start and Completion Dates

Estimated Total Item Amount: $2,550

0011 __________

Noun: EGLIN RANGE OVERTIME - CONTRACT BASE DD1423 is Exhibit: A Contract type: R - COST PLUS AWARD FEE Start Date: 01 OCT 2016 Completion Date: 31 MAR 2018 Descriptive Data:

This CLIN represents the maximum overtime costs allowed for performing O&M of the Eglin Range for the contract base period. The Contractor shall charge against this CLIN only the costs for overtime hours worked during the contract base period. This is a Cost Plus Award Fee CLIN. Period of Performance is 18 months. Actual Start and Completion

Estimated Total Item Amount: $10,125,000

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

0012 __________ Noun: NRTF OVERTIME - CONTRACT BASE DD1423 is Exhibit: A Contract type: R - COST PLUS AWARD FEE Start Date: 01 OCT 2016 Completion Date: 31 MAR 2018 Descriptive Data:

This CLIN represents the maximum overtime costs allowed for performing O&M of the NRTF for the contract base period. The Contractor shall charge against this CLIN only the costs for overtime hours worked during the contract base period. This is a Cost Plus Award Fee CLIN. Period of Performance is 18 months. Actual Start and Completion

Estimated Total Item Amount: $195,000

0013 __________

Noun: USATR OVERTIME - CONTRACT BASE DD1423 is Exhibit: A Contract type: R - COST PLUS AWARD FEE Start Date: 01 OCT 2016 Completion Date: 31 MAR 2018 Descriptive Data:

This CLIN represents the maximum overtime costs allowed for performing O&M of the USATR for the contract base period. The Contractor shall charge against this CLIN only the costs for overtime hours worked during the contract base period. This is a Cost Plus Award Fee CLIN. Period of Performance is 18 months. Actual Start and Completion

Estimated Total Item Amount: $48,225

0014 __________

Noun: EGLIN RANGE TIER 1 DIRECTIVE LABOR - CONTRACT

BASE

DD1423 is Exhibit: A Contract type: R - COST PLUS AWARD FEE Start Date: 01 OCT 2016 Completion Date: 31 MAR 2018 Descriptive Data:

The Contractor shall provide all labor identified in Tier 1 Technical Directives supporting Eglin Range O&M requirements for the contract base period. Period of Performance is 18 months. Actual Start and Completion Dates will be filled in accordingly at time of

Estimated Total Item Amount: $1,492,500

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

0015 __________ Noun: NRTF TIER 1 DIRECTIVE LABOR - CONTRACT BASE DD1423 is Exhibit: A Contract type: R - COST PLUS AWARD FEE Start Date: 01 OCT 2016 Completion Date: 31 MAR 2018 Descriptive Data:

The Contractor shall provide all labor identified in Tier 1 Technical Directives supporting NRTF O&M requirements for the contract base period. Period of Performance is 18 months. Actual Start and Completion Dates will be filled in accordingly at time of award.

Estimated Total Item Amount: $0

0016 __________

Noun: USATR TIER 1 DIRECTIVE LABOR - CONTRACT BASE DD1423 is Exhibit: A Contract type: R - COST PLUS AWARD FEE Start Date: 01 OCT 2016 Completion Date: 31 MAR 2018 Descriptive Data:

The Contractor shall provide all labor identified in Tier 1 Technical Directives supporting USATR O&M requirements for the contract base period. Period of Performance is 18

Estimated Total Item Amount: $7,500

0017 __________

Noun: DATA EXHIBIT A - CONTRACT BASE DD1423 is Exhibit: A Contract type: R - COST PLUS AWARD FEE Start Date: 01 OCT 2016 Completion Date: 31 MAR 2018 Descriptive Data:

The Contractor shall furnish data in support of the Eglin Range, NRTF, USATR and the MGTFs for the contract base period. Data shall be provided IAW the Performance Work Statement and Section J, Exhibit A, DD Form 1423. Data is Not Separately Priced (NSP).

0018 __________

Noun: EGLIN RANGE AWARD FEE POOL - CONTRACT BASE Contract type: R - COST PLUS AWARD FEE Start Date: 01 OCT 2016 Completion Date: 31 MAR 2018 Descriptive Data:

This CLIN represents the maximum award fee pool for the Eglin Range O&M CLIN, the Eglin Range Overtime CLIN, and the Eglin Range Tier 1 Directive Labor CLIN for the contract base period.

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

0019 __________ Noun: NRTF AWARD FEE POOL - CONTRACT BASE Contract type: R - COST PLUS AWARD FEE Start Date: 01 OCT 2016 Completion Date: 31 MAR 2018 Descriptive Data:

This CLIN represents the maximum award fee pool for the NRTF O&M CLIN, the NRTF Overtime CLIN, and the NRTF Tier 1 Directive Labor CLIN for the contract base period.

