Attachment 01 26R0177 ML-C00073 MACC Cover NPT NLON.pdf

Design Bid Build - Building 114 Crane 64 Replacement Solicitation No.: N4008526R0177 Naval Undersea Warfare Center, Newport Naval Station, Newport, RI Work Order No.: 1785210

NAVAL FACILITIES ENGINEERING SYSTEM COMMAND, MID-ATLANTIC

9324 VIRGINIA AVE, BLDG Z-144, ROOM 225

NAVAL STATION NORFOLK, NORFOLK, VA 23511

POC: Stefan Nassaney, stefan.e.nassaney.civ@us.navy.mil

DESIGN-BUILD (DB) / DESIGN-BID-BUILD (DBB), INDEFINITE DELIVERY /

INDEFINITE QUANTITY (IDIQ), MULTIPLE AWARD CONSTRUCTION

CONTRACT (MACC) FOR NEW LONDON, CT / NEWPORT, RI AORs

PROPOSED TASK ORDER:

N4008526R0177 Design Bid Build Building 114 Crance 64 Replacement. Naval Undersea

Warfare Center, Naval Station Newport, Newport, RI.

DATE OF SOLICITATION: 6/4/2026

NEWPORT/NEW LONDON MACC HOLDERS:

N40085-22-D-0022

Armitage SAI JV

Penny Armitage

505 Ellicott Street, Suite A2

Buffalo, NY 14203

Phone : 716-525-2754

Bob.Macdonald@armitagecorp.com (new

POC)

penny.armitage@armitagecorp.com (updated) bhalsey@structuralassociates.com jp.armitage@armitagecorp.com

N40085-22-D-0023

Black Horse Construction Group

681 Falmouth Rd Suite A-20f

Mashpee, Ma 02649 mary@blackhorsegroup.us

N40085-22-D-0024

CCI Facility Support Services, LLC

Candida Shelton/Ralph Snow

29 Bowdoin St., Ste. 109

Manchester, ME 04351 dmorrison@cci-alliance.com; CGeorge@cci-alliance.com; cshelton@cci-alliance.com;

rsnow@cci-alliance.comRETIRED

Jim Henebury takes Ralph Snow's POC spot: Jim Henebury jhenebury@bbch-llc.com

N40085-22-D-0025

Doyon Management Services, LLC

Anthony Wood

33 College Hill Road, #31 Second Floor

Warwick, RI 02886

BD@doyongovgrp.com;

anthony.wood@doyongovgrp.com

GENERAL REQUIREMENTS

mailto:Bob.Macdonald@armitagecorp.com mailto:penny.armitage@armitagecorp.com mailto:bhalsey@structuralassociates.com mailto:jp.armitage@armitagecorp.com mailto:rsnow@cci-alliance.com mailto:jhenebury@bbch-llc.com

All terms and conditions of N4008522D0022/0023/0024/0025 IDIQ Contract apply to this solicitation. Please review your MACC award document for guidance on contract clauses and requirements that may pertain to this order. You are responsible to adhere to all applicable clauses, even if they are not restated in this RFP package or the Task Order award document. For clarification on any clause or other contractual issue please contact Stefan Nassaney at stefan.e.nassaney.civ@us.navy.mil.

Amendments will be posted directly to PIEE, Sam.gov and sent directly via email to MACC

Holders. It is ultimately the responsibility of the MACC Holders to monitor SAM.gov for any updates.

NAVFAC Solicitation No.: N4008526R0177

NAVFAC Specification/Drawing: Work Order No. 1785210

Title: N4008526R0177 Naval Undersea Warfare Center Building 114 Crance 64 Replacement.

Naval Station Newport, Newport, RI.

Location of the work: Naval Undersea Warfare Center, Newport Naval Station, Newport, RI

Description of the work:

CLIN 0001 Base Price work includes, but is not limited to:

a. Removing and disposing the existing 3-ton overhead bridge crane.

b. Providing a new 3-ton overhead electric traveling bridge crane. New crane configuration shall be top-running bridge with an under-running trolley hoist.

c. Replacing existing crane rails and crane conductors with new rails and conductors to accommodate two cranes operating on the same common rail system.

d. Replacing existing electric power infrastructure to crane with a new upgraded power feed that will support two new 3-ton cranes operating on the common rail system.

CLIN 0002 Option Item No. 1 - Price includes the following:

a. CLIN 0002. Price for providing all work in connection with a second new 3-ton overhead electric traveling bridge crane in room 101 in Building 114, complete in accordance with the NAVFAC project drawings and technical specifications.

b. Option Item No. 1 includes providing a crane anti-collision sensor system for each of two cranes.

Estimated Budget Amount or Price Range: In accordance with FAR 36.204(g) Disclosure of the

Magnitude of Construction Projects, the estimated price range for this project is between

$1,000,000 and $5,000,000.

Time for completion: In accordance with FAR 52.211-10 Commencement, Prosecution, and

Completion of Work, the duration of this task order (including Bid Options) shall be 450 calendar days from date of award (includes 15 calendar days for submission and approval of bonds and insurance).

Wage Determination: Department of Labor (DoL) General Decision Number: RI20260001

05/18/2026 (Attachment 05) applies to this work. Should this wage determination be modified by DoL prior to award, the most current wage determination will be incorporated in the award.

Liquidated damages: In accordance with FAR 52.211-12 Liquidated Damages, if the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $192.16 for each calendar day of delay until the work is completed or accepted.

Utilities: The Contractor shall be responsible for obtaining all utilities required for construction and testing. The Contractor shall provide these utilities at his expense, paid for at the current utility rate delivered to the job site. The Contractor shall provide and maintain all temporary utility connections and distribution lines, and all meters required to measure the amount of each utility used.

Record Shop Drawings: In accordance with FAR 52.236.21, Specifications and Drawings for

Construction, record shop drawings are required. Reproducible copies of these record drawings are required.

Government Furnished Property: There is no Government Furnished Property.

Bond Requirements: In accordance with FAR 52.228-1, Bid Guarantees, each offeror shall submit with its offer a guarantee bond (Standard Form 24) in a penal sum equal to at least 20 percent of the offer price or $3,000,000, whichever is less.

Performance and Payment Bonds are required from the contract task order awardee ten (10) calendar days after date of award.

Proposal Acceptance Period: Proposal acceptance period shall be 120 days from receipt of offers.

90 Day for Options

Definitization Of Equitable Adjustments For Change Orders Under Construction Contracts

No data is available regarding the timely definitization of equitable adjustments for change orders under construction contracts. The REA definitization information referenced in Navy

Marine Corps Acquisition Regulation Supplement (NMCARS) 5236.211(b)(2), should not be utilized. There are no agency-specific policies and procedures that apply to the definitization of equitable adjustments for change orders under construction contracts. This Contract contains rated order quantities certified for national defense use, and you are required to follow all the provisions of the DPAS regulation (DPAS Regulation - 15 CFR Part 700.12) only as it pertains to the rated quantities.

Site Visit: All MACC holders are invited to attend the Site Visit for this project. Firms participating in the site visit will not be directly compensated for their participation.

Date: 24 JUNE 2026

Time: 1100 AM

Site Visit Location: Building 114 Naval Undersea Warfare Center

Base Access Instructions: Refer to Attachment 07, 08, 09, 10, and 11 for Base Access. ALL

BASE ACCESS FORMS ARE DUE BY NOON 10 JUNE 2026.

Site Visit Attachments:

Attachment 08 - SECNAV FORM 5512-NSNPT

Attachment 09 - Site Visit Instructions

Site Visit POCs:

Stefan Nussaney, Contracting Officer, (401) 829-9161

Ray Cournoyer, Design Manager, (401) 841-7625

Pre-Proposal Inquiries (PPIs): Offerors who determine that the technical and or contractual requirements of this RFP require clarification(s) in order to permit submittal of a responsive proposal shall submit all questions in writing. All inquiries shall be submitted via email to

Stefan Nassaney at stefan.e.nassaney.civ@us.navy.mil no later than, fourteen (14) calendar days prior to proposal due date. Additionally, all inquiries shall be submitted using the Pre-Proposal

Inquiry (PPI) form (Attachment 04). Do not submit the same inquiry more than once. Please verify that inquiries submitted by you on behalf of your subcontractors are not duplicates. A response will be published via an amendment by email to MACC holders.

