36C10F20R0019_1.docx

1. SOLICITATION NUMBER

2. TYPE OF SOLICITATION

3. DATE ISSUED

PAGE OF PAGES

4. CONTRACT NUMBER

5.

REQUISITION/PURCHASE REQUEST NUMBER

6. PROJECT NUMBER

7. ISSUED BY

CODE

8. ADDRESS OFFER TO

a. NAME

b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE

DOCUMENTS (Title, identifying number, date) 12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

12b. CALENDAR DAYS

13. ADDITIONAL

SOLICITATION REQUIREMENTS:

STANDARD FORM 1442 (REV. 8/2014)

STANDARD FORM 1442

Prescribed by GSA-FAR (48 CFR) 52.236-1(d)

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

SOLICITATION

SOLICITATION

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR INFORMATION

CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SEALED BID (IFB)

NEGOTIATED (RFP)

1. The Contractor shall begin performance within ____________ calendar days and complete it within calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. (See

YES

NO

a.

Sealed offers in original and ___________________copies to perform the work required are due at the place specified in Item 8 by _____________ (hour) local time _____________________ (date). If this is a sealed bid solicitation, offers must be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, the date and time offers are due.

b.

An offer guarantee is, is not required.

c.

All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d.

Offers providing less than ____ ___________________ calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

36C10F20R0019 X 07-06-2020 657-313H 003C4 Department of Veterans Affairs Office of Construction and Facilities Management (003C4D) 1425 Tri-State Parkway, Suite 140 Gurnee IL 60031 Department of Veterans Affairs Office of Construction and Facilities Management (003C4D) 1425 Tri-State Parkway, Suite 140 Gurnee IL 60031

KRYSTAL GLASPER

202-812-5083

Offeror shall provide all labor, materials, tools, equipment, transportation, supervision, coordination, and services necessary for construction of the project as described herein and other specific tasks as further defined by the Request for Proposal (RFP). The scope of the contract is described in Section 00 11 21 at Paragraph A1. Work is to be performed at the Jefferson Barracks Division Campus of the VA Medical Center located at 1 Jefferson Barracks Drive, St. Louis, MO 63125.

The project magnitude of construction is between $10,000,000.00 and $20,000,000.00. Davis Bacon Wages apply. The NAICS code is 238910 and the Small Business Size Standard is $15 million. The project is being solicited as a CVE Verified Service Disabled Veteran Owned Small Business (SDVOSB) set-aside. Any entity wishing to propose shall be listed as an SDVOSB concern in accordance with 38CFR 74 and shall be so listed in the Vendor Information Pages datab ase located at www.vip.vetbiz.gov, and shall comply with the subcontracting limitations in 13 CFR 125.6.

Please submit all questions regarding the solicitation and supporting documentation in writing using the RFI submission format as a Microsoft Word Document provided within this solicitation. All RFIs shall be submitted via email to Krystal Glasper at Krystal.Glasper@va.gov. RFIs will be accepted until July 23, 2020 at 2:00pm CST. All offerors are responsible for monitoring and downloading attachments and amendments from Contract Opportunities (beta.sam.gov)

Proposals are due August 6, 2020 at 2:00pm CST

A virtual pre-proposal conference will be conducted on July 13, 2020 at 9:00am CST. For registration, please email Victoria Wayne at Victoria.Wayne@va.gov, SUBJ: STL Virtual Conference Registration. Please register NLT Thursday, July 9, 2020 at 2:00pm CST.

Site Visits will be scheduled to take place at VAMC St. Louis on an individual basis following the pre-proposal conference.

X X 52.211-10 X

2:00PM

08-06-2020 X

14. NAME AND ADDRESS OF OFFEROR

15. TELEPHONE NUMBER

16. REMITTANCE ADDRESS

CODE

FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of the solicitation, if this offer is accepted by the Government in writing within __________ calendar days after the date offers are due.