0020 __________

Noun: USATR AWARD FEE POOL - CONTRACT BASE Contract type: R - COST PLUS AWARD FEE Start Date: 01 OCT 2016 Completion Date: 31 MAR 2018 Descriptive Data:

This CLIN represents the maximum award fee pool for the USATR O&M CLIN, the USATR Overtime CLIN, and the USATR Tier 1 Directive Labor CLIN for the contract base period.

TRANSITION

0021 __________ Noun: EGLIN RANGE & MGTF TRANSITION PERIOD DD1423 is Exhibit: A Contract type: J - FIRM FIXED PRICE Start Date: 01 APR 2016 Completion Date: 30 SEP 2016 Descriptive Data:

The Contractor shall perform a 6 Month Transition Period IAW Paragraph 9 of the Performance Work Statement and the Offeror's proposed Transition Plan (Section J Attachment 14) for the Eglin Range O&M and the MGTF. Period of Performance is 6 Months. Actual Start and Completion Dates will be filled in accordingly at time of award.

Total Item Amount: $

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

0022 __________ Noun: NRTF TRANSITION PERIOD DD1423 is Exhibit: A Contract type: J - FIRM FIXED PRICE Start Date: 01 APR 2016 Completion Date: 30 SEP 2016 Descriptive Data:

The Contractor shall perform a 6 Month Transition Period IAW Paragraph 9 of the Performance Work Statement and the Offeror's proposed Transition Plan (Section J Attachment 14) for the NRTF O&M. Period of Performance is 6 Months. Actual Start and Completion Dates will be filled in accordingly at time of award.

0023 __________

Noun: USATR TRANSITION PERIOD DD1423 is Exhibit: A Contract type: J - FIRM FIXED PRICE Start Date: 01 APR 2016 Completion Date: 30 SEP 2016 Descriptive Data:

The Contractor shall perform a 6 Month Transition Period IAW Paragraph 9 of the Performance Work Statement and the Offeror's proposed Transition Plan (Section J Attachment 14) for the USATR O&M. Period of Performance is 6 Months. Actual Start and Completion Dates will be filled in accordingly at time of award.

OPTION ONE

1001 OPTION CLIN (service) __________

Noun: EGLIN RANGE OPERATION & MAINTENANCE - OPTION

ONE

DD1423 is Exhibit: A Descriptive Data:

The Contractor shall provide O&M of the Eglin Range IAW the Performance Work Statement for the option one contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24 Months. Actual Start and Completion Dates will be filled in accordingly at time of award.

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

1002 OPTION CLIN (service) __________

Noun: NRTF OPERATION & MAINTENANCE - OPTION ONE DD1423 is Exhibit: A Descriptive Data:

The Contractor shall provide O&M of the NRTF IAW the Performance Work Statement for the option one contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24 Months. Actual Start and Completion Dates will be filled in accordingly

1003 OPTION CLIN (service) __________

Noun: USATR OPERATION & MAINTENANCE - OPTION ONE DD1423 is Exhibit: A Descriptive Data:

The Contractor shall provide O&M of the USATR IAW the Performance Work Statement for the option one contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24 Months. Actual Start and Completion Dates will be filled in accordingly

1004 OPTION CLIN (service) __________

Noun: MAJOR GROUND TEST FACILITIES - OPTION ONE DD1423 is Exhibit: A Descriptive Data:

The Contractor shall provide test and test support services in the Major Ground Test Facilities (MGTF) IAW the Performance Work Statement and Section B Clause B01, Contract Type: Cost Plus Fixed Fee, for the option one contract period. This CLIN includes performing MGTF directive requirements IAW PWS Section 6, and performing overtime within the MGTFs as required. Period of Performance is 24 Months. Actual Start and Completion Dates will be filled in accordingly at time of award.

The contract's most highly specialized positions are identified in paragraph (d)(2) of Clause B01 Contract Type: Cost Plus Fixed Fee. The subset of the estimated costs below for these highly specialized positions is $8,822,500.

Estimated Cost (if all six months are exercised): $40,620,000 Fixed Fee % %

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

1005 OPTION CLIN (service) __________

Noun: EGLIN RANGE & MGTF CONTRACTOR ACQUIRED

PROPERTY - OPTION ONE

Descriptive Data:

IAW Section H Clause H03 Contractor Acquired Property and the Performance Work Statement, the Contractor shall acquire property in support of O&M of the Eglin Range and for MGTF requirements for the option one contract period. This is a Cost- Reimbursement CLIN in which the Contractor receives no fee. Period of Performance is 24 months. Actual Start and Completion Dates will be filled in accordingly at time of

Estimated Total Item Amount: $50,440,000

1006 OPTION CLIN (service) __________

Noun: NRTF CONTRACTOR ACQUIRED PROPERTY - OPTION

ONE

Descriptive Data:

