Repair Roof and HVAC in Navy Facility (Bldg 1560)

The purpose of this Amendment is to: 

(1)  Update Sections L & M of the solicitation SF 1442.  See attachment(s): 

-  Attch 1 - SF1442 Solicitation_FA286020R00440006

 ---Attch 1f - SF30_Amendment_FA286020R00440006

All questions and proposals must be submitted to the Contracting Officer, 1Lt Tarha Mazyck, electronically via email at tarha.mazyck.2@us.af.mil. Offerors are responsible to ensure compliance with FAR 19.15 for this women-owned small business (WOSB) set-side, routinely check beta.sam.gov for updates, and must acknowledge all amendments and respective attachments. 

For more information, see the following attachments: 

-  Attch 1 - SF1442 Solicitation_FA286020R00440006

         ---Attch 1a - SF30_Amendment_FA286020R00440001

         ---Attch 1b - SF30_Amendment_FA286020R00440002

          ---Attch 1c - SF30_Amendment_FA286020R00440003

         ---Attch 1d - SF30_Amendment_FA286020R00440004

          ---Attch 1e - SF30_Amendment_FA286020R00440005

           ---Attch 1f - SF30_Amendment_FA286020R00440005

Attch 2 - 2019_1211 Design Analysis B1560

Attch 3 - 2019_1211 Design Build RFP 1560

Attch 4 - WD MD20200044 (11 Sep 2020)

Attch 5 - Contractor Access Information Sheet (used for site visit access only)

Attch 6 - Blank AF Form 3052

Attch 7  - Site Visit (17 Sep 20) Questions and Answers 

Attch 8 - 2004 Renovation Drawings_B1560

Attch 9 - Site Visit (15 Oct 20) Questions and Answers

Attch 10 - B1560 Original Drawings

Attch 11 - B1560 Phasing 

The purpose of this Amendment is to: 

(1)  Extend the solicitation deadline from 21 October 2020 at 3:00 PM EST to 29 October 2020 at 3:00 PM EST.  See attachment: 

 ---Attch 1e - SF30_Amendment_FA286020R00440005

All questions and proposals must be submitted to the Contracting Officer, 1Lt Tarha Mazyck, electronically via email at tarha.mazyck.2@us.af.mil. Offerors are responsible to routinely check beta.sam.gov for updates and must acknowledge all amendments and respective attachments. 

For more information, see the following attachments: 

-  Attch 1 - SF1442 Solicitation_FA286020R0044

         ---Attch 1a - SF30_Amendment_FA286020R00440001

         ---Attch 1b - SF30_Amendment_FA286020R00440002

          ---Attch 1c - SF30_Amendment_FA286020R00440003

         ---Attch 1d - SF30_Amendment_FA286020R00440004

          ---Attch 1e - SF30_Amendment_FA286020R00440005

Attch 2 - 2019_1211 Design Analysis B1560

Attch 3 - 2019_1211 Design Build RFP 1560

Attch 4 - WD MD20200044 (11 Sep 2020)

Attch 5 - Contractor Access Information Sheet (used for site visit access only)

Attch 6 - Blank AF Form 3052

Attch 7  - Site Visit (17 Sep 20) Questions and Answers 

Attch 8 - 2004 Renovation Drawings_B1560

The purpose of this Amendment is to: 

(1)  Extend the solicitation deadline from 12 October 2020 at 3:00 PM EST to 21 October 2020 at 3:00 PM EST.  See attachment: 

 ---Attch 1d - SF30_Amendment_FA286020R00440004

(2) Provide information for potential offerors to attend a Site Visit on 15 October 2020 as follows: 

The 316th Contraction Squadron at Joint Base Andrews, MD is seeking the  design-build construction services to repair the roof and HVAC of Naval Facility, Building 1560 on the installation.  All work shall be in strict accordance with (IAW) current state, federal and industry standards and other specifications identified in the attached contractual documents. 

