B08_Solit_Clauses_Construction_Final_3_21_23_doc.pdf

Solicitation 1/4/23

Document No.

140P2023R0070

Document Title MALU 318172 Stabilize and Rehabilitate the Birth Home

TABLE OF CONTENTS

PART I – THE SCHEDULE

SECTION A – SOLICITATION / CONTRACT FORM

SECTION B – BID SCHEDULE

SECTION C – SPECIFICATIONS / DRAWINGS

SECTION D – PACKING AND MARKING

SECTION E – INSPECTION AND ACCEPTANCE

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

SECTION F – DELIVERIES OR PERFORMANCE

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

52.211-12 LIQUIDATED DAMAGES—CONSTRUCTION (SEPT 2000)

52.211-13 TIME EXTENSIONS (SEPT 2000)

52.211-18 VARIATION IN ESTIMATED QUANTITY (APR 1984)

52.242-14 SUSPENSION OF WORK (APR 1984)

SECTION G – CONTRACT ADMINISTRATION DATA

36.211 DISTRUTION OF ADVANCE NOTICES AND SOLICITATIONS

1452.201-70 AUTHORITIES AND DELEGATIONS (SEPT 2011)

1452.204-70 RELEASE OF CLAIMS—DEPARTMENT OF THE INTERIOR (JUL 1996)

NOTICE TO CONTRACTORS - CONTRACTOR PERFORMANCE ASSESSMENT REPORTING SYSTEM (DEC

2015)

ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS – INTERNET PAYMENT PLATFORM (APR

2013)

SECTION H – SPECIAL CONTRACT REQUIREMENTS

SPECIAL REQUIREMENT 1: OPTION FOR ADDITIONAL SERVICES—SEPARATELY PRICED LINE ITEMS 15

SPECIAL REQUIREMENT 2: KEY PERSONNEL

SPECIAL REQUIREMENT 3: WORKING IN A FEDERAL BUILDING OR FEDERALLY CONTROLLED INDOOR

WORKSPACES

PART II – CONTRACT CLAUSES

SECTION I – CONTRACT CLAUSES

CLAUSES INCORPORATED BY REFERENCE

1452.203-70 RESTRICTIONS ON ENDORSEMENTS (JUL 1996)

52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS AND REQUIREMENT TO INFORM

EMPLOYEES OF WHISTLEBLOWER RIGHTS (JUN 2020)

52.204-23 PROHIBITION ON CONTRACTING FOR HARDWARE, SOFTWARE, AND SERVICES

DEVELOPED OR PROVIDED BY KASPERSKY LAB AND OTHER COVERED ENTITIES (NOV 2021)

52.204-25 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS AND VIDEO

SURVEILLANCE SERVICES AND EQUIPMENT (NOV 2021)

Document No.

140P2023R0070

Document Title MALU 318172 Stabilize and Rehabilitate the Birth Home

1452.215-70 EXAMINATION OF RECORDS BY THE DEPARTMENT OF THE INTERIOR (APR

52.219-14 LIMITATIONS ON SUBCONTRACTING (SEP 2021) (DEVIATION DEC 22)

52.225-9 BUY AMERICAN—CONSTRUCTION MATERIALS (OCT 2022)

1452.228-70 LIABILITY INSURANCE. (JUL 1996)

52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

52.236-2 DIFFERING SITE CONDITIONS (APR 1984)

52.236-3 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 1984)

52.236-5 MATERIAL AND WORKMANSHIP (APR 1984)

52.236-6 SUPERINTENDENCE BY THE CONTRACTOR (APR 1984)

52.236-7 PERMITS AND RESPONSIBILITIES (NOV 1991)

52.236-8 OTHER CONTRACTS (APR 1984)

52.236-9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS (APR 1984)

52.236-10 OPERATIONS AND STORAGE AREAS (APR 1984)

52.236-11 USE AND POSSESSION PRIOR TO COMPLETION (APR 1984)

52.236-12 CLEANING UP (APR 1984)

52.236-13 ACCIDENT PREVENTION (NOV 1991)

52.236-14 AVAILABILITY AND USE OF UTILITY SERVICES (APR 1984)

52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (APR 1984)

52.236-17 LAYOUT OF WORK. (APR 1984)

52.236-21 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (FEB 1997)

52.236-26 PRECONSTRUCTION CONFERENCE (FEB 1995)

1452.236-70 PROHIBITION AGAINST USE OF LEAD-BASED PAINT (JUL 1996)

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES. (NOV 2020)

PART IV – REPRESENTATIONS AND INSTRUCTIONS

SECTION K – REPRESENTATIONS, CERTIFICATIONS AND OTHER STATEMENTS OF OFFERORS

PROVISIONS INCORPORATED BY REFERENCE

52.229-11 TAX ON CERTAIN FOREIGN PROCUREMENTS – NOTICE AND REPRESENTATION (JUN 2020)

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (DEC 2022)

52.204-24 REPRESENTATIONS REGARDING CERTAIN TELECOMMUNICATIONS AND VIDEO

SURVEILLANCE SERVICES AND EQUIPMENT (NOV 2021)

52.204-26 COVERED TELECOMMUNICATIONS EQUIPMENT OR SERVICES-REPRESENTATION (OCT

2020)

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

52.209-13 VIOLATION OF ARMS CONTROL TREATIES OR AGREEMENTS-CERTIFICATION (NOV 2021) .. 38

SECTION L – INSTRUCTIONS, CONDITIONS AND NOTICES TO OFFERORS

Document No.

