A21_Solicitation-Amendment_1_-_W91QVN-17-R-0091-0001_(CONFORM_COPY).pdf

SEE ADDENDUM

(No Collect Calls)

W91QVN-17-R-0091 15-May-2017

b. TELEPHONE NUMBER

02-7914-7565

8. OFFER DUE DATE/LOCAL TIME

01:00 PM 14 Jun 2017

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

W91QVN9. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

MS. CHONG, SO-HUI

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

0 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED ORX

SMALL BUSINESS

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

411TH CONTRACTING SUPPORT BRIGADE, KOREA

RCC YONGSAN, UNIT #15289

APO AP 96205-5289

UNITED STATES OF AMERICA (THE)

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS A

13b. RATING

CODE15. DELIVER TO CODE WT4G3U 16. ADMINISTERED BY

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

HHC, 1ST SIG BDE

1ST SIGNAL BRIGADE

UNIT #15271

APO AP 96205-5271

UNITED STATES OF AMERICA (THE)

TEL: (0505) 725-6973 FAX: .

FAX:

TEL: SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

NAICS:

238210

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF193

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

W91QVN-17-R-0091

Section SF 30 - BLOCK 14 CONTINUATION PAGE

SOLICITATION NOTES

***ADMINISTRATIVE NOTE: Original Solicitation W91QVN-17-R-0091 has not been issued and will be replaced by Amendment W91QVN-17-R-0091-0001 (Conform Copy).***

Section SF 1449 - CONTINUATION SHEET

ITEM NO SUPPLIES/SERVICES MAX

QUANTITY

UNIT UNIT PRICE MAX AMOUNT

0001 40,000 Linear Foot

COPPER CABLE

FFP

Install, Splice, Terminate, and Test - Copper Cable (25 to 1200 PR).

FOB: Destination

MAX

NET AMT

UNIT UNIT PRICE MAX AMOUNT

0002 100 Each

GROUND ROD

FFP

Install Ground Rod to Include Grounding of Cable / Terminal.

UNIT UNIT PRICE MAX AMOUNT

0003 50 Each

PET HOUSING

FFP

Install Protected Entrance Terminal (PET) Housing for Copper Cable.

UNIT UNIT PRICE MAX AMOUNT

0004 50 Each

SPLICE CASE FOR COPPER CABLE

FFP

Install Splice Case for Copper Cable.

UNIT UNIT PRICE MAX AMOUNT

0005 40 Each

¾ INCH, FIRE-RETARDANT PLYWOOD BACKBOARD

FFP

Provide Contractor Furnished Material (CFM) and Install ¾ Inch, Fire-Retardant Plywood Backboard.

UNIT UNIT PRICE MAX AMOUNT

0006 160,000 Linear

FIBER OPTIC CABLE IN DUCT

Install, Terminate, Splice, and Test - Fiber Optic Cable in Duct (2 to 144 Fiber Cores).

UNIT UNIT PRICE MAX AMOUNT

0007 800,000 Linear

LEAF FIBER OPTIC CABLE IN DUCT

Install, Terminate, Splice, and Test - LEAF Fiber Optic Cable in Duct (12 to 96 Fiber Cores).

UNIT UNIT PRICE MAX AMOUNT

0008 100 Each

TERMINATION PANEL

FFP

Install Fiber Optic - Termination Panel (Wall Mount or Rack).

UNIT UNIT PRICE MAX AMOUNT

0009 100 Each

SPLICE ENCLOSURE KIT

Install Fiber Optic Cable - Splice Enclosure Kit (12 to 144 Cores).

UNIT UNIT PRICE MAX AMOUNT

0010 5,000 Linear

ENCASED BURIED (EB)-20 CONDUIT

Provide Contractor Furnished Material (CFM) and Install 4 Inch (1 to 4 Ducts) Encased Buried (EB)-20 Conduit Where Vehicular Traffic (i.e., Automotive, Railway) is Present.

Duct Installation to Include Excavation, Backfill, Restoration of Paved and Concrete Surfaces, Concrete Encasing, Spacers, Markers and Warning Tape(Paved Area).

UNIT UNIT PRICE MAX AMOUNT

0011 20,000 Linear

RIGID NONMETALLIC CONDUIT

Provide Contractor Furnished Material (CFM) and Install 4 Inch (1 to 4 Ducts) Rigid Nonmetallic Conduit Schedule 40 PVC Conduit.

Duct Installation to Include Excavation, Backfill, Markers and Warning Tape.

UNIT UNIT PRICE MAX AMOUNT

0012 10,000 Linear

SUB / MULTI / MESH INNERDUCT

Install Sub-Duct / Innerduct / Multi-Duct / Fabric-Mesh Innerduct.