Proposal Due Date: Wednesday, 31 JULY 2026 at 02:00PM EST. LATE RESPONSES WILL

BE HANDLED IN ACCORDANCE WITH FAR 15.208(b).

Electronic Copies: Only the PIEE Solicitation Module is authorized for the submission of electronic proposals in response to this solicitation. Electronic proposal submissions should be no larger than 1.9 GB per file. Offerors shall ensure that the Government has received the electronic proposal prior to the date and time specified. PIEE Solicitation Vendor Access

Instructions are provided via Attachment E. Emailed submissions will not be accepted.

Offerors shall allow adequate time to upload files which may be slower for non-DoD users and to avoid other technical difficulties that may be encountered. Offerors are also responsible for submitting files in the format specified and consistent with requirements stated elsewhere in this solicitation. Files that cannot be opened or are otherwise missing the required content are the responsibility of the Offeror.

The PIEE system will record the date and time of package submittal. Upon successful receipt of the proposal through PIEE, the Offeror should receive email confirmation. Please keep this for your records. The date and time of package receipt recorded in PIEE shall govern the timeliness of any proposal submission. Late responses will be handled in accordance with FAR 15.208(b).

Evaluation Factors for Award:

1. The proposed task order will be awarded to the responsible Offeror offering the best value to the Government. The lowest price source selection process is selected as appropriate for this acquisition because the best value is expected to result from selection of the proposal with the lowest evaluated price. To make a determination of best value, the Government shall evaluate each Offeror on price only.

2. Basis of Evaluation and Submittal Requirements.

Price:

i. Solicitation Submittal Requirements:

Price shall be submitted on the Price Proposal Form included in the solicitation. The offeror shall submit one (1) electronic copy via The Procurement Integrated Enterprise Environment (PIEE), with the solicitation submittal requirements identified below:

a. Cover page with solicitation number, solicitation title, offeror name, address, phone number, Employer Identification Number (EIN), Unique Entity Identifier (UEI) in SAM, CAGE code, Federal Tax ID number, Point of Contact (POC), POC phone number, and POC email address;

b. All amendments acknowledged;

c. Price Schedule Form;

d. Copy of Representation and Certifications and proof of registration in System for Award

Management (SAM);

e. Confirmation of filing of Veterans’ Employment and Training (VETS) VETS-4212 for the 2023/2024 filing cycle; and

f. Bid Guarantee in accordance with FAR Clause 52.228-1, Bid Guarantee. Amount shall be at least twenty percent (20%) of the proposed price, but shall not exceed $3 million

The Offeror is required to submit a complete Price Proposal Form that includes completion of all line-item numbers. All required proposal documents shall be submitted in accordance with FAR

15.208.

II. Basis of Evaluation:

The Government will evaluate price based on the total lump sum price. Analysis will be performed by one or more of the following techniques to ensure a fair and reasonable price:

a. Comparison of proposed prices received in response to the RFP.

b. Comparison of the proposed prices with the Independent Government Cost Estimate

(IGCE).

c. Comparison of proposed prices with available historical information.

d. Comparison of market survey results.

Evaluation:

1. The Government reserves the right to eliminate from consideration for award any or all offers at any time prior to award of the contract; to negotiate with offerors in the competitive range; and to award the contract to the Offeror submitting the lowest price proposal.

2. The Government intends to evaluate proposals and award a contract without discussions with offerors (except clarifications as described in FAR 15.306(a)). The Government reserves the right to conduct discussions if the Contracting Officer later determines them to be necessary.

In addition, if the Contracting Officer determines that the number of proposals that would otherwise be in the competitive range exceeds the number at which an efficient competition can be conducted, the Contracting Officer may limit the number of proposals in the competitive range to the greatest number that will permit an efficient competition among the most highly rated proposals.

ATTACHMENTS:

Attachment 01 ML-C00073 MACC Cover NPT NLON

Attachment 02 - Spec Rev 1 Final - Bldg 114 Crane 64 12-12-25

Attachment 03 - Dwgs Rev 1 Final - Bldg 114 Crane 64 12-10-25

Attachment 04 - Pre-Proposal Inquiry (PPI) form

Attachment 05 - WD RI20260001 5-18-26

Attachment 06 - Bid Schedule Bldg 114 Crane 64

Attachment 07 - PIEE Vendor Access Instructions

Attachment 08 - NUWC Visitor Request Information Guidelines

Attachment 09 - SECNAV Form 5512-NSNPT

Attachment 10 - Site Visit Instructions

Attachment 11 - Base Access Email Template

Attachment 01

MACC COVER PAGE with Solicitation General Requirements

Attachment 02

Entire Specification Request for Proposal Package, including:

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

00 01 15 02/11, CHG 1: 08/14 LIST OF DRAWINGS

00 22 13.00 20 02/14, CHG 3: 11/18 SUPPLEMENTARY INSTRUCTIONS TO OFFERORS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 08/15, CHG 2: 08/21 SUMMARY OF WORK

01 14 00 11/11, CHG 13: 08/21 WORK RESTRICTIONS

01 20 00 11/20, CHG 2: 08/21 PRICE AND PAYMENT PROCEDURES

01 30 00 11/20, CHG 1: 08/21 ADMINISTRATIVE REQUIREMENTS

01 31 23.13 20 05/17, CHG 7: 11/21 ELECTRONIC CONSTRUCTION AND FACILITY

SUPPORT CONTRACT MANAGEMENT SYSTEM

01 32 16.00 20 08/18, CHG 1: 08/20 SMALL PROJECT CONSTRUCTION PROGRESS

SCHEDULES

01 33 00 08/18, CHG 4: 02/21 SUBMITTAL PROCEDURES

01 35 26 11/20, CHG 2: 11/21 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 05/24 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.00 20 11/11, CHG 8: 02/21 QUALITY CONTROL

01 50 00 11/20, CHG 1: 08/21 TEMPORARY CONSTRUCTION FACILITIES AND

CONTROLS

01 57 19 11/15, CHG 5: 08/21 TEMPORARY ENVIRONMENTAL CONTROLS

01 57 19.01 20 11/15, CHG 5: 08/21 SUPPLEMENTAL TEMPORARY ENVIRONMENTAL

CONTROLS

01 74 19 02/19, CHG 3: 11/21 CONSTRUCTION WASTE MANAGEMENT AND

DISPOSAL

01 78 00 05/19, CHG 1: 08/21 CLOSEOUT SUBMITTALS

01 78 23 08/15, CHG 2: 08/21 OPERATION AND MAINTENANCE DATA

01 78 24.00 20 02/15, CHG 3: 08/21 FACILITY ELECTRONIC OPERATION AND

MAINTENANCE SUPPORT INFORMATION (eOMSI)

01 91 00.15 20 02/21, CHG 1: 05/21 TOTAL BUILDING COMMISSIONING

DIVISION 02 - EXISTING CONDITIONS

02 41 00 05/10, CHG 2: 02/19 DEMOLITION AND DECONSTRUCTION

DIVISION 05 - METALS

05 12 00 08/18, CHG 2: 05/21 STRUCTURAL STEEL

DIVISION 26 - ELECTRICAL

26 05 00.00 40 COMMON WORK RESULTS FOR ELECTRICAL

DIVISION 41 - MATERIAL PROCESSING AND HANDLING EQUIPMENT

41 22 13.15 11/22, CHG 1: 02/23 BRIDGE CRANES, OVERHEAD ELECTRIC,

UNDER RUNNING TROLLEY

See separately attached PDF Files labeled as follows:

