CDC - 2022-02-11_RSLFAC Phase 2A_DP8_Specifications.pdf

Request for Proposal

W912ER22R0028

Specifications for

Phase 2A, Package 5 (DP 8) Al Qassim Simulator Building

RSLFAC, Saudi Arabia

Volume 2 Specifications Divisions 1-41

US Army Corps of Engineers Middle East District

W912ER22R0028

RSLFAC PHASE 2A FACILITIES & INFRASTRUCTURE AL QASSIM AVIATION INSTITUTE,

DESIGN PACKAGE 8 KINGDOM OF SAUDI ARABIA

PROJECT TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 SUMMARY OF WORK

01 14 00 WORK RESTRICTIONS

01 15 00.12 10 SUPPLEMENTARY REQUIREMENTS

01 30 00 ADMINISTRATIVE REQUIREMENTS

01 32 17.12 10 COST-LOADED NETWORK ANALYSIS SCHEDULES (NAS)

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 42 15 METRIC MEASUREMENTS

01 45 00.00 10 QUALITY CONTROL

01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE (RMS CM)

01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS

01 57 19 TEMPORARY ENVIRONMENTAL CONTROLS

01 58 00 PROJECT IDENTIFICATION

01 78 00.49 CLOSEOUT SUBMITTALS

01 78 23 OPERATION AND MAINTENANCE DATA

01 91 00.15 TOTAL BUILDING COMMISSIONING

DIVISION 02 - EXISTING CONDITIONS

02 41 00 DEMOLITION

DIVISION 03 - CONCRETE

03 30 00 CAST-IN-PLACE CONCRETE

03 40 00.00 10 PLANT-PRECAST CONCRETE PRODUCTS FOR BELOW GRADE

CONSTRUCTION

03 45 00 PRECAST ARCHITECTURAL CONCRETE

DIVISION 04 - MASONRY

04 20 00 UNIT MASONRY

DIVISION 05 - METALS

05 05 23.16 STRUCTURAL WELDING

05 12 00 STRUCTURAL STEEL

05 30 00 STEEL DECKS

05 50 13 MISCELLANEOUS METAL FABRICATIONS

05 51 00 METAL STAIRS

05 51 33 ALUMINUM LADDERS

05 52 00 METAL RAILINGS

DIVISION 06 - WOOD, PLASTICS, AND COMPOSITES

06 10 00 ROUGH CARPENTRY

06 41 16.00 10 PLASTIC-LAMINATE-CLAD ARCHITECTURAL CABINETS

06 61 16 SOLID SURFACING FABRICATIONS

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 05 23 PRESSURE TESTING AN AIR BARRIER SYSTEM FOR AIR TIGHTNESS

07 13 53 ELASTOMERIC SHEET WATERPROOFING

07 14 00 FLUID-APPLIED WATERPROOFING

07 21 13 BOARD AND BLOCK INSULATION

PROJECT TABLE OF CONTENTS Page 1

READY TO ADVERTISE SUBMITTAL 11 FEBRUARY 2022W912ER22R0028

07 21 16 MINERAL FIBER BLANKET INSULATION

07 22 00 ROOF AND DECK INSULATION

07 27 10.00 10 BUILDING AIR/WATER/VAPOR BARRIER SYSTEM

07 27 19.01 SELF-ADHERING AIR BARRIERS

07 27 26 FLUID-APPLIED MEMBRANE AIR/VAPOR BARRIERS

07 52 00 MODIFIED BITUMINOUS MEMBRANE ROOFING

07 55 00 PROTECTED MEMBRANE ROOFING

07 60 00 FLASHING AND SHEET METAL

07 84 00 FIRESTOPPING

07 92 00 JOINT SEALANTS

DIVISION 08 - OPENINGS

08 11 13 STEEL DOORS AND FRAMES

08 11 16 ALUMINUM DOORS AND FRAMES

08 14 00 WOOD DOORS

08 22 20 FIBERGLASS REINFORCED PLASTIC (FRP) DOORS

08 31 00 ACCESS DOORS AND PANELS

08 33 23 OVERHEAD COILING DOORS

08 41 13 ALUMINUM-FRAMED ENTRANCES AND STOREFRONTS

08 51 13 ALUMINUM WINDOWS

08 71 00 DOOR HARDWARE

08 81 00 GLAZING

DIVISION 09 - FINISHES

09 06 00 SCHEDULES FOR FINISHES

09 22 00 SUPPORTS FOR PLASTER AND GYPSUM BOARD

09 23 00 GYPSUM PLASTERING (FOR INTERIOR USE)

09 24 23 CEMENT STUCCO (FOR EXTERIOR USE)

09 29 00 GYPSUM BOARD

09 30 10 CERAMIC, QUARRY, AND GLASS TILING

09 51 00 ACOUSTICAL CEILINGS

09 65 00 RESILIENT FLOORING

09 69 13 RIGID GRID ACCESS FLOORING

09 90 00 PAINTS AND COATINGS

DIVISION 10 - SPECIALTIES

10 11 00 VISUAL DISPLAY UNITS

10 14 00.10 EXTERIOR SIGNAGE

10 14 00.20 INTERIOR SIGNAGE

10 28 13 TOILET ACCESSORIES

10 44 16 FIRE EXTINGUISHERS

10 56 13 STEEL SHELVING (OPEN AND DRAWER UNITS)

