Archico Design Build Burnett Library Bid Package SIGNED~1_Redacted.pdf
PDF 3 MB Posted
- Solicitation number
- PW-24-454
- Issued by
- California
About this file
This is a bid package from the City of Long Beach Department of Public Works for the Burnett Library Energy Efficiency Upgrade project (R-7234). The project encompasses selective demolition of roofing, wood division work, thermal and moisture protection including roofing and sheet metal flashing, plumbing, mechanical packaged roof-top air-conditioning units, and electrical identification systems. The bid opening was scheduled for July 1, 2024, at 10:00 a.m. A mandatory pre-bid conference was conducted online via Microsoft Teams on June 13, 2024, at 9:30 a.m., with an in-person job-site walk-through at 560 E Hill Street, Long Beach, California at 11:30 a.m. that same date. The contract is for the City of Long Beach, a municipal corporation in Los Angeles County, California. The base bid total is $1,719,000.00, consisting of seven line items including mobilization/demobilization capped at 5% of the subtotal of items 1-6.
Archico Design Build Inc., a California corporation incorporated on October 13, 2016, submitted the bid as the prime contractor with a certified Small Business (SB) certification number 2011697. The bidder identified five subcontractors: ACCO Engineered Systems for HVAC and mechanical/plumbing work valued at $296,000; W.S. Klem Contractor for framing at $36,700; Best Contracting Services, Inc. for thermal moisture protection roofing at $347,200; Troy's Ornamental Iron Craft, Inc. for miscellaneous metal at $40,000; and Reyes & Sons Electric Co. for electrical work at $50,000. The bidder submitted standard certifications including workers' compensation insurance, non-collusion declaration, debarment and suspension certification, Equal Benefits Ordinance compliance, and Iran Contracting Act compliance. The contractor's average annual construction work value over the past five years was $48,192,157.00, with current work in progress valued at $8,388,888.
View the file
Other files
Show all 11
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
BIDDER'S NAME: _Archico Design Build Inc.
ITEM
NO.
ITEM DESCRIPTION
ESTIMATED
QUANTITY
UNIT
UNIT PRICE
(IN
FIGURES)
ITEM
TOTAL
(IN
FIGURES)
1. Division 2 – Existing
Conditions
Selective Demolition -
Roofing
1 LS $100,267.36 $100,267.36
2. Division 6 – Wood 1 LS $171,000.00 $171,000.00
3. Division 7 – Thermal and
Moisture Protection
Roofing, Sheet Metal
Flashing
1 LS $659,680.00 $659,680.00
4. Division 22 - Plumbing 1 LS $132,615.00 $132,615.00
5. Division 23 – Mechanical
Packaged, Roof Top Air-
Conditioning Units
1 LS $437,704.90 $437,704.90
6. Division 26 – Electrical
Identification for Electrical
Systems
1 LS $143,224.20 $143,224.20
7. Mobilization/Demobilizati on (No more than 5% of subtotal of 1-6 above)
1 LS $74,508.54 $74,508.54
Department of Public Works R-7234
City of Long Beach
BID TO THE CITY OF LONG BEACH
BASE BID – BURNETT LIBRARY ENERGENCY EFFIENCY UPGRADE
BURNETT LIBRARY ENERGY EFFICIENCY UPGRADE
BASE BID TOTAL $1,719,000.00
DO NOT SUBMIT THIS FORM AS YOUR BID. BIDS ARE TO BE SUBMITTED
ELECTRONICALLY AS DESCRIBED IN DIVISION B.
In accordance with the Notice Inviting Bids for this Work in the City of Long Beach, California, to be opened on July 1st, 2024, at 10:00 a.m., we offer to furnish all necessary labor, tools, materials, appliances and equipment for and perform all Work mentioned in the Notice Inviting
Bids, in full compliance with Plans (Drawings Set No. B-4803) and Specifications No.
3005010123 (R-7234) at the prices listed below.
We certify that we have examined the site and that the Bid is complete. By signing the Bid, we certify that the Contractor will not submit a claim based on failure to examine the site thoroughly.
The base bid total shall be used for determining the lowest bidder.
Division C - Bid DocumentsC-1
ACCO Engineered Systems HVAC
215 McCormick Ave.
Costa Mesa, CA
(949)205-9511
Mechanical / Plumbing
296,000.00
1000000546
Framing
36,700.00
W.S. Klem Contractor
5405 E. La Palma Ave.
Anaheim, CA
(310)414-0455
735376 1000009829
Best Contracting Services, Inc. Thermal Moisture Protection Roofing
347,200.00
19027 Shamilton Ave.
Gardena, CA 90248
456263
(310)308-6969
120696
Troy's Ornamental Iron Craft, Inc.