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMEN

DMENTS

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER 20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED:

22. AMOUNT

23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c)( 41 U.S.C. 3304(a) (

26. ADMINISTERED BY

27. PAYMENT WILL BE MADE BY

PHONE:

FAX:

28. NEGOTIATED AGREEMENT

29. AWARD

Your Contractor agrees offer on this solicitation is hereby accepted as to the items listed. This to furnish and deliver all items or perform all work requirements identified award consummates the contract, which consists of (a) the Government on this form and any continuation sheets for the consideration stated in solicitation and your offer, and (b) this contract award. No further cont-this contract. The rights and obligations of the parties to this contract ractual document is necessary.

shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

30a. NAME AND

TITLE OF CONTRACTOR OR PERSON AUTHORIZED

31a. NAME OF CONTRACTING OFFICER

TO SIGN

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. AWARD DATE

BY

OFFER

AWARD

STANDARD FORM 1442 (REV. 8/2014) BACK

(Include ZIP Code) (Include area code) (Include only if different than Item 14.)

(Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each) (Type or print) (4 copies unless otherwise specified) (Type or print) (Type or pr int) (Contractor is required to sign this document and return _______ copies to issuing office.)

(Contractor is not required to sign this document.)

(Must be fully completed by offeror) (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

101F Department of Veterans Affairs Office of Construction and Facilities Management 1425 Tri-State Parkway, Suite 140 Gurnee DC 60031 Department of Veterans Affairs

FMS-VA-2(101)

Financial Services Center

PO

Box 149971 Austin TX 78714-9971

SCHEDULE OF CONTRACT LINE ITEMS AND PRICES/COSTS

CAMPUS DEMOLITION & PAVING

In accordance with the Request For Proposal, the contract drawings and specifications and amendments to either, the work of each Contract Line Item as defined herein in general terms includes, but is not limited to, provision of all labor, materials, tools, equipment, transportation, management, supervision, quality control and all other necessary services and performance of all construction services and incidental related work for completion of fully functional, integrated and operational site improvements.

CLIN 1 SOUTH CAMPUS BASE PROPOSAL – GENERAL CONSTRUCTION: CLIN 1 is defined in general terms as cost for work associated with the south portion of the Medical Center campus as indicated in the contract documents including, but not limited to, demolition and removal of improvements and structures; abandonment, removal and relocation of existing utilities; earth and site work including excavation, fill and disposal of surplus excavated earth or other materials; new underground utilities, grading, drainage, sidewalks, roadways, parking, landscaping, site lighting and other site improvements.

CLIN 2 NORTH CAMPUS BASE PROPOSAL – GENERAL CONSTRUCTION: CLIN 2 is defined in general terms as cost for work associated with the north portion of the Medical Center campus as indicated in the contract documents including, but not limited to, demolition and removal of improvements and structures and Buildings 61 and 63; abandonment, removal and relocation of existing utilities; earth and site work including excavation, fill and disposal of excavated earth or other materials; new underground utilities, grading, drainage, sidewalks, roadways, parking, landscaping, site lighting and other site improvements.

CLIN 3 WEST CAMPUS BASE PROPOSAL – GENERAL CONSTRUCTION: CLIN 3 is defined in general terms as cost for work associated with the west portion of the Medical Center campus as indicated in the contract documents including, but not limited to, demolition and removal of site improvements; earth and site work including excavation, fill and disposal of surplus earth or other materials; new underground utilities, grading, drainage, sidewalks, specialty paving, site walls, fencing, landscaping, site lighting and other improvements.

CLIN 5 STEAM MANHOLE REPAIRS BASE PROPOSAL – GENERAL CONSTRUCTION: CLIN 5 is defined in general terms as cost for work associated with repairing deficiencies in designated steam manholes as indicated in the contract documents including, but not limited to, disconnecting and removal of existing piping components; demolition and repair of existing thrust blocks; providing and installing new expansion joint anchoring components; and re-installation and re-connection of existing piping components.