Attachment 02 - Spec Rev 1 Final - Bldg 114 Crane 64 12-12-25

Attachment 03

Complete Drawings

Attachment 03 - Dwgs Rev 1 Final - Bldg 114 Crane 64 12-10-25

Attachment 04

Pre-Proposal Inquiry (PPI) Form

Attachment 04 - Pre-Proposal Inquiry (PPI) form

Attachment 05

"General Decision Number: RI20260001 05/18/2026

State: Rhode Island

Construction Types: Building, Heavy and Highway

Counties: Rhode Island Counties of

Bristol, Kent, Newport, Providence and

Washington

Includes Marine Construction Projects

Modification Number Publication Date

2 01/30/2026

3 05/18/2026

ASBE0006-006 09/01/2024

Rates Fringes

HAZARDOUS MATERIAL HANDLER (INCLUDES PREPARATION,

WETTING, STRIPPING, REMOVAL SCRAPPING, VACUUMING,

BAGGING & DISPOSING OF ALL INSULATION MATERIALS,

WHETHER THEY CONTAIN ASBESTOS OR NOT, FROM

MECHANICAL SYSTEMS).................................$ 49.91 36.63

ASBE0006-008 09/01/2024

ASBESTOS WORKER/INSULATOR (INCLUDES APPLICATION OF

ALL INSULATING MATERIALS, PROTECTIVE COVERINGS,

COATINGS & FINISHES TO ALL TYPES OF MECHANICAL

SYSTEMS)............................................$ 49.91 36.63

BOIL0029-001 01/01/2025

BOILERMAKER.........................................$ 50.62 28.82

BRRI0003-001 06/01/2022

BRICKLAYER, STONEMASON, POINTER, CAULKER & CLEANER..$ 46.86 29.14

BRRI0003-002 09/01/2022

MARBLE SETTER, TERRAZZO WORKER & TILE SETTER........$ 46.54 30.34

BRRI0003-003 09/01/2022

MARBLE, TILE & TERRAZZO FINISHER....................$ 38.78 29.61

CARP0330-001 01/01/2023

PILEDRIVER FOOTNOTES: WHEN NOT DIVING OR

TENDING THE DIVER, THE DIVER AND DIVER TENDER SHALL

RECEIVE THE PILEDRIVER RATE. DIVER TENDERS SHALL

RECEIVE $1.00 PER HOUR ABOVE THE PILE DRIVER RATE

WHEN TENDING THE DIVER. WORK ON FREE-STANDING

STACKS, CONCRETE SILOS & PUBLIC UTILITY ELECTRICAL

POWER HOUSES, WHICH ARE OVER 35 FT. IN HEIGHT WHEN

CONSTRUCTED: $.50 PER HOUR ADDITIONAL. WORK ON

EXTERIOR CONCRETE SHEAR WALL GANG FORMS, 45 FT. OR

MORE ABOVE GROUND ELEVATION OR ON SETBACK: $.50 PER

HOUR ADDITIONAL. THE DESIGNATED PILEDRIVER,

KNOWN AS THE ""MONKEY"": $1.00 PER HOUR ADDITIONAL....$ 41.53 29.35

WELDER FOOTNOTES: WHEN NOT DIVING OR TENDING

THE DIVER, THE DIVER AND DIVER TENDER SHALL RECEIVE

THE PILEDRIVER RATE. DIVER TENDERS SHALL RECEIVE

$1.00 PER HOUR ABOVE THE PILE DRIVER RATE WHEN

TENDING THE DIVER. WORK ON FREE-STANDING STACKS,

CONCRETE SILOS & PUBLIC UTILITY ELECTRICAL POWER

HOUSES, WHICH ARE OVER 35 FT. IN HEIGHT WHEN

CONSTRUCTED: $.50 PER HOUR ADDITIONAL. WORK ON

EXTERIOR CONCRETE SHEAR WALL GANG FORMS, 45 FT. OR

MORE ABOVE GROUND ELEVATION OR ON SETBACK: $.50 PER

HOUR ADDITIONAL. THE DESIGNATED PILEDRIVER,

KNOWN AS THE ""MONKEY"": $1.00 PER HOUR ADDITIONAL....$ 48.68 30.50

DIVER TENDER FOOTNOTES: WHEN NOT DIVING OR

TENDING THE DIVER, THE DIVER AND DIVER TENDER SHALL

RECEIVE THE PILEDRIVER RATE. DIVER TENDERS SHALL

RECEIVE $1.00 PER HOUR ABOVE THE PILE DRIVER RATE

WHEN TENDING THE DIVER. WORK ON FREE-STANDING

STACKS, CONCRETE SILOS & PUBLIC UTILITY ELECTRICAL

POWER HOUSES, WHICH ARE OVER 35 FT. IN HEIGHT WHEN

CONSTRUCTED: $.50 PER HOUR ADDITIONAL. WORK ON

EXTERIOR CONCRETE SHEAR WALL GANG FORMS, 45 FT. OR

MORE ABOVE GROUND ELEVATION OR ON SETBACK: $.50 PER

HOUR ADDITIONAL. THE DESIGNATED PILEDRIVER,

KNOWN AS THE ""MONKEY"": $1.00 PER HOUR ADDITIONAL....$ 48.68 30.50

DIVER FOOTNOTES: WHEN NOT DIVING OR TENDING

THE DIVER, THE DIVER AND DIVER TENDER SHALL RECEIVE

THE PILEDRIVER RATE. DIVER TENDERS SHALL RECEIVE

$1.00 PER HOUR ABOVE THE PILE DRIVER RATE WHEN

TENDING THE DIVER. WORK ON FREE-STANDING STACKS,

CONCRETE SILOS & PUBLIC UTILITY ELECTRICAL POWER

HOUSES, WHICH ARE OVER 35 FT. IN HEIGHT WHEN

CONSTRUCTED: $.50 PER HOUR ADDITIONAL. WORK ON

EXTERIOR CONCRETE SHEAR WALL GANG FORMS, 45 FT. OR

MORE ABOVE GROUND ELEVATION OR ON SETBACK: $.50 PER

HOUR ADDITIONAL. THE DESIGNATED PILEDRIVER,

KNOWN AS THE ""MONKEY"": $1.00 PER HOUR ADDITIONAL....$ 60.83 30.50

CARPENTER: INCLUDES SOFT FLOOR LAYER................$ 47.88 30.50

CARP0330-001 06/02/2025

PILEDRIVER FOOTNOTES: WHEN NOT DIVING OR

TENDING THE DIVER, THE DIVER AND DIVER TENDER SHALL

RECEIVE THE PILEDRIVER RATE. DIVER TENDERS SHALL

RECEIVE $1.00 PER HOUR ABOVE THE PILE DRIVER RATE

WHEN TENDING THE DIVER. WORK ON FREE-STANDING

STACKS, CONCRETE SILOS & PUBLIC UTILITY ELECTRICAL

POWER HOUSES, WHICH ARE OVER 35 FT. IN HEIGHT WHEN

CONSTRUCTED: $.50 PER HOUR ADDITIONAL. WORK ON

EXTERIOR CONCRETE SHEAR WALL GANG FORMS, 45 FT. OR

MORE ABOVE GROUND ELEVATION OR ON SETBACK: $.50 PER

HOUR ADDITIONAL. THE DESIGNATED PILEDRIVER,

KNOWN AS THE ""MONKEY"": $1.00 PER HOUR ADDITIONAL....$ 41.53 29.35

WELDER FOOTNOTES: WHEN NOT DIVING OR TENDING

THE DIVER, THE DIVER AND DIVER TENDER SHALL RECEIVE

THE PILEDRIVER RATE. DIVER TENDERS SHALL RECEIVE

$1.00 PER HOUR ABOVE THE PILE DRIVER RATE WHEN

TENDING THE DIVER. WORK ON FREE-STANDING STACKS,

CONCRETE SILOS & PUBLIC UTILITY ELECTRICAL POWER

HOUSES, WHICH ARE OVER 35 FT. IN HEIGHT WHEN

CONSTRUCTED: $.50 PER HOUR ADDITIONAL. WORK ON

EXTERIOR CONCRETE SHEAR WALL GANG FORMS, 45 FT. OR

MORE ABOVE GROUND ELEVATION OR ON SETBACK: $.50 PER

HOUR ADDITIONAL. THE DESIGNATED PILEDRIVER,

KNOWN AS THE ""MONKEY"": $1.00 PER HOUR ADDITIONAL....$ 48.68 30.50

DIVER TENDER FOOTNOTES: WHEN NOT DIVING OR

TENDING THE DIVER, THE DIVER AND DIVER TENDER SHALL

RECEIVE THE PILEDRIVER RATE. DIVER TENDERS SHALL

RECEIVE $1.00 PER HOUR ABOVE THE PILE DRIVER RATE

WHEN TENDING THE DIVER. WORK ON FREE-STANDING

STACKS, CONCRETE SILOS & PUBLIC UTILITY ELECTRICAL

POWER HOUSES, WHICH ARE OVER 35 FT. IN HEIGHT WHEN

CONSTRUCTED: $.50 PER HOUR ADDITIONAL. WORK ON

EXTERIOR CONCRETE SHEAR WALL GANG FORMS, 45 FT. OR

MORE ABOVE GROUND ELEVATION OR ON SETBACK: $.50 PER