140P2023R0070

Document Title MALU 318172 Stabilize and Rehabilitate the Birth Home

PROVISIONS INCORPORATED BY REFERENCE

52.211-3 AVAILABILITY OF SPECIFICATIONS NOT LISTED IN THE GSA INDEX OF FEDERAL

SPECIFICATIONS, STANDARDS AND COMMERCIAL ITEM DESCRIPTIONS. (JUNE 1988)

1452.215-71 USE AND DISCLOSURE OF PROPOSAL INFORMATION—DEPARTMENT OF THE INTERIOR

(APR 1984)

52.216-1 TYPE OF CONTRACT (APR 1984)

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL EMPLOYMENT

OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT – CONSTRUCTION MATERIALS (MAY

52.228-1 BID GUARANTEE (SEP 1996)

52.233-2 SERVICE OF PROTEST DEPARTMENT OF THE INTERIOR (SEPT 2006) (DEVIATION) (JUL 1996)

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

52.236-27 SITE VISIT (CONSTRUCTION) – ALTERNATE I (FEB 1995)

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (NOV 2020)

INSTRUCTIONS FOR THE SUBMISSION OF OFFERS AND OTHER INFORMATION – COMPETITIVE

SOURCE SELECTION

SECTION M – EVALUATION FACTORS FOR AWARD

SPECIAL PROVISION 1: EVALUATION OF OPTIONS

Document No.

140P2023R0070

Document Title MALU 318172 Stabilize and Rehabilitate the Birth Home

PART I – THE SCHEDULE

SECTION A – SOLICITATION / CONTRACT FORM

Solicitation, Offer, and Award (SF-1442) - pages 1- 3 of this package

Document No.

140P2023R0070

Document Title MALU 318172 Stabilize and Rehabilitate the Birth Home

SECTION B – BID SCHEDULE

Contract Price Schedule Template National Park Service (NPS) - Denver Service Center (DSC) | 3-13-18

Solicitation Number:

PARK - PMIS: MALU 257817

(Project Management Information System)

Developed Area:

Project Title: Stabilize and Rehabilitate the Birth Home

Notice: Offerors are required to submit, a minimum, an offer that conforms to the solicitation documents with pricing for Base line items and all option line items. Failure to do so may render the proposal unacceptable. On lump-sum line items, provide the total price only. For all unit-priced line items, provide the unit price and the extended total price. If no specific line item exists for a portion of the work, include the costs in a related item. In case of error in calculation of extended prices, the unit price governs. In case of error in summation, the total of the corrected amounts govern. Round totals and extended prices to whole dollars.

Contract Line Item Number

(CLIN)

Contract Line Item (CLI) Title Quantity Unit of Measure Unit Price Total Price

1 Site Improvements 1 LS $0.00

2 Site Paving Improvements 1 LS $0.00

3 Site Drainage Improvements 1 LS $0.00

4 Selective Demolition 1 LS $0.00

5 Foundation and Structural Repairs 1 LS $0.00

6 Exterior Envelope Repairs 1 LS $0.00

7 Installation of Electrical System 1 LS $0.00

8 Installation of Mechanical System 1 LS $0.00

9 Installation of Fire Suppression System 1 LS $0.00

10 Installation of Fire Alarm System 1 LS $0.00

11 Interior Repairs/Wallpaper Replacement 1 LS $0.00

12 Commissioning 1 LS $0.00

TOTAL BASE PRICE (Contract Line Item Number 1 through 12 --------------------------------------------------------------------------------- $0.00

13 OPTION 1 Gift Shop Retiaing Wall Replacement 1 LS $0.00

14 OPTION2 Interior Painting 1 LS -

TOTAL PRICE FOR ALL OPTIONS (Contract Line Item Number 13 through 14) ---------------------------------------------------------- $0.00

TOTAL PROPOSED PRICE - BASE PLUS ALL OPTIONS (Contract Line Item Number 1 through 14) -------------------------- $0.00

All measurement and payment information is included in Division 01 Specifications Section 01 27 00 Definition of Contract Line Items.

Document No.

140P2023R0070

Document Title MALU 318172 Stabilize and Rehabilitate the Birth Home

SECTION C – SPECIFICATIONS / DRAWINGS

The project is located in the Martin Luther King, Jr. National Historical Park, Atlanta, Georgia and is listed on the National Register of Historic Places.

The Birth Home project will stabilize and rehabilitate the MLK Birth Home to protect and preserve to the period of significance the integrity of the building and artifacts which it contains. The work includes:

o Sitework to improve storm water management.

o Hazardous materials abatement.

o Exterior Improvements to the building envelope including exterior siding and trim repairs; window rehabilitation, miscellaneous exterior door repairs; brick masonry cleaning and repairs; porch floor, railing, and ceiling repairs; and exterior painting.

o Integration of new mechanical, electrical, and plumbing systems including a fire protection system and fire alarm system.

o Repointing of the brick masonry foundation walls, piers, and chimneys. Construction of new structural CMU piers with 4 x 4 posts. Additional new shear walls within the crawlspace.

o Strengthening of structural connections in the attic. Partial reframing of the roof structure.

o Interior work includes the repair to any plaster repairs at disturbed areas and the removal of existing wallpaper and replacement with new wallpaper with replicated patterns.

