Attachment 3 Supplemental Contract Requirements.pdf
PDF 141 KB Posted
- Attached to
- Steam Plant Upgrades - Projects B260 at Hill AFB
- Solicitation number
- W9123822R0007
About this file
This document contains details for a federal construction contract opportunity and related supplemental contract requirements. The Army Corps of Engineers is seeking a design-build contractor to perform improvements and repairs to boilers in Building 260 at Hill Air Force Base, including replacing eight existing boilers with new dual-fuel boilers meeting emissions standards. The estimated value of construction is between $25-100 million. The work must be completed within 730 calendar days and is subject to liquidated damages of $2,053.46 per day of delay. Only the contracting officer is authorized to modify the contract terms. The project will utilize the wage determination for Utah and allow for weather-related time extensions with approval from the contracting officer's representative.
View the file
Other files
Show all 30
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Attachment 3
SUPPLEMENTAL CONTRACT REQUIREMENTS
1. Performance Period: Refer to contract section 00700, FAR 52.211-10. The performance period for the work stated above shall be 730 calendar days.
2. Liquidated Damages: Refer to contract section 00700, FAR 52.211-12, Liquidated Damages-Construction. Liquidated damages for this work are $2,053.46 for each day of delay.
3. Authorities: “Only a warranted Contracting Officer (either PCO or ACO) acting within their delegated limits has the authority to issue modifications or otherwise change the terms and conditions of this contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this contract you shall not proceed with the change and shall immediately notify the Contracting Officer.”
4. Wage Determination: General Decision No. UT20210083, or its most current modification at the time of award is hereby applicable to work performed under this task order.
The most current decision or its modification can be found at:
SAM.gov
6. Time Extensions For Unusually Severe Weather: Refer to FAR 52.249-10, Default (Fixed- Priced Construction). All weather delay will need to be submitted and approved by the Contracting Officer Representative.
MONTHLY ANTICIPATED ADVERSE WEATHER DELAY
WORK DAYS BASED ON (5) DAY WORK WEEK-HILL AFB
JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC
(22) (19) (15) (07) (04) (03) (01) (02) (02) (05) (15) (22) https://sam.gov/wage-determination/UT20210083/5
File details come from the government source that posted it. Updated .