DIVISION 12 - FURNISHINGS

12 24 13 ROLLER WINDOW SHADES

12 34 00 MANUFACTURED PLASTIC CASEWORK

12 36 00 COUNTERTOPS

12 50 00.13 10 FURNITURE AND FURNITURE INSTALLATION

12 59 00 SYSTEMS FURNITURE

DIVISION 13 - SPECIAL CONSTRUCTION

13 31 33 TENSIONED FABRIC STRUCTURES

13 48 73 SEISMIC CONTROL FOR MISCELLANEOUS EQUIPMENT

PROJECT TABLE OF CONTENTS Page 2

DIVISION 21 - FIRE SUPPRESSION

21 13 13.00 10 WET PIPE SPRINKLER SYSTEM, FIRE PROTECTION

21 13 18.00 10 PREACTION SPRINKLER SYSTEMS, FIRE PROTECTION

21 22 00.00 40 CLEAN AGENT FIRE EXTINGUISHING SYSTEMS

DIVISION 22 - PLUMBING

22 00 00 PLUMBING, GENERAL PURPOSE

DIVISION 23 - HEATING, VENTILATING, AND AIR CONDITIONING (HVAC)

23 03 00.00 20 BASIC MECHANICAL MATERIALS AND METHODS

23 05 93 TESTING, ADJUSTING, AND BALANCING FOR HVAC

23 07 00 THERMAL INSULATION FOR MECHANICAL SYSTEMS

23 09 13 INSTRUMENTATION AND CONTROL DEVICES FOR HVAC

23 23 00 REFRIGERANT PIPING

23 25 00 CHEMICAL TREATMENT OF WATER FOR MECHANICAL SYSTEMS

23 30 00 HVAC AIR DISTRIBUTION

23 35 16.17 10 MECHANICAL ENGINE EXHAUST SYSTEMS

23 64 10 WATER CHILLERS, VAPOR COMPRESSION TYPE

23 64 26 CHILLED AND CONDENSATE WATER PIPING SYSTEMS

23 81 00 DECENTRALIZED UNITARY HVAC EQUIPMENT

23 81 23.00 20 COMPUTER ROOM AIR CONDITIONING UNITS

DIVISION 26 - ELECTRICAL

26 08 00 APPARATUS INSPECTION AND TESTING

26 11 16 13.8KV COMPACT SUBSTATIONS

26 20 00 INTERIOR DISTRIBUTION SYSTEM

26 24 13 SWITCHBOARDS

26 33 53.00 20 UNINTERRUPTIBLE POWER SUPPLY (UPS)

26 41 00 LIGHTNING PROTECTION SYSTEM

26 51 00 INTERIOR LIGHTING

26 56 00 EXTERIOR LIGHTING

DIVISION 27 - COMMUNICATIONS

27 05 28.36 40 CABLE TRAYS FOR COMMUNICATIONS SYSTEMS

27 10 00 BUILDING TELECOMMUNICATIONS CABLING SYSTEM

27 20 01.12 10 INTERIOR DISTRIBUTION SYSTEM FOR COMMUNICATIONS SYSTEMS

27 41 16.00 10 SATELLITE TELEVISION SIGNAL RECEPTION SYSTEM (SATV)

27 51 16 PUBLIC ADDRESS SYSTEMS

DIVISION 28 - ELECTRONIC SAFETY AND SECURITY

28 10 05 ELECTRONIC SECURITY SYSTEMS (ESS)

28 31 76 INTERIOR FIRE ALARM AND MASS NOTIFICATION SYSTEM

DIVISION 31 - EARTHWORK

31 00 00 EARTHWORK

31 32 11 SOIL SURFACE EROSION CONTROL

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 01 19 FIELD MOLDED SEALANTS FOR SEALING JOINTS IN RIGID PAVEMENTS

32 11 20 SUBBASES FOR FLEXIBLE PAVING

32 11 23.01 AGGREGATE BASE COURSES

PROJECT TABLE OF CONTENTS Page 3

32 12 10 BITUMINOUS TACK AND PRIME COATS

32 12 16 HOT-MIX ASPHALT (HMA) FOR ROADS

32 16 13 CONCRETE SIDEWALKS AND CURBS

32 17 23.00 20 PAVEMENT MARKINGS

DIVISION 33 - UTILITIES

33 11 00 WATER UTILITY DISTRIBUTION PIPING

33 30 00 SANITARY SEWERS

33 71 02 UNDERGROUND ELECTRICAL DISTRIBUTION

33 72 02 UNDERGROUND COMMUNICATION SYSTEM

33 82 00 TELECOMMUNICATIONS OUTSIDE PLANT (OSP)

DIVISION 41 - MATERIAL PROCESSING AND HANDLING EQUIPMENT

41 22 13.15 BRIDGE CRANES, OVERHEAD ELECTRIC, UNDER RUNNING (SINGLE

GIRDER)

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 4

SECTION 01 11 00

SUMMARY OF WORK

PART 1 GENERAL

1.1 WORK COVERED BY CONTRACT DOCUMENTS

1.1.1 Project Description

Under the Foreign Military Sales (FMS) case, SR-B-WAL the Kingdom of Saudi Arabia (KSA) has a requirement for a design bid build RFP to construct a Simulator Building along with all supporting facilities including electric service, water, sewer, gas, paving, drainage, site improvements, demolition, and information systems for the Royal Saudi Land Forces Aviation Command (RSLFAC) at the Aviation Institute in Al Qassim. All work shall be done in accordance with the design documents including plans and specifications provided herein. All construction and other associated efforts shall be done in accordance with local building codes and internationally recognized standards with respect to safety and general construction, and as described in these documents. Moreover, the construction contractor will be responsible for reviewing and confirming the site conditions in the topographic and geotechnical surveys and reports provided. The Contractor shall also perform a pre-construction site investigation with the USACE field staff and RSLFAC to evaluate and finalize travel routes, site conditions, and any other incidental work to make requirements fully functional in order to provide the Government with a complete construction and warranty for this project.