CLIN 6 BASE PROPOSAL – ASBESTOS ABATEMENT: CLIN 6 is defined in general terms as cost for work required for the entire project to perform asbestos abatement associated with existing buildings, existing underground utilities or as otherwise required including, but not limited to, planning, documentation, notifications, permits, temporary protection controls, monitoring, sampling, cleaning and all other incidental related work specific to the proper removal and disposal of asbestos and asbestos containing materials to facilitate demolition and removal of existing structures and construction and as otherwise required for execution of the work of the project.

CLIN 7 BASE PROPOSAL – HAZARDOUS MATERIALS ABATEMENT: CLIN 7 is defined in general terms as cost for work required for the entire project to perform hazardous materials abatement including, but not limited to, planning documentation, notifications, permits, temporary protection controls, monitoring, sampling, cleaning and all other incidental related work specific to the proper removal and disposal of hazardous materials (lead containing paint, ozone depleting substances (ODS), PCBs, etc.) to facilitate demolition and removal of existing structures and construction and as otherwise required for execution of the work of the project.

CLIN 8 WEST CAMPUS – DEDUCT ALTERNATE NO. 1: CLIN 8 is defined in general terms as a cost deduct to delete applicable Base Proposal costs for all general conditions, labor, material, tools, equipment, transportation, supervision, submittals, testing, inspections and all other incidental related work costs to modify the work of the project in accordance with the West Campus Alternate 1 contract drawings. The contract specifications remain unchanged unless noted otherwise. CLIN 8 includes deduct costs for modifications to reduce the scope of work for the development of the West Campus area including, but not limited to, reductions in site walls, sidewalks, finished paving, landscaping and as otherwise defined in the Alternate 1 contract drawings.

Table of Contents

INSTRUCTIONS, CONDITIONS AND OTHER STATEMENTS TO BIDDERS/OFFERORS 11

SECTION 00 11 21

REQUEST FOR PROPOSAL TO BUILD

SECTION 01 00 00

INSTRUCTIONS, CONDITIONS AND OTHER STATEMENTS TO BIDDERS/OFFERORS

SECTION 00 11 21

REQUEST FOR PROPOSAL TO BUILD

CAMPUS DEMOLITION & PAVING

PROJECT NO. 657-313H

VA MEDICAL CENTER JEFFERSON BARRACKS DIVISION

ST. LOUIS, MISSOURI

A. PART I - General

A. PART I - GENERAL

A1. Scope of Contract

A2. Definitions A2. Definitions

A.

Request for proposal issued

7/6/2020

Pre-proposal conference

7/13/2020 (virtual)

Written Requests for Information before

7/23/2020

Proposal submitted

8/6/2020

Contract award

8/31/2020

Notice to proceed

9/21/2020

Construction completion/final inspection/ custody receipt

_530_ calendar days from NTP

D. Schedule Objectives - The anticipated completion of this project is 530 calendar days after “Notice to Proceed” (NTP). The proposed schedule may not be shorter than this, see Part III, C3.A.3.a.4). No work, to include mobilization, shall occur until the baseline schedule has been approved by the Contracting Officer/ACO.

A3. Cost Range A3. Cost Range

The anticipated cost range for this project is between $10,000,000.00 and $20,000,000.00.

A4. Pre-Proposal Conference A4. Pre-Proposal Conference A pre-proposal conference date, time and location will be advertised via amendment to this solicitation. All Offerors, subcontractors, manufacturers and suppliers are invited to attend. The following agenda is furnished for this meeting:

A5. Selection Criteria and Weightings

Note: Factor 4: Past Performance is a non-technical factor

C. Cost Proposal - Offerors are advised that if the technical proposals are essentially equal, award will be made based on the lowest cost. See Part III, paragraph C4. for cost proposal requirements and basis of evaluation.