HOUR ADDITIONAL. THE DESIGNATED PILEDRIVER,

KNOWN AS THE ""MONKEY"": $1.00 PER HOUR ADDITIONAL....$ 48.68 30.50

DIVER FOOTNOTES: WHEN NOT DIVING OR TENDING

THE DIVER, THE DIVER AND DIVER TENDER SHALL RECEIVE

THE PILEDRIVER RATE. DIVER TENDERS SHALL RECEIVE

$1.00 PER HOUR ABOVE THE PILE DRIVER RATE WHEN

TENDING THE DIVER. WORK ON FREE-STANDING STACKS,

CONCRETE SILOS & PUBLIC UTILITY ELECTRICAL POWER

HOUSES, WHICH ARE OVER 35 FT. IN HEIGHT WHEN

CONSTRUCTED: $.50 PER HOUR ADDITIONAL. WORK ON

EXTERIOR CONCRETE SHEAR WALL GANG FORMS, 45 FT. OR

MORE ABOVE GROUND ELEVATION OR ON SETBACK: $.50 PER

HOUR ADDITIONAL. THE DESIGNATED PILEDRIVER,

KNOWN AS THE ""MONKEY"": $1.00 PER HOUR ADDITIONAL....$ 60.83 30.50

CARPENTER: INCLUDES SOFT FLOOR LAYER................$ 47.88 30.50

CARP1121-002 04/21/2025

MILLWRIGHT..........................................$ 45.72 31.50

ELEC0099-002 06/01/2025

TELEDATA SYSTEM INSTALLER FOOTNOTES: WORK OF

A HAZARDOUS NATURE, OR WHERE THE WORK HEIGHT IS 30

FT. OR MORE FROM THE FLOOR, EXCEPT WHEN WORKING

OSHA-APPROVED LIFTS: 20% PER HOUR ADDITIONAL.

WORK IN TUNNELS BELOW GROUND LEVEL IN COMBINED

SEWER OUTFALL: 20% PER HOUR ADDITIONAL..............$ 42.09 19.71

ELECTRICIAN FOOTNOTES: WORK OF A HAZARDOUS

NATURE, OR WHERE THE WORK HEIGHT IS 30 FT. OR MORE

FROM THE FLOOR, EXCEPT WHEN WORKING OSHA-APPROVED

LIFTS: 20% PER HOUR ADDITIONAL. WORK IN TUNNELS

BELOW GROUND LEVEL IN COMBINED SEWER OUTFALL: 20%

PER HOUR ADDITIONAL.................................$ 56.11 24.74

ELEV0039-001 01/01/2025

ELEVATOR MECHANIC FOOTNOTES: A. PAID HOLIDAYS:

NEW YEARS DAY; MEMORIAL DAY; INDEPENDENCE DAY;

LABOR DAY; VETERANS' DAY; THANKSGIVING DAY; THE

FRIDAY AFTER THANKSGIVING DAY; AND CHRISTMAS DAY.

B. EMPLOYER CONTRIBUTES 8% BASIC HOURLY RATE FOR

5 YEARS OR MORE OF SERVICE OF 6% BASIC HOURLY RATE

FOR 6 MONTHS TO 5 YEARS OF SERVICE AS VACATION PAY

CREDIT..............................................$ 64.52 38.44

ENGI0057-001 12/01/2025

Rates Fringes

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

SUBTERRANEAN & OTHER MARINE AND HEAVY CONSTRUCTION

WORK: GROUP 9 BOAT & TUG OPERATOR.

A. BOOM LENGTHS, INCLUDING JIBS: 150 FEET

AND OVER + $ 2.00 180 FEET AND OVER + $ 3.00 210

FEET AND OVER + $ 4.00 240 FEET AND OVER + $ 5.00

270 FEET AND OVER + $ 7.00 300 FEET AND OVER + $

8.00 350 FEET AND OVER + $ 9.00 400 FEET AND OVER

+ $10.00 A. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY, CHRISTMAS DAY. A: ANY EMPLOYEE

WHO WORKS 3 DAYS IN THE WEEK IN WHICH A HOLIDAY

FALLS SHALL BE PAID FOR THE HOLIDAY. A. FOOTNOTES:

HAZMAT WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL........$ 48.92 29.95

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

SUBTERRANEAN & OTHER MARINE AND HEAVY CONSTRUCTION

WORK: GROUP 8 HEATER, CONCRETE MIXER, STONE

CRUSHER, WELDING MACHINE, GENERATOR AND LIGHT

PLANT, GAS AND ELECTRIC DRIVEN PUMP AND AIR

COMPRESSOR.

A. BOOM

LENGTHS, INCLUDING JIBS: 150 FEET AND OVER + $

2.00 180 FEET AND OVER + $ 3.00 210 FEET AND OVER

+ $ 4.00 240 FEET AND OVER + $ 5.00 270 FEET AND

OVER + $ 7.00 300 FEET AND OVER + $ 8.00 350 FEET

AND OVER + $ 9.00 400 FEET AND OVER + $10.00 A.

PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY,

CHRISTMAS DAY. A: ANY EMPLOYEE WHO WORKS 3 DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. A. FOOTNOTES: HAZMAT WORK: $2.00 PER

HOUR ADDITIONAL. TUNNEL/SHAFT WORK: $5.00 PER HOUR

ADDITIONAL..........................................$ 45.00 29.95

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

WORK: GROUP 7 UTILITY ENGINEERS AND SIGNAL PERSONS

A.

BOOM LENGTHS, INCLUDING JIBS: 150 FEET AND OVER +

$ 2.00 180 FEET AND OVER + $ 3.00 210 FEET AND

OVER + $ 4.00 240 FEET AND OVER + $ 5.00 270 FEET

AND OVER + $ 7.00 300 FEET AND OVER + $ 8.00 350

FEET AND OVER + $ 9.00 400 FEET AND OVER + $10.00

A. PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY,

CHRISTMAS DAY. A: ANY EMPLOYEE WHO WORKS 3 DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. A. FOOTNOTES: HAZMAT WORK: $2.00 PER

HOUR ADDITIONAL. TUNNEL/SHAFT WORK: $5.00 PER HOUR

ADDITIONAL..........................................$ 33.15 29.95

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

WORK: GROUP 6 WELL-POINT INSTALLATION CREW.

A. BOOM LENGTHS, INCLUDING JIBS: 150 FEET AND

OVER + $ 2.00 180 FEET AND OVER + $ 3.00 210 FEET

AND OVER + $ 4.00 240 FEET AND OVER + $ 5.00 270

FEET AND OVER + $ 7.00 300 FEET AND OVER + $ 8.00

350 FEET AND OVER + $ 9.00 400 FEET AND OVER +

$10.00 A. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY, CHRISTMAS DAY. A: ANY EMPLOYEE

WHO WORKS 3 DAYS IN THE WEEK IN WHICH A HOLIDAY

FALLS SHALL BE PAID FOR THE HOLIDAY. A. FOOTNOTES:

HAZMAT WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL........$ 39.15 29.95

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

SUBTERRANEAN & OTHER MARINE AND HEAVY CONSTRUCTION

WORK: GROUP 5 BULLDOZER, BOBCATS, SKID STEER

LOADER, TRACTOR, SCRAPER, COMBINATION LOADER

BACKHOE, ROLLER, FRONT END LOADER (LESS THAN 3

YDS.), STREET AND MOBILE-POWERED SWEEPER (3-YD.

CAPACITY), 8-FT. SWEEPER MINIMUM 65 HP).

A. BOOM LENGTHS, INCLUDING JIBS: 150

FEET AND OVER + $ 2.00 180 FEET AND OVER + $ 3.00

210 FEET AND OVER + $ 4.00 240 FEET AND OVER + $

5.00 270 FEET AND OVER + $ 7.00 300 FEET AND OVER

+ $ 8.00 350 FEET AND OVER + $ 9.00 400 FEET AND

OVER + $10.00 A. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY, CHRISTMAS DAY. A: ANY EMPLOYEE

WHO WORKS 3 DAYS IN THE WEEK IN WHICH A HOLIDAY

FALLS SHALL BE PAID FOR THE HOLIDAY. A. FOOTNOTES:

HAZMAT WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL........$ 48.35 29.95

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

WORK: GROUP 4 OILER ON CRAWLER BACKHOE.