IAW Section H Clause H03 Contractor Acquired Property and the Performance Work Statement, the Contractor shall acquire property in support of O&M of the NRTF for the option one contract period. This is a Cost-Reimbursement CLIN in which the Contractor receives no fee. Period of Performance is 24 months. Actual Start and Completion

Estimated Total Item Amount: $2,140,000

1007 OPTION CLIN (service) __________

Noun: USATR CONTRACTOR ACQUIRED PROPERTY - OPTION

ONE

Descriptive Data:

IAW Section H Clause H03 Contractor Acquired Property and the Performance Work Statement, the Contractor shall acquire property in support of O&M of the USATR for the option one contract period. This is a Cost-Reimbursement CLIN in which the Contractor receives no fee. Period of Performance is 24 months. Actual Start and Completion

Estimated Total Item Amount: $360,000

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

1008 OPTION CLIN (service) __________

Noun: EGLIN RANGE & MGTF TRAVEL - OPTION ONE Descriptive Data:

When directed by the Government, the Contractor shall travel in support of O&M of the Eglin Range O&M CLIN and the MGTF requirements for the option one contract period IAW the Performance Work Statement and Section H Clause H06 Travel. This is a Cost- Reimbursement CLIN in which the Contractor receives no fee. The Government shall reimburse the Contractor for travel costs in accordance with the applicable Federal Acquisition Regulation and its supplements. Period of Performance is 24 months. Actual

Estimated Total Item Amount: $5,000,000

1009 OPTION CLIN (service) __________

Noun: NTRF TRAVEL - OPTION ONE Descriptive Data:

When directed by the Government, the Contractor shall travel in support of O&M of the NRTF requirements for the option one contract period IAW the Performance Work Statement and Section H Clause H06 Travel. This is a Cost-Reimbursement CLIN in which the Contractor receives no fee. The Government shall reimburse the Contractor for travel costs in accordance with the applicable Federal Acquisition Regulation and its supplements. Period of Performance is 24 months. Actual Start and Completion Dates

Estimated Total Item Amount: $230,400

1010 OPTION CLIN (service) __________

Noun: USATR TRAVEL - OPTION ONE Descriptive Data:

When directed by the Government, the Contractor shall travel in support of O&M of the USATR requirements for the option one contract period IAW the Performance Work Statement and Section H Clause H06 Travel. This is a Cost-Reimbursement CLIN in which the Contractor receives no fee. The Government shall reimburse the Contractor for travel costs in accordance with the applicable Federal Acquisition Regulation and its supplements. Period of Performance is 24 months. Actual Start and Completion Dates

Estimated Total Item Amount: $3,400

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

1011 OPTION CLIN (service) __________

Noun: EGLIN RANGE OVERTIME - OPTION ONE DD1423 is Exhibit: A Descriptive Data:

This CLIN represents the maximum overtime costs allowed for performing O&M of the Eglin Range for the option one contract period. The Contractor shall charge against this CLIN only the costs for overtime hours worked during the option one contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24 months. Actual Start and

Estimated Total Item Amount $14,330,000

1012 OPTION CLIN (service) __________

Noun: NRTF OVERTIME - OPTION ONE DD1423 is Exhibit: A Descriptive Data:

This CLIN represents the maximum overtime costs allowed for performing O&M of the NRTF for the option one contract period. The Contractor shall charge against this CLIN only the costs for overtime hours worked during the option one contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24 months. Actual Start and

Estimated Total Item Amount: $260,000

1013 OPTION CLIN (service) __________

Noun: USATR OVERTIME - OPTION ONE DD1423 is Exhibit: A Descriptive Data:

This CLIN represents the maximum overtime costs allowed for performing O&M of the USATR for the option one contract period. The Contractor shall charge against this CLIN only the costs for overtime hours worked during the option one contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24 months. Actual Start and

Estimated Total Item Amount $68,200

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

1014 OPTION CLIN (service) __________

Noun: EGLIN RANGE TIER 1 DIRECTIVE LABOR - OPTION ONE DD1423 is Exhibit: A Descriptive Data:

The Contractor shall provide all labor identified in Tier 1 Technical Directives supporting Eglin Range O&M requirements for the option one contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24 Months. Actual Start and Completion

Estimated Total Item Amount: $2,980,000

1015 OPTION CLIN (service) __________

Noun: NRTF TIER 1 DIRECTIVE LABOR - OPTION ONE DD1423 is Exhibit: A Descriptive Data:

The Contractor shall provide all labor identified in Tier 1 Technical Directives supporting NRTF O&M requirements for the option one contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24 Months. Actual Start and Completion Dates will be filled in accordingly at time of award.