A site visit will be conducted at Building 1560, Joint Base Andrews, MD at 10:00 AM EST on  Thursday, 15 October 2020.  All prospective Offerors are urged to attend this conference and are requested to contact 1Lt Tarha Mazyck, Contracting Officer, via  e-mail at tarha.mazyck.2@us.af.mil no later than Tuesday, 13 October 2020 at 1:00 PM EST if they plan to attend.  If attending the site visit and you have base access, when notified of your attendance the Contracting Officer will provide you an address to meet. If you do not have base access, fill out attached base access sheet (see Attch 5 - Contractor Access Information Sheet) and send to 1Lt Tarha Mazyck at tarha.mazyck.2@us.af.mil no later than 13 October 2020 at 1:00 PM EST. The following documentation is required for access: US Citizens must provide a valid Real ID compliant state or federally issued photo ID to include Gold Star driver's license (if driving) or passport;  valid vehicle registration (if driving); and proof of current vehicle insurance with expiration date displayed (if driving). Additionally, Non-US Citizens are required to provide a  resident alien card; work authorization card and social security card. 

Offerors are cautioned that Joint Base Andrews has visitor control procedures requiring individuals not affiliated with the installation to obtain a visitor pass prior to entrance. An offerors' failure to submit requested information at the aforementioned date/time may result in the ability to access the installation and attend the site visit. Due to the Coronavirus pandemic, JBA is currently under HPCON Bravo. SOME DELAY SHOULD BE ANTICIPATED.  Offerors may submit no more than two (2) representatives to attend the site visit and all representatives must bring and wear proper PPE (face mask that covers mouth and nose). 

Funds are not presently available for this effort. No award will be made under this solicitation until funds become available. The Government reserves the right to cancel this solicitation, either before or after the closing date. In the event the Government cancels this solicitation, the Government has no obligation to reimburse the contractor for any costs.

All questions and proposals must be submitted to the Contracting Officer, 1Lt Tarha Mazyck, electronically via email at tarha.mazyck.2@us.af.mil. Offerors are responsible to routinely check beta.sam.gov for updates and must acknowledge all amendments and respective attachments. 

For more information, see the following attachments: 

-  Attch 1 - SF1442 Solicitation_FA286020R0044

         ---Attch 1a - SF30_Amendment_FA286020R00440001

         ---Attch 1b - SF30_Amendment_FA286020R00440002

          ---Attch 1c - SF30_Amendment_FA286020R00440003

         ---Attch 1d - SF30_Amendment_FA286020R00440004

Attch 2 - 2019_1211 Design Analysis B1560

Attch 3 - 2019_1211 Design Build RFP 1560

Attch 4 - WD MD20200044 (11 Sep 2020)

Attch 5 - Contractor Access Information Sheet (used for site visit access only)

Attch 6 - Blank AF Form 3052

Attch 7  - Site Visit (17 Sep 20) Questions and Answers 

Attch 8 - 2004 Renovation Drawings_B1560

The purpose of this Amendment is to provide: 

(1)  Extend the solicitation deadline from 23 September 2020 at 3:00 PM EST to 12 October 2020 at 3:00 PM EST and add 2004 Renovation Drawings to Section J of the SF1442. See updated attachment(s): 

 ---Attch 1c - SF30_Amendment_FA286020R00440003

(2) Submit Questions and Answers from the Site Visit held 17 September 2020.  See Attch 7 - Site Visit (17 Sep 20) Questions and Answers. 

(3) Submit 2004 Renovation Drawings (to accompany Questions and Answers in item (2) above). See Attch 8 - 2004 Renovation Drawings_B1560

The 316th Contraction Squadron at Joint Base Andrews, MD is seeking the  design-build construction services to repair the roof and HVAC of Naval Facility, Building 1560 on the installation.  All work shall be in strict accordance with (IAW) current state, federal and industry standards and other specifications identified in the attached contractual documents. 

Funds are not presently available for this effort. No award will be made under this solicitation until funds become available. The Government reserves the right to cancel this solicitation, either before or after the closing date. In the event the Government cancels this solicitation, the Government has no obligation to reimburse the contractor for any costs.