The Contractor is to construct improvements at Al Qassim as identified below:

Construct Simulator Building along with all supporting facilities including electric service, water, sewer, gas, paving, walks, curbs, gutters, drainage, site improvements, demolition, and information systems.

1.1.2 Location

Institute at Al Qassim: Located in Al Qassim approximately 395 KM north-wast of Riyadh.

1.2 EXISTING WORK

In addition to "FAR 52.236-9, Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements":

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work shall be in a condition equal to or better than that which existed before new work started.

SECTION 01 11 00 Page 1

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

In addition to work being executed in accordance with the Technical Requirements described in this package, all work shall be coordinated and approved with the CONTRACTING OFFICER prior to further coordination with representatives of Royal Saudi Land Forces Aviation Command (RSLFAC) and other Command elements, either identified or not, that may be impacted during this project. The Contractor shall be responsible for coordinating and completing all work under this contract within the performance period under this contract. Base Life Support Area is not available, the Contractor is responsible for the sustainment of their work force, and the Contractor shall plan for daily commutes to access work sites. Base access is the sole responsibility of the Contractor. The Contractor shall follow all regulation and process put forth by the Royal Saudi Land Forces Aviation Command (RSLFAC) necessary to obtain and maintain base access for the duration of the project. USACE has no obligation to act as an intermediary. The U.S. Government will not be responsible for any lack of coordination and communication by the Contractor which results in delays.

The Contractor is responsible for all delays with base access for personnel, vehicles, and deliveries.

-- End of Section --

SECTION 01 11 00 Page 2

SECTION 01 14 00

WORK RESTRICTIONS

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

List of Contact Personnel; G, R

1.2 SPECIAL SCHEDULING REQUIREMENTS

1.2.1 Temporary Utilities

Temporary utilities shall be working including, but not limited to, electric service, plumbing systems, HVAC, fire alarm, sprinkler and telecommunication, and shall be in continuous service for the Government personnel to carry out their work.

1.2.2 Prior to Commencement of Work

Have materials, equipment, and personnel required to perform the work at the site prior to the commencement of the work.

1.2.3 Permission to interrupt Activity

Permission to interrupt any Activity including, but not limited to, roads, egress corridors and stairways, and/or utility service must be requested in writing a minimum of 15 calendar days and again two work days prior to the desired date of interruption.

1.3 CONTRACTOR ACCESS AND USE OF PREMISES

1.3.1 Activity Regulations

Ensure that Contractor personnel employed on the Activity become familiar with and obey Activity regulations including safety, fire, traffic and security regulations. Keep within the limits of the work and avenues of ingress and egress. Wear hard hats in designated areas. Do not enter any restricted areas unless required to do so and until cleared for such entry. Mark Contractor equipment for identification.

1.3.1.1 Subcontractors and Personnel Contacts

Provide a list of contact personnel of the Contractor and subcontractors including addresses and telephone numbers for use in the event of an emergency. As changes occur and additional information becomes available, correct and change the information contained in previous lists.

SECTION 01 14 00 Page 1

1.3.1.2 No Smoking Policy

Smoking is prohibited within and outside of all buildings on installation, except in designated smoking areas. This applies to existing buildings, buildings under construction and buildings under renovation. Discarding tobacco materials other than into designated tobacco receptacles is considered littering and is subject to fines. The Contracting Officer will identify designated smoking areas.

1.3.2 Working Hours

Regular working hours must consist of a 10 hour period, between 730 a.m.

and 1800 p.m., Sunday to Thursday, , excluding Government holidays. KSA holiday of Ramadan and other holidays may be observed and should be included in initial schedule submittal. KSA summer work hours shall be observed in accordance with KSA Ministry of Labor mandate.

1.3.3 Work Outside Regular Hours

Work outside regular working hours requires Contracting Officer approval.

Make application 15 calendar days prior to such work to allow arrangements to be made by the Government for inspecting the work in progress, giving the specific dates, hours, location, type of work to be performed, contract number and project title. Based on the justification provided, the Contracting Officer may approve work outside regular hours. During periods of darkness, the different parts of the work must be lighted in a manner approved by the Contracting Officer. Make utility cutovers after normal working hours or on Saturdays, Sundays, and Government holidays unless directed otherwise.

1.3.4 Utility Cutovers and Interruptions

a. Make utility cutovers and interruptions after normal working hours or on Fridays, Saturdays, and Government holidays. Conform to procedures required in paragraph WORK OUTSIDE REGULAR HOURS.

b. Ensure that new utility lines are complete, except for the connection, before interrupting existing service.

All utility outages shall be coordinated with the Operations and Maintenance (O&M) Group for the Base, and a minimum of 24-hour notice shall be given prior to any utility outages.

Interruption to water, sanitary sewer, storm sewer, telephone service, electric service, air conditioning, heating, fire alarm, compressed air, and sprinkler service are considered utility cutovers pursuant to the paragraph entitled "Work Outside Regular Hours." Such interruptions are further limited to 8 hours. This time limit includes time for deactivation and reactivation.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

-- End of Section --

SECTION 01 14 00 Page 2

SECTION 01 15 00.12 10

SUPPLEMENTARY REQUIREMENTS

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Registered Designers' Proof of Degrees and Licensing; G M/R

Requests for Digging Permits; G M/R

Proposed Means of Providing Project Security; G M/R

Requests for Hot Work Permits; G M/R

SD-07 Certificates

Certificates Of Compliance

SD-11 Closeout Submittals

Consolidated Inventory of All Excess Supplies, Materials and Equipment; G M/R

1.2 DESIGNER OF RECORD QUALIFICATIONS

The following shall serve as minimum requirements for Registered Designers, including engineers and architects acting as Designer(s) of Record (DOR). The Designer(s) of Record shall have responsibility for the preparation and issuing of documents and services pertaining to that specific discipline. All design work shall be performed or supervised by the appropriate Designer of Record.