1016 OPTION CLIN (service) __________

Noun: USATR TIER 1 DIRECTIVE LABOR - OPTION ONE DD1423 is Exhibit: A Descriptive Data:

The Contractor shall provide all labor identified in Tier 1 Technical Directives supporting USATR O&M requirements for the option one contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24 Months. Actual Start and Completion Dates will

Estimated Total Item Amount: $10,800

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

1017 OPTION CLIN (service) __________

Noun: DATA EXHIBIT A - OPTION ONE DD1423 is Exhibit: A Descriptive Data:

The Contractor shall furnish data in support of the Eglin Range, NRTF, USATR and the MGTFs for the option one contract period. Data shall be provided IAW the Performance Work Statement and Section J, Exhibit A, DD Form 1423. Data is Not Separately Priced

(NSP).

1018 OPTION CLIN (service) __________

Noun: EGLIN RANGE AWARD FEE POOL - OPTION ONE Descriptive Data:

This CLIN represents the maximum award fee pool for the Eglin Range O&M CLIN, the option one contract period.

1019 OPTION CLIN (service) __________

Noun: NRTF AWARD FEE POOL - OPTION ONE Descriptive Data:

This CLIN represents the maximum award fee pool for the NRTF O&M CLIN, the NRTF Overtime CLIN, and the NRTF Tier 1 Directive Labor CLIN for the option one contract period.

1020 OPTION CLIN (service) __________

Noun: USATR AWARD FEE POOL - OPTION ONE Descriptive Data:

This CLIN represents the maximum award fee pool for the USATR O&M CLIN, the USATR Overtime CLIN, and the USATR Tier 1 Directive Labor CLIN for the option one contract period.

OPTION TWO

2001 OPTION CLIN (service) __________

Noun: EGLIN RANGE OPERATION & MAINTENANCE - OPTION

TWO

DD1423 is Exhibit: A Descriptive Data:

The Contractor shall provide O&M of the Eglin Range IAW the Performance Work Statement for the option two contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24 Months. Actual Start and Completion Dates will be filled in

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

2002 OPTION CLIN (service) __________

Noun: NRTF OPERATION & MAINTENANCE - OPTION TWO DD1423 is Exhibit: A Descriptive Data:

The Contractor shall provide O&M of the NRTF IAW the Performance Work Statement for the option two contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24 Months. Actual Start and Completion Dates will be filled in accordingly

2003 OPTION CLIN (service) __________

Noun: USATR OPERATION & MAINTENANCE - OPTION TWO DD1423 is Exhibit: A Descriptive Data:

The Contractor shall provide O&M of the USATR IAW the Performance Work Statement for the option two contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24 Months. Actual Start and Completion Dates will be filled in accordingly

2004 OPTION CLIN (service) __________

Noun: MAJOR GROUND TEST FACILITIES - OPTION TWO DD1423 is Exhibit: A Descriptive Data:

The Contractor shall provide test and test support services in the Major Ground Test Facilities (MGTF) IAW the Performance Work Statement and Section B Clause B01, Contract Type: Cost Plus Fixed Fee, for the option two contract period. This CLIN includes performing MGTF directive requirements IAW PWS Section 6, and performing overtime within the MGTFs as required. Period of Performance is 24 Months. Actual Start and Completion Dates will be filled in accordingly at time of award.

The contract's most highly specialized positions are identified in paragraph (d)(2) of Clause B01 Contract Type: Cost Plus Fixed Fee. The subset of the estimated costs below number for these highly specialized positions is $9,359,800.

Estimated Cost (if all six months are exercised): $43,100,000 Fixed Fee % %

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

2005 OPTION CLIN (service) __________

Noun: EGLIN RANGE & MGTF CONTRACTOR ACQUIRED

PROPERTY - OPTION TWO

Descriptive Data:

IAW Section H Clause H03 Contractor Acquired Property and the Performance Work Statement, the Contractor shall acquire property in support of O&M of the Eglin Range and for MGTF requirements for the option two contract period. This is a Cost- Reimbursement CLIN in which the Contractor receives no fee. Period of Performance is 24 months. Actual Start and Completion Dates will be filled in accordingly at time of

2006 OPTION CLIN (service) __________

Noun: NRTF CONTRACTOR ACQUIRED PROPERTY - OPTION

TWO

Descriptive Data:

IAW Section H Clause H03 Contractor Acquired Property and the Performance Work Statement, the Contractor shall acquire property in support of O&M of the NRTF for the option two contract period. This is a Cost-Reimbursement CLIN in which the Contractor receives no fee. Period of Performance is 24 months. Actual Start and Completion

2007 OPTION CLIN (service) __________

TWO

Descriptive Data:

IAW Section H Clause H03 Contractor Acquired Property and the Performance Work Statement, the Contractor shall acquire property in support of O&M of the USATR for the option two contract period. This is a Cost-Reimbursement CLIN in which the Contractor receives no fee. Period of Performance is 24 months. Actual Start and Completion

