Appendix F - SC6.21 DBB A_2026_0.docx

STATE OF COLORADO

OFFICE OF THE STATE ARCHITECT

STATE BUILDINGS PROGRAM

CONTRACTOR'S

DESIGN/BID/BUILD (D/B/B)

AGREEMENT

(STATE FORM SC-6.21)

State Agency Insert Department or IHE’s Full Legal Name Department I.D.

Insert Department identification Contract I.D. Number Insert CMS number or other contract number Project Number Insert OSC Project Number Project Name Insert Project as as provided by the State Controller's Office Contractor Name Insert Contractor's full Legal Name including "Inc.", "LLC" etc.

SC-6.21

Rev. 079/20265

Principal Representatives

For the State:

Name Department Name Address Line 1 Address Line 2 City, State ZIP Email

For Contractor:

Name Company Name Address Line 1 Address Line 2 City, State ZIP Email

ATTACHMENT 1: The General Conditions of the Contractor’s Design/Bid/Build (D/B/B) Agreement (SC-6.23)

OFFICE OF THE STATE ARCHITECT

STATE BUILDINGS PROGRAM

CONTRACTOR'S DESIGN/BID/BUILD AGREEMENT

(STATE FORM SC-6.21)

TABLE OF CONTENTS… Page Table of Contents for the entire Agreement is located in THE GENERAL CONDITIONS OF THE CONTRACTOR’S DESIGN/BID/BUILD (D/B/B) AGREEMENT (SC-6.23)

THE PARTIES HERETO HAVE EXECUTED THIS AGREEMENT

Each person signing this Agreement represents and warrants that the signer is duly authorized to execute this Agreement and to bind the Party authorizing such signature.

In accordance with §24-30-202, C.R.S., this Contract is not valid until signed by the State Controller (or an authorized delegate) or the Title of IHE CFO per the Fiscal Rules of the individual Institution of Higher Education Comment by State Buildings Program: Note to Drafters: If this contract is for a University that is outside State Fiscal Rule, insert the name of your organization here

Project Number/Name: Insert OSC Project Number followed by Project Name Contract ID No.: Insert CMS Number & Encumbrance Number

SC-5.3

Rev. 02/2022 Page 1

SC-6.21

Rev. 079/20265 15

CONTRACTOR

INSERT: Legal Name of Contractor By: Name & Title of Person Signing for Contractor Date: __________________

STATE OF COLORADO

Jared S. Polis, Governor INSERT: Name of Agency or IHE INSERT: Name & Title of Head of Agency or IHE By: Name & Title of Person Signing for Agency or IHE Date: __________________

OFFICE OF THE STATE ARCHITECT

State Buildings Program

By: Name & Title of Person Signing for State Buildings Date: __________________

LEGAL REVIEW

Philip J. Weiser, Attorney General

By: Assistant Attorney General Date: __________________

STATE CONTROLLER

Robert Jaros, CPA, MBA, JD By: Name of Agency or IHE Delegate Effective Date: __________________

STATE OF COLORADO

OFFICE OF THE STATE ARCHITECT

STATE BUILDINGS PROGRAM

CONTRACTOR'S DESIGN/BID/BUILD (D/B/B) AGREEMENT

(STATE FORM SC-6.21)

Department ID: Insert Dept. Code Contract ID #: Insert Contract ID Project #:Insert Project #

1. PARTIES. THIS AGREEMENT is entered into by and between the STATE OF COLORADO, acting by and through the Insert Department's or IHE's Full Legal Name hereinafter referred to as the State or Principal Representative, and Insert Contractor's full Legal Name including "Inc.", "LLC" etc. having its offices at Street address, City, State and Zip Code hereinafter referred to as the Contractor.

2. EFFECTIVE DATE AND NOTICE OF NONLIABILITY. This Agreement shall not be effective or enforceable until it is approved and signed by the State Controller or its designee (hereinafter called the “Effective Date”), but shall be effective and enforceable thereafter in accordance with its provisions. The State shall not be bound by any provision of this Contract before the Effective Date, and shall have no obligation to pay Contractor for any Work performed or expense incurred before the Effective Date.

RECITALS:

WHEREAS, the Principal Representative intends to engage the services of a Contractor for the Insert Project Name as provided by the State Controller's Office hereinafter called the Project; and Comment by State Buildings Program: Note to Drafter: Do not include scope of work here. This is only the Project Name.