A. BOOM LENGTHS, INCLUDING JIBS: 150 FEET AND OVER

+ $ 2.00 180 FEET AND OVER + $ 3.00 210 FEET AND

OVER + $ 4.00 240 FEET AND OVER + $ 5.00 270 FEET

AND OVER + $ 7.00 300 FEET AND OVER + $ 8.00 350

FEET AND OVER + $ 9.00 400 FEET AND OVER + $10.00

A. PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY,

CHRISTMAS DAY. A: ANY EMPLOYEE WHO WORKS 3 DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. A. FOOTNOTES: HAZMAT WORK: $2.00 PER

HOUR ADDITIONAL. TUNNEL/SHAFT WORK: $5.00 PER HOUR

ADDITIONAL..........................................$ 42.07 29.95

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

WORK: GROUP 3 OILERS ON CRANES.

A. BOOM LENGTHS, INCLUDING JIBS: 150

FEET AND OVER + $ 2.00 180 FEET AND OVER + $ 3.00

210 FEET AND OVER + $ 4.00 240 FEET AND OVER + $

5.00 270 FEET AND OVER + $ 7.00 300 FEET AND OVER

+ $ 8.00 350 FEET AND OVER + $ 9.00 400 FEET AND

OVER + $10.00 A. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY, CHRISTMAS DAY. A: ANY EMPLOYEE

WHO WORKS 3 DAYS IN THE WEEK IN WHICH A HOLIDAY

FALLS SHALL BE PAID FOR THE HOLIDAY. A. FOOTNOTES:

HAZMAT WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL........$ 44.92 29.95

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

SUBTERRANEAN & OTHER MARINE AND HEAVY CONSTRUCTION

WORK: GROUP 2 DIGGING MACHINE, ROSS CARRIER,

LOCOMOTIVE, HOIST, ELEVATOR, BIDWELL-TYPE MACHINE,

SHOT & WATER BLASTING MACHINE, PAVER, SPREADER,

GRADERS, FRONT END LOADER (3 YDS. AND OVER),

VIBRATORY HAMMER & VACUUM TRUCK, ROADHEADERS,

FORKLIFTS, ECONOMOBILE TYPE EQUIPMENT, TUNNEL

BORING MACHINES, CONCRETE PUMP AND ON SITE CONCRETE

PLANTS.

A. BOOM LENGTHS, INCLUDING

JIBS: 150 FEET AND OVER + $ 2.00 180 FEET AND

OVER + $ 3.00 210 FEET AND OVER + $ 4.00 240 FEET

AND OVER + $ 5.00 270 FEET AND OVER + $ 7.00 300

FEET AND OVER + $ 8.00 350 FEET AND OVER + $ 9.00

400 FEET AND OVER + $10.00 A. PAID HOLIDAYS: NEW

YEAR'S DAY, PRESIDENT'S DAY, MEMORIAL DAY, JULY

FOURTH, VICTORY DAY, LABOR DAY, COLUMBUS DAY,

VETERANS DAY, THANKSGIVING DAY, CHRISTMAS DAY. A:

ANY EMPLOYEE WHO WORKS 3 DAYS IN THE WEEK IN WHICH

A HOLIDAY FALLS SHALL BE PAID FOR THE HOLIDAY. A.

FOOTNOTES: HAZMAT WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL.......$ 49.30 29.95

POWER EQUIPMENT OPERATOR: POWER PLANTS, SEWER

TREATMENT PLANTS, PUMPING STATIONS, TUNNELS,

CAISSONS, PIERS, DOCKS, BRIDGES, WIND TURBINES,

SUBTERRANEAN & OTHER MARINE AND HEAVY CONSTRUCTION

WORK: GROUP 1 CRANES, LIGHTERS, BOOM TRUCKS AND

DERRICKS

A. BOOM LENGTHS,

INCLUDING JIBS: 150 FEET AND OVER + $ 2.00 180

FEET AND OVER + $ 3.00 210 FEET AND OVER + $ 4.00

240 FEET AND OVER + $ 5.00 270 FEET AND OVER + $

7.00 300 FEET AND OVER + $ 8.00 350 FEET AND OVER

+ $ 9.00 400 FEET AND OVER + $10.00 A. PAID

HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY,

CHRISTMAS DAY. A: ANY EMPLOYEE WHO WORKS 3 DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. A. FOOTNOTES: HAZMAT WORK: $2.00 PER

HOUR ADDITIONAL. TUNNEL/SHAFT WORK: $5.00 PER HOUR

ADDITIONAL..........................................$ 51.30 29.95

ENGI0057-003 12/01/2025

POWER EQUIPMENT OPERATOR: BUILDING CONSTRUCTION:

GROUP 8 HEATER, CONCRETE MIXER, STONE CRUSHER,

WELDING MACHINE, GENERATOR FOR LIGHT PLANT, GAS AND

ELECTRIC DRIVEN PUMP & AIR COMPRESSOR

A. BOOM LENTHS, INCLUDING JIBS: 150 FT. AND OVER:

+ $ 2.00 180 FT. AND OVER: + $ 3.00 210 FT. AND

OVER: + $ 4.00 240 FT. AND OVER: + $ 5.00 270 FT.

AND OVER: + $ 7.00 300 FT. AND OVER: + $ 8.00 350

FT. AND OVER: + $ 9.00 400 FT. AND OVER: +

$10.00 A. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY. A: ANY EMPLOYEE

WHO WORKS 3 DAYS IN THE WEEK IN WHICH A HOLIDAY

FALLS SHALL BE PAID FOR THE HOLIDAY.

A. FOOTNOTE: HAZMAT WORK: $2.00 PER HOUR

ADDITIONAL. TUNNEL/SHAFT WORK: $5.00 PER

HOUR ADDITIONAL.....................................$ 44.54 29.95

POWER EQUIPMENT OPERATOR: BUILDING CONSTRUCTION:

GROUP 7 WELL POINT INSTALLATION CREW

A. BOOM LENTHS,

INCLUDING JIBS: 150 FT. AND OVER: + $ 2.00 180

FT. AND OVER: + $ 3.00 210 FT. AND OVER: + $ 4.00

240 FT. AND OVER: + $ 5.00 270 FT. AND OVER: + $

7.00 300 FT. AND OVER: + $ 8.00 350 FT. AND OVER:

+ $ 9.00 400 FT. AND OVER: + $10.00 A.

PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY &

CHRISTMAS DAY. A: ANY EMPLOYEE WHO WORKS 3 DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. A. FOOTNOTE: HAZMAT

WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL........$ 47.22 29.95

POWER EQUIPMENT OPERATOR: BUILDING CONSTRUCTION:

GROUP 6 BULLDOZER,SKID STEER LOADERS,BOBCATS,

TRACTOR, GRADER, SCRAPER,COMBINATION LOADER

BACKHOE, ROLLER, FRONT END LOADER (LESS THAN 3

YDS.), STREET AND MOBILE POWERED SWEEPER (3 YDS.

CAPACITY), 8-FT. SWEEPER (MINIMUM 65 HP)

OVER: + $ 4.00 240 FT. AND OVER: + $ 5.00 270 FT.

AND OVER: + $ 7.00 300 FT. AND OVER: + $ 8.00 350

FT. AND OVER: + $ 9.00 400 FT. AND OVER: +

$10.00 A. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY. A: ANY EMPLOYEE

WHO WORKS 3 DAYS IN THE WEEK IN WHICH A HOLIDAY

FALLS SHALL BE PAID FOR THE HOLIDAY.

A. FOOTNOTE: HAZMAT WORK: $2.00 PER HOUR

ADDITIONAL. TUNNEL/SHAFT WORK: $5.00 PER

HOUR ADDITIONAL.....................................$ 47.65 29.95

GROUP 5 OILER ON CRAWLER BACKHOE

A. BOOM LENTHS, INCLUDING JIBS: 150 FT. AND

OVER: + $ 2.00 180 FT. AND OVER: + $ 3.00 210 FT.

AND OVER: + $ 4.00 240 FT. AND OVER: + $ 5.00 270

FT. AND OVER: + $ 7.00 300 FT. AND OVER: + $ 8.00

350 FT. AND OVER: + $ 9.00 400 FT. AND OVER: +

$10.00 A. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY. A: ANY EMPLOYEE

WHO WORKS 3 DAYS IN THE WEEK IN WHICH A HOLIDAY

FALLS SHALL BE PAID FOR THE HOLIDAY.