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

2008 OPTION CLIN (service) __________

Noun: EGLIN RANGE & MGTF TRAVEL - OPTION TWO Descriptive Data:

When directed by the Government, the Contractor shall travel in support of O&M of the Eglin Range O&M CLIN and the MGTF requirements for the option two contract period IAW the Performance Work Statement and Section H Clause H06 Travel. This is a Cost- Reimbursement CLIN in which the Contractor receives no fee. The Government shall reimburse the Contractor for travel costs in accordance with the applicable Federal Acquisition Regulation and its supplements. Period of Performance is 24 months. Actual

2009 OPTION CLIN (service) __________

Noun: NRTF TRAVEL - OPTION TWO Descriptive Data:

When directed by the Government, the Contractor shall travel in support of O&M of the NRTF requirements for the option two contract period IAW the Performance Work Statement and Section H Clause H06 Travel. This is a Cost-Reimbursement CLIN in which the Contractor receives no fee. The Government shall reimburse the Contractor for travel costs in accordance with the applicable Federal Acquisition Regulation and its supplements. Period of Performance is 24 months. Actual Start and Completion Dates

2010 OPTION CLIN (service) __________

Noun: USATR TRAVEL - OPTION TWO Descriptive Data:

When directed by the Government, the Contractor shall travel in support of O&M of the USATR requirements for the option two contract period IAW the Performance Work Statement and Section H Clause H06 Travel. This is a Cost-Reimbursement CLIN in which the Contractor receives no fee. The Government shall reimburse the Contractor for travel costs in accordance with the applicable Federal Acquisition Regulation and its supplements. Period of Performance is 24 months. Actual Start and Completion Dates

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

2011 OPTION CLIN (service) __________

Noun: EGLIN RANGE OVERTIME - OPTION TWO DD1423 is Exhibit: A Descriptive Data:

This CLIN represents the maximum overtime costs allowed for performing O&M of the Eglin Range for the option two contract period. The Contractor shall charge against this CLIN only the costs for overtime hours worked during the option two contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24 months. Actual Start and

Estimated Total Item Amount $15,190,000

2012 OPTION CLIN (service) __________

Noun: NRTF OVERTIME - OPTION TWO DD1423 is Exhibit: A Descriptive Data:

This CLIN represents the maximum overtime costs allowed for performing O&M of the NRTF for the option two contract period. The Contractor shall charge against this CLIN only the costs for overtime hours worked during the option two contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24 months. Actual Start and

2013 OPTION CLIN (service) __________

Noun: USATR OVERTIME - OPTION TWO DD1423 is Exhibit: A Descriptive Data:

This CLIN represents the maximum overtime costs allowed for performing O&M of the USATR for the option two contract period. The Contractor shall charge against this CLIN only the costs for overtime hours worked during the option two contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24 months. Actual Start and

Estimated Total Item Amount $72,300

2014 OPTION CLIN (service) __________

Noun: EGLIN RANGE TIER 1 DIRECTIVE LABOR - OPTION TWO DD1423 is Exhibit: A Descriptive Data:

The Contractor shall provide all labor identified in Tier 1 Technical Directives supporting Eglin Range O&M requirements for the option two contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24 Months. Actual Start and Completion

Estimated Total Item Amount: $3,980,000

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

2015 OPTION CLIN (service) __________

Noun: NRTF TIER 1 DIRECTIVE LABOR - OPTION TWO DD1423 is Exhibit: A Descriptive Data:

The Contractor shall provide all labor identified in Tier 1 Technical Directives supporting NRTF O&M requirements for the option two contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24 Months. Actual Start and Completion Dates will

2016 OPTION CLIN (service) __________

Noun: USATR TIER 1 DIRECTIVE LABOR - OPTION TWO DD1423 is Exhibit: A Descriptive Data:

The Contractor shall provide all labor identified in Tier 1 Technical Directives supporting USATR O&M requirements for the option two contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24 Months. Actual Start and Completion Dates will

Estimated Total Item Amount: $11,400

2017 OPTION CLIN (service) __________

Noun: DATA EXHIBIT A - OPTION TWO DD1423 is Exhibit: A Descriptive Data:

The Contractor shall furnish data in support of the Eglin Range, NRTF, USATR and the MGTFs for the option two contract period. Data shall be provided IAW the Performance Work Statement and Section J, Exhibit A, DD Form 1423. Data is Not Separately Priced

(NSP).

2018 OPTION CLIN (service) __________

Noun: EGLIN RANGE AWARD FEE POOL - OPTION TWO Descriptive Data:

This CLIN represents the maximum award fee pool for the Eglin Range O&M CLIN, the option two contract period.