B. PART II - RESPONSIBILITIES

B. PART II - RESPONSIBILITIES

B1. VA Team

B2. Construction Team:

C. PART III - PROPOSAL REQUIREMENTS

C. PART III - PROPOSAL REQUIREMENTS

C1. General

Victoria Wayne, Contract Specialist (003C4D) Office of Construction & Facilities Management Department of Veterans Affairs 1425 Tri State Parkway, Suite 140 Gurnee, IL 60031;

2. Hand Carry Only (office open Monday- Friday, 7:30 am to 4:30 PM CST), proposals shall be received by 2:00 p.m. Central Standard Time (CST) on 6 August 2020:

Victoria Wayne, Contract Specialist Office of Construction & Facilities Management Department of Veterans Affairs 1425 Tri State Parkway, Suite 140 Gurnee, IL 60031

D. Technical, Past Performance and Cost factors of the Offeror’s proposals will be evaluated independently. Offeror shall separate the technical/non-technical section from the cost section. Each section shall be labeled with the Offeror's organization, business address, DUNS number, Cage Code, and VA Project Number.

E. Carefully follow “Instructions, Conditions, and Notices to Offerors”. Standard Form 1442, Solicitation, Offer, and Award (Construction, Alteration, or Repair) shall be used for submitting price offers. Submit price offers electronically on Standard Form 1442 and original bid guarantee via mail as stipulated in part C of this section:

C2. Proposal Revisions (FAR 52.215-1)

C3. Technical Proposal Requirements C3. Technical Proposal Requirements

1. The technical proposal shall be limited to not more than 160 pages and shall address the factors listed in Part I, A5. Pages beyond the stated limit will NOT be considered. Offeror is required to prepare and submit an electronic copy of the technical proposal. Submission requirements and the basis of evaluation for each factor are provided in paragraphs C3.A.1 thru C3.A.5.b that follow. NOTE: Proposals that exceed stated minimum requirements for individual factors may be rated higher and similarly, proposals that fail to meet or address minimum requirements for individual factors may be rated lower or unacceptable (except as otherwise noted). The following chart may be used as a checklist to assist in making a complete proposal and may be used as a table of contents for the technical/non-technical proposal. Past performance is a non-technical factor. Technical Factors and Non-Technical Factors (other than cost or price) when combined are approximately equal in importance to cost or price. Technical factors will be weighted equally.

TECHNICAL/NON-TECHNICAL PROPOSAL BINDER SUBMITTAL

(One Original and one copy)

RFP: _____________________

Project Title: Campus Demolition & Paving, JB Division, VAMC St Louis, MO

INTRO

PAGE

First Page MUST clearly indicate Name and Address of Offeror Business Arrangement (If Joint Venture or other teaming arrangement) Contact Name and Phone Number Email Address DUNS Number CAGE Code Tax Identification Number Description of all deviations from the RFP requirements contained within the offeror’s proposal

0. Factor 1 – Project Personnel Experience (Specialized experience and technical competence):

1. Submittal Requirements: The Offeror shall demonstrate the relevant experience & qualifications of key project personnel.

0. Supply biographical data for at least the following key personnel (Note if one individual is proposed for more than one position listed):

0. Overall Construction Project Manager.

0. Project Superintendent(s).

0. Site Safety and Health Manager(s)

0. Quality Assurance/Quality Control Manager(s).

0. Project Engineer(s).

0. Certified Industrial Hygienist(s)

0. Biographical data shall include the following:

1. Name of individual.

1. Company employed by.

1. Company position title.

1. Years with the company.

1. Describe work experience with projects that were building abatement and demolition and site improvements on active medical campuses (or similar campus environment) and the company (by name) they worked for when involved in the project.

1. An indication of which (if any) projects submitted under Corporate Project Experience the individual participated in and what the individual’s responsibility was for that project.

1. An indication of which other individuals submitted under Project Personnel Experience this individual has worked with and the project they worked on together, noting if that project has been submitted under Corporate Project Experience.