All questions and proposals must be submitted to the Contracting Officer, 1Lt Tarha Mazyck, electronically via email at tarha.mazyck.2@us.af.mil. Offerors are responsible to routinely check beta.sam.gov for updates and must acknowledge all amendments and respective attachments. 

For more information, see the following attachments: 

-  Attch 1 - SF1442 Solicitation_FA286020R0044

         ---Attch 1a - SF30_Amendment_FA286020R00440001

         ---Attch 1b - SF30_Amendment_FA286020R00440002

          ---Attch 1c - SF30_Amendment_FA286020R00440003

Attch 2 - 2019_1211 Design Analysis B1560

Attch 3 - 2019_1211 Design Build RFP 1560

Attch 4 - WD MD20200044 (11 Sep 2020)

Attch 5 - Contractor Access Information Sheet (used for site visit access only)

Attch 6 - Blank AF Form 3052

Attch 7  - Site Visit (17 Sep 20) Questions and Answers 

Attch 8 - 2004 Renovation Drawings_B1560

The purpose of this Amendment is to provide: 

(1) Extend the solicitation deadline from 21 September 2020 at 1:00 PM EST to 23 September 2020 at 3:00 PM EST.  See updated attachment(s): 

-  Attch 1 - Solicitation FA286020R0044

         ---Attch 1a - SF30_Amendment_FA286020R00440001

         ---Attch 1b - SF30_Amendment_FA286020R00440002

All other terms and conditions remain unchanged and in full force and effect. 

The 316th Contraction Squadron at Joint Base Andrews, MD is seeking the  design-build construction services to repair the roof and HVAC of Naval Facility, Building 1560 on the installation.  All work shall be in strict accordance with (IAW) current state, federal and industry standards and other specifications identified in the attached contractual documents. 

A site visit will be conducted at Building 1560, Joint Base Andrews, MD at 11:00 AM EST on  Thursday, 17 September 2020.  All prospective Offerors are urged to attend this conference and are requested to contact 1Lt Tarha Mazyck, Contracting Officer, via  e-mail at tarha.mazyck.2@us.af.mil no later than 15 September 2020 at 2:00PM EST if they plan to attend.  If attending the site visit and you have base access, when notified of your attendance the Contracting Officer will provide you an address to meet. If you do not have base access, fill out attached base access sheet (see Attch 5 - Contractor Access Information Sheet) and send to 1Lt Tarha Mazyck at tarha.mazyck.2@us.af.mil no later than 15 September 2020 at 2:00 PM EST. The following documentation is required for access: US Citizens must provide a valid Real ID compliant state or federally issued photo ID to include Gold Star driver's license (if driving) or passport;  valid vehicle registration (if driving); and proof of current vehicle insurance with expiration date displayed (if driving). Additionally, Non-US Citizens are required to provide a  resident alien card; work authorization card and social security card. 

Offerors are cautioned that Joint Base Andrews has visitor control procedures requiring individuals not affiliated with the installation to obtain a visitor pass prior to entrance. An offerors' failure to submit requested information at the aforementioned date/time may result in the ability to access the installation and attend the site visit. Due to the Coronavirus pandemic, JBA is currently under HPCON Bravo. SOME DELAY SHOULD BE ANTICIPATED.  Offerors may submit no more than two (2) representatives to attend the site visit and all representatives must bring and wear proper PPE (face mask that covers mouth and nose). 

Funds are not presently available for this effort. No award will be made under this solicitation until funds become available. The Government reserves the right to cancel this solicitation, either before or after the closing date. In the event the Government cancels this solicitation, the Government has no obligation to reimburse the contractor for any costs.

All questions and proposals must be submitted to the Contracting Officer, 1Lt Tarha Mazyck, electronically via email at tarha.mazyck.2@us.af.mil.

