Attachment 8 Change Request Proposal Form.xlsx
XLSX spreadsheet 44 KB Posted
- Solicitation number
- 70Z08526QLREP0020
About this file
This is a Change Request Proposal Form (Form 002, Rev 12/00) used by the U.S. Coast Guard Naval Engineering Department for requesting and estimating the cost of additional work on existing contracts. The form is specifically formatted for the USCGC WAESCHE vessel and serves as a template for vendors to submit detailed price proposals for change orders or supplemental work.
The form requires contractors to provide comprehensive labor cost estimates broken down by trade classification, including welder, ship fitter, sheet metal worker, sandblaster, rigger, pipefitter, painter, lagger, layout technician, machinist, shipwright, equipment operator, electrician, steel work specialist, NDT technician, competent person, quality assurance personnel, and firewatch. Contractors must also submit estimates for subcontractor costs, material costs with quantities and unit pricing, and any markup or loading rates applied. The proposal must include identification of any schedule extension required beyond the current delivery date, with documented notification from the Operational Commander acknowledging potential schedule impacts. Proposals are requested within three calendar days from the Contracting Officer's issuance date, and no government obligation exists until price and performance period are mutually agreed upon and a bilateral contract modification is executed. All work must fall within the scope of the existing subject contract, with all original contract terms and conditions remaining applicable to the change request.
View the file
Other files
| File | Type | Posted |
|---|---|---|
| Amendment 001 - CGC WAESCHE DS FY27.doc | DOC document | |
| Attachment 2-WAESCHE DS FQ2 FY27 Specification REV-0.docx | DOCX document | |
| Attachment 3 Consolidated List of References.docx | DOCX document | |
| Attachment 5 Questions.docx | DOCX document | |
| Attachment 1-Pricing Scheduel DS FQ2 FY27.xls | XLS spreadsheet | |
| Attachment 4 Past Performance Questionnaire.docx | DOCX document | |
| Attachment 7 Department of Homeland Security Non-Disclosure Agreement (NDA).pdf | ||
| Attachment 6 - Government Property Report.pdf | ||
| Solicitation-WAESCHE-Q2-FY27 Rev 4.docx | DOCX document |
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Vendor Estimate
| Department of Transportation // U.S. Coast Guard // Naval Engineering // Form 002 (Rev 12/00) | |||||||
| Independent Contractor Estimate | Page | ||||||
| Contract Availability | CR | 1 | of | 1 | |||
| Auto fill | USCGC WAESCHE | Item: | Estimate Prepared By: | Date Prepared | |||
| Auto fill | TBD | AFC: | |||||
| CFR Nr. |
| Welder | Labor Scale | Ship Fitter | Sheet Metal | Sandblaster | Rigger | Pipefitter | Painter | Lagger | Layout | Machinist | Shipwright | Equip Oper | Electrician | Steel Work | NDT | Competent | |||
| Person | Quality Assurance | Firewatch |
| Totals From Page 2: | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 |
| Trade Totals(inlcudes page 2): | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 |
| SUMMARY OF LABOR | ||||
| Total Regular Labor Hours Cost | $ - 0 | |||
| Total Overtime Labor Hours Cost | $ - 0 | |||
| Total Cost of Labor | $ - 0 | |||
| SUMMARY OF SUB-CONTRACTOR | ||||
| Sub-Contractor | Cost | |||
| $ - 0 | ||||
| $ - 0 | ||||
| $ - 0 | ||||
| Totals From Page 2: | ||||
| Total: | $ - 0 | |||
| SUMMARY OF MATERIALS | ||||
| Item | U/I | QTY | Cost | Total Cost |
| $ - 0 | ||||
| $ - 0 | ||||
| $ - 0 |
| Totals From Page 2: | |||||
| Total: | 0 | $ -0 | $ - 0 | ||
| SUMMARY OF ESTIMATE | The above work will require an extension of | days beyond the current delivery | |||
| Labor | $ - 0 | date of | |||
| Material | $ - 0 | ||||
| Sub Contractor | $ - 0 | ||||
| mark-up/loading rate for materials and subcontractors | $ - 0 | ||||
| Total Estimate | $ - 0 |
MLCPAC(vr) Approval: Spec Review Required?