A. FOOTNOTE: HAZMAT WORK: $2.00 PER HOUR

ADDITIONAL. TUNNEL/SHAFT WORK: $5.00 PER

HOUR ADDITIONAL.....................................$ 41.50 29.95

GROUP 4 FIREMAN & OILER ON CRANES

A. BOOM

LENTHS, INCLUDING JIBS: 150 FT. AND OVER: + $ 2.00

180 FT. AND OVER: + $ 3.00 210 FT. AND OVER: + $

4.00 240 FT. AND OVER: + $ 5.00 270 FT. AND OVER:

+ $ 7.00 300 FT. AND OVER: + $ 8.00 350 FT. AND

OVER: + $ 9.00 400 FT. AND OVER: + $10.00

A. PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY &

CHRISTMAS DAY. A: ANY EMPLOYEE WHO WORKS 3 DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. A. FOOTNOTE: HAZMAT

WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL........$ 44.35 29.95

POWER EQUIPMENT OPERATOR: BUILDING CONSTRUCTION:

GROUP 3 TELEHANDLER EQUIPMENT, FORKLIFT, CONCRETE

PUMP & ON-SITE CONCRETE PLANT

OVER: + $ 4.00 240 FT. AND OVER: + $ 5.00 270 FT.

AND OVER: + $ 7.00 300 FT. AND OVER: + $ 8.00 350

FT. AND OVER: + $ 9.00 400 FT. AND OVER: +

$10.00 A. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY. A: ANY EMPLOYEE

WHO WORKS 3 DAYS IN THE WEEK IN WHICH A HOLIDAY

FALLS SHALL BE PAID FOR THE HOLIDAY.

A. FOOTNOTE: HAZMAT WORK: $2.00 PER HOUR

ADDITIONAL. TUNNEL/SHAFT WORK: $5.00 PER

HOUR ADDITIONAL.....................................$ 48.35 29.95

POWER EQUIPMENT OPERATOR: BUILDING CONSTRUCTION:

GROUP 2 DIGGING MACHINE, ROSS CARRIER, LOCOMOTIVE,

HOIST, ELEVATOR, BIDWELL-TYPE MACHINE, SHOT & WATER

BLASTING MACHINE, PAVER, SPREADER, FRONT END LOADER

(3 YDS. AND OVER), VIBRATORY HAMMER AND VACUUM

TRUCK

180 FT. AND OVER: + $ 3.00 210 FT. AND OVER: + $

4.00 240 FT. AND OVER: + $ 5.00 270 FT. AND OVER:

+ $ 7.00 300 FT. AND OVER: + $ 8.00 350 FT. AND

OVER: + $ 9.00 400 FT. AND OVER: + $10.00

A. PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY &

CHRISTMAS DAY. A: ANY EMPLOYEE WHO WORKS 3 DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. A. FOOTNOTE: HAZMAT

WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL........$ 48.57 29.95

POWER EQUIPMENT OPERATOR: BUILDING CONSTRUCTION:

GROUP 1 CRANES, LIGHTERS, BOOM TRUCKS AND

DERRICKS.

180 FT. AND OVER: + $ 3.00 210 FT. AND OVER: + $

4.00 240 FT. AND OVER: + $ 5.00 270 FT. AND OVER:

+ $ 7.00 300 FT. AND OVER: + $ 8.00 350 FT. AND

OVER: + $ 9.00 400 FT. AND OVER: + $10.00

A. PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY &

CHRISTMAS DAY. A: ANY EMPLOYEE WHO WORKS 3 DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. A. FOOTNOTE: HAZMAT

WORK: $2.00 PER HOUR ADDITIONAL.

TUNNEL/SHAFT WORK: $5.00 PER HOUR ADDITIONAL........$ 50.57 29.95

ENGI0057-005 12/01/2025

POWER EQUIPMENT OPERATOR: HIGHWAY CONSTRUCTION

PROJECTS; WATER AND SEWERLINE PROJECTS WHICH ARE

INCIDENTAL TO HIGHWAY CONSTRUCTION PROJECTS; AND

BRIDGE PROJECTS THAT DO NOT SPAN WATER: GROUP 8 GAS

AND ELECTRIC DRIVE HEATERS, CONCRETE MIXERS, LIGHT

PLANTS, WELDING MACHINES, PUMPS AND COMPRESSORS

A. FOOTNOTE: A. ANY

EMPLOYEE WHO WORKS THREE DAYS IN THE WEEK IN WHICH

A HOLIDAY FALLS SHALL BE PAID FOR THE HOLIDAY. B.

PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY &

CHRISTMAS DAY.......................................$ 38.70 29.95

POWER EQUIPMENT OPERATOR: HIGHWAY CONSTRUCTION

PROJECTS; WATER AND SEWERLINE PROJECTS WHICH ARE

INCIDENTAL TO HIGHWAY CONSTRUCTION PROJECTS; AND

BRIDGE PROJECTS THAT DO NOT SPAN WATER: GROUP 7

COMBINATION LOADER / BACKHOES, FRONT-END LOADERS

(LESS THAN 3 YDS.), FORKLIFT, BULLDOZERS, SCRAPERS,

BOATS, ROLLERS, SKID STEER LOADERS (REGARDLESS OF

ATTACHMENTS), STREET SWEEPERS, MECHANICS, WELDERS,

OPERATORS IN MATERIALS YARDS, SHOPS AND GARAGES

A HOLIDAY FALLS SHALL BE PAID FOR THE HOLIDAY. B.

PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY &

CHRISTMAS DAY.......................................$ 43.43 29.95

POWER EQUIPMENT OPERATOR: HIGHWAY CONSTRUCTION

PROJECTS; WATER AND SEWERLINE PROJECTS WHICH ARE

INCIDENTAL TO HIGHWAY CONSTRUCTION PROJECTS; AND

BRIDGE PROJECTS THAT DO NOT SPAN WATER: GROUP 6

OILERS ON CRANES AND DECKHANDS

A HOLIDAY FALLS SHALL BE PAID FOR THE HOLIDAY. B.

PAID HOLIDAYS: NEW YEAR'S DAY, PRESIDENT'S DAY,

MEMORIAL DAY, JULY FOURTH, VICTORY DAY, LABOR DAY,

COLUMBUS DAY, VETERANS DAY, THANKSGIVING DAY &

CHRISTMAS DAY.......................................$ 39.73 29.95

POWER EQUIPMENT OPERATOR: HIGHWAY CONSTRUCTION

PROJECTS; WATER AND SEWERLINE PROJECTS WHICH ARE

INCIDENTAL TO HIGHWAY CONSTRUCTION PROJECTS; AND

BRIDGE PROJECTS THAT DO NOT SPAN WATER: GROUP 5

SIGNAL PERSONS

A.

FOOTNOTE: A. ANY EMPLOYEE WHO WORKS THREE DAYS IN

THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE PAID FOR

THE HOLIDAY. B. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY....................$ 33.15 29.95

POWER EQUIPMENT OPERATOR: HIGHWAY CONSTRUCTION

PROJECTS; WATER AND SEWERLINE PROJECTS WHICH ARE

INCIDENTAL TO HIGHWAY CONSTRUCTION PROJECTS; AND

BRIDGE PROJECTS THAT DO NOT SPAN WATER: GROUP 4

UTILITY ENGINEERS

A. FOOTNOTE:

A. ANY EMPLOYEE WHO WORKS THREE DAYS IN THE WEEK IN

WHICH A HOLIDAY FALLS SHALL BE PAID FOR THE

HOLIDAY. B. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY....................$ 25.75 29.95

POWER EQUIPMENT OPERATOR: HIGHWAY CONSTRUCTION

PROJECTS; WATER AND SEWERLINE PROJECTS WHICH ARE

INCIDENTAL TO HIGHWAY CONSTRUCTION PROJECTS; AND

BRIDGE PROJECTS THAT DO NOT SPAN WATER: GROUP 3

WELLPOINT INSTALLATION AND DRILL/BORING MACHINE

ASSISTANTS

A. FOOTNOTE: A. ANY EMPLOYEE WHO WORKS THREE

DAYS IN THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE

PAID FOR THE HOLIDAY. B. PAID HOLIDAYS: NEW YEAR'S

DAY, PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH,

VICTORY DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY....................$ 39.15 29.95