Specifications and drawings are attached and incorporated herein by reference. Refer to section J.

SECTION D – PACKING AND MARKING

No clauses included

SECTION E – INSPECTION AND ACCEPTANCE

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

(a) Definition. “Work” includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not—

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer’s written authorization.

Document No.

140P2023R0070

Document Title MALU 318172 Stabilize and Rehabilitate the Birth Home

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may—

(1) By contract or otherwise, replace or correct the work and charge the cost to the Contractor; or

(2) Terminate for default the Contractor’s right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government’s rights under any warranty or guarantee.

(End of clause)

SECTION F – DELIVERIES OR PERFORMANCE

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within ten (10) calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 260 days. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 LIQUIDATED DAMAGES—CONSTRUCTION (SEPT 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,482.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

1/4/23

Document No.

140P2023R0070

Document Title MALU 318172 Stabilize and Rehabilitate the Birth Home

52.211-13 TIME EXTENSIONS (SEPT 2000)

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

(End of clause)

52.211-18 VARIATION IN ESTIMATED QUANTITY (APR 1984)

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgement of the Contracting Officer, is justified.

(End of clause)

52.242-14 SUSPENSION OF WORK (APR 1984)

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting Officer’s failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed—

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

Document No.

140P2023R0070

Document Title MALU 318172 Stabilize and Rehabilitate the Birth Home

(End of clause)

SECTION G – CONTRACT ADMINISTRATION DATA

36.211 DISTRUTION OF ADVANCE NOTICES AND SOLICITATIONS

(a) Advance notices and solicitations should be distributed to reach as many prospective offerors as practicable. Contracting officers may send notices and solicitations to organizations that maintain, without charge to the public, display rooms for the benefit of prospective offerors, subcontractors, and material suppliers. If requested by such organizations, this may be done for all or a stated class of construction projects on an annual or semiannual basis. Contracting officers may determine the geographical extent of distribution of advance notices and solicitations on a case-by-case basis.

(b) As required by 15 U.S.C. 644(w), the contracting officer shall transmit to the Governmentwide point of entry (GPE) a notice (see 5.205(h), in solicitation notices posted at the GPE for construction contracts anticipated to be awarded to a small business pursuant to part 19. The notice shall include certain information regarding the agency's definitization of equitable adjustments for change orders under construction contracts. This information includes:

(1) A description of agency policies or procedures, in addition to that outlined in FAR 43.204, that apply to definitization of equitable adjustments for change orders under construction contracts. This description may be provided in a notice by including an address of an agency-specific, publicly accessible website containing this information. If no agency-specific additional policies and procedures exist, the notice shall include a statement to that effect.

(2) Data on the agency's past performance, for the prior 3 fiscal years, regarding the time required to definitize equitable adjustments for change orders under construction contracts (see 43.204). If fewer than 3 fiscal years of data are available, agencies shall provide data for the number of fiscal years that are available.

Data shall be provided in the solicitation notice as shown in the following table, or provide the address of an agency-specific, publicly accessible website containing this information. An adequate change order definitization proposal shall contain sufficient information to enable the contracting officer to conduct meaningful analyses and audits of the information contained in the proposal.

Table 1 to Paragraph (b)(2)

Time to definitize after receipt of an adequate change Number of change order proposals definitized order defeminization proposal under construction contracts construction contracts

30 days or less

31 to 60 days

61 to 90 days

91 to 180 days

181 to 365 days

366 or more days

After completion of contract performance via a contract modification addressing all undefinitized equitable adjustments received during contract performance

1452.201-70 AUTHORITIES AND DELEGATIONS (SEPT 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any https://www.govinfo.gov/link/uscode/15/644

Document No.

140P2023R0070

Document Title MALU 318172 Stabilize and Rehabilitate the Birth Home term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award. The COR will be responsible for technical monitoring of the contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor. Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum. The Contractor need not proceed with direction that it considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's appointment, within 3 days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30 days to any notice made under paragraph (d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor's risk.

(End of clause)

1452.204-70 RELEASE OF CLAIMS—DEPARTMENT OF THE INTERIOR (JUL 1996)

After completion of work and prior to final payment, the Contractor shall furnish the Contracting Officer with a release of claims against the United States relating to this contract. The Release of Claims form (DI–137) shall be used for this purpose. The form provides for exception of specified claims from operation of the release.

Document No.

140P2023R0070

Document Title MALU 318172 Stabilize and Rehabilitate the Birth Home

NOTICE TO CONTRACTORS - CONTRACTOR PERFORMANCE ASSESSMENT REPORTING

SYSTEM (DEC 2015)

1. FAR 42.1502 directs all Federal agencies to collect past performance information on contracts. The Department of the Interior (DOI) has implemented the Contractor Performance Assessment Reporting System (CPARS) to comply with this regulation. One or more past performance evaluations will be conducted in order to record your contract performance as required by FAR 42.15.