UNIT UNIT PRICE MAX AMOUNT

0013 1,000 Each

CORE DRILL ½ TO 4 INCH HOLE

FFP

Core Drill ½ to 4 Inch Hole.

UNIT UNIT PRICE MAX AMOUNT

0014 50 Each

2 TO 4 INCH BUILDING ENTRANCE CONDUIT

FFP

Provide Contractor Furnished Material (CFM) and Install 2 to 4 Inch Building Entrance Conduit.

UNIT UNIT PRICE MAX AMOUNT

0015 25 Each

MULTIDIRECTIONAL HANDHOLE

FFP

Provide Contractor Furnished Material (CFM) and Install Multidirectional 1220 x 1220mm x 1220 Millimeter Handhole to Include Excavation, Restoration, Backfill, Plugging Ducts, All Hardware and Grounding Installation.

UNIT UNIT PRICE MAX AMOUNT

0016 5 Each

MULTIDIRECTIONAL MAINTENANCE HOLE

FFP

Provide Contractor Furnished Material (CFM) and Install Multidirectional W1850 x L3700 x H2150 Millimeter Maintenance Hole to Include Excavation, Restoration, Backfill, Plugging Ducts, All Hardware and Grounding Installation.

UNIT UNIT PRICE MAX AMOUNT

0017 500,000 Linear

CAT 6 LAN CABLE

Install, Terminate, and Test CAT 6 LAN Cable.

UNIT UNIT PRICE MAX AMOUNT

0018 500 Each

CAT 6 WALL OUTLET BOX

FFP

Install CAT 6 Wall Outlet Box.

UNIT UNIT PRICE MAX AMOUNT

0019 30,000 Linear

NON-METALLIC RACEWAY

Install Non-Metallic Raceway.

UNIT UNIT PRICE MAX AMOUNT

0020 10 Linear

6 TO 12 INCH METAL CABLE LADDER RACK

Install and Bonding of 6 to 12 Inch Metal Cable Ladder Rack.

UNIT UNIT PRICE MAX AMOUNT

0021 10 Each

EQUIPMENT RACK

FFP

Install Equipment Rack.

UNIT UNIT PRICE MAX AMOUNT

0022 50,000 Linear

STRAND AND GUY WIRES FOR AERIAL CABLE

Provide Contractor Furnished Material (CFM) and Install Strand and Guy Wires for Aerial Cable.

UNIT UNIT PRICE MAX AMOUNT

0023 65,000 Linear

CABLE ON STRAND USING LASHING MACHINE

Install Cable on Strand Using Lashing Machine to Include Splicing, Termination, and Testing of Cable.

UNIT UNIT PRICE MAX AMOUNT

0024 20 Each

SPLICE CASE ON STRAND

FFP

Install Splice Case on Strand.

UNIT UNIT PRICE MAX AMOUNT

0025 35,000 Linear

½ TO 2 INCH EMT CONDUIT INSIDE

Installation of ½ to 2 Inch Electrical Metallic Tubing (EMT) Conduit Inside of Building.

UNIT UNIT PRICE MAX AMOUNT

0026 10 Each

PULL OR DROP BOX FOR PDS

FFP

Install Pull or Drop Box for Protected Distribution System (PDS).

UNIT UNIT PRICE MAX AMOUNT

0027 100 Linear

GIP 4 INCH CONDUIT WITH COUPLINGS INSIDE

Provide Contractor Furnished Material (CFM) and Install Galvanized (GIP) 4 Inch Conduit with Couplings Inside of Building.

UNIT UNIT PRICE MAX AMOUNT

0028 200 Linear

GIP 4 INCH CONDUIT WITH COUPLINGS BURIED

Provide Contractor Furnished Material (CFM) and Install Galvanized (GIP) 4 Inch Conduit with Couplings Buried at a Minimum of 1 Meter Below the Surface, Encased Within a Minimum of 20 Centimeters of Concrete On All Sides.

UNIT UNIT PRICE MAX AMOUNT

0029 1,000,000 Linear

DEINSTALL CABLE IN CONDUITS

Deinstall Cable in Conduits.

UNIT UNIT PRICE MAX AMOUNT

0030 6,000 Linear

CIS TYPE 25 MILLIMETER X 4 EACH

Provide Contractor Furnished Material (CFM) and Install Combined Innerduct System (CIS) Type 25 Millimeter X 4 Each (Black, Yellow, Red, Green).

UNIT UNIT PRICE MAX AMOUNT

0031 40 Each

OUTSIDE PULL-BOX

FFP

Install Outside Pull-Box (Various Sizes).