1. Position that the individual will hold on this contract/Construction Team, description of duties and what percentage of the individual’s time that would be committed to the project during the construction of the project.

1. Describe job related educational experience including degrees, certificates, etc. and granting institutions.

1. Information provided for this factor shall not conflict with other parts of the proposal and shall demonstrate a qualified team whose background, qualifications (including education, training, certifications, and/or licensure) and experience are commensurate with their proposed positions; who have experience with at least two (2) projects of similar size, scope, and complexity in the last 12 years; that have worked together successfully on past similar projects; and who are available to perform in their proposed positions for the duration of construction or the durations stated in the proposal.

1. Basis of Evaluation: This factor will be evaluated based on the offeror’s proposed key personnel and how well the information provided compares to the stated requirements and demonstrates the team’s potential to successfully perform.

1. Factor 2 - Technical/Management Approach:

1. Submittal Requirements: - The Offeror shall describe and/or demonstrate the following.

0. An effective Project Delivery Philosophy – Include statements that:

0. Describe offeror’s approach (including measures offeror has taken/will take) to avoid cost or schedule growth

0. Express offeror’s expectations and commitments concerning elements for Successful Partnering, Communication, Commitment and Conflict Resolution.

0. A Quality Assurance/Quality Control Plan(s) with sufficient detail to demonstrate effective controls and practices to ensure adherence to contract requirements and successful delivery of quality construction.

0. Project Organizational Chart and Narrative - Include team members submitted under Project Personnel Experience. Clearly describe the prime responsible firm (or firms if a J/V) and individuals as well as the roles and responsibilities of individuals proposed as subcontractors. Provide a list of all proposed major Subcontractors, including telephone number, address, and name of contact. (Note, identifying multiple “potential” subcontractors for each major trade, who may or may not end up part of the offeror’s team, will be considered ambiguous and will be evaluated as though the major subcontractor had not been identified, which may be rated lower).

0. Capability to perform:

3. Provide the Offeror's total bonding capacity, current available bonding capacity and expected available capacity in 2020 and 2021.

3. Provide the Offeror's current workload and availability of staff listed under Project Personnel Experience to execute the project.

0. The Offeror shall describe in a written narrative the plan for controlling and sequencing the work to avoid or minimize adverse impact to the Medical Center or its environment from construction traffic, construction noise or vibration, construction activities (building demolition, site work, underground utilities, crane or equipment operations, etc.), utility outages, construction dust & debris, storm water runoff, waste storage, fire, etc. Narrative shall specifically address how the offeror will ensure the facility remains operational and address how the Offeror intends to prepare the site, disassemble, relocate, reassemble, and reactivate utility services to the facility within any specified time limits.

0. Offeror shall clarify its intended uses of the portions of the site indicated to be available to the Contractor elsewhere in the RFP Documents for materials staging, temporary trailer offices, employee parking, and other activities.

0. The offeror shall identify which elements of the work it intends to self- perform including percentage of total value that work represents.

1. Basis of Evaluation: This factor will be evaluated based on the how well the offer’s technical/management approach demonstrates capability, availability, and capacity to successfully perform including measures to avoid cost or schedule growth, how well defined the proposed prime/subcontractor team is and how well its organizational structure, controls, lines of authority, planned subcontractors, quality controls and practices, and plans for execution and site use suggest a successful project outcome; & whether the offeror meets the minimum required self-performance.

1. Factor 3 - Corporate Project Experience:

1. Submittal Requirements: The Offeror shall demonstrate relevant project, safety, and environmental experience, utilizing the General Contractor Reference form at the end of this specification section, the following, relevant to corporate project experience.