2. The past performance evaluation process is a totally paperless process using CPARS. CPARS is a web-based system that allows for electronic processing of the performance evaluation report. Once the report is processed, it is available in the Past Performance Information Retrieval System (PPIRS) for Government use in evaluating past performance as part of a source selection action.

3. We request that you furnish the Contracting Officer (CO) with the name, position title, phone number, and email address for each person designated to have access to your firm's past performance evaluation(s) for the contract no later than 30 days after award. Each person granted access will have the ability to provide comments in the Contractor portion of the report and state whether or not the Contractor agrees with the evaluation, before returning the report to the Assessing Official (AO). Information in the report must be protected as source selection sensitive information not releasable to the public.

4. When your Contractor Representative(s) are registered in CPARS, they will receive an automatically generated email with detailed login instructions. Further details, systems requirements, and training information for CPARS is available at https://www.cpars.gov/.

5. Within 60 days after the end of a performance period, the AO will complete an interim or final past performance evaluation, and the report will be accessible at https://www.cpars.gov/.

a. Contractor Representatives may then provide comments in response to the evaluation, or return the evaluation without comment.

b. Your comments should focus on objective facts in the AO's narrative and should provide your views on the causes and ramifications of the assessed performance.

c. All information provided should be reviewed for accuracy prior to submission.

d. If you elect not to provide comments, please acknowledge receipt of the evaluation by indicating "No comment" in the space provided, and then selecting “Accept the Ratings and Close the Evaluation”.

e. Your response is due within 60 calendar days after receipt of the CPAR. On day 15, the evaluation will become available in PPIRS-RC marked as “Pending” with or without comments and whether or not it has been closed.

f. If you do not sign and submit the CPAR within 60 days, it will automatically be returned to the Government and will be annotated: "The report was delivered/received by the contractor on (date). The contractor neither signed nor offered comment in response to this assessment."

6. The following guidelines apply concerning your use of the past performance evaluation:

a. Protect the evaluation as source selection information. After review, transmit the evaluation by completing and submitting the form through CPARS. If for some reason you are unable to view and/or submit the form through CPARS, contact the CO for instructions.

b. Strictly control access to the evaluation within your organization. Ensure the evaluation is never released to persons or entities outside of your control.

c. Prohibit the use of or reference to evaluation data for advertising, promotional material, pre-award surveys, responsibility determinations, production readiness reviews, or other similar purposes.

https://www.acquisition.gov/sites/default/files/current/far/html/Subpart%2042_15.html https://www.acquisition.gov/sites/default/files/current/far/html/Subpart%2042_15.html https://www.cpars.gov/ https://www.cpars.gov/

Document No.

140P2023R0070

Document Title MALU 318172 Stabilize and Rehabilitate the Birth Home

7. If you wish to discuss a past performance evaluation, you should request a meeting in writing to the CO no later than seven days following your receipt of the evaluation. The meeting will be held in person or via telephone or other means during your 60-day review period.

8. A copy of the completed past performance evaluation will be available in CPARS for your viewing and for Government use supporting source selection actions after it has been finalized.

(End of Notice)

ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS – INTERNET PAYMENT PLATFORM

(APR 2013)

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract. The IPP website address is: https://www.ipp.gov.

The contractor shall submit a draft Invoice Package, including copies of the following documents, to the National Park Service’s (NPS) Construction Management Representative (CMR) a minimum of 5 working days prior to submittal of the formal Invoice through IPP. Within 5 working days of receipt, the CMR shall provide an acceptability recommendation to both the NPS Contracting Officer’s Representative (COR) and the contractor. If the CMR recommends acceptance, the contractor shall submit a copy of the final version of the CMR’s checklist and the Invoice Package to the NPS through IPP.

1. Completed copy of the CMR’s final Construction Payment Request Checklist (Submit only with the formal submittal to IPP)

2. Completed copy of the Pay Estimate Form (including signed certification of subcontractor payments)

3. Completed copy of the Limitations on Subcontracting Report (Include if acquisition is being set-aside and clause

52.219-14 is included)

4. Information required by contract clause 52.232-27, Prompt Payment for Construction Contracts

5. A copy of the current construction schedule (refer to project specification section 013216)

6. A copy of the current Schedule of Values. (refer to project specification section 013216)

The Contractor must use the IPP website to register access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM) will receive enrollment instructions via email from the Federal Reserve Bank of Boston (FRBB) within 3 - 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

(End of Clause) https://www.ipp.gov/ mailto:ippgroup@bos.frb.org

Document No.

140P2023R0070

Document Title MALU 318172 Stabilize and Rehabilitate the Birth Home

SECTION H – SPECIAL CONTRACT REQUIREMENTS

SPECIAL REQUIREMENT 1: OPTION FOR ADDITIONAL SERVICES—SEPARATELY PRICED

LINE ITEMS

The Government may require the delivery of the numbered line items identified in the Schedule as option items at the price stated in the Schedule. The Contracting Officer may unilaterally exercise the option by written notice to the Contractor within 90 days after contract award. Performance of added line item tasks shall be at the price negotiated in the contract Schedule.