Each Registered Designer and/or Design Firm performing design work shall have at minimum one person with a bachelor's degree or equivalent college degree in the applicable discipline, and each shall hold a current professional registration in any of the 50 States of the United States of America, or equivalent recognized international body such as Europeene d'Associations Nationales d'Ingenieurs. Acceptance of equivalency of a university's degree for professional registration and each professional registration shall be at the sole discretion of the Contracting Officer. Proof of degrees and licensing shall be provided.

At a minimum each design discipline shall have at least one person with a minimum of five (5) years of experience in the applicable field designing projects of similar scope, complexity and

SECTION 01 15 00.12 10 Page 1 magnitude, or as otherwise specified in the Contract Documents.

1.3 MEETING MINUTES

The Contractor shall be responsible for the preparation of minutes of all meetings specified in the contract documents. Unless otherwise specified, these minutes shall be prepared within two (2) working days after meeting and signed by both the Contractor and Contracting Officer. Contractor shall provide signed copies to all attendees.

1.4 UNSCHEDULED WORK STOPPAGES

The Contractor shall anticipate unscheduled removal from the work site an average of 10 hours per month per installation. If the total quantity of delays varies above or below the stated quantity, an equitable adjustment under Contract Clause 52.243-4 CHANGES shall be made upon written demand of either party. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date if, in the judgment of the Contracting Officer, a delay is justified.

1.5 DIGGING PERMITS

1.5.1 Requirements for Digging Permits

Prior to the start of any work activity which requires excavation within the current project site, the Contractor shall obtain a digging permit.

1.5.2 Requests for Digging Permits

Requests for Digging Permits shall be submitted through the Contracting Officer to the project site a minimum of seven (7) days prior to the start of the work activity covered by the permit. The request for a Digging Permit shall include a narrative description of the work to be performed and a detailed map of the area of the excavation clearly marking the location of all known utilities or other obstructions. If the work activity covered by the Digging Permit request also requires a utility outage, a separate request for the outage shall be submitted.

1.5.3 Preparation of Requests for Digging Permits

Prior to submitting a request for a Digging Permit, the Contractor shall carefully review the area to be excavated to determine the location of existing utilities and other obstructions. The Contractor will review available drawings and will conduct a visual inspection of the site. The Contractor will utilize underground utility detecting devices such as metal and cable detectors to determine the location of existing utilities.

All utility lines found shall be clearly flagged or marked and the location of the utility shall be shown on the drawing to be submitted with the request for Digging Permit.

1.5.4 Existing Underground Utilities

Existing utilities may be present in the construction area which may not be shown, or are inaccurately shown, on the base as-built drawings and the contract drawings. The Contractor shall exercise utmost care in researching locations of existing utilities and reducing damage to existing utilities.

Any utilities damaged by the Contractor shall be promptly repaired by the Contractor. The Contracting Officer will review and approve any proposed

SECTION 01 15 00.12 10 Page 2 repairs. Any damage to existing utilities will be immediately reported to the Contracting Officer and the Base/Site Operator. The repair work and any temporary work required to keep the system operational while repairs are being completed shall be performed at no cost to the Government..

1.5.5 Use of Underground Utility Detecting Device

Prior to any excavation, a metal and/or cable detecting device shall be used along the route of the excavation. All underground utilities discovered by this method will be flagged a minimum distance of one-half (1/2) meter on each side of the location.

1.5.6 Hand Excavation

Hand excavation methods and special supervisory care shall be used between any flagged markers, in areas of known or suspected hazards, and in areas known or suspected to have multiple and/or concentrated utility lines or connections.

1.6 HAUL ROUTES - SPECIAL REQUIREMENTS

The Contractor shall be responsible for coordinating with the Host Government use of any existing roads as haul routes. Construction, and routing of new haul roads, and/or upgrading of existing roads for the Contractor's use, is the sole responsibility of the Contractor. It shall be the Contractor's responsibility to obtain such local authorizations, permits and licenses necessary to establish his mobilization camp, quarry operations, batching operations and haul routes.

1.7 RESPONSIBILITY FOR PHYSICAL SECURITY

Prior to mobilization, the Contractor shall submit his proposed means of providing project security to prevent unauthorized access to equipment, facilities, materials and documents, and to safeguard them against sabotage, damage, and theft. The Contractor shall be responsible for physical security of all materials, supplies, and equipment of every description, including property which may be Government-furnished or owned, for all areas occupied jointly by the Contractor and the Government, as well as for all work performed.

1.8 CERTIFICATES OF COMPLIANCE

Any certificates required for demonstrating proof of compliance of materials with specification requirements shall be executed in accordance with Section 01 33 00 SUBMITTAL PROCEDURES. Each certificate shall be signed by an official authorized to certify in behalf of the manufacturing company involved and shall contain the name and address of the Contractor, the project name and location, description and the quantity of the items involved, and date or dates of shipment or delivery to which the certificates apply. Copies of laboratory test reports submitted with certificates shall contain the name and address of the testing laboratory and the date or dates of the tests to which the report applies.

Certification shall not be construed as relieving the Contractor from furnishing satisfactory material.