Stanton, CA
(949)587-9604
945177
Misc. Metal
40,000.00
1000412581
8150 Eletric Ave.
Reyes & Sons Electric Co.
12939 Arroyo St.
Sylmar, CA 91342
817091
(8158)365-2030
Electrical
50,000.00
1000003506
3. FINANCIAL RESOURCES
3.1 In the past five years, has a bonding company completed a contract on your behalf, or paid for completion because your firm was terminated or found in default? ________________________________________________________
4. EXPERIENCE
4.1 List classifications of work your organization typically performs with its own forces.
4.2 Claims and Suits (If the answer to any of the questions below is yes, please attach specifics.)
4.2.1 Has your organization ever failed to complete any work awarded to it?
4.2.2 Are there any judgments, claims, suits or arbitration proceedings pending against your organization or its officers within the last five (5) years, or such actions related to labor compliance, prevailing wages, or the Department of Industrial Relations within said period?
4.2.3 Has your organization filed any law suits or requested arbitration related to construction within the last five (5) years?
4.3 Has your firm, or any firm with which any of your company’s owners, officers, partners, or employees was associated, been debarred from bidding on, accepting, or performing any government agency or public works project(s), either as a prime contractor or subcontractor? ___________________________________________________
4.4 On a separate sheet, list major construction projects your organization has in progress.
Indicate name of the project, project description, Contract amount, owner, architect/engineer, percent complete and scheduled completion.
4.4.1 Indicate total value of work in progress and under Contract:
4.5 On a separate sheet, list all projects your organization has completed in the past five years. Indicate name of project, project description, Contract amount, owner, owner's phone number, project manager, completion date, and percentage of the cost of the work performed with your own forces. (’None’, ‘N/A’ or its equivalent is not an acceptable response and will be a basis for disqualifying your bid as non-responsive.)
4.5.1 Indicate average annual value of construction work performed during the past five years:
No
No
No
No
No
Construction Management, Labor, Purchasing
Please see attached
Please see attached
$8,388,888
$48,192,157.00
Archico Design Build Inc In Progree Project List
Project Name
Project Description
Contract Amount Including
Change Orders
Owner Architect Engineer
Complete
Scheduled Completion
Collection Yard Relocation and Warehouse Demolition
New Collections Yard Building and Warehouse Demolition including utilities
6,500,000.00$ Orange County Sanitation District
(OCSAN)
Project Line Technical Services
60% 9/21/2024
El Segundo Unified School District District Office Site Work
Alterations to xisting parking lot walkways including sloped walks covered walkways and ramps and irectional signage
1,888,888.00$ El Segundo USD PBK Architects 1% 9/26/2024
Project References
Project # :
Performed as:
Office Location:
Project Name:
Project Location:
Phone: Email:
Phone: Email:
Phone: Email:
Phone: Email:
Yes No
No
Architect / Engineer:
Owner:
Owner Contact Name:
Inspector Of Record:
Actual Final Completion Date:
Construction Manager :
Liquidated Damages or Back Charges:
Project Description:
Final Contract Amount:
Original Contract Amount Awarded:
Original Final Completion Date:
Scope of Work:
YesDSA Project:
General Contractor
2010 N Tustin Ave Santa Ana CA 92705
Katella Range Facility Upgrade
1900 W Katella Ave, Orange Ca 92867
County of Orange - Orange County Sheriff Department
Robert Bingham
949-251-0702 Rbingham@joagroup.com
Demolition of existing outdoor shooting range and build a new fully enclosed shooting range, relocate the existing kennel enclosure, and add new shooting range storage rooms along the North and South walls. Interior work in Existing building to include relocation of existing lobby counter, 2 storage access vestibules, conversion of storage to new weapons cleaning room and addition of small employee break room.