(End of clause)

SPECIAL REQUIREMENT 2: KEY PERSONNEL

(a) The Contractor shall assign to this contract the following key personnel:

Project Manager:

Job-site Superintendent:

Quality Control Manager:

Safety Manager:

(b) During the first 90 days of performance, the Contractor shall make no substitutions of key personnel unless the substitution is necessitated by illness, death, or termination of employment. The Contractor shall notify the Contracting Officer within 15 calendar days after the occurrence of any of these events and provide the information required by paragraph (c) below. After the initial 90-day period, the Contractor shall submit the information required by paragraph (c) to the Contracting Officer at least 15 days prior to making any permanent substitutions.

(c) The Contractor shall provide a detailed explanation of the circumstances necessitating the proposed substitutions, complete resumes for the proposed substitutes, and any additional information requested by the Contracting Officer.

Proposed substitutes should have comparable qualifications to those of the persons being replaced. The Contracting Officer will notify the Contractor within 15 calendar days after receipt of all required information of the decision on substitutions. This clause will be modified to reflect any approved changes of key personnel.

(End of clause)

SPECIAL REQUIREMENT 3: WORKING IN A FEDERAL BUILDING OR FEDERALLY

CONTROLLED INDOOR WORKSPACES

In order to take steps to prevent the spread of COVID-19 and to protect the health and safety of all Federal employees, onsite contractors, visitors to Federal buildings or Federally controlled indoor workspaces, and other individuals interacting with the Federal workforce, employees under the subject contract who are required to work on site in Federal buildings or Federally controlled indoor worksites must comply with requirements located at https://www.saferfederalworkforce.gov/overview/.

(End of Local Clause) https://gcc02.safelinks.protection.outlook.com/?url=https%3A%2F%2Fwww.saferfederalworkforce.gov%2Foverview%2F&data=04%7C01%7CJohn_Chaney%40nps.gov%7C49fb4f738b5e4e0df1ee08d9c18e4e52%7C0693b5ba4b184d7b9341f32f400a5494%7C0%7C0%7C637753639221692348%7CUnknown%7CTWFpbGZsb3d8eyJWIjoiMC4wLjAwMDAiLCJQIjoiV2luMzIiLCJBTiI6Ik1haWwiLCJXVCI6Mn0%3D%7C3000&sdata=9a0TxfGouMVk0mX%2FbzGgxHO%2BqKZDdzjXsnXFWaK%2FRK0%3D&reserved=0

Document No.

140P2023R0070

Document Title MALU 318172 Stabilize and Rehabilitate the Birth Home

PART II – CONTRACT CLAUSES

SECTION I – CONTRACT CLAUSES

CLAUSES INCORPORATED BY REFERENCE

The following contract clauses pertinent to this section are incorporated by reference (by Citation Number, Title, and Date) per the clause at FAR “52.252-2 CLAUSES INCORPORATED BY REFERENCE” in Section I of this contract. See FAR 52.252-2 for an internet address (if specified) for electronic access to a clause’s full text.

52.202-1 DEFINITIONS (JUN 2020)

52.203-3 GRATUITIES (APR 1984)

52.203-5 COVENANT AGAINST CONTINGENT FEES (MAY 2014)

52.203-6 RESTRICTIONS ON SUBCONTRACTOR SALES TO THE GOVERNMENT (JUN 2020)

52.203-7 ANTI-KICKBACK PROCEDURES (JUN 2020)

52.203-8 CANCELLATION, RECESSION, AND RECOVERY OF FUNDS FOR ILLEGAL OR IMPROPER ACTIVITY

(MAY 2014)

52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (MAY 2014)

52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE CERTAIN FEDERAL TRANSACTIONS (JUN 2020)

52.203-14 DISPLAY OF HOTLINE POSTER(S) (NOV 2021)

52.203-19 PROHIBITION ON REQUIRING CERTAIN INTERNAL CONFIDENTIALITY AGREEMENTS OR

STATEMENTS (JAN 2017)

52.204-4 PRINTED OR COPIED DOUBLE SIDED ON POSTCONSUMER FIBER CONTENT PAPER (MAY 2011)

52.204-9 PERSONAL IDENTITY VERIFICATION OF CONTRACTOR PERSONNEL (JAN 2011)

52.204-10 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT AWARDS (JUN 2020)

52.204-13 SYSTEM FOR AWARD MANAGEMENT MAINTENANCE (OCT 2018)

52.204-14 SERVICE CONTRACT REPORTING REQUIREMENTS (OCT 2016

52.204-18 COMMERCIAL AND GOVERNMENT ENTITY CODE MAINTENANCE (AUG 2020)

52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND CERTIFICATIONS (DEC 2014) 52.204-21 BASIC SAFEGUARDING OF COVERED CONTRACTOR INFORMATION SYSTEMS (NOV 2021) 52.209-6 PROTECTING THE GOVERNMENT’S INTEREST WHEN SUB-CONTRACTING WITH CONTRACTOR’S

DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (NOV 2021)

52.209-10 PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS (NOV 2015)

52.215-2 AUDIT AND RECORDS-NEGOTIATIONS (JUN 2020)

52.215-8 ORDER OF PRECEDENCE - UNIFORM CONTRACT FORMAT (OCT 1997)

52.219-6 NOTICE OF TOTAL SMALL BUSINESS SET-ASIDE (MAR 2020)

52.219-8 UTILIZATION OF SMALL BUSINESS CONCERNS (OCT 2022)

52.219-28 POST AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (OCT 2022)

52.222-3 CONVICT LABOR (JUN 2003)

52.222-4 CONTRACT WORK HOURS AND SAFETY STANDARDS-OVERTIME COMPENSATION (MAR 2018)

52.222-6 CONSTRUCTION WAGE RATE REQUIREMENTS (AUG 2018)

52.222-7 WITHHOLDING OF FUNDS (MAY 2014)

52.222-8 PAYROLLS AND BASIC RECORDS (JUL 2021)

52.222-9 APPRENTICES AND TRAINEES (JUL 2005)

52.222-10 COMPLIANCE WITH COPELAND ACT REQUIREMENTS (FEB 1988)

Document No.