1.9 ACCIDENT PREVENTION

The Contractor shall comply with all applicable Host Country laws and with

SECTION 01 15 00.12 10 Page 3 such additional measures as the Contracting Officer may find necessary in accordance with CONTRACT CLAUSE 52.236-13 entitled ACCIDENT PREVENTION (NOV 1991). Applicable provisions of the Corps of Engineers manual entitled Safety and Health Requirements Manual EM 385-1-1, will be applied to all work under this contract. The referenced manual may be obtained from the Contracting Officer's Representative at the jobsite or from the Middle East District at Winchester, Virginia.

1.9.1 Ground Fault Circuit Interrupter (GFCI) Requirement - Overseas Construction

The Corps of Engineers Health and Safety Manual, EM 385-1-1, section 11.C.05.a. states: "The GFCI device shall be calibrated to trip within the threshold values of 5 ma +/- 1 ma as specified in Underwriters Laboratory (UL) Standard 943." A variance from USACE has been granted allowing 10 ma, in lieu of 5 ma, for overseas activities that use 220 Volts(V)/50 hertz(hz) electrical power.

1.9.2 Temporary Power - Electrical Distribution Boxes

EM 385-1-1 section 11.A.01.a. states "All electrical wiring and equipment shall be a type listed by a nationally recognized testing laboratory for the specific application for which it is to be used." This includes temporary electrical distribution boxes. Locally manufactured electrical boxes will not be allowed. Only manufactured electrical distribution boxes that meet the European CE requirements, with 10 ma CE type GFCIs installed shall be allowed.

Contractors shall:

a. Make no modifications that might void any CE or manufacturer certification.

b. Test the installed systems to demonstrate that they operate properly and provide the 10 ma earth leakage protection.

c. Ensure GFCIs will have an integral push-to-test function. The testing shall be performed on a regular basis.

d. Check that proper grounding is checked regularly and flexible cords, connectors, and sockets inspected before each use.

1.9.3 Reinforcement Caps

All rebar and other protruding reinforcing steel, onto and into which employees could fall, shall be guarded to eliminate the hazard of impalement. The guarding shall meet Code of Regulations, Title 8, Section

344.90 California Impalement Protection. Each protective cover shall be marked with the following information:

(1) Model Number or Trademark.

(2) California Approval Number as issued pursuant to Sections 1712 and 1505 of the above listed Code .

(3) Size(s) designation.

SECTION 01 15 00.12 10 Page 4

1.10 CONTRACTOR FURNISHED SPARE PARTS

1.10.1 General

The requirements of this clause are in addition to any requirements for the provision of specific spare parts to be provided by the Contractor included in the contract documents. The Contractor shall furnish spare parts as directed by the Contracting Officer under the provisions of this clause for all equipment for which O&M data is to be provided under Section 01 78 23 Operations and Maintenance Data of this contract. The term "spare parts" as used herein shall include spare parts, special tools and test equipment.

1.10.2 Selection of Spare Parts to be Furnished

The Contractor shall provide master parts lists, recommended spare parts lists and lists of special tools and test equipment as a part of the equipment O&M data required by Section 01 78 23 Operations and Maintenance Data. The master parts list shall include the supplier's price for each part. After review of the lists, the Contracting Officer will select spare parts and furnish written direction to the Contractor indicating quantities and types of spare parts to be furnished by the Contractor.

Written directions for spare parts orders may be provided on an incremental basis as reviews of O&M data submitted by the Contractor are completed but will not necessarily be issued in the sequence in which the Contractor submitted the equipment O&M data.

1.10.3 Procurement and Delivery of Spare Parts

The Contractor shall procure and be responsible for delivery, receipt, handling, placing in storage, inventory, and turnover to the Contracting Officer all spare parts selected by the Contracting Officer.

In addition to the recommended spare parts list required in paragraph SELECTION OF SPARE PARTS TO BE FURNISHED above, the Contractor is responsible to have six (6) months supply of manufacturer's recommended spare parts on site ready to turn over to the Contracting Officer at the time of acceptance of the facility.

1.10.3.1 Shipment and Delivery

The Contractor shall be responsible for the shipment and delivery of spare parts to the location on or near the site in as selected by the Contracting Officer. The Contractor shall provide all manpower and equipment required to receive and place into designated storage areas all spare parts purchased under this clause. The Contractor shall give the Contracting Officer thirty (30) calendar days notice of arrival at the site of the first shipment.

1.10.3.2 Turnover of Spare Parts

The Contractor shall notify the Contracting Officer seventy-two (72) hours prior to delivery of spare parts to the designated storage area. The Contractor and a representative of the Contracting Officer will perform a joint inventory of the spare parts and the spare parts will be turned over to the Contracting Officer. Spare parts purchased under this clause shall not be used by the Contractor.

SECTION 01 15 00.12 10 Page 5

1.10.3.3 Parts and Package Identification

Prior to shipment from point of purchase, each spare part shall be tagged or otherwise marked or labeled. Such labeling may be placed or affixed to the container, box or packaging in which spare parts are located when it is not feasible to place or affix such labeling directly on each spare part. Tags or labels shall include, but not necessarily be limited to;

part number, description, parent equipment name and number location, project and/or other data as directed by the Contracting Officer.

1.10.3.4 Preservation and Packaging Instruction

a. Items ordered under this contract shall be preserved and packed for a minimum of three (3) years shelf life storage. All items shall be individually packaged except when the manufacturer specifies that the items are to be used in sets. Appropriate identification labels must be affixed to the items protective box or package. After the spare parts are packaged, the manufacturer shall weigh the spare parts and packaging and place the weight and size of the packaged container on the label with other information as outlined herein. Each item, not normally identified with manufacturer's name and part number, shall have an appropriate label affixed to it with manufacturer's name and part number.

b. Machined spare parts shall be lubricated or coated in order to withstand extensive periods of storage in a highly corrosive atmosphere.

c. Large items (greater than 50 lbs., or larger than one cubic foot) shall be packaged in waterproof wooden boxes and properly braced.