New Building
7,146,000.00
HMC Architects - Steven Kiss
630-730-8355 steven.kiss@hmcarchitects.com
18015
JOA Group - Bob Bingham
949-378-2014
8/22/2023
10,983,245.31 rbingham@joagroup.com
Djan Chandra
949-250-1421 dchandra@leightongroup.com
X
4/27/2022 adjusted to 8/28/2023 with added scopes
Project # :
Performed as:
Office Location:
Project Name:
Project Location:
Phone: Email:
Phone: Email:
Phone: Email:
Phone: Email:
Yes No
No
Architect / Engineer:
Owner:
Owner Contact Name:
Inspector Of Record:
Actual Final Completion Date:
Construction Manager :
Project Description:
Original Contract Amount Awarded:
Original Final Completion Date:
Scope of Work:
DSA Project:
General Contractor
2010 N Tustin Ave Santa Ana CA 92705
Lincoln Middle School HVAC Project
1501 California Ave Santa Monica CA 90403
Santa Monica Malibu Unified School District
7,844,000.00
Building Modernization School modernization including HVAC, electrical and plumbing improvements, replacement of campus wide fire alarm system & all other associated improvements per construction documents
Gafcon Inc - Eric Brooks
Rachlin Partners - Rudy Monico
310-204-3400 rmonico@rachlinpartners.com
21.05.SMS
9/17/2022
X Yes
Matt Rafi mattael2021@gmail.com
Final Contract Amount: 92%
Liquidated Damages or Back Charges:
310-980-2217
9,261,968.78
8/12/2022
Kevin Klaus
310-279-3008 kklaus@smmusd.org
818-749-5577 ebrooks06@gmail.com
Project # :
Performed as:
Office Location:
Project Name:
Project Location:
Phone: Email:
Phone: Email:
Phone: Email:
Phone: Email:
Yes No
No
Architect / Engineer:
Owner:
Owner Contact Name:
Inspector Of Record:
Actual Final Completion Date:
Construction Manager :
Project Description:
Original Final Completion Date:
Scope of Work:
General Contractor
1835 W. Orangewood Ave. Suite 325 Orange, CA 92868
Liquidated Damages or Back Charges:
C56872C1142
Josie Mellen
213-922-1105 mellenj@metro.net
818-484-4446 famelegacy@famelegacy.com
626-405-8001
435 E 208th Street Long Beach CA 90810 & 14724 Aviation Blvd Lawndale CA 90260
Robert Fahim
Design Build Roofing & HVAC Project - Provide the architectural, structural, electrical, and mechanical design and construction services for roof and HVAC replacement at LA Metro divisions 11 and divisions 22.The scope of work includes asbestos abatement, demolition, install new insulation underneath a new thermoplastic polyolefin roofing membrane (TPO) sheet roofing system. Also included Installation of all new mechanical, electrical, and plumbing items, and control system. Install new fall protection devices around all new replacement skylights, new permanent parapet guard railings and surface mounted access ladders.
8/14/2020 with added scope adjusted to 12/11/2021
Original Contract Amount Awarded: $6,381,000.00
Final Contract Amount: 8,390,744.00
213-922-4797
12/10/2021
X
XDSA Project: Yes
Metro Divisions 11 and 22 Roof Replacement
Los Angeles County Metropolitan Transportation Authority (LACMTA)
Onyx Architiect Steve Kuchenski
Raul Pedroza skuchenski@onyxarchitects.com
PedrozaR@metro.net
Project # :
Performed as:
Office Location:
Project Name:
Project Location:
Phone: Email:
Phone: Email:
Phone: Email:
Phone: Email:
Yes No
No
Architect / Engineer:
Owner:
Owner Contact Name:
Inspector Of Record:
Actual Final Completion Date:
Construction Manager :
Liquidated Damages or Back Charges:
Project Description:
Final Contract Amount:
Original Contract Amount Awarded:
Original Final Completion Date:
Scope of Work:
DSA Project:
General Contractor
21.18.SMS
2010 N Tustin Ave Santa Ana CA 92705
Lincoln Middle School Building G & K Modernization
1501 California Ave Santa Monica CA 90403
Santa Monica Malibu Unified School District
Rachlin Partners - Rudy Monico
310-204-3400 rmonico@rachlinpartners.com
Tenant Improvement Building G - 1 story classroom building, replace, flooring window, paint walls, replace doors, replace ceiling tiles.