UNIT UNIT PRICE MAX AMOUNT

0032 1,000,000 Linear

PULLING WIRE IN DUCTS

Provide Contractor Furnished Material (CFM) and Install Pulling Wire in Ducts.

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0033 1 Job

ACCOUNTING FOR CONTRACT SERVICES

FFP

Contractor Manpower Reporting (CMR) Must be Reported by 31 October of Each Calendar Year During the Life of the Contract.

ESTIMATED COST FOR WAR HAZARD LOSSES

FFP

Estimated Cost for War Hazard Losses is Zero ($0.00).

UNIT UNIT PRICE MAX AMOUNT

1001 40,000 Linear

OPTION COPPER CABLE

UNIT UNIT PRICE MAX AMOUNT

1002 100 Each

OPTION GROUND ROD

FFP

UNIT UNIT PRICE MAX AMOUNT

1003 50 Each

OPTION PET HOUSING

FFP

UNIT UNIT PRICE MAX AMOUNT

1004 50 Each

OPTION SPLICE CASE FOR COPPER CABLE

FFP

UNIT UNIT PRICE MAX AMOUNT

1005 40 Each

OPTION ¾ INCH, FIRE-RETARDANT PLYWOOD BACKBOARD

FFP

Provide Contractor Furnished Material (CFM) and Install ¾ Inch, Fire-Retardant

UNIT UNIT PRICE MAX AMOUNT

1006 160,000 Linear

OPTION FIBER OPTIC CABLE IN DUCT

Install, Terminate, Splice, and Test - Fiber Optic Cable in Duct (2 to 144 Fiber

UNIT UNIT PRICE MAX AMOUNT

1007 800,000 Linear

OPTION LEAF FIBER OPTIC CABLE IN DUCT

Install, Terminate, Splice, and Test - LEAF Fiber Optic Cable in Duct (12 to 96

UNIT UNIT PRICE MAX AMOUNT

1008 100 Each

OPTION TERMINATION PANEL

FFP

UNIT UNIT PRICE MAX AMOUNT

1009 100 Each

OPTION SPLICE ENCLOSURE KIT

UNIT UNIT PRICE MAX AMOUNT

1010 5,000 Linear

OPTION ENCASED BURIED (EB)-20 CONDUIT

Provide Contractor Furnished Material (CFM) and Install 4 Inch (1 to 4 Ducts) Encased Buried (EB)-20 Conduit Where Vehicular Traffic (i.e., Automotive, Railway) is Present.

Duct Installation to Include Excavation, Backfill, Restoration of Paved and Concrete Surfaces, Concrete Encasing, Spacers, Markers and Warning

UNIT UNIT PRICE MAX AMOUNT

1011 20,000 Linear

OPTION RIGID NONMETALLIC CONDUIT

Provide Contractor Furnished Material (CFM) and Install 4 Inch (1 to 4 Ducts) Rigid Nonmetallic Conduit Schedule 40 PVC Conduit.

UNIT UNIT PRICE MAX AMOUNT

1012 10,000 Linear

OPTION SUB / MULTI / MESH INNERDUCT

UNIT UNIT PRICE MAX AMOUNT

1013 1,000 Each

OPTION CORE DRILL ½ TO 4 INCH HOLE

FFP

UNIT UNIT PRICE MAX AMOUNT

1014 50 Each

OPTION 2 TO 4 INCH BUILDING ENTRANCE CONDUIT

FFP

Provide Contractor Furnished Material (CFM) and Install 2 to 4 Inch Building

UNIT UNIT PRICE MAX AMOUNT

1015 25 Each

OPTION MULTIDIRECTIONAL HANDHOLE

FFP

Provide Contractor Furnished Material (CFM) and Install Multidirectional 1220 x 1220mm x 1220 Millimeter Handhole to Include Excavation, Restoration, UNIT UNIT PRICE MAX AMOUNT

1016 5 Each

OPTION MULTIDIRECTIONAL MAINTENANCE HOLE

FFP

Provide Contractor Furnished Material (CFM) and Install Multidirectional W1850 x L3700 x H2150 Millimeter Maintenance Hole to Include Excavation, UNIT UNIT PRICE MAX AMOUNT