See the following attachments: 

-  Attch 1 - Solicitation FA286020R0044

         ---Attch 1a - SF30_Amendment_FA286020R00440001

         ---Attch 1b - SF30_Amendment_FA286020R00440002

Attch 2 - 2019_1211 Design Analysis B1560

Attch 3 - 2019_1211 Design Build RFP 1560

Attch 4 - WD MD20200044 (11 Sep 2020)

Attch 5 - Contractor Access Information Sheet 

Attch 6 - Blank AF Form 3052

The purpose of this Amendment is to provide: 

(1) Extend the solicitation deadline from 21 September 2020 at 1:00 PM EST to 23 September 2020 at 3:00 PM EST.  

All other terms and conditions remain unchanged and in full force and effect. 

The 316th Contraction Squadron at Joint Base Andrews, MD is seeking the  design-build construction services to repair the roof and HVAC of Naval Facility, Building 1560 on the installation.  All work shall be in strict accordance with (IAW) current state, federal and industry standards and other specifications identified in the attached contractual documents. 

A site visit will be conducted at Building 1560, Joint Base Andrews, MD at 11:00 AM EST on  Thursday, 17 September 2020.  All prospective Offerors are urged to attend this conference and are requested to contact 1Lt Tarha Mazyck, Contracting Officer, via  e-mail at tarha.mazyck.2@us.af.mil no later than 15 September 2020 at 2:00PM EST if they plan to attend.  If attending the site visit and you have base access, when notified of your attendance the Contracting Officer will provide you an address to meet. If you do not have base access, fill out attached base access sheet (see Attch 5 - Contractor Access Information Sheet) and send to 1Lt Tarha Mazyck at tarha.mazyck.2@us.af.mil no later than 15 September 2020 at 2:00 PM EST. The following documentation is required for access: US Citizens must provide a valid Real ID compliant state or federally issued photo ID to include Gold Star driver's license (if driving) or passport;  valid vehicle registration (if driving); and proof of current vehicle insurance with expiration date displayed (if driving). Additionally, Non-US Citizens are required to provide a  resident alien card; work authorization card and social security card. 

Offerors are cautioned that Joint Base Andrews has visitor control procedures requiring individuals not affiliated with the installation to obtain a visitor pass prior to entrance. An offerors' failure to submit requested information at the aforementioned date/time may result in the ability to access the installation and attend the site visit. Due to the Coronavirus pandemic, JBA is currently under HPCON Bravo. SOME DELAY SHOULD BE ANTICIPATED.  Offerors may submit no more than two (2) representatives to attend the site visit and all representatives must bring and wear proper PPE (face mask that covers mouth and nose). 

Funds are not presently available for this effort. No award will be made under this solicitation until funds become available. The Government reserves the right to cancel this solicitation, either before or after the closing date. In the event the Government cancels this solicitation, the Government has no obligation to reimburse the contractor for any costs.

All questions and proposals must be submitted to the Contracting Officer, 1Lt Tarha Mazyck, electronically via email at tarha.mazyck.2@us.af.mil.

See the following attachments: 

Attch 1  - Solicitation Amendment_FA286020R00440001

Attch 2 - 2019_1211 Design Analysis B1560

Attch 3 - 2019_1211 Design Build RFP 1560

Attch 4 - WD MD20200044 (11 Sep 2020)

Attch 5 - Contractor Access Information Sheet 

Attch 6 - Blank AF Form 3052

The purpose of this Amendment is to provide: 

(1) Solicitation Amendment FA2860R00440001. See Attch 1 - Soliciation Amendment_FA286020R00440001. This document incorporates the following changes: 

- Update Block 10 details; 
- Update Block 13 from ten (10) to sixty (60) days
- Remove non-applicable clauses: 52.211-11; 252.215-7009; and 5352.223-9001
- Add LPO DoDAAC to WAWF clause 252.232-7006
- Update CLIN 0001 and add CLIN 0002

(All other terms and conditions remain unchanged and in full force and effect)

(2) Updated Wage Determination. See Attch 4 - WD MD20200044 (11Sep20)

(3)  Blank  AF Form 3052. See Attch 6 - AF Form 3052

(4) Point-of-Contact information for the Contract Specialist, Mr. Dennis Early

The 316th Contraction Squadron at Joint Base Andrews, MD is seeking the  design-build construction services to repair the roof and HVAC of Naval Facility, Building 1560 on the installation.  All work shall be in strict accordance with (IAW) current state, federal and industry standards and other specifications identified in the attached contractual documents. 