2019 OPTION CLIN (service) __________

Noun: NRTF AWARD FEE POOL - OPTION TWO Descriptive Data:

This CLIN represents the maximum award fee pool for the NRTF O&M CLIN, the NRTF Overtime CLIN, and the NRTF Tier 1 Directive Labor CLIN for the option two contract period.

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

2020 OPTION CLIN (service) __________

Noun: USATR AWARD FEE POOL - OPTION TWO Descriptive Data:

This CLIN represents the maximum award fee pool for the USATR O&M CLIN, the USATR Overtime CLIN, and the USATR Tier 1 Directive Labor CLIN for the option two

AWARD TERM OPTION ONE

3001 OPTION CLIN (service) __________

Noun: EGLIN RANGE OPERATION & MAINTENANCE - AWARD

TERM OPTION ONE

DD1423 is Exhibit: A Descriptive Data:

The contractor shall provide O&M of the Eglin Range IAW the Performance Work Statement for the award term option one contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24 Months. Actual Start and Completion Dates will be filled in accordingly at time of award.

3002 OPTION CLIN (service) __________

Noun: NRTF OPERATION & MAINTENANCE - AWARD TERM

OPTION ONE

DD1423 is Exhibit: A Descriptive Data:

The contractor shall provide O&M of the NRTF IAW the Performance Work Statement for the award term option one contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24 Months. Actual Start and Completion Dates will be filled in accordingly

3003 OPTION CLIN (service) __________

Noun: USATR OPERATION & MAINTENANCE - AWARD TERM

OPTION ONE

DD1423 is Exhibit: A Descriptive Data:

The contractor shall provide O&M of the USATR IAW the Performance Work Statement for the award term option one contract period. This is a Cost Plus Award Fee CLIN.

Period of Performance is 24 Months. Actual Start and Completion Dates will be filled in

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

3004 OPTION CLIN (service) __________

Noun: MAJOR GROUND TEST FACILITIES - AWARD TERM

OPTION ONE

DD1423 is Exhibit: A Descriptive Data:

The Contractor shall provide test and test support services in the Major Ground Test Facilities (MGTF) IAW the Performance Work Statement and Section B Clause B01, Contract Type: Cost Plus Fixed Fee, for the award term option one contract period. This CLIN includes performing MGTF directive requirements IAW PWS Section 6, and performing overtime within the MGTFs as required. Period of Performance is 24 Months.

Actual Start and Completion Dates will be filled in accordingly at time of award.

The contract's most highly specialized positions are identified in paragraph (d)(2) of Clause B01 Contract Type: Cost Plus Fixed Fee. The subset of the estimated costs below number for these highly specialized positions is $9,929,800.

Estimated Cost (if all six months are exercised): $45,720,000 Fixed Fee % %

3005 OPTION CLIN (service) __________

Noun: EGLIN RANGE & MGTF CONTRACTOR ACQUIRED

PROPERTY - AWARD TERM OPTION ONE

Descriptive Data:

IAW Section H Clause H03 Contractor Acquired Property and the Performance Work Statement, the Contractor shall acquire property in support of O&M of the Eglin Range and for MGTF requirements for the award term option one contract period. This is a Cost- Reimbursement CLIN in which the Contractor receives no fee. Period of Performance is 24 months. Actual Start and Completion Dates will be filled in accordingly at time of

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

3006 OPTION CLIN (service) __________

Noun: NRTF CONTRACTOR ACQUIRED PROPERTY - AWARD

TERM OPTION ONE

Descriptive Data:

IAW Section H Clause H03 Contractor Acquired Property and the Performance Work Statement, the Contractor shall acquire property in support of O&M of the NRTF for the award term option one contract period. This is a Cost-Reimbursement CLIN in which the Contractor receives no fee. Period of Performance is 24 months. Actual Start and

3007 OPTION CLIN (service) __________

Noun: USATR CONTRACTOR ACQUIRED PROPERTY - AWARD

TERM OPTION ONE

Descriptive Data:

IAW Section H Clause H03 Contractor Acquired Property and the Performance Work Statement, the Contractor shall acquire property in support of O&M of the USATR for the award term option one contract period. This is a Cost-Reimbursement CLIN in which the Contractor receives no fee. Period of Performance is 24 months. Actual Start and

3008 OPTION CLIN (service) __________

Noun: EGLIN RANGE & MGTF TRAVEL - AWARD TERM OPTION

ONE

Descriptive Data:

When directed by the Government, the Contractor shall travel in support of O&M of the Eglin Range O&M CLIN and the MGTF requirements for the award term option one contract period IAW the Performance Work Statement and Section H Clause H06 Travel.