0. A maximum of four (4) example projects completed within the last twelve

(12) years, similar in size (physical), scope (building abatement, demolition, and site improvements on an active campus), and complexity (multiple elements of construction including hazardous material abatement, building demolition, site work, underground utilities and infrastructure, sidewalks, paving, landscaping, plumbing, electrical, low voltage communication systems, work near occupied buildings, and strict requirements for site access, security, utility outages & cutovers, coordination with public & private utility companies, etc.) to this project. In describing project construction experience, provide the following information:

1. Project title, location and brief description including project type (building demolition, roadway construction, buried utility construction, etc.) and contracting method (design/bid/construct, CM at risk, etc.).

1. Project owner and name and telephone number of owner’s contact person.

1. Project Design Architect and Engineers and name and telephone number of contact person(s).

1. Name and number of contact person(s) of Major Subcontractors if also proposed for this solicitation.

1. Project Statistics including start and completion dates (original vs. actual) for construction; cost (original award price versus final, with brief explanation of what is included in the cost including any cost and/or schedule growth); building abatement, building demolition, utilities and infrastructure, landscaping, etc. and any awards (prizes) received.

1. Provide the required information utilizing the General Contractor Reference Form included at the end of this specification section.

0. All OSHA and EPA reports for last three years

0. Experience modifier rate (EMR) for last three years.

b.) Basis of Evaluation: This factor will be evaluated based on how well the information provided compares to the stated requirements and on how relevant the proposed examples of projects are, as well as, the proposed project examples similarity in size and scope to the project described in the solicitation. Overall the offeror should demonstrate their ability to handle projects of this nature.

1. Factor 4 – Past Performance (non-technical):

1. Submittal Requirements: The offeror shall demonstrate performance on relevant past projects by providing complete General Contractor Reference forms for each example project (under Corporate Project Experience), with accurate point of contact information. In addition to considering all other information available to the Government on the Offeror’s past performance, the evaluation panel will evaluate the information supplied by the offeror on these forms, in response to this solicitation, including contacting the owner’s point of contact supplied for projects submitted under Corporate Project Experience to determine:

0. Presence and character of any cost growth

0. Presence and character of any schedule growth

0. Client overall satisfaction with project: Contact persons will be asked:

2. Does the project fulfill the requirements of the client’s stated function?

2. Does the project require unexpected maintenance activity?

2. Have latent defects been found?

2. Was the construction staffing level consistent with the project size and complexity?

2. How well did the contractor plan and coordinate work to avoid disruption to client’s operations?

2. Was communication of schedule and problem issues adequate and consistent?

2. Was there an established problem solving routine?

2. Was the project completed on time and within the project budget?

2. Would the client like to use this firm again?

1. Basis of Evaluation: This factor will be evaluated based on past performance including evaluation of example project statistics (for cost and schedule growth) and client satisfaction. Evaluation will also include past performance evaluations obtained from the Contractor Performance Appraisal System (CPARS) via the Past Performance Information Retrieval System (PPIRS) along with any data obtained on projects in progress for VA or other agencies. Past Performance is its own factor and will be evaluated separately from the other factors as it is considered non-technical.

1) Proposals that indicate Offeror has no relevant project experience will be held neutral for the past performance factor

1. Factor 5 - Schedule:

1. Submittal Requirements: The offeror shall provide information on his proposed plan for executing the work in the time allocated for the contract. Proposal shall:

0. Identify name, address, phone number of proposed schedule consultant, if any (include resume for individual who will prepare all schedule submissions).

0. Provide proposed schedule in a time scaled bar graph format. The horizontal axis will be scaled for time beginning with the Notice to Proceed and concluding with contract completion. The vertical axis will show the milestones and major portions of the contract work. All schedule items will show a start date and a completion date. The detailed schedule will indicate specific tasks with dates for each step of the process including:

1. Construction Period: Mobilization; submission, review, and approval of key submittals and notices; abatement and testing activities; demolition method and sequencing; excavation, removal, and disposal of buried construction; procurement and installation of equipment; provisions for overtime or shift work; utility interruption notices and associated outage durations; excavation, installation, testing, and backfill for site utilities; backfill and grading; parking, paving, sidewalk, and roadway completion and realignment including temporary re-routed Medical Center vehicular and pedestrian routes; testing; preliminary and final inspection(s); punch list completion; closeout submittals. Show relationships between these activities and durations.