POWER EQUIPMENT OPERATOR: HIGHWAY CONSTRUCTION

PROJECTS; WATER AND SEWERLINE PROJECTS WHICH ARE

INCIDENTAL TO HIGHWAY CONSTRUCTION PROJECTS; AND

BRIDGE PROJECTS THAT DO NOT SPAN WATER: GROUP 2

DIGGING MACHINES, EXCAVATORS, LOCOMOTIVES, JOHN

HENRY'S, DIRECTIONAL DRILLING MACHINES, COLD

PLANERS, RECLAIMERS, PAVERS, SPREADERS, GRADERS,

FRONT-END LOADERS (3YDS & OVER), VACUUM TRUCK,

DRILL/BORING MACHINE OPERATORS, VERMEER SAW, WATER

BLASTER, HYDRAULIC-DEMOLITION ROBOT, ROSS CARRIERS,

CONCRETE PUMP OPERATORS, ASPHALT/MATERIAL TRANSFER

MACHINES, ROTATING TELEHANDLERS, SPMT TYPE

EQUIPMENT

A. FOOTNOTE: A.

ANY EMPLOYEE WHO WORKS THREE DAYS IN THE WEEK IN

WHICH A HOLIDAY FALLS SHALL BE PAID FOR THE

HOLIDAY. B. PAID HOLIDAYS: NEW YEAR'S DAY,

PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH, VICTORY

DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY....................$ 44.45 29.95

POWER EQUIPMENT OPERATOR: HIGHWAY CONSTRUCTION

PROJECTS; WATER AND SEWERLINE PROJECTS WHICH ARE

INCIDENTAL TO HIGHWAY CONSTRUCTION PROJECTS; AND

BRIDGE PROJECTS THAT DO NOT SPAN WATER: GROUP 1

CRANES, PILE DRIVERS, LIGHTERS, BOOM TRUCKS,

HOISTS, DERRICKS

A. FOOTNOTE: A. ANY EMPLOYEE WHO WORKS THREE

DAYS IN THE WEEK IN WHICH A HOLIDAY FALLS SHALL BE

PAID FOR THE HOLIDAY. B. PAID HOLIDAYS: NEW YEAR'S

DAY, PRESIDENT'S DAY, MEMORIAL DAY, JULY FOURTH,

VICTORY DAY, LABOR DAY, COLUMBUS DAY, VETERANS DAY,

THANKSGIVING DAY & CHRISTMAS DAY....................$ 46.45 29.95

IRON0037-001 09/16/2025

IRONWORKER..........................................$ 43.03 33.53

LABO0271-001 12/03/2023

LABORER GROUP 5 (BUILDING CONSTRUCTION).............$ 39.00 26.90

LABORER GROUP 4 (BUILDING CONSTRUCTION).............$ 37.00 26.90

LABORER GROUP 3 (BUILDING CONSTRUCTION).............$ 37.00 26.90

LABORER GROUP 2 (BUILDING CONSTRUCTION).............$ 37.00 26.90

LABORER GROUP 1 (BUILDING CONSTRUCTION).............$ 37.00 26.90

LABO0271-002 11/27/2022

LABORER TEST BORING LABORER.........................$ 41.95 24.15

LABORER TEST BORING DRILLER.........................$ 41.95 24.15

LABORER OPEN AIR CAISSON, UNDERPINNING WORK AND

BORING CREW TOP MAN & LABORER...................$ 35.60 24.15

LABORER OPEN AIR CAISSON, UNDERPINNING WORK AND

BORING CREW BOTTOM MAN..............................$ 41.50 24.15

LABORER FREE AIR GROUP 3............................$ 42.45 24.15

LABORER FREE AIR GROUP 2............................$ 45.00 24.15

LABORER FREE AIR GROUP 1............................$ 46.00 24.15

LABORER COMPRESSED AIR GROUP 3......................$ 42.45 24.15

LABORER COMPRESSED AIR GROUP 2......................$ 52.93 24.15

LABORER COMPRESSED AIR GROUP 1......................$ 55.40 24.15

PAIN0011-005 06/01/2025

Rates Fringes

PAINTER (SPRAY, SAND & WATER BLASTING)..............$ 42.57 26.60

PAINTER (EPOXY, TANKS, TOWERS, SWING STAGE &

STRUCTURAL STEEL)...................................$ 41.57 26.60

PAINTER (BRUSH AND ROLLER)..........................$ 39.57 26.60

PAIN0011-006 06/01/2024

GLAZIER FOOTNOTES: SWING STAGE: $1.00 PER

HOUR ADDITIONAL. PAID HOLIDAYS: LABOR DAY &

CHRISTMAS DAY.......................................$ 41.63 26.15

PAIN0011-011 06/01/2024

PAINTER (BRIDGE WORK)...............................$ 57.85 26.40

PAIN0035-008 06/01/2011

SIGN PAINTER........................................$ 24.79 13.72

PLAS0040-001 01/01/2025

CEMENT MASON/CONCRETE FINISHER (BUILDING

CONSTRUCTION) FOOTNOTE: CEMENT MASON: WORK ON

FREE SWINGING SCAFFOLDS UNDER 3 PLANKS WIDTH AND

WHICH IS 20 OR MORE FEET ABOVE GROUND AND ANY

OFFSET STRUCTURE: $.30 PER HOUR ADDITIONAL..........$ 44.75 29.10

PLAS0040-002 01/01/2025

CEMENT MASON/CONCRETE FINISHER (HEAVY AND HIGHWAY

CONSTRUCTION).......................................$ 44.75 29.10

PLAS0040-003 01/01/2025

PLASTERER...........................................$ 45.52 29.43

PLUM0051-002 08/25/2025

PLUMBERS AND PIPEFITTERS............................$ 54.34 34.50

ROOF0033-004 12/01/2025

ROOFER..............................................$ 47.49 31.44

SFRI0669-001 04/01/2025

SPRINKLER FITTER....................................$ 53.76 33.44

SHEE0017-002 06/01/2025

SHEET METAL WORKER..................................$ 44.42 41.94

TEAM0251-001 05/01/2025

TRUCK DRIVER: HEAVY AND HIGHWAY CONSTRUCTION: GROUP

5 FOUR- AND FIVE-AXLE EQUIPMENT

FOOTNOTES:

A. PAID HOLIDAYS: NEW YEAR'S DAY, MEMORIAL DAY,

INDEPENDENCE DAY, LABOR DAY, THANKSGIVING DAY AND

CHRISTMAS DAY, PLUS PRESIDENTS' DAY, COLUMBUS DAY,

VETERAN'S DAY & V-J DAY, PROVIDING THE EMPLOYEE HAS

WORKED AT LEAST ONE DAY IN THE CALENDAR WEEK IN

WHICH THE HOLIDAY FALLS. B. EMPLOYEE WHO HAS

BEEN ON THE PAYROLL FOR 1 YEAR OR MORE BUT LESS

THAN 5 YEARS AND HAS WORKED 150 DAYS DURING THE

LAST YEAR OF EMPLOYMENT SHALL RECEIVE 1 WEEK'S PAID

VACATION; 5 TO 10 YEARS - 2 WEEKS' PAID VACATION;

10 OR MORE YEARS - 3 WEEK'S PAID VACATION. C.

EMPLOYEES ON THE SENIORITY LIST SHALL BE PAID A ONE

HUNDRED DOLLAR ($100.00) BONUS FOR EVERY FOUR

HUNDRED (400) HOURS WORKED, UP TO A MAXIMUM OF FIVE

HUNDRED DOLLARS ($500.00) ALL DRIVERS WORKING ON A

DEFINED HAZARD MATERIAL JOB SITE SHALL BE PAID A

PREMIUM OF $2.00 PER HOUR OVER APPLICABLE RATE.