This is a Cost-Reimbursement CLIN in which the Contractor receives no fee. The Government shall reimburse the Contractor for travel costs in accordance with the applicable Federal Acquisition Regulation and its supplements. Period of Performance is 24 months. Actual Start and Completion Dates will be filled in accordingly at time of

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

3009 OPTION CLIN (service) __________

Noun: NRTF TRAVEL - AWARD TERM OPTION ONE Descriptive Data:

When directed by the Government, the Contractor shall travel in support of O&M of the NRTF requirements for the award term option one contract period IAW the Performance Work Statement and Section H Clause H06 Travel. This is a Cost-Reimbursement CLIN in which the Contractor receives no fee. The Government shall reimburse the Contractor for travel costs in accordance with the applicable Federal Acquisition Regulation and its supplements. Period of Performance is 24 months. Actual Start and Completion Dates

3010 OPTION CLIN (service) __________

Noun: USATR TRAVEL - AWARD TERM OPTION ONE Descriptive Data:

When directed by the Government, the Contractor shall travel in support of O&M of the USATR requirements for the award term option one contract period IAW the Performance Work Statement and Section H Clause H06 Travel. This is a Cost-Reimbursement CLIN in which the Contractor receives no fee. The Government shall reimburse the Contractor for travel costs in accordance with the applicable Federal Acquisition Regulation and its supplements. Period of Performance is 24 months. Actual Start and Completion Dates

3011 OPTION CLIN (service) __________

Noun: EGLIN RANGE OVERTIME - AWARD TERM OPTION ONE DD1423 is Exhibit: A Descriptive Data:

This CLIN represents the maximum overtime costs allowed for performing O&M of the Eglin Range for the award term option one contract period. The Contractor shall charge against this CLIN only the costs for overtime hours worked during the award term option one contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24

Estimated Total Item Amount: $16,120,000

3012 OPTION CLIN (service) __________

Noun: NRTF OVERTIME - AWARD TERM OPTION ONE DD1423 is Exhibit: A Descriptive Data:

This CLIN represents the maximum overtime costs allowed for performing O&M of the NRTF for the award term option one contract period. The Contractor shall charge against this CLIN only the costs for overtime hours worked during the award term option one contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

3013 OPTION CLIN (service) __________

Noun: USATR OVERTIME - AWARD TERM OPTION ONE DD1423 is Exhibit: A Descriptive Data:

This CLIN represents the maximum overtime costs allowed for performing O&M of the USATR for the award term option one contract period. The Contractor shall charge against this CLIN only the costs for overtime hours worked during the award term option one contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24

Estimated Total Item Amount: $76,800

3014 OPTION CLIN (service) __________

Noun: EGLIN RANGE TIER 1 DIRECTIVE LABOR - AWARD TERM

OPTION ONE

DD1423 is Exhibit: A Descriptive Data:

The Contractor shall provide all labor identified in Tier 1 Technical Directives supporting Eglin Range O&M requirements for the award term option one contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24 Months. Actual Start and

Estimated Total Item Amount: $4,980,000

3015 OPTION CLIN (service) __________

Noun: NRTF TIER 1 DIRECTIVE LABOR - AWARD TERM OPTION

ONE

DD1423 is Exhibit: A Descriptive Data:

The Contractor shall provide all labor identified in Tier 1 Technical Directives supporting NRTF O&M requirements for the award term option one contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24 Months. Actual Start and Completion

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

3016 OPTION CLIN (service) __________

Noun: USATR TIER 1 DIRECTIVE LABOR - AWARD TERM

OPTION ONE

DD1423 is Exhibit: A Descriptive Data:

The Contractor shall provide all labor identified in Tier 1 Technical Directives supporting USATR O&M requirements for the award term option one contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24 Months. Actual Start and Completion

Estimated Total Item Amount: $12,300

3017 OPTION CLIN (service) __________

Noun: DATA EXHIBIT A - AWARD TERM OPTION ONE DD1423 is Exhibit: A Descriptive Data:

The Contractor shall furnish data in support of the Eglin Range, NRTF, USATR and the MGTFs for the award term option one contract period. Data shall be provided IAW the Performance Work Statement and Section J, Exhibit A, DD Form 1423. Data is Not Separately Priced (NSP).

3018 OPTION CLIN (service) __________

Noun: EGLIN RANGE AWARD FEE POOL - AWARD TERM

OPTION ONE

Descriptive Data:

This CLIN represents the maximum award fee pool for the Eglin Range O&M CLIN, the award term option one contract period.

3019 OPTION CLIN (service) __________

Noun: NRTF AWARD FEE POOL - AWARD TERM OPTION ONE Descriptive Data:

This CLIN represents the maximum award fee pool for the NRTF O&M CLIN, the NRTF Overtime CLIN, and the NRTF Tier 1 Directive Labor CLIN for the award term option one

3020 OPTION CLIN (service) __________

Noun: USATR AWARD FEE POOL - AWARD TERM OPTION ONE Descriptive Data:

This CLIN represents the maximum award fee pool for the USATR O&M CLIN, the USATR Overtime CLIN, and the USATR Tier 1 Directive Labor CLIN for the award term option one contract period.