1017 400,000 Linear

OPTION CAT 6 LAN CABLE

UNIT UNIT PRICE MAX AMOUNT

1018 400 Each

OPTION CAT 6 WALL OUTLET BOX

FFP

UNIT UNIT PRICE MAX AMOUNT

1019 24,000 Linear

OPTION NON-METALLIC RACEWAY

UNIT UNIT PRICE MAX AMOUNT

1020 10 Linear

OPTION 6 TO 12 INCH METAL CABLE LADDER RACK

UNIT UNIT PRICE MAX AMOUNT

1021 10 Each

OPTION EQUIPMENT RACK

FFP

UNIT UNIT PRICE MAX AMOUNT

1022 50,000 Linear

OPTION STRAND AND GUY WIRES FOR AERIAL CABLE

Provide Contractor Furnished Material (CFM) and Install Strand and Guy Wires

UNIT UNIT PRICE MAX AMOUNT

1023 65,000 Linear

OPTION CABLE ON STRAND USING LASHING MACHINE

Install Cable on Strand Using Lashing Machine to Include Splicing, Termination, UNIT UNIT PRICE MAX AMOUNT

1024 20 Each

OPTION SPLICE CASE ON STRAND

FFP

UNIT UNIT PRICE MAX AMOUNT

1025 30,000 Linear

OPTION ½ TO 2 INCH EMT CONDUIT INSIDE

Installation of ½ to 2 Inch Electrical Metallic Tubing (EMT) Conduit Inside of

UNIT UNIT PRICE MAX AMOUNT

1026 10 Each

OPTION PULL OR DROP BOX FOR PDS

FFP

UNIT UNIT PRICE MAX AMOUNT

1027 80 Linear

OPTION GIP 4 INCH CONDUIT WITH COUPLINGS INSIDE

Provide Contractor Furnished Material (CFM) and Install Galvanized (GIP) 4

UNIT UNIT PRICE MAX AMOUNT

1028 160 Linear

OPTION GIP 4 INCH CONDUIT WITH COUPLINGS BURIED

Provide Contractor Furnished Material (CFM) and Install Galvanized (GIP) 4 Inch Conduit with Couplings Buried at a Minimum of 1 Meter Below the Surface, UNIT UNIT PRICE MAX AMOUNT

1029 800,000 Linear

OPTION DEINSTALL CABLE IN CONDUITS

UNIT UNIT PRICE MAX AMOUNT

1030 5,000 Linear

OPTION CIS TYPE 25 MILLIMETER X 4 EACH

Provide Contractor Furnished Material (CFM) and Install Combined Innerduct

UNIT UNIT PRICE MAX AMOUNT

1031 35 Each

OPTION OUTSIDE PULL-BOX

FFP

UNIT UNIT PRICE MAX AMOUNT

1032 800,000 Linear

OPTION PULLING WIRE IN DUCTS

1033 1 Job

OPTION ACCOUNTING FOR CONTRACT SERVICES

FFP

Contractor Manpower Reporting (CMR) Must be Reported by 31 October of Each

OPTION ESTIMATED COST FOR WAR HAZARD LOSSES

FFP

UNIT UNIT PRICE MAX AMOUNT

2001 40,000 Linear

UNIT UNIT PRICE MAX AMOUNT

2002 100 Each

OPTION GROUND ROD

FFP

UNIT UNIT PRICE MAX AMOUNT

2003 50 Each

OPTION PET HOUSING

FFP

UNIT UNIT PRICE MAX AMOUNT

2004 50 Each

OPTION SPLICE CASE FOR COPPER CABLE

FFP

UNIT UNIT PRICE MAX AMOUNT

2005 40 Each

OPTION ¾ INCH, FIRE-RETARDANT PLYWOOD BACKBOARD

FFP

Provide Contractor Furnished Material (CFM) and Install ¾ Inch, Fire-Retardant

UNIT UNIT PRICE MAX AMOUNT

2006 160,000 Linear

Install, Terminate, Splice, and Test - Fiber Optic Cable in Duct (2 to 144 Fiber

UNIT UNIT PRICE MAX AMOUNT

2007 800,000 Linear

Install, Terminate, Splice, and Test - LEAF Fiber Optic Cable in Duct (12 to 96

UNIT UNIT PRICE MAX AMOUNT

2008 100 Each

OPTION TERMINATION PANEL

FFP

UNIT UNIT PRICE MAX AMOUNT

2009 100 Each

OPTION SPLICE ENCLOSURE KIT

UNIT UNIT PRICE MAX AMOUNT

2010 5,000 Linear

Provide Contractor Furnished Material (CFM) and Install 4 Inch (1 to 4 Ducts) Encased Buried (EB)-20 Conduit Where Vehicular Traffic (i.e., Automotive, Railway) is Present.

Duct Installation to Include Excavation, Backfill, Restoration of Paved and Concrete Surfaces, Concrete Encasing, Spacers, Markers and Warning

UNIT UNIT PRICE MAX AMOUNT

2011 20,000 Linear

Provide Contractor Furnished Material (CFM) and Install 4 Inch (1 to 4 Ducts) Rigid Nonmetallic Conduit Schedule 40 PVC Conduit.