A site visit will be conducted at Building 1560, Joint Base Andrews, MD at 11:00 AM EST on  Thursday, 17 September 2020.  All prospective Offerors are urged to attend this conference and are requested to contact 1Lt Tarha Mazyck, Contracting Officer, via  e-mail at tarha.mazyck.2@us.af.mil no later than 15 September 2020 at 2:00PM EST if they plan to attend.  If attending the site visit and you have base access, when notified of your attendance the Contracting Officer will provide you an address to meet. If you do not have base access, fill out attached base access sheet (see Attch 5 - Contractor Access Information Sheet) and send to 1Lt Tarha Mazyck at tarha.mazyck.2@us.af.mil no later than 15 September 2020 at 2:00 PM EST. The following documentation is required for access: US Citizens must provide a valid Real ID compliant state or federally issued photo ID to include Gold Star driver's license (if driving) or passport;  valid vehicle registration (if driving); and proof of current vehicle insurance with expiration date displayed (if driving). Additionally, Non-US Citizens are required to provide a  resident alien card; work authorization card and social security card. 

Offerors are cautioned that Joint Base Andrews has visitor control procedures requiring individuals not affiliated with the installation to obtain a visitor pass prior to entrance. An offerors' failure to submit requested information at the aforementioned date/time may result in the ability to access the installation and attend the site visit. Due to the Coronavirus pandemic, JBA is currently under HPCON Bravo. SOME DELAY SHOULD BE ANTICIPATED.  Offerors may submit no more than two (2) representatives to attend the site visit and all representatives must bring and wear proper PPE (face mask that covers mouth and nose). 

Funds are not presently available for this effort. No award will be made under this solicitation until funds become available. The Government reserves the right to cancel this solicitation, either before or after the closing date. In the event the Government cancels this solicitation, the Government has no obligation to reimburse the contractor for any costs.

All questions and proposals must be submitted to the Contracting Officer, 1Lt Tarha Mazyck, electronically via email at tarha.mazyck.2@us.af.mil.

See the following attachments: 

Attch 1  - Solicitation Amendment_FA286020R00440001

Attch 2 - 2019_1211 Design Analysis B1560

Attch 3 - 2019_1211 Design Build RFP 1560

Attch 4 - WD MD20200044 (11 Sep 2020)

Attch 5 - Contractor Access Information Sheet 

Attch 6 - Blank AF Form 3052

The purpose of this Amendment is to provide an updated Attch 5 - Contractor Access Information Sheet and solicitation details as follows:   

The 316th Contraction Squadron at Joint Base Andrews, MD is seeking the  design-build construction services to repair the roof and HVAC of Naval Facility, Building 1560 on the installation.  All work shall be in strict accordance with (IAW) current state, federal and industry standards and other specifications identified in the attached contractual documents. 

A site visit will be conducted at Building 1560, Joint Base Andrews, MD at 11:00 AM EST on  Thursday, 17 September 2020.  All prospective Offerors are urged to attend this conference and are requested to contact 1Lt Tarha Mazyck, Contracting Officer, via  e-mail at tarha.mazyck.2@us.af.mil no later than 15 September 2020 at 2:00PM EST if they plan to attend.  If attending the site visit and you have base access, when notified of your attendance the Contracting Officer will provide you an address to meet. If you do not have base access, fill out attached base access sheet (see Attch 5 - Contractor Access Information Sheet) and send to 1Lt Tarha Mazyck at tarha.mazyck.2@us.af.mil no later than 15 September 2020 at 2:00 PM EST. The following documentation is required for access: US Citizens must provide a valid Real ID compliant state or federally issued photo ID to include Gold Star driver's license (if driving) or passport;  valid vehicle registration (if driving); and proof of current vehicle insurance with expiration date displayed (if driving). Additionally, Non-US Citizens are required to provide a  resident alien card; work authorization card and social security card. 