Building K - 2 story building renovation on 1st floor only, replace, flooring window, paint walls, replace doors, replace ceiling tiles, remove & replace gutters, remodel storage rooms 311B & 314A, remodel classroom 312 to add breakout room, remodel Janitor 314B to staff accessible toilet, additional special needs shower in room 314D
9/7/2021
8/7/2021
499,000.00
Yes
Chris Emmett cemmett@smmusd.org mattael2021@gmail.com
Matt Rafi
548,500.00
310-980-2217
310-450-8338
Kevin Klaus
310-279-3008 kklaus@smmusd.org
Project # :
Performed as:
Office Location:
Project Name:
Project Location:
Phone: Email:
Phone: Email:
Phone: Email:
Phone: Email:
Yes No
No
Architect / Engineer:
Owner:
Owner Contact Name:
Inspector Of Record:
Construction Manager :
Project Description:
Original Final Completion Date:
Scope of Work:
Liquidated Damages or Back Charges:
General Contractor
1835 W. Orangewood Ave. Suite 325 Orange, CA 92868
F793
Katella Avenue Widening Of the Fourth Eastbound Lane Adjacent to the Convention Center to Hotel Way
Katella Avenue, From 922' east of Disneyland Drive to Hotel Way in Anaheim, California
City of Anaheim
Joel Jordan
714-231-8368 jjordan@anaheim.net
Joel Jordan
714-231-8368 jjordan@anaheim.net
4/31/2021
Original Contract Amount Awarded:
Final Contract Amount:
2,149,649.00
Actual Final Completion Date: 4/31/2021
Tim Flint
X
949-254-7954 tflint@ghirardelliassoc.com
Road Expansion - Widening and constructing an additional travel lane and bus turnout along the convention center frontage removal and reconstruction of curb and gutter, fixed, lighted, and retractable bollards, landscaped parkway with trees, concrete sidewalk, concrete pavers, driveway, streetlights, replacement of traffic striping to accommodate the additional travel lane, two fiber optic connected changeable message signs in the median, modifications to a motorized gate and all additional work necessary to properly construct the proposed improvements
2,358,335.57
X
Joe Buckner
949-428-1500 jbuckner@ardurra.com
YesDSA Project:
4/30/2021
4/30/2021
Project # :
Performed as:
Office Location:
Project Name:
Project Location:
Phone: Email:
Phone: Email:
Phone: Email:
Phone: Email:
Yes No
No
Architect / Engineer:
Owner:
Owner Contact Name:
Inspector Of Record:
Actual Final Completion Date:
Construction Manager :
Project Description:
Original Contract Amount Awarded:
Original Final Completion Date:
Scope of Work:
General Contractor
1835 W. Orangewood Ave. Suite 325 Orange, CA 92868
04-119162
Walker Elementary School Interim Housing Project
811 E Bishop Street Santa Ana CA 92701
Santa Ana Unified School District
Jeremy Cogan
714-480-5359 jeremy.cogan@sausd.us
Morrissey Associates Inc / Tom Morrissey
714-836-6137 tmorrissey@morrisseyal.com
Tilden-Coil Constructors / David Joseph
909-376-1462 DJoseph@tilden-coil.com
7/24/2020
7/24/2020
823,625.00
Bill Priest
714-812-4859 wmpriest@att.net
Final Contract Amount:
Liquidated Damages or Back Charges:
DSA Project:
Site prep for installation of new modular classrooms & restroom, along with all associated utilities & related site work.
Site Improvements & Utility Relocation
864,015.69
Reference Letter Attached
Yes
Project # :
Performed as:
Office Location:
Project Name:
Project Location:
Phone: Email:
Phone: Email:
Phone: Email:
Phone: Email:
Yes No
No
Architect / Engineer:
Owner:
Owner Contact Name:
Inspector Of Record:
Actual Final Completion Date:
Construction Manager :
Project Description:
Final Contract Amount:
Original Contract Amount Awarded:
Original Final Completion Date:
Scope of Work:
Liquidated Damages or Back Charges:
DSA Project:
General Contractor
1835 W. Orangewood Ave. Suite 325 Orange, CA 92868
$1,237,253.00
1,331,092.25
5/15/2020
6/2/2020
Steel Materials Storage Structure at Prima Deshecha Landfill
MA-299-19011462
949-728-3042
Ryan Wilson
909-655-3209 ryan.wilson@tetratech.com
562-243-2125 hal.arbogast@tetratech.com
The project is to design and install a new pre-engineered storage building (8,000 sq ft.). The scope of work includes clearing, grubbing, excavation, unclassified fill, asphalt concrete (AC) paving, striping, stenciling, signage, building permitting and construction including a building protection system, building foundations, pre-engineered metal storage building design, permitting and installation of a fire suppression system, electrical and firewater supply, drainage improvements.