| Department of Transportation // U.S. Coast Guard // Naval Engineering // Form 002 (Rev 12/00) | ||||||||
| Independent Government Estimate (Cont.) | Page | |||||||
| Contract Availability | Work Request Nr: | 2 | of | 2 | ||||
| USCGC WAESCHE | Item: | Estimate Prepared By | Estimate Prepared By: | Date Prepared | Date Prepared | |||
| TBD | CFR Nr: |
0 Welder Labor Scale Ship Fitter Sheet Metal Sandblaster Rigger Pipefitter Painter Lagger Layout Machinist Shipwright Equip Oper Electrician Steel Work NDT Competent Person
| Trade Totals: | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | 0 | |
| SUMMARY OF LABOR | ||||||||||||||||||||
| Total Regular Labor Hours | 0 | |||||||||||||||||||
| Total Overtime Labor Hours | ||||||||||||||||||||
| Total of All Labor Hours | 0 | |||||||||||||||||||
| Total Cost of Labor | $ - 0 | |||||||||||||||||||
| SUMMARY OF SUB-CONTRACTOR | ||||||||||||||||||||
| Sub-Contractor | Cost |
| Total | $ - 0 | |||
| SUMMARY OF MATERIALS | ||||
| Item | U/I | QTY | Cost | Total Cost |
| Total | $ - 0 | |
| SUMMARY OF ESTIMATE | ||
| Labor | $ - 0 | |
| Material | $ - 0 | |
| Sub Contractor | $ - 0 | |
| Profit | $ - 0 | |
| Total Estimate | $ - 0 |
Part I. This is a request for proposal only. You are requested to provide a detailed price proposal within 3 calendar days from the date of issuance by the Contracting Officer or earlier. No obligation is created for the United States Government to award any work until an agreement on price and performance period is reached and a bilateral contract modification is executed between the Government and the Contractor.
The work described below is withing the scope fo the subject contract. All terms and conditions of the subject contract are applicable to this work request.
Provide all labor and materials to accomplish the following additional work. This work request is in response to the Contractor's CFR listed above:
The above work will require an extension of ______ days beyond the current delivery date of __________.
FOR COAST GUARD USE ONLY
Operational Commander (___________________) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.
Ref: Phoncon between _____________________ and _________________________ Of _________________________________________________________________ Remarks:
The above work will require an extension of days beyond the current delivery date of ____.
FOR COAST GUARD USE ONLY
Operational Commander ( ___ ) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.
Ref: Phonecon between and of
The above work will require an extension of ______ days beyond the current delivery date of __________.
FOR COAST GUARD USE ONLY
Operational Commander (___________________) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.
Ref: Phoncon between _____________________ and _________________________ Of _________________________________________________________________ Remarks:
The above work will require an extension of days beyond the current delivery date of ____.
FOR COAST GUARD USE ONLY
Operational Commander ( ___ ) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.
The above work will require an extension of ______ days beyond the current delivery date of __________.
Operational Commander (___________________) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.
Ref: Phoncon between _____________________ and _________________________ Of _________________________________________________________________ Remarks:
See page 1 for info on need for contract extension.
Part I. This is a request for proposal only. You are requested to provide a detailed price proposal within 3 calendar days from the date of issuance by the Contracting Officer or earlier. No obligation is created for the United States Government to award any work until an agreement on price and performance period is reached and a bilateral contract modification is executed between the Government and the Contractor.
The work described below is withing the scope fo the subject contract. All terms and conditions of the subject contract are applicable to this work request.
Provide all labor and materials to accomplish the following additional work. This work request is in response to the Contractor's CFR listed above:
The above work will require an extension of ______ days beyond the current delivery date of __________.
FOR COAST GUARD USE ONLY
Operational Commander (___________________) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.
Ref: Phoncon between _____________________ and _________________________ Of _________________________________________________________________ Remarks:
The above work will require an extension of days beyond the current delivery date of ____.
