PH-582-232-002 - HVAC Replacement/Upgrades at Maryland State Police Barrack “H”, La Plata

This state and local contracting opportunity is for the replacement and upgrade of the HVAC system at the Maryland State Police Barrack "H" located in La Plata, Maryland. The project involves replacing the primary air handling unit with a new 40-ton split system AC unit, removing a small 5-ton air handling unit, replacing all existing variable air volume boxes and hot water coils, and replacing the existing barrack and garage boilers. The contractor will be responsible for providing a fully operational HVAC system. The project is being solicited by the Maryland Department of General Services with a total project value classified as "C" ($500,000 - $1,000,000). Bids are due on November 28, 2023, and the project must be completed within 180 calendar days of the notice to proceed, with liquidated damages of $550 per day for late completion. The contractor must be licensed in Maryland and have a minimum of 5 years' experience in similar work.

The contract has a 15% Minority Business Enterprise (MBE) subcontracting participation goal. Respondents must submit the required MBE forms and documentation as part of their bid. Prevailing wage rates apply to this project, and contractors must comply with reporting and compliance requirements. There are no set-asides or restrictions on the types of organizations that can respond, and no incumbent vendors or contractors are identified. The available budget range for this project is $500,000 to $1,000,000.