New Pre-Fabricated Metal Building & Sitework Construction
909-860-7777
Tetra Tech - Hal Arbogast
Yes
X
X
32250 Avenida La Pata Ave San Juan Capistrano CA 92675
County of Orange
Tetra Tech Bas info@tetratech.com
Kevin Oxford kevin.oxford@ocwr.ocgov.com
Project # :
Performed as:
Office Location:
Project Name:
Project Location:
Phone: Email:
Phone: Email:
Phone: Email:
Phone: Email:
Yes No
No
Architect / Engineer:
Owner:
Owner Contact Name:
Inspector Of Record:
Actual Final Completion Date:
Construction Manager :
Project Description:
Final Contract Amount:
Original Contract Amount Awarded:
Original Final Completion Date:
Scope of Work:
General Contractor
1835 W. Orangewood Ave. Suite 325 Orange, CA 92868
Woodworth-Monroe TK5 Modular Classroom Project
10711 S 10th Ave Inglewood CA 90301
Inglewood Unified School District
Steven Ross
909-331-8258 sross@cordobacorp.com
Lionakis - Steven Kendrick
949-955-1919 steven.kendrick@lionakis.com
Steven Ross
909-331-8258 sross@cordobacorp.com
1/15/2020
1/5/2020
5,989,000.00
6,144,960.03
XLiquidated Damages or Back Charges:
DSA Project:
C18.19.046
Galil Tadros
818-486-7907 galilt@aol.com
Installation of concrete foundations for (4) modular that will house classrooms, resource rooms, workrooms, custodial room, restrooms, and IDF., new utility lines, new parking lot, hardscape and landscape. Work will also be coordinated with installation of PC approved shade structures and play structures.
Site Improvements & Underground Utilities
X Yes
Project # :
Performed as:
Office Location:
Project Name:
Project Location:
Phone: Email:
Phone: Email:
Phone: Email:
Phone: Email:
Yes No
No
Architect / Engineer:
Owner:
Owner Contact Name:
Inspector Of Record:
Actual Final Completion Date:
Construction Manager :
Project Description:
Final Contract Amount:
Original Contract Amount Awarded:
Original Final Completion Date:
Scope of Work:
Liquidated Damages or Back Charges:
DSA Project:
General Contractor
1835 W. Orangewood Ave. Suite 325 Orange, CA 92868
1,738,000.00
9/19/2019 with CO to 1/5/2020
12/30/2019
X
X
Woodcrest Park Renovation
440 W Orangethorpe Ave Fullerton CA 92832
54023
City of Fullerton
David Grantham
714-738-6853 david.grantham@cityoffullerton.com
BGB Design Group - Art Guy
714-545-2898 art@bgb-inc.com
David Grantham
714-738-6853 david.grantham@cityoffullerton.com
Elias Capelle ecapelle@ci.fullerton.ca.us657-248-5141
1,976,795.88
Park Renovation - Various renovated and new park improvements, including demolition of existing restroom, total lot area, selected walkways and fencing, selected picnic tables and planters, clearing and grubbing of all specified turf and landscape material, and hauling and disposing of all demolished materials. New work shall include miscellaneous concrete installation, new restroom, exercise area and equipment installation, play areas and equipment installation, basketball courts, benches, picnic tables, shade structures, masonry planters and low walls, “urban street scene” [road pavement refurbishment, skateboard elements, painted street graphics, fencing, decomposed granite surfacing, landscaping, irrigation, lighting, and all related work shown on plans.
Yes
Project # :
Performed as:
Office Location:
Project Name:
Project Location:
Owner:
Phone: Email:
Phone: Email:
Phone: Email:
Phone: Email:
Yes No
No
Architect / Engineer:
Owner Contact Name:
Inspector Of Record:
Construction Manager :
Liquidated Damages or Back Charges:
Project Description:
Final Contract Amount:
Original Contract Amount Awarded:
Original Final Completion Date:
Scope of Work:
TVUSD District Office Conference Center Renovation
31350 Rancho Vista Road Temecula, CA 92592
Temecula Valley Unified School District
Janet Dixon
951-676-2661 jdixon@tvusd.us
MGPA Architecture, Inc Fred Gualda
760-473-9809 fgualda@mgpaia.com
Janet Dixon
951-676-2661 jdixon@tvusd.us
$1,385,000.00
Actual Final Completion Date: 2/8/2019
2/8/2019
2018-19-101
General Contractor
1835 W. Orangewood Ave. Suite 325 Orange, CA 92868
KT Services _ Kevin Lastrapes
626-523-5574
1,523,498.34
DSA Project:
kls12inspect@yahoo.com
Renovations and Upgrades for the District Conference Center / Board Room at the main district offices including replacement of ceilings, flooring, miscellaneous architectural upgrades, HVAC upgrades, folding partition walls, electrical, audio/visual equipment, and new ADA flatwork path-of-travel from street.
Tenant Improvement
YesX
Project # :
Performed as:
Office Location:
Project Name:
Project Location:
Owner:
Phone: Email:
Phone: Email:
Phone: Email:
Phone: Email:
Yes No
No
Architect / Engineer:
Owner Contact Name:
Inspector Of Record:
Actual Final Completion Date:
Construction Manager :
Liquidated Damages or Back Charges:
Project Description:
Final Contract Amount:
Original Contract Amount Awarded:
Original Final Completion Date:
Scope of Work:
Palm Springs Fire Station #4 Remodel and Expansion
1300 S Laverne Way, Palm Springs CA 92264
City of Palm Springs
Marcus Fuller
Marcus.Fuller@palmspringsca.gov760-323-8202
Marcus Fuller
760-323-8202 Marcus.Fuller@palmspringsca.gov
Marcus.Fuller@palmspringsca.gov760-323-8202
Work includes the renovation of the existing building to the Gym, Lockers and contamination area and building approximately 3,000 SF of new Fire station and all new site work and landscaping.