Qty Unit Price

ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

AWARD TERM OPTION TWO

4001 OPTION CLIN (service) __________

Noun: EGLIN RANGE OPERATION & MAINTENANCE - AWARD

TERM OPTION TWO

DD1423 is Exhibit: A Descriptive Data:

The contractor shall provide O&M of the Eglin Range IAW the Performance Work Statement for the award term option two contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24 Months. Actual Start and Completion Dates will be filled in accordingly at time of award.

4002 OPTION CLIN (service) __________

Noun: NRTF OPERATION & MAINTENANCE - AWARD TERM

OPTION TWO

DD1423 is Exhibit: A Descriptive Data:

The contractor shall provide O&M of the NRTF IAW the Performance Work Statement for the award term option two contract period. This is a Cost Plus Award Fee CLIN. Period of Performance is 24 Months. Actual Start and Completion Dates will be filled in accordingly

4003 OPTION CLIN (service) __________

Noun: USATR OPERATION & MAINTENANCE - AWARD TERM

OPTION TWO

DD1423 is Exhibit: A Descriptive Data:

The contractor shall provide O&M of the USATR IAW the Performance Work Statement for the award term option two contract period. This is a Cost Plus Award Fee CLIN.

Period of Performance is 24 Months. Actual Start and Completion Dates will be filled in

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

4004 OPTION CLIN (service) __________

Noun: MAJOR GROUND TEST FACILITIES - AWARD TERM

OPTION TWO

DD1423 is Exhibit: A Descriptive Data:

The Contractor shall provide test and test support services in the Major Ground Test Facilities (MGTF) IAW the Performance Work Statement and Section B Clause B01, Contract Type: Cost Plus Fixed Fee, for the award term option two contract period. This CLIN includes performing MGTF directive requirements IAW PWS Section 6, and performing overtime within the MGTFs as required. Period of Performance is 24 Months.

Actual Start and Completion Dates will be filled in accordingly at time of award.

The contract's most highly specialized positions are identified in paragraph (d)(2) of Clause B01 Contract Type: Cost Plus Fixed Fee. The subset of the estimated costs below for these highly specialized positions is $10,534,500.

Estimated Cost (if all six months are exercised): $48,510,000 Fixed Fee % %

4005 OPTION CLIN (service) __________

PROPERTY - AWARD TERM OPTION TWO

Descriptive Data:

IAW Section H Clause H03 Contractor Acquired Property and the Performance Work Statement, the Contractor shall acquire property in support of O&M of the Eglin Range and for MGTF requirements for the award term option two contract period. This is a Cost- Reimbursement CLIN in which the Contractor receives no fee. Period of Performance is 24 months. Actual Start and Completion Dates will be filled in accordingly at time of

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

4006 OPTION CLIN (service) __________

Noun: NRTF CONTRACTOR ACQUIRED PROPERTY - AWARD

TERM OPTION TWO

Descriptive Data:

IAW Section H Clause H03 Contractor Acquired Property and the Performance Work Statement, the Contractor shall acquire property in support of O&M of the NRTF for the award term option two contract period. This is a Cost-Reimbursement CLIN in which the Contractor receives no fee. Period of Performance is 24 months. Actual Start and

4007 OPTION CLIN (service) __________

Noun: USATR CONTRACTOR ACQUIRED PROPERTY - AWARD

TERM OPTION TWO

Descriptive Data:

IAW Section H Clause H03 Contractor Acquired Property and the Performance Work Statement, the Contractor shall acquire property in support of O&M of the USATR for the award term option two contract period. This is a Cost-Reimbursement CLIN in which the Contractor receives no fee. Period of Performance is 24 months. Actual Start and

4008 OPTION CLIN (service) __________

Noun: EGLIN RANGE & MGTF TRAVEL - AWARD TERM OPTION

TWO

Descriptive Data:

When directed by the Government, the Contractor shall travel in support of O&M of the Eglin Range O&M CLIN and the MGTF requirements for the award term option two contract period IAW the Performance Work Statement and Section H Clause H06 Travel.

This is a Cost-Reimbursement CLIN in which the Contractor receives no fee. The Government shall reimburse the Contractor for travel costs in accordance with the applicable Federal Acquisition Regulation and its supplements. Period of Performance is 24 months. Actual Start and Completion Dates will be filled in accordingly at time of

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

4009 OPTION CLIN (service) __________

Noun: NRTF TRAVEL - AWARD TERM OPTION TWO Descriptive Data:

When directed by the Government, the Contractor shall travel in support of O&M of the…