Cushioning shall be used to prevent damage to the item and to the packaging material.

d. Solid state components, such as diodes, transistors, integrated circuits or equipment consisting of such parts which can be damaged as a result of static electricity and other stray electro-magnetic fields shall be packaged in heat-sealed, aluminum foil, laminated, flexible packages.

e. All other spare parts shall be packaged in heat sealed plastic bags or wrap. Delicate and more fragile items such as test equipment shall be cushioned or wrapped with transparent bubble wrap material prior to being inserted into the plastic package.

1.10.4 Warranty

All spare parts provided by the Contractor under this clause are subject to the general warranty clauses of this contract.

1.10.5 Payments for Spare Parts

Payments for spare parts ordered under the paragraph entitled "Selection of Spare Parts To Be Furnished" will be made under the payment item of the Proposal Schedule entitled "Spare Parts". Payments for spare parts specifically required elsewhere in this contract shall be considered as part of those equipment costs and shall be included in other payment items as appropriate. Payments for spare parts ordered under this clause shall be based on the invoice price (FOB supplier) plus certified invoice price of surface shipment to the site. The invoice price (FOB supplier) shall

SECTION 01 15 00.12 10 Page 6 include the separately listed cost for preservation and packaging by the manufacturer as specified herein. The Contractor shall provide invoices and any additional backup which may be required to demonstrate that the invoices presented represent the cost of spare parts, preservation and packaging, and cost of surface shipment to the site. Payment for handling, delivery, inventory, turnover, customs, overhead or profit shall not be paid or allowed under this Contract Provision, and shall be included in the cost for installation of this equipment under the other appropriate payment items of this contract. Price increases over prices furnished under paragraph SELECTION OF SPARE PARTS TO BE FURNISHED shall be fully substantiated. Payment for spare parts will be made after the spare parts have been accepted at the site by the Contracting Officer. If the total payments under the payment item entitled "Spare Parts" does not reduce the balance of this payment item to zero, the remaining balance will be deducted from the final contract amount. If orders exceed the payment item entitled "Spare Parts", a modification for equitable adjustment will be issued in accordance with Contract Clause 52.243-4 entitled CHANGES. Payments for spare parts ordered under this clause shall constitute full payment for all cost of the spare parts and associated cost of preservation and packaging, and cost of surface shipment to the site. Other ancillary costs shall be included by the Contractor under the other appropriate payment items of this contract and no additional cost except as provided herein will be allowed.

1.11 LOCALLY AVAILABLE SERVICE FOR EQUIPMENT

All equipment furnished under this contract, regardless of country of manufacture or purchase, must have in-country service availability. In the event that the Contractor proposed to provide equipment for which in-country service is not available, the Contractor must provide written justification for the Contracting Officer's approval. This justification shall be submitted for each product or material for which a waiver is sought concurrently with the submittal required by the Technical Provisions. Submission of group or "blanket" waivers is unacceptable.

1.12 CONTRACTOR'S MOBILIZATION AREA

The contractor shall not be authorized to have living accommodations for his work force on the site. The Contractor is responsible for obtaining any required additional mobilization area above that designated. On completion of the contract, all facilities shall be removed from the mobilization area by the Contractor and shall be disposed of in accordance with applicable Host Government Laws and Regulations. The site shall be cleared of construction debris and other materials and the area restored to its final grade. See Section 01 50 00 TEMPORARY CONSTRUCTION FACILITIES for additional requirements.

1.13 CONTRACTOR'S OFF BASE MOBILIZATION AREA

The Contractor shall provide, furnish, operate and maintain facilities for his batching operations (e.g. concrete, asphalt, etc.) major shops and living facilities for his workers in an area off base. The specific area must be located such that no new contractor facilities are within the "Inhabited Building Clear Zone" (approximately 1355 meters, radius) surrounding ammunition/explosives storage and/or handling areas. The Contractor must submit his desired site location to the Contracting Officer for approval. All utilities will be the responsibility of the Contractor

SECTION 01 15 00.12 10 Page 7 and shall be provided at no cost to the Government. On completion of the contract, all facilities shall be removed by the Contractor and shall be disposed of in the manner directed by the Contracting Officer. The site shall be cleared of construction debris and other materials and the area restored to its original condition. See Section 01 50 00 TEMPORARY CONSTRUCTION FACILITIES for additional requirements.

1.13.1 Facilities Within the Mobilization Site

All facilities within the Contractor's mobilization site shall be of substantial construction suitable for the local weather conditions.

Housing, messing and sanitary facilities shall meet the requirements of Corps of Engineers Safety and Health Requirements Manual EM 385-1-1. The Contractor shall provide all utilities required to make the site self-sufficient.

1.14 PHYSICAL CONDITIONS

The indications of physical conditions on the drawings and in the specifications are the result of site investigations.

1.15 STANDARDIZATION

Where two or more items of the same type or class of equipment furnished in this project are required, the units shall be products of the same manufacturer and shall be interchangeable when of the same size, capacity, performance characteristics, and rating. The only exception to this requirement is where the items are interchangeable due to conformance with industry standards (valves, fittings, etc.), they need not be by the same manufacturer. This requirement applies to all manufactured items in the project which normally require repair or replacement during the life of the equipment.

1.16 ON-BASE PHOTOGRAPHY PROHIBITION

The Contractor shall not engage in any form of photography without prior written approval from the Contracting Officer.