New Building & Tenant Improvements
$4,149,446.78
3/28/2019
4/16/2019
$3,975,000.00
X
X
1835 W. Orangewood Ave. Orange, CA 92868
General Contractor
CP 15-25
DSA Project:
760-323-8202 Marcus.Fuller@palmspringsca.gov
Marcus Fuller
Marcus Fuller
Project # :
Performed as:
Office Location:
Project Name:
Project Location:
Owner:
Phone: Email:
Phone: Email:
Phone: Email:
Phone: Email:
Yes No
No
Architect / Engineer:
Owner Contact Name:
Inspector Of Record:
Actual Final Completion Date:
Construction Manager :
Project Description:
Final Contract Amount:
Original Contract Amount Awarded:
Original Final Completion Date:
Scope of Work:
Liquidated Damages or Back Charges:
DSA Project:
GF339
General Contractor
2372 Morse Ave #307, Irvine, CA 92614
Fountain Valley Recreation Center Exterior Improvement
16400 Brookhurst St, Fountain Valley, CA 92708
City of Fountain Valley
Temo Galvez
Meyer and Associates
949-380-7016 None
John Wolitarsky 310-359-1203 949-339-9154 jwolitarsky@ardurra.com
Building Renovation
Remodel improvements to the exterior of the existing recreational center facility including replacement of the main entrance concrete slab and stucco, replacement of the doors, hardware, storefronts, curtain walls. Replacing sheet metal roof and painting the entire exterior of the building.
11/7/2018
11/7/2018
$ 599,599.00
$ 659,558.00
X
X temo.galvez@fountainvalley.org714-593-4517
Enedino Arroyos
760-792-8152 D-arroyos@hotmail.com
Project # :
Performed as:
Office Location:
Project Name:
Project Location:
Owner:
Phone: Email:
Phone: Email:
Phone: Email:
Phone: Email:
Yes No
No
Architect / Engineer:
Owner Contact Name:
Inspector Of Record:
Actual Final Completion Date:
Construction Manager :
Project Description:
Final Contract Amount:
Original Contract Amount Awarded:
Original Final Completion Date:
Scope of Work:
1133-18
General Contractor
1835 W. Orangewood Ave. Suite 325 Orange, CA 92868
Manhattan Beach Pier Utilities and Roundhouse Exterior Improvements
1 Manhattan Beach Blvd, Manhattan Beach, CA 90266
City of Manhattan Beach
Gilbert Gamboa
310-802-5356 ggamboa@citymb.info ggamboa@citymb.info
310-802-5356
Gilbert Gamboa
Nonzero Architecture - Peter Grueneisen peterg@nonzeroarch.com310-313-1000
Building and Utilities Renovation on a Landmark
Removal and replacement of pier utility runs. Installation of new life ring cabinets, emergency call box and fish cleaning sinks to pier deck. Rehabilitation and renovation of roundhouse building exterior.
05/29/2018
05/16/2018
$ 1,692,975.00
$ 1,862,431.41
X
X
Liquidated Damages or Back Charges:
DSA Project:
Fariba Yazdi
310-808-7409 fyazdi@thequantumconsulting.com
Project # :
Performed as:
Office Location:
Project Name:
Project Location:
Owner:
Phone: Email:
Phone: Email:
Phone: Email:
Phone: Email:
Yes No
No
Architect / Engineer:
Owner Contact Name:
Inspector Of Record:
Actual Final Completion Date:
Construction Manager :
Project Description:
Final Contract Amount:
Original Contract Amount Awarded:
Original Final Completion Date:
Scope of Work:
Werle Building Tenant Improvement
CIP 55-15/16-02
General Contractor
2372 Morse Ave #307, Irvine, CA 92614
626 N. Robertson Blvd West Hollywood, CA 90069
City of West Hollywood
Helen Collins
323-848-6895 Hcollins@weho.org
IDS Group - John Silber
949-387-8500 john.silber@idsgi.com
Helen Collins
323-848-6895 hcollins@weho.org
Tenant improvement of a 6,000 SF two-story building with addition of two-story meeting room and office area. We have seismic reinforced the entire existing building while maintaining the historic façade of the building without any damages. We have added an elevator to the building to bring it up to ADA codes and requirement. The project also included replacing entire mechanical, electrical and plumbing system and adding a security access control system, replacing the roof to comply with new TITLE 24 requirement and remodeling the entire building interiors. The exterior hardscape has also been remodeled and an entry canopy and a building signage monument to the building has been added.