Offerors are cautioned that Joint Base Andrews has visitor control procedures requiring individuals not affiliated with the installation to obtain a visitor pass prior to entrance. An offerors' failure to submit requested information at the aforementioned date/time may result in the ability to access the installation and attend the site visit. Due to the Coronavirus pandemic, JBA is currently under HPCON Bravo. SOME DELAY SHOULD BE ANTICIPATED.  Offerors may submit no more than two (2) representatives to attend the site visit and all representatives must bring and wear proper PPE (face mask that covers mouth and nose). 

Funds are not presently available for this contract. The Government’s obligation under a contract is contingent upon the availability of appropriated funds from which payment for contract purposes can be made. No legal liability on the part of the Government for any payment may arise until funds are made available to the Contracting Officer for this contract and until the Contractor receives notice of such availability, to be confirmed in writing by the Contracting Officer. The government reserves the right to cancel this solicitation, either before or after the closing date for receipt of proposals. In the event the government cancels this solicitation the government has no obligation to reimburse or offeror any costs incurred in preparation of a proposal.

All questions and proposals must be submitted to the Contracting Officer, 1Lt Tarha Mazyck, electronically via email at tarha.mazyck.2@us.af.mil.

See the following attachments: 

Attch 1  -  Solicitation _FA286020R0044

Attch 2 - 2019_1211 Design Analysis B1560

Attch 3 - 2019_1211 Design Build RFP 1560

Attch 4 - WD MD20200044 (066262020)

Attch 5 - Contractor Access Information Sheet 

All other terms and conditions of the solicitation remain unchanged and in full force and effect. End of Amendment. 

The 316th Contraction Squadron at Joint Base Andrews, MD is seeking the  design-build construction services to repair the roof and HVAC of Naval Facility, Building 1560 on the installation.  All work shall be in strict accordance with (IAW) current state, federal and industry standards and other specifications identified in the attached contractual documents. 

The purpose of this Amendment is to provide site visit details and attachments as follows:   

A site visit will be conducted at Building 1560, Joint Base Andrews, MD at 11:00 AM EST on  Thursday, 17 September 2020.  All prospective Offerors are urged to attend this conference and are requested to contact 1Lt Tarha Mazyck, Contracting Officer, via  e-mail at tarha.mazyck.2@us.af.mil no later than 15 September 2020 at 2:00PM EST if they plan to attend.  If attending the site visit and you have base access, when notified of your attendance the Contracting Officer will provide you an address to meet. If you do not have base access, fill out attached base access form (see Attch 5 - Contractor Access Form) and send to 1Lt Tarha Mazyck at tarha.mazyck.2@us.af.mil no later than 15 September 2020 at 2:00 PM EST. The following documentation is required for access: US Citizens must provide a valid Real ID compliant state or federally issued photo ID to include Gold Star driver's license (if driving) or passport;  valid vehicle registration (if driving); and proof of current vehicle insurance with expiration date displayed (if driving). Additionally, Non-US Citizens are required to provide a  resident alien card; work authorization card and social security card. 

Offerors are cautioned that Joint Base Andrews has visitor control procedures requiring individuals not affiliated with the installation to obtain a visitor pass prior to entrance. An offerors' failure to submit requested information at the aforementioned date/time may result in the ability to access the installation and attend the site visit. Due to the Coronavirus pandemic, JBA is currently under HPCON Bravo. SOME DELAY SHOULD BE ANTICIPATED.  Offerors may submit no more than two (2) representatives to attend the site visit and all representives must bring and wear proper PPE (face mask that covers mouth and nose). 

All other terms and conditions of the solicitation remain unchanged and in full force and effect. End of Amendment. 

The 316th Contraction Squadron at Joint Base Andrews, MD is seeking the  design-build construction services to repair the roof and HVAC of Naval Facility, Building 1560 on the installation.  All work shall be in strict accordance with (IAW) current state, federal and industry standards and other specifications identified in the attached contractual documents.