UNIT UNIT PRICE MAX AMOUNT

2012 10,000 Linear

UNIT UNIT PRICE MAX AMOUNT

2013 1,000 Each

OPTION CORE DRILL ½ TO 4 INCH HOLE

FFP

UNIT UNIT PRICE MAX AMOUNT

2014 50 Each

OPTION 2 TO 4 INCH BUILDING ENTRANCE CONDUIT

FFP

Provide Contractor Furnished Material (CFM) and Install 2 to 4 Inch Building

UNIT UNIT PRICE MAX AMOUNT

2015 25 Each

OPTION MULTIDIRECTIONAL HANDHOLE

FFP

Provide Contractor Furnished Material (CFM) and Install Multidirectional 1220 x 1220mm x 1220 Millimeter Handhole to Include Excavation, Restoration, UNIT UNIT PRICE MAX AMOUNT

2016 5 Each

OPTION MULTIDIRECTIONAL MAINTENANCE HOLE

FFP

Provide Contractor Furnished Material (CFM) and Install Multidirectional W1850 x L3700 x H2150 Millimeter Maintenance Hole to Include Excavation, UNIT UNIT PRICE MAX AMOUNT

2017 300,000 Linear

UNIT UNIT PRICE MAX AMOUNT

2018 300 Each

OPTION CAT 6 WALL OUTLET BOX

FFP

UNIT UNIT PRICE MAX AMOUNT

2019 18,000 Linear

UNIT UNIT PRICE MAX AMOUNT

2020 10 Linear

UNIT UNIT PRICE MAX AMOUNT

2021 10 Each

OPTION EQUIPMENT RACK

FFP

UNIT UNIT PRICE MAX AMOUNT

2022 50,000 Linear

Provide Contractor Furnished Material (CFM) and Install Strand and Guy Wires

UNIT UNIT PRICE MAX AMOUNT

2023 65,000 Linear

Install Cable on Strand Using Lashing Machine to Include Splicing, Termination, UNIT UNIT PRICE MAX AMOUNT

2024 20 Each

OPTION SPLICE CASE ON STRAND

FFP

UNIT UNIT PRICE MAX AMOUNT

2025 25,000 Linear

Installation of ½ to 2 Inch Electrical Metallic Tubing (EMT) Conduit Inside of

UNIT UNIT PRICE MAX AMOUNT

2026 10 Each

OPTION PULL OR DROP BOX FOR PDS

FFP

UNIT UNIT PRICE MAX AMOUNT

2027 60 Linear

Provide Contractor Furnished Material (CFM) and Install Galvanized (GIP) 4

UNIT UNIT PRICE MAX AMOUNT

2028 120 Linear

Provide Contractor Furnished Material (CFM) and Install Galvanized (GIP) 4 Inch Conduit with Couplings Buried at a Minimum of 1 Meter Below the Surface, UNIT UNIT PRICE MAX AMOUNT

2029 600,000 Linear

UNIT UNIT PRICE MAX AMOUNT

2030 4,000 Linear

Provide Contractor Furnished Material (CFM) and Install Combined Innerduct

UNIT UNIT PRICE MAX AMOUNT

2031 30 Each

OPTION OUTSIDE PULL-BOX

FFP

UNIT UNIT PRICE MAX AMOUNT

2032 600,000 Linear

2033 1 Job

OPTION ACCOUNTING FOR CONTRACT SERVICES

FFP

Contractor Manpower Reporting (CMR) Must be Reported by 31 October of Each

OPTION ESTIMATED COST FOR WAR HAZARD LOSSES

FFP

UNIT UNIT PRICE MAX AMOUNT

3001 40,000 Linear

UNIT UNIT PRICE MAX AMOUNT

3002 100 Each

OPTION GROUND ROD

FFP

UNIT UNIT PRICE MAX AMOUNT

3003 50 Each

OPTION PET HOUSING

FFP

UNIT UNIT PRICE MAX AMOUNT

3004 50 Each

OPTION SPLICE CASE FOR COPPER CABLE

FFP

UNIT UNIT PRICE MAX AMOUNT

3005 40 Each

OPTION ¾ INCH, FIRE-RETARDANT PLYWOOD BACKBOARD

FFP

Provide Contractor Furnished Material (CFM) and Install ¾ Inch, Fire-Retardant

UNIT UNIT PRICE MAX AMOUNT

3006 160,000 Linear

Install, Terminate, Splice, and Test - Fiber Optic Cable in Duct (2 to 144 Fiber

UNIT UNIT PRICE MAX AMOUNT

3007 800,000 Linear

Install, Terminate, Splice, and Test - LEAF Fiber Optic Cable in Duct (12 to 96

UNIT UNIT PRICE MAX AMOUNT

3008 100 Each

OPTION TERMINATION PANEL

FFP

UNIT UNIT PRICE MAX AMOUNT

3009 100 Each

OPTION SPLICE ENCLOSURE KIT

UNIT UNIT PRICE MAX AMOUNT

3010 5,000 Linear

Provide Contractor Furnished Material (CFM) and Install 4 Inch (1 to 4 Ducts) Encased Buried (EB)-20 Conduit Where Vehicular Traffic (i.e., Automotive, Railway) is Present.