Tenant Improvement & Addition
$ 2,418,000.00
8/15/17 with CO to 10/5/2017
9/27/17
$3,332,240.26
X
X
Liquidated Damages or Back Charges:
DSA Project:
Murray Armstrong
323-848-6872 marmstrong@weho.org
Project # :
Performed as:
Office Location:
Project Name:
Project Location:
Owner:
Phone: Email:
Phone: Email:
Phone: Email:
Phone: Email:
Yes No
No
Architect / Engineer:
Owner Contact Name:
Inspector Of Record:
Actual Final Completion Date:
Construction Manager :
Project Description:
Final Contract Amount:
Original Contract Amount Awarded:
Original Final Completion Date:
Scope of Work:
Chino II Desalter Phase 3 Expansion, Pre-Engineered metal Storage Building
CDAEXP3-13-12
General Contractor
2372 Morse Ave #307, Irvine, CA 92614
11251 Harrel St. Jurupa Valley, CA 91752
Chino Basin Desalter Authority
Vlad Burce
Vburce@butier.com949-375-1611
$ 949,000.00
$ 981,160.80
Tetra Tech - Ken Berard ken.berard@tetratech.com
Vlad Burce
949-375-1611 Vburce@butier.com
New Metal Building and Site Work
6/30/2017
6/30/2017
X
X
Design build a new metal storage building including earthwork, foundation and slab, new metal building, electrical, plumbing, HVAC, and underground utility.
Liquidated Damages or Back Charges:
DSA Project:
626-351-4664 909-305-2939
Kenneth Stiles
909-721-4865 kstiles@butier.com
Project # :
Performed as:
Office Location:
Project Name:
Project Location:
Owner:
Phone: Email:
Phone: Email:
Phone: Email:
Phone: Email:
Yes No
No
Architect / Engineer:
Owner Contact Name:
Inspector Of Record:
Actual Final Completion Date:
Construction Manager :
Project Description:
Final Contract Amount:
Original Contract Amount Awarded:
Original Final Completion Date:
Scope of Work:
Euclid & Sunkist Branch Library Renovation
1340 Euclid St, Anaheim, CA 92802 & 901 S. Sunkist St, Anaheim, CA 92806
City of Anaheim
Tasneem Watts
714-765-3625
Group 4 Architecture Gary Ching
650-871-0709 gching@g4arch.com
Tasneem Watts
714-765-3625
9/16/2016
8/20/2016
$ 999,999.00
$1,099,434.00
X
X
15460-01
General Contractor
2372 Morse Ave #307, Irvine, CA 92614
Liquidated Damages or Back Charges:
DSA Project:
P. John
714-765-5153 None
Building Remodel - Sunkist Library: Paint, Carpet , Limited Door Upgrade Replacement of Luminous Ceiling Lense, Acoustic Ceiling Tiles Interior Book Return, Wayfinding Signes Partitions Relocating existing power poles and associated conduits structural mechanical plumbing lighting electrical.
Euclid Library: Interior Renovation of the Existing Euclid Branch Library includes the renovation of restrooms, drinking fountains code upgrades interior book return interior windows replacing luminous ceiling lenses acoustic celing tiles in the public areas interior finishes and metal shelving.
Site work to renovating the accessible parking spaces and walkways to meet current code.
twatts@anaheim.net twatts@anaheim.net
Project # :
Performed as:
Office Location:
Project Name:
Project Location:
Owner:
Phone: Email:
Phone: Email:
Phone: Email:
Phone: Email:
Yes No
No
Architect / Engineer:
Owner Contact Name:
Inspector Of Record:
Actual Final Completion Date:
Construction Manager :
Project Description:
Final Contract Amount:
Original Contract Amount Awarded:
Original Final Completion Date:
Scope of Work:
Liquidated Damages or Back Charges:
DSA Project:
590-412-3131-9605
General Contractor
2372 Morse Ave, Ste 307 Irvine, CA 92614
400 E. Vermont Ave, Anaheim, CA 92804
Crew Quarters Rehabilitation for Public Work Operations
City of Anaheim
Dan Debassio
562-879-3602 ddebassio@anaheim.net
Border Architect
949-851-1317 info@bordersarchitects.com
Tim Flint
949-254-7954 tflint@ghirardelliassoc.com
City of Anaheim Crew Quarters Locker & Restroom complete renovation including demolition of the existing restroom lockers and building a new ADA bathroom and locker and painting the entire building interiors.