1.17 PUBLIC RELEASE OF INFORMATION

1.17.1 Prohibition

There shall be no public release of information or photographs concerning any aspect of the materials or services relating to this bid, contract, purchase order, or other documents resulting therefrom without the prior written approval of the Contracting Officer.

1.17.2 Subcontract and Purchase Orders

The Contractor agrees to insert the substance of this clause in all purchase orders and subcontract agreements issued under this contract.

1.18 RESIDUAL CONSTRUCTION MATERIAL

All Contractor purchased materials and equipment intended for incorporation into the completed facilities and which are later determined excess to the actual construction requirements, will become the property of the Government. The residual materials and equipment shall be tagged

SECTION 01 15 00.12 10 Page 8

(giving the area where like type material and equipment were installed), and stored in an orderly manner in a designated area as directed and approved by the Contracting Officer.

1.19 CUSTOM EXEMPT CONTRACT

The Contractor shall furnish to the Contracting Officer, just prior to completion of this contract, a consolidated inventory of all inventory of all excess supplies, materials and equipment imported duty free for use under this contract. The Contractor shall either pay required duties on the excesses, re-export the excesses, or the excesses shall become the property of the Government.

1.20 COMPLIANCE WITH HOST COUNTRY RULES AND CUSTOMS

The laws of Host Country may prohibit access to certain areas of the country which are under military control. The Contractor shall furnish the Contracting Officer the names of personnel, type, and amounts of equipment, dates and length of time required at the site, and the purpose of entering the host country. It is understood that areas to which rights of entry are provided by the Host Government are to be used only for work carried out under the contract and no destruction or damages shall be caused, except through normal usage, without concurrence of the Host Government.

1.20.1 Contractor's Responsibilities

The following items are the sole responsibility of the Contractor to investigate, estimate as to cost, and assume the risk, as normally encountered by Contractors. The Contractor shall be responsible for determining the effect of the following on his own cost of performance of the contract and for including sufficient amount in the contract price:

a. Official language and type of accounts required to satisfy the officials of the Local Government.

b. Entry and exit visas, residence permits, and residence laws applicable to aliens. This includes any special requirements of the Host Government, including those required by local Labor Offices, which the Contractor may have to fulfill before an application for a regular block of visas will be accepted.

c. Passports, health and immunization certificates, and quarantine clearance.

d. Compliance with local labor and insurance laws, including payment of employer's share of contribution, collecting balance from employee and paying into insurance funds.

e. Strikes, demonstrations and work stoppage.

f. Collection through withholding and payment to local Government, of any Host Country income tax on employees subject to tax.

g. Arranging to perform work in the Host Country, to import personnel, to employ non-indigenous labor, to receive payments and to remove such funds from the country.

h. Operating under local laws, practices, customs and controls, and with local unions, in connection with hiring and firing, mandatory

SECTION 01 15 00.12 10 Page 9 wage scales, vacation pay, severance pay, overtime, holiday pay, 7th day of rest, legal notice or pay in lieu thereof for dismissal of employees, slowdown and curtailed schedules during religious holidays and ratio of local labor employed in comparison to others.

i. Possibility of claims in local bureaus, litigation in local courts, or attachment of local bank accounts.

j. Compliance with workmen's compensation laws and contributions into funds. Provisions of necessary medical service for Contractor employees.

k. Special license required by the local Government for setting up and operating any manufacturing plant in the Host Country, e.g.

concrete batching, precast concrete, concrete blocks, etc.

l. Sales within the host country of Contractor-owned materials, and equipment.

m. Special licenses for physicians, mechanics, tradesmen, drivers, etc.

n. Identification and/or registration with local police of imported personnel.

o. Stamp tax on documents, payments and payrolls.

p. Base passes for permanent staff, day laborers, motor vehicles, etc.

q. Compliance with all customs and import rules, regulations and restrictions, including, but not limited to, local purchase requirements.

1.21 RADIO TRANSMITTER RESTRICTIONS

To preclude accidental actuation of sensitive electronic equipment, the Contractor shall not use radio transmitting equipment without prior approval of the Contracting Officer.

1.22 BASE HOT WORK PERMITS

1.22.1 Requirement for Hot Work Permits

Prior to the start of a work activity including hot work (welding, burning, etc.) or the operating of other flame producing devices, the Contractor shall obtain a Hot Work Permit.

1.22.2 Requests for Hot Work Permits

Requests for Hot Work Permits shall be submitted through the Contracting Officer to the Base Fire Department a minimum of 7 days prior to the start of the work activity covered by the permit. The request for a Hot Work Permit shall include a narrative description of the work to be accomplished, a list of equipment to be used, and a description of special safety precautions that the Contractor will put in place during the work to assure compliance with EM 385-1-1 and Base Fire Regulations.

SECTION 01 15 00.12 10 Page 10

1.22.3 Preparatory Inspections and Inspection of Equipment

During the Preparatory Inspection for any work activity including hot work, the Hot Work Permit shall be reviewed. During the Preparatory inspection, all hot equipment and safety equipment shall be checked to assure that it is in proper working order. Safety equipment required by the Hot Work Permit shall be checked at the beginning of each shift to assure that it is in proper working order.

-- End of Section --

SECTION 01 15 00.12 10 Page 11

THIS PAGE INTENTIONALLY LEFT BLANK

SECTION 01 15 00.12 10 Page 12

SECTION 01 30 00

ADMINISTRATIVE REQUIREMENTS

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

1.2 MINIMUM INSURANCE REQUIREMENTS

Provide the minimum insurance coverage required by FAR 28.307-2 Liability, during the entire period of performance under this contract. Provide other insurance coverage as required by law.

