Construction - NUWCDIVNPT Facilities Stairwell Renovation Project
Closed Solicitation Posted
This opportunity was awarded. See the award notice from .
- Solicitation number
- N6660425Q0084
- Agency
- Naval Sea Systems Command Department of the Navy, Department of Defense
- Responses due
- Set-aside
- Total Small Business
Opportunity facts
- NAICS code
- 236220 Commercial and Institutional Building Construction
- Place of performance
- Newport, Rhode Island 02841, United States
- Points of contact
-
- Michael Ouellette michael.n.ouellette.civ@us.navy.mil (401) 832-5568
- Alexander Olarte alexander.olarte.civ@us.navy.mil (401) 832-2648
Notice details come from SAM.gov. Updated .
About this opportunity
The Naval Undersea Warfare Center Division, Newport (NUWCDIVNPT) is seeking a construction contractor to complete a Facilities Stairwell Renovation Project across multiple buildings, specifically Buildings B1171, 1246, 1258, and 1259. The Department of the Navy Naval Sea Systems Command will award a firm-fixed price contract for comprehensive stairwell renovations, which includes painting, lead paint abatement through encapsulation, and addressing various structural improvements. Contractors must be registered in SAM.gov and submit proposals electronically by December 13, 2024, at 2:00 PM EST, following a mandatory site visit held on November 6, 2024. The government will evaluate proposals based on relevant past performance and technical capability to complete the project, with a focus on demonstrating the ability to meet specifications and renovation requirements. Proposals must include bid guarantees, and the contract includes liquidated damages of $200 per day for late completion.
This solicitation is a 100% small business set-aside under NAICS code 236220, with a size standard of $45 million, targeting commercial and institutional building construction contractors. The contract has a 180-day period of performance and an estimated value between $100,000 and $250,000, with electronic payment processed through Wide Area Workflow (WAWF). The place of performance is located in Newport, Rhode Island (02841), and contractors will be required to follow the attached Davis-Bacon wage determination for labor classifications. While no specific incumbent contractors are mentioned, interested parties must have the capability to manage controlled documents and potentially request special access through SAM.gov. The project involves intricate renovation work, including wall-hanging material management, specific painting requirements, and adherence to strict finish standards for elements like handrails.
Notice text
3 versions
Update #3 · Latest ·
The Naval Undersea Warfare Center Division, Newport (NUWCDIVNPT) has a construction requirement for the renovation of multiple stairwells throughout various buildings. Please see attached Solicitation (N6660425Q0084) and all attachments for full information and details regarding this requirement.
Contractors do not have to be JCP certified to receive the Solicitation, including drawings, specifications, and photos, but they must have an active registration in SAM.GOV.
Interested parties should request access to drawings, specifications, and photos within the attachments section of this solicitation. NUWCDIVNPT will review and approved requests within SAM.GOV.
A controlled attachment requires special handling due to the information it contains. You must have a data entry or administrator role within the Contract Opportunities domain for an entity in SAM.gov in order to request access. If you do not have a proper role, you can request it from an existing entity administrator or have the existing administrator assign roles directly to you. If your entity does not have a direct employee, officer or board member appointed as the Entity Administrator, you will need to complete an Entity Administrator Appointment Letter.
You must request access to the attachment by clicking on its title and providing the reason you need access.
You will not receive immediate access to view the document. The contracting officer will review your request to grant or reject your access.
Your entity is responsible for managing the documents in accordance with prescribed directives.
https://www.fsd.gov/gsafsd_sp?id=gsafsd_kb_articles&sys_id=733b9d881bbc71506397ec21f54bcb0a
Please See Amendment 0001 attached.
Please See Amendment 0002 attached.
Update #2 ·
The Naval Undersea Warfare Center Division, Newport (NUWCDIVNPT) has a construction requirement for the renovation of multiple stairwells throughout various buildings. Please see attached Solicitation (N6660425Q0084) and all attachments for full information and details regarding this requirement.
Contractors do not have to be JCP certified to receive the Solicitation, including drawings, specifications, and photos, but they must have an active registration in SAM.GOV.
Interested parties should request access to drawings, specifications, and photos within the attachments section of this solicitation. NUWCDIVNPT will review and approved requests within SAM.GOV.
A controlled attachment requires special handling due to the information it contains. You must have a data entry or administrator role within the Contract Opportunities domain for an entity in SAM.gov in order to request access. If you do not have a proper role, you can request it from an existing entity administrator or have the existing administrator assign roles directly to you. If your entity does not have a direct employee, officer or board member appointed as the Entity Administrator, you will need to complete an Entity Administrator Appointment Letter.
You must request access to the attachment by clicking on its title and providing the reason you need access.
You will not receive immediate access to view the document. The contracting officer will review your request to grant or reject your access.
Your entity is responsible for managing the documents in accordance with prescribed directives.
https://www.fsd.gov/gsafsd_sp?id=gsafsd_kb_articles&sys_id=733b9d881bbc71506397ec21f54bcb0a
Please See Amendment 0001 attached.
Update #1 ·
The Naval Undersea Warfare Center Division, Newport (NUWCDIVNPT) has a construction requirement for the renovation of multiple stairwells throughout various buildings. Please see attached Solicitation (N6660425Q0084) and all attachments for full information and details regarding this requirement.
Contractors do not have to be JCP certified to receive the Solicitation, including drawings, specifications, and photos, but they must have an active registration in SAM.GOV.
Interested parties should request access to drawings, specifications, and photos within the attachments section of this solicitation. NUWCDIVNPT will review and approved requests within SAM.GOV.
A controlled attachment requires special handling due to the information it contains. You must have a data entry or administrator role within the Contract Opportunities domain for an entity in SAM.gov in order to request access. If you do not have a proper role, you can request it from an existing entity administrator or have the existing administrator assign roles directly to you. If your entity does not have a direct employee, officer or board member appointed as the Entity Administrator, you will need to complete an Entity Administrator Appointment Letter.
You must request access to the attachment by clicking on its title and providing the reason you need access.
You will not receive immediate access to view the document. The contracting officer will review your request to grant or reject your access.
Your entity is responsible for managing the documents in accordance with prescribed directives.
https://www.fsd.gov/gsafsd_sp?id=gsafsd_kb_articles&sys_id=733b9d881bbc71506397ec21f54bcb0a
Attachments
| File | Type | Posted |
|---|---|---|
| N6660425Q0084 Amendment 0002.pdf | ||
| N6660425Q0084 Amendment 0001.pdf | ||
| Attachment_4_Davis Bacon RI WD 10_11_2024.pdf | ||
| N6660425Q0084.pdf |
Notice history
| Notice | Type | Posted |
|---|---|---|
| Construction - NUWCDIVNPT Facilities Stairwell Renovation Project | Award Notice | |
| Construction - NUWCDIVNPT Facilities Stairwell Renovation Project | Solicitation |
On GovTribe
Work this opportunity on GovTribe
- Track it in your pipeline
- Find teaming partners
- Similar opportunities
- Ask GovTribe AI about this opportunity