Tenant Improvement
$283,570.00
$310,156.90
08/31/2015
8/20/2015
X
X
Terry Alford
714-765-5153 talford@anaheim.net
Project # :
Performed as:
Office Location:
Project Name:
Project Location:
Owner:
Phone: Email:
Phone: Email:
Phone: Email:
Phone: Email:
Yes No
No
Architect / Engineer:
Owner Contact Name:
Inspector Of Record:
Construction Manager :
Project Description:
Final Contract Amount:
Original Contract Amount Awarded:
Scope of Work:
Liquidated Damages or Back Charges:
DSA Project:
Material Canopy at Garden Grove Municipal Service Center
5-1124-A
General Contractor
2372 Morse Ave, Ste 307 Irvine, CA 92614
13802 New hope St, Garden Grove, CA 92843
City of Garden Grove
Les Ruitenschild
714-741-5348 lesr@ci.garden-grove.ca.us
$294,600.00
$313,260.00
05/12/2015Original Final Completion Date:
Actual Final Completion Date: 5/5/2015
X
X
Building a new metal canopy over the existing material storage for the city operation yard including foundation and lighting.
New Pre-Fabricated Metal Canopy & Site Work
F Earl Mellot & Associates-Architects - Earl Mellot
714-741-5348 foremellott@sbcglobal.net
Les Ruitenschild
714-741-5348 lesr@ci.garden-grove.ca.us
Daniel Windham
714-741-5339 None
Project # :
Performed as:
Office Location:
Project Name:
Project Location:
Owner:
Phone: Email:
Phone: Email:
Phone: Email:
Phone: Email:
Yes No
No
Architect / Engineer:
Owner Contact Name:
Inspector Of Record:
Actual Final Completion Date:
Construction Manager :
Project Description:
Final Contract Amount:
Original Contract Amount Awarded:
Original Final Completion Date:
Scope of Work:
Fire Station #1 Training Tower Retrofit
General Contractor
2372 Morse Ave, Ste 307 Irvine, CA 92614
555 N. Berry Street, Brea, CA 92821
City of Brea
Michael Ho
714-990-7691 michaelh@ci.brea.ca.us
Pac Rim Engineering Gilbert Guevara
714-683-0470 gguevara@pacrimengineering.com
Michael Ho
714-990-7691 michaelh@ci.brea.ca.us
Retrofit Brea Fire station No.1 training tower including replacing the second-floor concrete slab and reinforcement. Replacing of the existing wood staircase with new stainless-steel stair way.
Tenant Improvement
$206,756.00
9/17/2014
08/17/2014
$184,025.00
X
X
Liquidated Damages or Back Charges:
DSA Project:
Jim Brodhag
714-671-4460 jimbr@cityofbrea.net
5. MINIMUM QUALIFICATIONS
5.1 The minimum acceptable experience to be qualified for this project is as follows:
5.1.1 The Contractor must have completed at least one (1) project of similar scope to this project with a minimum value of $500,000, within the last five calendar years (from the date of the bid opening) and for a public agency. For a project to be qualified as having a similar scope, it should include at least one major type of related improvements: HVAC replacement
5.2 List project(s) to satisfy minimum qualifications noted above. ’None’, ‘N/A’ or its equivalent is not an acceptable response and will be a basis for disqualifying your bid as non-responsive.:
Project Name:
Agency/Owner:
Project Manager:
Phone Number:
Contract Amount:
Scope of Work:
Name of Project:
Project Manager:
Phone Number:
Name of Project:
Project Manager:
Phone Number:
Katella Range Facility Upgrade County of Orange-Orange County Sheriff Dept.
Robert Bingham (949)251-0702
Demo of existing outdoor shooting range storage room along the north & south walls. Interior work in existing building- relocation of existing lobby counter, 2 storage access vestibules, conversion of storage to new weapons, cleaning room, and addition of small employee break room.
Lincoln Middle School HVAC Santa Monica Malibu Unified School District Kevin Klaus (310)279-3008
School modernization including HVAC, electrical, and plumbing improvements, replacement of campus wide fire alarm system & all other associated improvements per construction documents.
Metro Division 11 and 22 Roof Replacement
LACMTA
Josie Mellen (213)922-1105
Design build roofing & HVAC project - Provide the architectural, structural, electrical, and mechanical design and construction services for roof and HVAC replacement at LA Metro divisions 11 and 22.
$10,983,245.31
$9,261,968.78
$8,390,744.00
File details come from the government source that posted it. Updated .