1.3 SUPERVISION

1.3.1 Minimum Communication Requirements

Have at least one qualified superintendent, or competent alternate, capable of reading, writing, and conversing fluently in the English language, on the job-site at all times during the performance of contract work. In addition, if a Quality Control (QC) representative is required on the contract, then that individual must also have fluent English communication skills.

1.3.2 Duties

The project superintendent is primarily responsible for managing and coordinating day-to-day production and schedule adherence on the project.

The superintendent is required to attend partnering meetings, and quality control meetings. The superintendent or qualified alternative must be on-site at all times during the performance of this contract until the work is completed and accepted.

1.3.3 Non-Compliance Actions

The Project Superintendent is subject to removal by the Contracting Officer for non-compliance with requirements specified in the contract and for failure to manage the project to insure timely completion.

Furthermore, the Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. No part of the time lost due to such stop orders is acceptable as the subject of claim for extension of time for excess costs or damages by the Contractor.

1.4 PRECONSTRUCTION CONFERENCE

A kick-off meeting will be held not later than 15 days post award. It may be held either in person or virtually. After award of the contract but prior to commencement of any work at the site, meet with the Contracting Officer to discuss and develop a mutual understanding relative to the

SECTION 01 30 00 Page 1 administration of the value engineering and safety program, preparation of the schedule of prices or earned value report, shop drawings, and other submittals, scheduling programming, prosecution of the work. The provided design documents include technical requirements, conceptual floor plans, site layouts, and utility infrastructure pertaining to the facility that have been coordinated with the end user. Any and all deviations/changes should be made through the USACE Contracting Officer. Major subcontractors who will engage in the work must also attend.

1.5 PARTNERING

To most effectively accomplish this contract, the Government requires the formation of a cohesive partnership within the Project Team whose members are from the Government, the Contractor and their Subcontractors. Key personnel from the Supported Command, the End User (who will occupy the facility), the Government Design and Construction team and Subject Matter Experts, the Installation, the Contractor and Subcontractors, and the Designer of Record will be invited to participate in the Partnering process. The Partnership will draw on the strength of each organization in an effort to achieve a project that is without any safety mishaps, conforms to the Contract, and stays within budget and on schedule.

The Contracting Officer will provide Information on the Partnering Process and a list of key and optional personnel who should attend the Partnering meeting.

1.5.1 Informal Partnering

The Contracting Officer will organize the Partnering Sessions with key personnel of the project team, including Contractor personnel and Government personnel.

The Initial Partnering session should be a part of the Pre-Construction Meeting. Partnering sessions will be held at a location agreed to by the Contracting Officer and the Contractor (typically a conference room provided by the Resident Engineer office or the Contractor). The Initial Informal Partnering Session will be conducted and facilitated using electronic media (a video and accompanying forms) provided by the Contracting Officer. The Partners will determine the frequency of the follow-on sessions, at no more than 3 to six month intervals.

1.6 ELECTRONIC MAIL (E-MAIL) ADDRESS

Establish and maintain electronic mail (e-mail) capability along with the capability to open various electronic attachments as text files, pdf files, and other similar formats. Within 10 days after contract award, provide the Contracting Officer a single (only one) e-mail address for electronic communications from the Contracting Officer related to this contract including, but not limited to contract documents, invoice information, request for proposals, and other correspondence. The Contracting Officer may also use email to notify the Contractor of base access conditions when emergency conditions warrant, such as hurricanes or terrorist threats. Multiple email addresses are not allowed.

It is the Contractor's responsibility to make timely distribution of all Contracting Officer initiated e-mail with its own organization including field office(s). Promptly notify the Contracting Officer, in writing, of any changes to this email address.

SECTION 01 30 00 Page 2

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

-- End of Section --

SECTION 01 30 00 Page 3

THIS PAGE INTENTIONALLY LEFT BLANK

SECTION 01 30 00 Page 4

SECTION 01 32 17.12 10

COST-LOADED NETWORK ANALYSIS SCHEDULES (NAS)

PART 1 GENERAL

1.1 DESCRIPTION

The Contractor is responsible for scheduling procurement, Contractor quality control and construction, acceptance testing and training. Refer to Specification Section 01 33 00 SUBMITTAL PROCEDURES to determine if any items require Government approval prior to construction; if any are required, include that submittal review time in the schedule. The schedule is a tool to manage the project, both for Contractor and Government activities. It will also be used to report progress and evaluate time extensions. The Project NAS must be cost-loaded and will provide the basis for progress payments. Use the Critical Path Method (CPM) and the Precedence Diagram Method (PDM) to satisfy time and cost applications. For consistency, when scheduling software terminology is used in this specification, the terms in Primavera's scheduling programs are used.

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Qualifications; G M/R Baseline Network Analysis Schedule (NAS); G M/R

SD-07 Certificates

Monthly Network Analysis Schedule Update; G M

SD-11 Closeout Submittals

As-Built Schedule; G M/R

1.3 SCHEDULE ACCEPTANCE PRIOR TO START OF WORK

Contractor shall participate with the Contracting Officer in a preliminary meeting(s) to discuss the proposed schedule and requirements of this section prior to the Contractor preparing the Project Baseline Schedule.

Construction management scheduler must be present in preliminary meeting.

Government review comments on the Contractor's schedule(s) do not relieve the Contractor from compliance with requirements of the Contract Documents. Only bonds may be paid prior to acceptance of the Baseline Network Analysis Schedule (NAS). The Baseline NAS must be submitted within 30 days of NTP. The acceptance of a Baseline NAS is a condition precedent to:

a. The Contractor starting work on the demolition or construction

SE…