WHEREAS, authority exists in the Law and Funds have been budgeted, appropriated, and otherwise made available, and a sufficient unencumbered balance thereof remains available for payment in Fund Number Insert Fund Number Here, Account Number Insert Account Number here; and

WHEREAS, the State has Appropriated and the Principal Representative has been authorized to expend the total sum of Insert Dollar Value in Written Words Dollars ($ ) for this project including all professional services, construction/improvements, project contingencies, furnishings, movable equipment, reimbursable expenses and miscellaneous expenses; and

(WHEREAS, funds are available for only a portion of the services defined herein, as more fully described in the funding Condition Precedent clause in Article 5.1; and) Comment by State Buildings Program: Note to Drafters: If the Condition Precedent clause is to be used REMOVE the parenthesis and the italics.

If not accepting the Condition Precedent strike out the language – DO NOT DELETE

WITNESSETH, that the State of Colorado and the Contractor agree as follows:

1. ARTICLE 1 PERFORMANCE OF THE WORK

The Contractor shall perform all of the Work required for the complete and prompt execution of everything described or shown in, or reasonably implied from the Contract Documents for the above referenced Project.

ARTICLE 2 PROVISIONS OF THE CONTRACT DOCUMENTS

The Contractor agrees to perform the Work to the highest industry standards and to the satisfaction of the State of Colorado and its contractor in strict accordance with the provisions of the Contract Documents.

ARTICLE 3 TIME OF COMPLETION

The Contractor agrees to Substantially Complete the Project within calendar days from the date of the Notice to Proceed, in addition, the Contractor agrees to finally complete the Project from Substantial Completion to Final Acceptance within calendar days for a total time of completion of the entire Project of calendar days. The Contractor shall perform the Work with due diligence to completion.

ARTICLE 4 ESSENTIAL CONDITION

Timely completion of the Project is an essential condition of this Agreement. The Contractor shall be subject to any liquidated damages described in Article 7.6 for failure to satisfactorily complete the Work within the time periods in Article 3 above.

ARTICLE 5 CONTRACT SUM

The Contractor shall be paid for the performance of this Agreement, subject to any additions and deductions as provided for in Articles 32, 34 and 35 of The General Conditions of the Construction Contract SC-6.23, the sum of INSERT DOLLAR VALUE IN WORDS DOLLARS AND NO/100 ($ ).

CONDITION PRECEDENT

(At the time of the execution of this Agreement, there are sufficient funds budgeted and appropriated to compensate the Contractor only for performance of the services through and including Insert the project phases that have been fully funded Therefore, it shall be a Condition Precedent to the Contractor’s performance of the remaining services and the State's liability to pay for such performance, sufficient funding must be appropriated and made available to the Principal Representative for the Project prior to and, as a further Condition Precedent, a written Amendment is entered into in accordance with the State of Colorado Fiscal Rules, stating that additional funds are lawfully available for the project. If either Condition Precedent is not satisfied by , the Contractor’s obligation to perform services for Insert the scope pf work or phases that will be completed in the future and the State's obligation to pay for such service is discharged without liability to each other. If funding is eventually made available after , the Contractor has no right to perform services under of this Agreement and the state has no right to require the Architect/Engineer to perform the said services.) Comment by State Buildings Program: Note to Drafter: This is usually PROJECT PHASES not Design Phases Comment by State Buildings Program: Note to Drafter: Insert the latest date that the funds will be released and the Architect/Engineer is willing to hold their fee. Comment by State Buildings Program: Note to Drafter: Insert the latest date that the funds will be released and the Architect/Engineer is willing to hold their fee. Comment by State Buildings Program: Note to Drafter: Insert the last date the architect is willing to hold their fee. Comment by State Buildings Program: Note to Drafter: Insert the latest date that the funds will be released and the Architect/Engineer is willing to hold their fee. Comment by State Buildings Program: Note to Drafter: Insert the last date the architect is willing to hold their fee.

ARTICLE 6 CONTRACT DOCUMENTS

The Contract Documents, as enumerated in Article 1.1 of The General Conditions of the Contractor’s Design/Bid/Build (D/B/B) Agreement (SC-6.23), (the “General Conditions”). The Contract Documents, including the General Conditions, are all essential parts of this Agreement and are fully incorporated herein.