0. Provide a narrative to explain the proposed general project delivery schedule. The Offeror shall specify:

2. How much allowance has been made for bad weather in the schedule

2. The days of the week and the hours of construction operations during each sequence of the work

2. The percentage of contract completion that will be achieved at the end of each month of the contract.

0. Short Schedules - Short schedules will not be accepted and will be evaluated unfavorably. Critical path activity durations shall total the number of days indicated on Standard Form 1442, Construction, Offer and Award (Construction, Alteration or Repair), and in section I, paragraph A.2.C. and D. This duration shall establish the contract completion date. Please see above section “Definitions” for the definition of “completion” as it relates to duration) and assessment of liquidated damages (see FAR 52.211-12 Liquidated Damages – Construction, Sept 2000).

1. Basis of Evaluation: This factor will be evaluated based on how reasonably and realistically the proposed schedule captures and addresses key elements and project phasing with respect to conditions and requirements indicated in the RFP and how effectively it demonstrates a successful approach to completing all the work of the contract in the time allotted for performance.

C4. Price Proposal Requirements.

1. The offeror shall prepare and submit an original and one (1) copy of the following price documents in a SEPARATE SEALED ENVELOPE MARKED:

“PRICE PROPOSAL – DO NOT OPEN IN MAILROOM” The price proposal shall be submitted in a separate binding from the technical proposal. Pricing shall be entered onto the Bid Schedule located within the SF1442. The price proposal shall be tabbed using the following Table which can be used as a checklist to ensure a complete price proposal. NOTE: It is the offeror’s responsibility to contact the Department of Revenue to determine appropriate tax status for this project (federal, state, local contractor tax, etc.) for inclusion or exemption in the overall proposed price. See FAR 52.229-3.

PRICE PROPOSAL BINDER SUBMITTAL

(One Original and one copy)

RFP: ___________________

Project Title: Campus Demolition & Paving, JB Division, VAMC St Louis, MO

Also indicate:

Name and Address of Offeror Business Arrangement (If Joint Venture or other teaming arrangement) Contact Name and Phone Number Email Address DUNS Number CAGE Code Tax Identification Number

1. Basis of Evaluation: Price will be evaluated based on its fairness and reasonableness to ensure that it is in the best interest of the Government.

1. Price Analysis will be performed using one or more of the techniques listed in FAR 15.404-1(b)(2) below to ensure a fair and reasonable price.

1. Evaluation will be based on total price for base CLINs 1 thru 6. Deductive alternates (CLINS 7 and 8) will be evaluated only as necessary to bring the total price within available funding. Deductive alternates (CLINS 7 and 8) will not be evaluated when one or more proposals fall within the amount of available funding.

1. The Government reserves the right to make cost/technical trade-offs that are in the best interest and advantageous to the Government.

- - - END - - -

Page 1 of Page 1 of General Contractor Reference Form

GENERAL CONTRACTOR REFERENCE FORM

OFFEROR:_____________________________________________________________________

SOLICITATION NO._____________________________________________________________

CONTRACT NO.____________________PROJECT NO.__________________________________

PROJECT TITLE:_______________________________________________________________

LOCATION:____________________________________________________________________

CONTRACTING OFFICER/POC:_____________________________________________________

PHONE NO:________________________________________________________

EMAIL ADDRESS:___________________________________________________

OWNERS PROJECT MANAGER/POC___________________________________________________

PHONE NO:________________________________________________________

EMAIL ADDRESS:___________________________________________________

TYPE OF CONTRACT (Negotiated, Design/Build, Design/Bid/Build)

AWARD AMOUNT:________________________FINAL…