Duct Installation to Include Excavation, Backfill, Restoration of Paved and Concrete Surfaces, Concrete Encasing, Spacers, Markers and Warning

UNIT UNIT PRICE MAX AMOUNT

3011 20,000 Linear

Provide Contractor Furnished Material (CFM) and Install 4 Inch (1 to 4 Ducts) Rigid Nonmetallic Conduit Schedule 40 PVC Conduit.

UNIT UNIT PRICE MAX AMOUNT

3012 10,000 Linear

UNIT UNIT PRICE MAX AMOUNT

3013 1,000 Each

OPTION CORE DRILL ½ TO 4 INCH HOLE

FFP

UNIT UNIT PRICE MAX AMOUNT

3014 50 Each

OPTION 2 TO 4 INCH BUILDING ENTRANCE CONDUIT

FFP

Provide Contractor Furnished Material (CFM) and Install 2 to 4 Inch Building

UNIT UNIT PRICE MAX AMOUNT

3015 25 Each

OPTION MULTIDIRECTIONAL HANDHOLE

FFP

Provide Contractor Furnished Material (CFM) and Install Multidirectional 1220 x 1220mm x 1220 Millimeter Handhole to Include Excavation, Restoration, UNIT UNIT PRICE MAX AMOUNT

3016 5 Each

OPTION MULTIDIRECTIONAL MAINTENANCE HOLE

FFP

Provide Contractor Furnished Material (CFM) and Install Multidirectional W1850 x L3700 x H2150 Millimeter Maintenance Hole to Include Excavation, UNIT UNIT PRICE MAX AMOUNT

3017 200,000 Linear

UNIT UNIT PRICE MAX AMOUNT

3018 200 Each

OPTION CAT 6 WALL OUTLET BOX

FFP

UNIT UNIT PRICE MAX AMOUNT

3019 12,000 Linear

UNIT UNIT PRICE MAX AMOUNT

3020 10 Linear

UNIT UNIT PRICE MAX AMOUNT

3021 10 Each

OPTION EQUIPMENT RACK

FFP

UNIT UNIT PRICE MAX AMOUNT

3022 50,000 Linear

Provide Contractor Furnished Material (CFM) and Install Strand and Guy Wires

UNIT UNIT PRICE MAX AMOUNT

3023 65,000 Linear

Install Cable on Strand Using Lashing Machine to Include Splicing, Termination, UNIT UNIT PRICE MAX AMOUNT

3024 20 Each

OPTION SPLICE CASE ON STRAND

FFP

UNIT UNIT PRICE MAX AMOUNT

3025 20,000 Linear

Installation of ½ to 2 Inch Electrical Metallic Tubing (EMT) Conduit Inside of

UNIT UNIT PRICE MAX AMOUNT

3026 10 Each

OPTION PULL OR DROP BOX FOR PDS

FFP

UNIT UNIT PRICE MAX AMOUNT

3027 40 Linear

Provide Contractor Furnished Material (CFM) and Install Galvanized (GIP) 4

UNIT UNIT PRICE MAX AMOUNT

3028 80 Linear

Provide Contractor Furnished Material (CFM) and Install Galvanized (GIP) 4 Inch Conduit with Couplings Buried at a Minimum of 1 Meter Below the Surface, UNIT UNIT PRICE MAX AMOUNT