........................................$ 32.21 34.51

10 TRACTOR TRAILER

FOOTNOTES: A. PAID HOLIDAYS: NEW YEAR'S DAY,

MEMORIAL DAY, INDEPENDENCE DAY, LABOR DAY,

THANKSGIVING DAY AND CHRISTMAS DAY, PLUS

PRESIDENTS' DAY, COLUMBUS DAY, VETERAN'S DAY & V-J

DAY, PROVIDING THE EMPLOYEE HAS WORKED AT LEAST ONE

DAY IN THE CALENDAR WEEK IN WHICH THE HOLIDAY

FALLS. B. EMPLOYEE WHO HAS BEEN ON THE PAYROLL

FOR 1 YEAR OR MORE BUT LESS THAN 5 YEARS AND HAS

WORKED 150 DAYS DURING THE LAST YEAR OF EMPLOYMENT

SHALL RECEIVE 1 WEEK'S PAID VACATION; 5 TO 10 YEARS

- 2 WEEKS' PAID VACATION; 10 OR MORE YEARS - 3

WEEK'S PAID VACATION. C. EMPLOYEES ON THE

SENIORITY LIST SHALL BE PAID A ONE HUNDRED DOLLAR

($100.00) BONUS FOR EVERY FOUR HUNDRED (400) HOURS

WORKED, UP TO A MAXIMUM OF FIVE HUNDRED DOLLARS

($500.00) ALL DRIVERS WORKING ON A DEFINED HAZARD

MATERIAL JOB SITE SHALL BE PAID A PREMIUM OF $2.00

PER HOUR OVER APPLICABLE RATE. .....$ 32.36 34.51

9 SPECIAL EARTH-MOVING EQUIPMENT, 35 TONS OR OVER

THANKSGIVING DAY AND CHRISTMAS DAY, PLUS

PRESIDENTS' DAY, COLUMBUS DAY, VETERAN'S DAY & V-J

DAY, PROVIDING THE EMPLOYEE HAS WORKED AT LEAST ONE

DAY IN THE CALENDAR WEEK IN WHICH THE HOLIDAY

FALLS. B. EMPLOYEE WHO HAS BEEN ON THE PAYROLL

FOR 1 YEAR OR MORE BUT LESS THAN 5 YEARS AND HAS

WORKED 150 DAYS DURING THE LAST YEAR OF EMPLOYMENT

SHALL RECEIVE 1 WEEK'S PAID VACATION; 5 TO 10 YEARS

- 2 WEEKS' PAID VACATION; 10 OR MORE YEARS - 3

WEEK'S PAID VACATION. C. EMPLOYEES ON THE

SENIORITY LIST SHALL BE PAID A ONE HUNDRED DOLLAR

($100.00) BONUS FOR EVERY FOUR HUNDRED (400) HOURS

WORKED, UP TO A MAXIMUM OF FIVE HUNDRED DOLLARS

($500.00) ALL DRIVERS WORKING ON A DEFINED HAZARD

MATERIAL JOB SITE SHALL BE PAID A PREMIUM OF $2.00

PER HOUR OVER APPLICABLE RATE. .....$ 32.56 34.51

8 SPECIAL EARTH-MOVING EQUIPMENT, UNDER 35 TONS

FOOTNOTES: A. PAID HOLIDAYS: NEW

YEAR'S DAY, MEMORIAL DAY, INDEPENDENCE DAY, LABOR

DAY, THANKSGIVING DAY AND CHRISTMAS DAY, PLUS

PRESIDENTS' DAY, COLUMBUS DAY, VETERAN'S DAY & V-J

DAY, PROVIDING THE EMPLOYEE HAS WORKED AT LEAST ONE

DAY IN THE CALENDAR WEEK IN WHICH THE HOLIDAY

FALLS. B. EMPLOYEE WHO HAS BEEN ON THE PAYROLL

FOR 1 YEAR OR MORE BUT LESS THAN 5 YEARS AND HAS

WORKED 150 DAYS DURING THE LAST YEAR OF EMPLOYMENT

SHALL RECEIVE 1 WEEK'S PAID VACATION; 5 TO 10 YEARS

- 2 WEEKS' PAID VACATION; 10 OR MORE YEARS - 3

WEEK'S PAID VACATION. C. EMPLOYEES ON THE

SENIORITY LIST SHALL BE PAID A ONE HUNDRED DOLLAR

($100.00) BONUS FOR EVERY FOUR HUNDRED (400) HOURS

WORKED, UP TO A MAXIMUM OF FIVE HUNDRED DOLLARS

($500.00) ALL DRIVERS WORKING ON A DEFINED HAZARD

MATERIAL JOB SITE SHALL BE PAID A PREMIUM OF $2.00

PER HOUR OVER APPLICABLE RATE. .....$ 32.31 34.51

TRUCK DRIVER: HEAVY AND HIGHWAY CONSTRUCTION: GROUP

7 TRAILERS WHEN USED ON A DOUBLE HOOK UP (PULLING

2 TRAILERS)

FOOTNOTES: A. PAID

HOLIDAYS: NEW YEAR'S DAY, MEMORIAL DAY,

INDEPENDENCE DAY, LABOR DAY, THANKSGIVING DAY AND

CHRISTMAS DAY, PLUS PRESIDENTS' DAY, COLUMBUS DAY,

VETERAN'S DAY & V-J DAY, PROVIDING THE EMPLOYEE HAS

WORKED AT LEAST ONE DAY IN THE CALENDAR WEEK IN

WHICH THE HOLIDAY FALLS. B. EMPLOYEE WHO HAS

BEEN ON THE PAYROLL FOR 1 YEAR OR MORE BUT LESS

THAN 5 YEARS AND HAS WORKED 150 DAYS DURING THE

LAST YEAR OF EMPLOYMENT SHALL RECEIVE 1 WEEK'S PAID

VACATION; 5 TO 10 YEARS - 2 WEEKS' PAID VACATION;

10 OR MORE YEARS - 3 WEEK'S PAID VACATION. C.

EMPLOYEES ON THE SENIORITY LIST SHALL BE PAID A ONE

HUNDRED DOLLAR ($100.00) BONUS FOR EVERY FOUR

HUNDRED (400) HOURS WORKED, UP TO A MAXIMUM OF FIVE

HUNDRED DOLLARS ($500.00) ALL DRIVERS WORKING ON A

DEFINED HAZARD MATERIAL JOB SITE SHALL BE PAID A

PREMIUM OF $2.00 PER HOUR OVER APPLICABLE RATE.

........................................$ 32.81 34.51

6 LOW-BED OR BOOM TRAILER.

THANKSGIVING DAY AND CHRISTMAS DAY, PLUS

PRESIDENTS' DAY, COLUMBUS DAY, VETERAN'S DAY & V-J

DAY, PROVIDING THE EMPLOYEE HAS WORKED AT LEAST ONE

DAY IN THE CALENDAR WEEK IN WHICH THE HOLIDAY

FALLS. B. EMPLOYEE WHO HAS BEEN ON THE PAYROLL

FOR 1 YEAR OR MORE BUT LESS THAN 5 YEARS AND HAS

WORKED 150 DAYS DURING THE LAST YEAR OF EMPLOYMENT

SHALL RECEIVE 1 WEEK'S PAID VACATION; 5 TO 10 YEARS

- 2 WEEKS' PAID VACATION; 10 OR MORE YEARS - 3

WEEK'S PAID VACATION. C. EMPLOYEES ON THE

SENIORITY LIST SHALL BE PAID A ONE HUNDRED DOLLAR

($100.00) BONUS FOR EVERY FOUR HUNDRED (400) HOURS

WORKED, UP TO A MAXIMUM OF FIVE HUNDRED DOLLARS

($500.00) ALL DRIVERS WORKING ON A DEFINED HAZARD

MATERIAL JOB SITE SHALL BE PAID A PREMIUM OF $2.00

PER HOUR OVER APPLICABLE RATE. .....$ 32.61 34.51

4 THREE-AXLE DUMP TRUCK

THANKSGIVING DAY AND CHRISTMAS DAY, PLUS

PRESIDENTS' DAY, COLUMBUS DAY, VETERAN'S DAY & V-J

DAY, PROVIDING THE EMPLOYEE HAS WORKED AT LEAST ONE

DAY IN THE CALENDAR WEEK IN WHICH THE HOLIDAY

FALLS. B. EMPLOYEE WHO HAS BEEN ON THE PAYROLL

FOR 1 YEAR OR MORE BUT LESS THAN 5 YEARS AND HAS

WORKED 150 DAYS DURING THE LAST YEAR OF EMPLOYMENT

SHALL RECEIVE 1 WEEK'S PAID VACATION; 5 TO 10 YEARS

- 2 WEEKS' PAID VACATION; 10 OR MORE YEARS - 3

WEEK'S PAID VACATION. C. EMPLOYEES ON THE

SENIORITY LIST SHALL BE PAID A ONE HUNDRED DOLLAR

($100.00) BONUS FOR EVERY FOUR HUNDRED (400) HOURS

WORKED, UP TO A MAXIMUM OF…