140P2023R0070

Document Title MALU 318172 Stabilize and Rehabilitate the Birth Home

52.222-11 SUBCONTRACTS (LABOR STANDARDS) (MAY 2014)

52.222-12 CONTRACT TERMINATION - DEBARMENT (MAY 2014)

52.222-13 COMPLIANCE WITH CONSTRUCTION WAGE RATE REQUIRMENTS AND RELATED REGULATIONS

(MAY 2014)

52.222-14 DISPUTES CONCERNING LABOR STANDARDS (FEB 1988)

52.222-15 CERTIFICATION OF ELIGIBILITY (MAY 2014)

52.222-21 PROHIBITION OF SEGREGATED FACILITIES (APR 2015)

52.222-26 EQUAL OPPORTUNITY (SEP 2016)

52.222-27 AFFIRMATIVE ACTION COMPLIANCE REQUIREMENTS FOR CONSTRUCTION (APRIL 2015)

52.222-35 EQUAL OPPORTUNITY FOR VETERANS (JUN 2020)

52.222-36 EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES (JUN 2020)

52.222-37 EMPLOYMENT REPORTS ON VETERANS (JUN 2020)

52.222-40 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE NATIONAL LABOR RELATIONS ACT (DEC 2010)

52.222-50 COMBATING TRAFFICKING IN PERSONS (NOV 2021)

52.222-54 EMPLOYMENT ELIGIBILITY VERIFICATION (MAY 2022)

52.222-55 MINIMUM WAGES UNDER EXECUTIVE ORDER 14026 (JAN 2022)

52.222-62 PAID SICK LEAVE UNDER EXECUTIVE ORDER 13706 (JAN 2022)

52.223-2 AFFIRMATIVE PROCUREMENT OF BIOBASED PRODUCTS UNDER SERVICE AND CONSTRUCTION

(SEP 2013)

52.223-5 POLLUTION PREVENTION AND RIGHT-TO-KNOW INFORMATION (MAY 2011)

52.223-6 DRUG-FREE WORKPLACE (MAY 2001)

52.223-15 ENERGY EFFICIENCY IN ENERGY-CONSUMING PRODUCTS (MAY 2020)

52.223-17 AFFIRMATIVE PROCUREMENT OF EPA-DESIGNATED ITEMS IN SERVICE AND CONSTRUCTION

CONTRACTS (AUG 2018)

52.223-18 ENCOURAGING CONTRACTOR POLICIES TO BAN TEXT MESSAGING WHILE DRIVING (JUN 2020)

52.223-21 FOAMS (JUN 2016)

52.224-1 PRIVACY ACT NOTIFICATION (APR 1984)

52.224-2 PRIVACY ACT (APR 1984)

52.224-3 PRIVACY TRAINING (JAN 2017)

52.225-13 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (FEB 2021)

52.227-1 AUTHORIZATION AND CONSENT (JUN 2020)

52.227-2 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT INFRINGEMENT (JUN 2020)

52.227-4 PATENT INDEMNITY—CONSTRUCTION CONTRACTS (DEC 2007)

52.227-17 RIGHTS IN DATA – SPECIAL WORKS (DEC 2007)

52.228-2 ADDITIONAL BOND SECURITY (OCT 1997)

52.228-5 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (JAN 1997)

52.228-11 PLEDGES OF ASSETS (FEB 2021)

52.228-12 PROSPECTIVE SUBCONTRACTOR REQUESTS FOR BONDS (DEC 2022)

52.228-14 IRREVOCABLE LETTER OF CREDIT (NOV 2014)

52.228-15 PERFORMANCE AND PAYMENT BONDS-CONSTRUCTION (JUN 2020)

52.229-3 FEDERAL, STATE, AND LOCAL TAXES (FEB 2013)

52.229-12 TAX ON CERTAIN FOREIGN PROCUREMENTS (FEB 2021)

52.232-5 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (MAY 2014)

52.232-17 INTEREST (MAY 2014)

52.232-23 ASSIGNMENT OF CLAIMS (MAY 2014)

52.232-27 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (JAN 2017)

Document No.