CAPITALIZED TERMS

Capitalized terms used herein and not defined shall have the meanings ascribed to them in The General Conditions of Design/Bid/Build (D/B/B) Agreement (SC-6.23)

ARTICLE 7 OPTIONAL PROVISIONS AND ELECTIONS

The provisions of this Article 7 alter or enlarge upon the following Articles (the General Conditions of the Contractor’s Design/Bid/Build Agreement SC-6.23):

☒ ______ Principal Representative initial MODIFICATION OF ARTICLE 13: Shop Drawings, Product Data and Samples Comment by : Note to Drafter: The Buy Clean Colorado Act applies to all projects with a construction value of $500,000 or more If the box below is marked, the Buy Clean Colorado Act, §24-92-117, C.R.S., shall be applicable to the Project. The Contractor is responsible for submitting Environmental Product Declaration (EPD) information for all eligible materials to be used on the project.

☐ ______ Principal Representative initial

☐ ______ Principal Representative initial

☐ ______ Principal Representative initial MODIFICATION OF ARTICLE 39: Non-Binding Dispute Resolution – Facilitated Negotiations If the box below is marked, and initialed by the State as noted, the requirement to participate in facilitated negotiations shall be deleted from this Contract. Article 39, Non-Binding Dispute Resolution – Facilitated Negotiations, shall be deleted in its entirety and all references to the right to the same where ever they appear in the contract shall be similarly deleted.

The box may be marked only for projects with an estimated value of less than $500,000. Comment by : Note to Drafter: Double-click on the box to bring up Check Box Form Field window and select “Checked” ☒ ______ Principal Representative initial MODIFICATION OF ARTICLE 45: Guarantee Inspections After Completion If the box below is marked the six month guarantee inspection is not required. Comment by : Note to Drafter: Double-click on the box to bring up Check Box Form Field window and select “Checked” ☐ ______ Principal Representative initial MODIFICATION OF ARTICLE 46: Time of Completion and Liquidated Damages If an amount is indicated immediately below, liquidated damages shall be applicable to this Project as, and to, the extent shown below. Where an amount is indicated below, liquidated damages shall be assessed in accordance with and pursuant to the terms of The General Conditions of the Design/Bid/Build Agreement Article 46, Time of Completion And Liquidated Damages, in the amounts and as here indicated. The election of liquidated damages shall limit and control the parties right to damages as the State’s sole and exclusive remedy for delay.

Inability To Use The Project For the inability to use the Project, for each day after the number of calendar days specified in the Contractor’s bid for the Project and the Agreement for achievement of Substantial Completion, until the day that the Project has achieved Substantial Completion and the Notice of Substantial Completion is issued, the Contractor agrees that an amount equal Insert dollar value in words Dollars ($ ). shall be assessed against Contractor from amounts due and payable to the Contractor under the Contract, or the Contractor and the Contractor’s Surety shall pay to the Principal Representative such sum for any deficiency, if amounts on account thereof are deducted from remaining amounts due, but amounts remaining are insufficient to cover the entire assessment. Comment by State Buildings Program: Note to drafter: If liquidated damages are not applicable Note “Not Applicable” in this field.

Damages Related to Extended Closeout For damages related to or arising from additional administrative, technical, supervisory and professional expenses related to and arising from the extended closeout period, for each day in excess of the number of calendar days specified in the Contractor’s bid for the Project and the Agreement to finally complete the Project as defined by the issuance of the Notice of Final Acceptance (after the issuance of the final Notice of Substantial Completion), the Contractor agrees that an amount equal to Insert dollar value in words Dollars ($ ). shall be assessed against Contractor from amounts due and payable to the Contractor under the Contract, or the Contractor and the Contractor’s Surety shall pay to the Principal Representative such sum for any deficiency, if amounts on account thereof are deducted from remaining amounts due but amounts remaining are insufficient to cover the entire assessment. Comment by : Note to drafter: If liquidated damages are not applicable Note “Not Applicable” in this field.

ARTICLE 8 NOTICE IDENTIFICATION

All Notices pertaining to this Agreement and the General Conditions (SC-5.23) or otherwise required to be given shall be transmitted in writing, to the individuals at the addresses listed below, and shall be deemed duly given when received by the parties at their addresses below or any subsequent persons or addresses provided to the other party in writing.