FOR COAST GUARD USE ONLY
Operational Commander ( ___ ) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.
The above work will require an extension of ______ days beyond the current delivery date of __________.
Operational Commander (___________________) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.
Ref: Phoncon between _____________________ and _________________________ Of _________________________________________________________________ Remarks:
The above work will require an extension of days beyond the current delivery date of ____.
FOR COAST GUARD USE ONLY
Operational Commander ( ___ ) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.
The above work will require an extension of ______ days beyond the current delivery date of __________.
Operational Commander (___________________) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.
Ref: Phoncon between _____________________ and _________________________ Of _________________________________________________________________ Remarks:
The above work will require an extension of days beyond the current delivery date of ____.
FOR COAST GUARD USE ONLY
Operational Commander ( ___ ) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.
Part I. This is a request for proposal only. You are requested to provide a detailed price proposal within 3 calendar days from the date of issuance by the Contracting Officer or earlier. No obligation is created for the United States Government to award any work until an agreement on price and performance period is reached and a bilateral contract modification is executed between the Government and the Contractor.
The work described below is withing the scope fo the subject contract. All terms and conditions of the subject contract are applicable to this work request.
Provide all labor and materials to accomplish the following additional work. This work request is in response to the Contractor's CFR listed above:
The above work will require an extension of ______ days beyond the current delivery date of __________.
FOR COAST GUARD USE ONLY
Operational Commander (___________________) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.
Ref: Phoncon between _____________________ and _________________________ Of _________________________________________________________________ Remarks:
The above work will require an extension of days beyond the current delivery date of ____.
FOR COAST GUARD USE ONLY
Operational Commander ( ___ ) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.
The above work will require an extension of ______ days beyond the current delivery date of __________.
Operational Commander (___________________) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.
Ref: Phoncon between _____________________ and _________________________ Of _________________________________________________________________ Remarks:
The above work will require an extension of days beyond the current delivery date of ____.
FOR COAST GUARD USE ONLY
Operational Commander ( ___ ) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.
The above work will require an extension of ______ days beyond the current delivery date of __________.
Operational Commander (___________________) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.
Ref: Phoncon between _____________________ and _________________________ Of _________________________________________________________________ Remarks:
The above work will require an extension of days beyond the current delivery date of ____.
FOR COAST GUARD USE ONLY
Operational Commander ( ___ ) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.
Part I. This is a request for proposal only. You are requested to provide a detailed price proposal within 3 calendar days from the date of issuance by the Contracting Officer or earlier. No obligation is created for the United States Government to award any work until an agreement on price and performance period is reached and a bilateral contract modification is executed between the Government and the Contractor.
The work described below is withing the scope fo the subject contract. All terms and conditions of the subject contract are applicable to this work request.
Provide all labor and materials to accomplish the following additional work. This work request is in response to the Contractor's CFR listed above:
The above work will require an extension of ______ days beyond the current delivery date of __________.
FOR COAST GUARD USE ONLY
Operational Commander (___________________) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.
Ref: Phoncon between _____________________ and _________________________ Of _________________________________________________________________ Remarks:
The above work will require an extension of days beyond the current delivery date of ____.
FOR COAST GUARD USE ONLY
Operational Commander ( ___ ) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.
Provide all labor and materials to accomplish the following:
The above work will reuire an extension of ______ days beyond the current delivery date of __________.
FOR COAST GUARD USE ONLY
Operational Commander (___________________) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.
Ref: Phoncon between _____________________ and _________________________ Of _________________________________________________________________
Remarks:
You are requested to provide a detailed price proposal for the work described below to the Contracting Officer within 3 calendar days (or earlier if requested) from the date of issuance. No obligation is created for the United States Government to award any work until an agreement on price and performance period is reached. Following agreement on price and performance period a bilateral contract modification is executed between the Government and the Contractor.
The work described below is within the scope of the subject contract. All terms and conditions of the subject contract are applicable to this work request.
Sheet1
File details come from the government source that posted it. Updated .