00430_Payment_Bond_Revised_Sample.pdf
PDF 82 KB Posted
- Solicitation number
- 2026-059
- Issued by
- Los Angeles County, California
About this file
This is a Payment Bond document for Mt. San Antonio College, a California community college undertaking construction of a new four-story Technology and Health Building. The document establishes the bonding requirements that contractors must satisfy before beginning work on the project. The payment bond is required in an amount equal to 100 percent of the contract price and must be filed with the College's governing board prior to the contractor's commencement of work. The bond secures claims related to labor, materials, provisions, and supplies necessary for project performance, as well as employment-related withholdings required under California Unemployment Insurance Code Section 13020. The bond document provides that it must be executed in two identical counterparts and requires the contractor to affix a corporate seal, provide notarial acknowledgment of all surety signatures, and submit a Power of Attorney and Certificate of Authority for the surety. The surety must be an admitted surety insurer authorized by the California Department of Insurance.
The bond obligates the principal (contractor) and surety jointly and severally to pay all laborers, material suppliers, and other persons entitled to file claims under California Civil Code Section 9100 for any unpaid labor, materials, or services related to the contract performance. The surety waives notice of any changes, extensions, alterations, or additions to contract terms or specifications and agrees that such modifications will not affect its bond obligations. In the event of breach, the surety commits to paying reasonable attorney's fees as awarded and fixed by the court and included in any judgment rendered. The bond document requires bidders to use the College's form rather than a surety company's alternative form and mandates inclusion of the California agent's name, address, and telephone number on the executed document.
View the file
Other files
| File | Type | Posted |
|---|---|---|
| Prequalification_for_Purchase_of_Custom_Furniture_(FF&E)_Bid.pdf | ||
| Prequalification_Application_(rev_06-2026).pdf | ||
| Written_Specifications.pdf | ||
| FF&E_Phase_II_Schedule.pdf | ||
| CAD_x-1_arch_231128-hh.dwg | DWG drawing | |
| CAD_x-2_arch_231128-HH.dwg | DWG drawing | |
| CF1_SCE_Reception_Spec.pdf | ||
| CAD_1_Furn_Bid_2.dwg | DWG drawing | |
| CT1A_CT1B_Custom_Work_Table.pdf | ||
| CF2_Division_Reception_Spec.pdf | ||
| WT3_Work_Table.pdf | ||
| RB1_Residential_Bed.pdf | ||
| WT4A_WT4B__Work_Table.pdf | ||
| CAD_4_Furn_Bid_2.dwg | DWG drawing | |
| WT1A_WT1B_Work_Table.pdf | ||
| CAD_2_Furn_Bid_2.dwg | DWG drawing | |
| Furniture_Plan_Color_Coded.pdf | ||
| WT2_Work_Table.pdf | ||
| CAD_x-4_arch_231128_HH.dwg | DWG drawing | |
| Furniture_Log.pdf | ||
| MSR1_Sheet_Rack.pdf | ||
| Custom_Furniture_-_Standard.zip | ZIP file | |
| 00420_Performance_Bond_Revised_sample.pdf | ||
| Mt._SAC_-_Template_Field_Services_Contract.pdf |
Show all 24
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
MT. SAN ANTONIO COLLEGE PAYMENT BOND
DOCUMENT 00 61 13.16-1
DOCUMENT 00 61 13.16
PAYMENT BOND
Contractor's Labor & Material Bond
(100% of Contract Price)
(Note: Bidders must use this form, NOT a surety company form.)
KNOW ALL PERSONS BY THESE PRESENTS:
WHEREAS, the governing board (“Board”) of the Mt. San Antonio College, (“Owner”) and , (“Principal”) have entered into a contract for the furnishing of all materials and labor, services and transportation, necessary, convenient, and proper to perform the following project:
(Project Name)
(“Contract”) which Contract dated , 20___, and all of the Contract Documents attached to or forming a part of the Contract, are hereby referred to and made a part hereof; and
WHEREAS, pursuant to law and the Contract, the Principal is required, before entering upon the performance of the work, to file a good and sufficient bond with the body by which the Contract is awarded in an amount equal to one hundred percent (100%) of the Contract price, to secure the claims to which reference is made in sections 9000 through 9510 and 9550 through 9566 of the Civil Code, and division 2, part 7, of the Labor Code.
NOW, THEREFORE, the Principal and , (“Surety”) are held and firmly bound unto all laborers, material men, and other persons referred to in said statutes in the sum of Dollars ($ ), lawful money of the United States, being a sum not less than the total amount payable by the terms of Contract, for the payment of which sum well and truly to be made, we bind ourselves, our heirs, executors, administrators, successors, or assigns, jointly and severally, by these presents.
The condition of this obligation is that if the Principal or any of his or its subcontractors, of the heirs, executors, administrators, successors, or assigns of any, all, or either of them shall fail to pay for any labor, materials, provisions, provender, or other supplies, used in, upon, for or about the performance of the work contracted to be done, or for any work or labor thereon of any kind, or for amounts required to be deducted, withheld, and paid over to the Employment Development Department from the wages of employees of the Principal or any of his or its subcontractors of any tier under Section 13020 of the Unemployment Insurance Code with respect to such work or labor, that the Surety will pay the same in an amount not exceeding the amount herein above set forth, and also in case suit is brought upon this bond, will pay a reasonable attorney’s fee to be awarded and fixed by the Court, and to be taxed as costs and to be included in the judgment therein rendered.
It is hereby expressly stipulated and agreed that this bond shall inure to the benefit of any and all persons, companies, and corporations entitled to file claims under section 9100 of the Civil Code, so as to give a right of action to them or their assigns in any suit brought upon this bond.
Should the condition of this bond be fully performed, then this obligation shall become null and void; otherwise it shall be and remain in full force and affect.
MT. SAN ANTONIO COLLEGE PAYMENT BOND
DOCUMENT 00 61 13.16-2
And the Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration, or addition to the terms of Contract or the specifications accompanying the same shall in any manner affect its obligations on this bond, and it does hereby waive notice of any such change, extension, alteration, or addition.
IN WITNESS WHEREOF, two (2) identical counterparts of this instrument, each of which shall for all purposes be deemed an original thereof, have been duly executed by the Principal and Surety above named, on the day of , 20___.
(Affix Corporate Seal)
Principal
By
Surety
By
Name of California Agent of Surety
Address of California Agent of Surety
Telephone Number of California Agent of Surety
Bidder must attach a Notarial Acknowledgment for all Surety's signatures and a Power of Attorney and Certificate of Authority for Surety. The California Department of Insurance must authorize the Surety to be an admitted surety insurer.
END OF DOCUMENT
File details come from the government source that posted it. Updated .