3029 400,000 Linear

UNIT UNIT PRICE MAX AMOUNT

3030 3,000 Linear

Provide Contractor Furnished Material (CFM) and Install Combined Innerduct

UNIT UNIT PRICE MAX AMOUNT

3031 25 Each

OPTION OUTSIDE PULL-BOX

FFP

UNIT UNIT PRICE MAX AMOUNT

3032 400,000 Linear

3033 1 Job

OPTION ACCOUNTING FOR CONTRACT SERVICES

FFP

Contractor Manpower Reporting (CMR) Must be Reported by 31 October of Each

OPTION ESTIMATED COST FOR WAR HAZARD LOSSES

FFP

UNIT UNIT PRICE MAX AMOUNT

4001 40,000 Linear

UNIT UNIT PRICE MAX AMOUNT

4002 100 Each

OPTION GROUND ROD

FFP

UNIT UNIT PRICE MAX AMOUNT

4003 50 Each

OPTION PET HOUSING

FFP

UNIT UNIT PRICE MAX AMOUNT

4004 50 Each

OPTION SPLICE CASE FOR COPPER CABLE

FFP

UNIT UNIT PRICE MAX AMOUNT

4005 40 Each

OPTION ¾ INCH, FIRE-RETARDANT PLYWOOD BACKBOARD

FFP

Provide Contractor Furnished Material (CFM) and Install ¾ Inch, Fire-Retardant

UNIT UNIT PRICE MAX AMOUNT

4006 160,000 Linear

Install, Terminate, Splice, and Test - Fiber Optic Cable in Duct (2 to 144 Fiber

UNIT UNIT PRICE MAX AMOUNT

4007 800,000 Linear

Install, Terminate, Splice, and Test - LEAF Fiber Optic Cable in Duct (12 to 96

UNIT UNIT PRICE MAX AMOUNT

4008 100 Each

OPTION TERMINATION PANEL

FFP

UNIT UNIT PRICE MAX AMOUNT

4009 100 Each

OPTION SPLICE ENCLOSURE KIT

UNIT UNIT PRICE MAX AMOUNT

4010 5,000 Linear

Provide Contractor Furnished Material (CFM) and Install 4 Inch (1 to 4 Ducts) Encased Buried (EB)-20 Conduit Where Vehicular Traffic (i.e., Automotive, Railway) is Present.

Duct Installation to Include Excavation, Backfill, Restoration of Paved and Concrete Surfaces, Concrete Encasing, Spacers, Markers and Warning

UNIT UNIT PRICE MAX AMOUNT

4011 20,000 Linear

Provide Contractor Furnished Material (CFM) and Install 4 Inch (1 to 4 Ducts) Rigid Nonmetallic Conduit Schedule 40 PVC Conduit.

UNIT UNIT PRICE MAX AMOUNT

4012 10,000 Linear

UNIT UNIT PRICE MAX AMOUNT

4013 1,000 Each

OPTION CORE DRILL ½ TO 4 INCH HOLE

FFP

UNIT UNIT PRICE MAX AMOUNT

4014 50 Each

OPTION 2 TO 4 INCH BUILDING ENTRANCE CONDUIT

FFP

Provide Contractor Furnished Material (CFM) and Install 2 to 4 Inch Building

UNIT UNIT PRICE MAX AMOUNT

4015 25 Each

OPTION MULTIDIRECTIONAL HANDHOLE

FFP

Provide Contractor Furnished Material (CFM) and Install Multidirectional 1220 x 1220mm x 1220 Millimeter Handhole to Include Excavation, Restoration, UNIT UNIT PRICE MAX AMOUNT

4016 5 Each

OPTION MULTIDIRECTIONAL MAINTENANCE HOLE

FFP

Provide Contractor Furnished Material (CFM) and Install Multidirectional W1850 x L3700 x H2150 Millimeter Maintenance Hole to Include Excavation, UNIT UNIT PRICE MAX AMOUNT

4017 100,000 Linear

UNIT UNIT PRICE MAX AMOUNT

4018 100 Each

OPTION CAT 6 WALL OUTLET BOX

FFP

UNIT UNIT PRICE MAX AMOUNT

4019 6,000 Linear

UNIT UNIT PRICE MAX AMOUNT

4020 10 Linear

UNIT UNIT PRICE MAX AMOUNT

4021 10 Each

OPTION EQUIPMENT RACK

FFP

UNIT UNIT PRICE MAX AMOUNT

4022 50,000 Linear

Provide Contractor Furnished Material (CFM) and Install Strand and Guy Wires

UNIT UNIT PRICE MAX AMOUNT

4023 65,000 Linear

Install Cable on Strand Using Lashing Machine to Include Splicing, Termination, UNIT UNIT PRICE MAX AMOUNT

4024 20 Each

OPTION SPLICE CASE ON STRAND

FFP

UNIT UNIT PRICE MAX AMOUNT

4025 15,000 Linear

Installation of ½ to 2 Inch Electrical Metallic Tubing (EMT) Conduit Inside of

UNIT UNIT PRICE MAX AMOUNT

4026 10 Each

OPTION PULL OR DROP BOX FOR PDS

FFP

UNIT UNIT PRICE MAX AMOUNT

4027 40 Linear

Provide Contractor Furnished Material (CFM) and Install Galvanized (GIP) 4

UNIT UNIT PRICE MAX AMOUNT

4028 80 Linear

Provide Contractor Furnished Material (CFM) and Install Galvanized (GIP) 4 Inch Conduit with Couplings Buried at a Minimum of 1 Meter Below the Surface, UNIT UNIT PRICE MAX AMOUNT