140P2023R0070

Document Title MALU 318172 Stabilize and Rehabilitate the Birth Home

52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER – SYSTEM FOR AWARD MANAGEMENT (OCT 2018)

52.232-39 UNENFORCEABILITY OF UNAUTHORIZED OBLIGATIONS (JUN 2013)

52.232-40 PROVIDING ACCELERATED PAYMENTS TO SMALL BUSINESS CONTRACTORS (NOV 2021)

52.233-1 DISPUTES (MAY 2014) – ALTERNATE 1 (DEC 1991)

52.233-3 PROTEST AFTER AWARD (AUG 1996)

52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (DEC 2004)

52.242-13 BANKRUPTCY (JUL 1995)

52.243-4 CHANGES (JUN 2007)

52.244-6 SUBCONTRACTS FOR COMMERCIAL ITEMS (MAR 2023)

52.248-3 VALUE ENGINEERING – CONSTRUCTION (OCT 2020)

52.249-2 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED-PRICE) (APR 2012), ALT 1 (SEP

1996)

52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION) (APR 1984)

52.253-1 COMPUTER GENERATED FORMS (JAN 1991)

1452.203-70 RESTRICTIONS ON ENDORSEMENTS (JUL 1996)

The Contractor shall not refer to contracts awarded by the Department of the Interior in commercial advertising, as defined in FAR 31.205–1, in a manner which states or implies that the product or service provided is approved or endorsed by the Government or is considered by the Government to be superior to other products or services. This restriction is intended to avoid the appearance of preference by the Government toward any product or service. The Contractor may request the Contracting Officer to make a determination as to the propriety of promotional material.

(End of clause)

52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS AND REQUIREMENT TO

INFORM EMPLOYEES OF WHISTLEBLOWER RIGHTS (JUN 2020)

(a) This contract and employees working on this contract will be subject to the whistleblower rights and remedies in the pilot program on Contractor employee whistleblower protections established at 41 U.S.C. 4712 by section 828 of the National Defense Authorization Act for Fiscal Year 2013 (Pub. L. 112-239) and Federal Acquisition Regulation

(FAR) 3.908.

(b) The Contractor shall inform its employees in writing, in the predominant language of the workforce, of employee whistleblower rights and protections under 41 U.S.C. 4712, as described in section FAR 3.908.

(c) The Contractor shall insert the substance of this clause, including this paragraph (c), in all subcontracts over the simplified acquisition threshold, as defined in FAR 2.101 on the date of subcontract award.

(End of clause)

52.204-23 PROHIBITION ON CONTRACTING FOR HARDWARE, SOFTWARE, AND SERVICES

DEVELOPED OR PROVIDED BY KASPERSKY LAB AND OTHER COVERED ENTITIES (NOV

2021)

(a) Definitions. As used in this clause— Covered article means any hardware, software, or service that–

(1) Is developed or provided by a covered entity;

(2) Includes any hardware, software, or service developed or provided in whole or in part by a covered entity; or https://gcc02.safelinks.protection.outlook.com/?url=http%3A%2F%2Fuscode.house.gov%2Fbrowse.xhtml%3Bjsessionid%3D114A3287C7B3359E597506A31FC855B3&data=05%7C01%7CDane_Johnson%40nps.gov%7Ca990f0ff24554331c19208da2f998723%7C0693b5ba4b184d7b9341f32f400a5494%7C0%7C0%7C637874633686003181%7CUnknown%7CTWFpbGZsb3d8eyJWIjoiMC4wLjAwMDAiLCJQIjoiV2luMzIiLCJBTiI6Ik1haWwiLCJXVCI6Mn0%3D%7C3000%7C%7C%7C&sdata=gMYr0FU0HiQmDQpByxu8YAACMVrIP0kHjKC3zeDQwKc%3D&reserved=0 https://gcc02.safelinks.protection.outlook.com/?url=https%3A%2F%2Fwww.acquisition.gov%2Ffar%2Fpart-3%23FAR_3_908&data=05%7C01%7CDane_Johnson%40nps.gov%7Ca990f0ff24554331c19208da2f998723%7C0693b5ba4b184d7b9341f32f400a5494%7C0%7C0%7C637874633686003181%7CUnknown%7CTWFpbGZsb3d8eyJWIjoiMC4wLjAwMDAiLCJQIjoiV2luMzIiLCJBTiI6Ik1haWwiLCJXVCI6Mn0%3D%7C3000%7C%7C%7C&sdata=rbkF8f6l9acAdQqI%2FAXkLJ4JOeCzR%2BhlpBIL7eNYq2Q%3D&reserved=0 https://gcc02.safelinks.protection.outlook.com/?url=http%3A%2F%2Fuscode.house.gov%2Fbrowse.xhtml%3Bjsessionid%3D114A3287C7B3359E597506A31FC855B3&data=05%7C01%7CDane_Johnson%40nps.gov%7Ca990f0ff24554331c19208da2f998723%7C0693b5ba4b184d7b9341f32f400a5494%7C0%7C0%7C637874633686003181%7CUnknown%7CTWFpbGZsb3d8eyJWIjoiMC4wLjAwMDAiLCJQIjoiV2luMzIiLCJBTiI6Ik1haWwiLCJXVCI6Mn0%3D%7C3000%7C%7C%7C&sdata=gMYr0FU0HiQmDQpByxu8YAACMVrIP0kHjKC3zeDQwKc%3D&reserved=0 https://gcc02.safelinks.protection.outlook.com/?url=https%3A%2F%2Fwww.acquisition.gov%2Ffar%2Fpart-3%23FAR_3_908&data=05%7C01%7CDane_Johnson%40nps.gov%7Ca990f0ff24554331c19208da2f998723%7C0693b5ba4b184d7b9341f32f400a5494%7C0%7C0%7C637874633686003181%7CUnknown%7CTWFpbGZsb3d8eyJWIjoiMC4wLjAwMDAiLCJQIjoiV2luMzIiLCJBTiI6Ik1haWwiLCJXVCI6Mn0%3D%7C3000%7C%7C%7C&sdata=rbkF8f6l9acAdQqI%2FAXkLJ4JOeCzR%2BhlpBIL7eNYq2Q%3D&reserved=0 https://gcc02.safelinks.protection.outlook.com/?url=https%3A%2F%2Fwww.acquisition.gov%2Ffar%2Fpart-2%23FAR_2_101&data=05%7C01%7CDane_Johnson%40nps.gov%7Ca990f0ff24554331c19208da2f998723%7C0693b5ba4b184d7b9341f32f400a5494%7C0%7C0%7C637874633686003181%7CUnknown%7CTWFpbGZsb3d8eyJWIjoiMC4wLjAwMDAiLCJQIjoiV2luMzIiLCJBTiI6Ik1haWwiLCJXVCI6Mn0%3D%7C3000%7C%7C%7C&sdata=5gcnSAxux%2Bs3uQBgBZj0%2BjRmjdnTK2xSwtuurkNUgH8%3D&reserved=0