NOTICE TO PRINCIPAL REPRESENTATIVE:

Insert Name of Individual acting on the PR behalf Insert Street Address City, State Zip Code Insert email address With copies to State Buildings Program (or Delegate) Insert Name of Individual acting on OSA/SBP behalf Insert Street Address City, State Zip Code Insert email address

NOTICE TO CONTRACTOR:

Insert Name of Individual acting on the contractor behalf Insert Street Address City, State Zip Code Insert email address

SC-6.21

Rev. 02/2025 1

SC-6.21

Rev. 079/20265 3

STATE OF COLORADO

OFFICE OF THE STATE ARCHITECT

STATE BUILDINGS PROGRAM

CONTRACTOR'S DESIGN/BID/BUILD AGREEMENT

EXHIBIT A: CONTRACTORS BID

CONTRACTOR’S BID (Form SBP-6.13) Workers’ Compensation Certification (SBP-4.1) Comment by : Note to Drafter: Delete Alternates and Unit Pricing if not applicable Bid Alternates (Form SBP-6.131) Unit Pricing (Form SBP-6.133) Bid Bond (Form SBP-6.14) Comment by : Note to drafter: Labor burden is required on ALL construction projects Labor Burden Calculation (Form SBP-6.18)

STATE BUILDINGS PROGRAM

CONTRACTOR'S DESIGN/BID/BUILD AGREEMENT

EXHIBIT B: PERFORMANCE BOND

PERFORMANCE BOND (Form SC-6.22)

STATE BUILDINGS PROGRAM

CONTRACTOR'S DESIGN/BID/BUILD AGREEMENT

EXHIBIT C: LABOR AND MATERIAL PAYMENT BOND

LABOR AND MATERIAL PAYMENT BOND (Form SC-6.221)

STATE BUILDINGS PROGRAM

CONTRACTOR'S DESIGN/BID/BUILD AGREEMENT

EXHIBIT D: INSURANCE CERTIFICATE(S)

INSURANCE CERTIFICATE(S) (attached)

STATE BUILDINGS PROGRAM

CONTRACTOR'S DESIGN/BID/BUILD AGREEMENT

EXHIBIT E: BUILDING CODE COMPLIANCE POLICY

BUILDING CODE COMPLIANCE POLICY: COORDINATION OF APPROVED BUILDING CODES, PLAN REVIEWS, BUILDING INSPECTIONS AND STATE DEVELOPMENT REQUIREMENTS

Refer to the Office of the State Architect’s Building Codes Webpage for the Building Code Compliance Policy (Rev. July 2025)

Exhibit A: Approved Building Codes of the Code Compliance Policy dated July 2025 including the Amendments to the International Building Code and Code Compliance Plan Review Procedures (Rev. July 2025);

Exhibit B: Plan Review Procedures of the Code Compliance Policy dated July 2025

Exhibit I: State Development Requirements of the Code Compliance Policy dated July 2025

The State Buildings Program Building Codes Webpage may be found at:

Rev. 079/20265 Ex B https://osa.colorado.gov/state-buildings/building-codes

SC-5.3

Rev. 08/2023 Ex B

STATE OF COLORADO

OFFICE OF THE STATE ARCHITECT

STATE BUILDINGS PROGRAM

CONTRACTOR'S DESIGN/BID/BUILD AGREEMENT

(STATE FORM SC-6.21)

STATE SALES AND USE TAX FORM

STATE BUILDINGS PROGRAM

CONTRACTOR'S DESIGN/BID/BUILD AGREEMENT

(STATE FORM SC-6.21)

STATE BUILDINGS PROGRAM

CONTRACTOR'S DESIGN/BID/BUILD AGREEMENT

(STATE FORM SC-6.21)

APPRENTICESHIP UTILIZATION CERTIFICATIONS

Rev. 079/20265 Ex H

STATE BUILDINGS PROGRAM

CONTRACTOR'S DESIGN/BID/BUILD AGREEMENT

(STATE FORM SC-6.21)

Comment by : Note to drafter: Delete this page if not applicable

SUPPLEMENTARY GENERAL CONDITIONS: FEDERAL PROVISIONS

Supplementary General Conditions Federal Provisions

SLFRF Federal Funds: Contractor Terms and Conditions Certification

SLFRF Federal Funds: Contractor Terms and Conditions

SC-6.21

Rev. 079/20265 image1.emf

Microsoft_Excel_Worksheet.xlsx Sheet1

Name of Document Short Description of Work/Date Dollar Amount

Base Bid Amount Base Bid

Alt. #

Alt. #

Total Contract Sum $ - 0