Document No.

140P2023R0070

Document Title MALU 318172 Stabilize and Rehabilitate the Birth Home

(3) Contains components using any hardware or software developed in whole or in part by a covered entity.

Covered entity means–

(1) Kaspersky Lab;

(2) Any successor entity to Kaspersky Lab;

(3) Any entity that controls, is controlled by, or is under common control with Kaspersky Lab; or

(4) Any entity of which Kaspersky Lab has a majority ownership.

(b) Prohibition. Section 1634 of Division A of the National Defense Authorization Act for Fiscal Year 2018 (Pub. L. 115-

91) prohibits Government use of any covered article. The Contractor is prohibited from—

(1) Providing any covered article that the Government will use on or after October 1, 2018; and

(2) Using any covered article on or after October 1, 2018, in the development of data or deliverables first produced in the performance of the contract.

(c) Reporting requirement.

(1) In the event the Contractor identifies a covered article provided to the Government during contract performance, or the Contractor is notified of such by a subcontractor at any tier or any other source, the Contractor shall report, in writing, to the Contracting Officer or, in the case of the Department of Defense, to the website at https://dibnet.dod.mil. For indefinite delivery contracts, the Contractor shall report to the Contracting Officer for the indefinite delivery contract and the Contracting Officer(s) for any affected order or, in the case of the Department of Defense, identify both the indefinite delivery contract and any affected orders in the report provided at https://dibnet.dod.mil.

(2) The Contractor shall report the following information pursuant to paragraph (c)(1) of this clause:

(i) Within 1 business day from the date of such identification or notification: the contract number; the order number(s), if applicable; supplier name; brand; model number (Original Equipment Manufacturer (OEM) number, manufacturer part number, or wholesaler number); item description; and any readily available information about mitigation actions undertaken or recommended.

(ii) Within 10 business days of submitting the report pursuant to paragraph (c)(1) of this clause: any further available information about mitigation actions undertaken or recommended. In addition, the Contractor shall describe the efforts it undertook to prevent use or submission of a covered article, any reasons that led to the use or submission of the covered article, and any additional efforts that will be incorporated to prevent future use or submission of covered articles.

(d) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (d), in all subcontracts including subcontracts for the acquisition of commercial products or commercial services.

(End of clause)

52.204-25 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS AND

VIDEO SURVEILLANCE SERVICES AND EQUIPMENT (NOV 2021)

The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the Offeror has represented that it "does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract , subcontract , or other contractual instrument" in paragraph (c)(1) in the provision at 52.204-26, Covered Telecommunications Equipment or Services —Representation, or in paragraph (v)(2)(i) of the provision at 52.212-3, Offeror Representations and Certifications-Commercial Products or Commercial Services.

The Offeror shall not complete the representation in paragraph (d)(2) of this provision if the Offeror has represented that it "does not use covered telecommunications equipment or services , or any equipment , system, or service that uses covered telecommunications equipment or services " in paragraph (c)(2) of the provision at 52.204-26, or in paragraph (v)(2)(ii) of the provision at 52.212-3.

(a) Definitions . As used in this provision—

Backhaul , covered telecommunications equipment or services , critical technology , interconnection arrangements , reasonable inquiry , roaming , and substantial or essential component have the meanings provided in the https://dibnet.dod.mil/ https://dibnet.dod.mil/ https://www.acquisition.gov/far/part-52#FAR_52_204_26 https://www.acquisition.gov/far/part-52#FAR_52_212_3 https://www.acquisition.gov/far/part-52#FAR_52_204_26 https://www.acquisition.gov/far/part-52#FAR_52_212_3

Document No.

140P2023R0070

Document Title MALU 318172 Stabilize and Rehabilitate the Birth Home clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment .

(b) Prohibition.

(1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment , system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Nothing in the prohibition shall be construed to—

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul , roaming , or interconnection arrangements ; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the…