4029 200,000 Linear

UNIT UNIT PRICE MAX AMOUNT

4030 2,000 Linear

Provide Contractor Furnished Material (CFM) and Install Combined Innerduct

UNIT UNIT PRICE MAX AMOUNT

4031 20 Each

OPTION OUTSIDE PULL-BOX

FFP

UNIT UNIT PRICE MAX AMOUNT

4032 200,000 Linear

4033 1 Job

OPTION ACCOUNTING FOR CONTRACT SERVICES

FFP

Contractor Manpower Reporting (CMR) Must be Reported by 31 October of Each

OPTION ESTIMATED COST FOR WAR HAZARD LOSSES

FFP

NOTICE TO OFFERORS

All sources may submit a proposal as applicable. However, the Republic of Korea (ROK)-United States (U.S.)

Status of Forces Agreement (SOFA), precludes the U.S. Government from granting Invited Contractor or Technical Representative Status to any offeror, for this requirement. All sources submitting a proposal, as applicable, including U.S. sources, must already have, or obtain the requisite business licenses directly from the ROK Government, and conduct business in accordance with all applicable ROK laws, including but not limited to, rules and policies regarding labor, taxation, and immigration. Any contractor not already doing business in Korea, must submit adequate verification in its initial proposal - that it has the requisite business licenses directly from the ROK Government to perform the contract and the capacity to conduct business in accordance with all applicable ROK laws, including but not limited to, rules and policies regarding labor, taxation, and immigration. If an initial proposal does not fully demonstrate this authorization and capacity, it will not be further considered for award.

Whether an offeror demonstrates this authorization and capacity shall be determined by the Contracting Officer.

“All offerors interested in competing for this requirement are required to submit their price proposal in Korean Won (KW) only. A proposal submitted in currency other than Korean Won will not be considered for award.”

CONTRACT PERIOD

Base Period: 1 September 2017 – 31 August 2018 1st Option Year: 1 September 2018 – 31 August 2019 2nd Option Year: 1 September 2019 – 31 August 2020 3rd Option Year: 1 September 2020 – 31 August 2021 4th Option Year: 1 September 2021 – 31 August 2022

PWS

PERFORMANCE WORK STATEMENT (PWS)

FOR

TELECOMMUNICATIONS INFRASTRUCTURE SUPPORT SERVICE (TISS)

1. GENERAL: The Contractor shall supply all personnel, equipment, tools, materials, supervision, other items and non-personal services necessary to provide the Telecommunications Infrastructure Support Services (TISS) as defined in this Performance Work Statement (PWS).

1.1. Background: This document will identify the safety requirements, list of materials/specifications and performance work standards that will be required by the contractor. It is the vehicle that will allow the assignment of work to a contractor when the 1st Signal Brigade deems it necessary. This document is also synchronized with the Unified Facilities Criteria (UFC), which are mandated under Department of Defense (DOD) policy. The UFC system is prescribed by Military Standard (MIL-STD) 3007, Standard Practice for Unified Facilities Criteria and Unified Facilities Guide Specifications (UFGS) and provides planning, design, construction, sustainment, restoration, and modernization criteria. The standard applies to military departments, defense agencies, and DOD field activities in accordance with (IAW) the Under Secretary of Defense for Acquisition Technology and Logistics (AT&L) Memorandum dated 29 May 2002. The Technical Criteria for the Installation Information Infrastructure Architecture (I3A) document dated February 2010 will be the governing document for the contractor. This document establishes an implementation concept that can be used to shape architectural templates and to influence the design process for the I3A. It identifies proven infrastructure construction techniques, defines common practices, and serves as an authoritative implementation criterion.

1.2. Scope of Work: The contractor shall install, relocate, repair, or remove fiber optic and/or copper cable, and/or Protected Distribution Systems, and/or LAN infrastructure in accordance with (IAW) Contract Line Item Numbers (CLINs) identified within project specific Engineering Design Plans (EDPs). The contractor shall provide emergency repairs/relocations for outside plant (OSP) (copper and/or fiber optic) cables and except those items specified in paragraph 3 as government furnished materials (GFM) for this contract. The contractor shall perform to the standards identified by paragraph 4 and associated attachments.

1.3. Quality Control Plan (QCP): The Contractor shall develop and maintain an effective quality control plan to ensure services are performed in accordance with this PWS. The Contractor shall develop and implement procedures to identify, prevent, and ensure non-recurrence of defective services. The Contractor shall provide the QCP as a part of the proposal to be evaluated. The contractor shall implement data collection methods to record data ensuring work accomplished meets acceptable performance and technical standards. The data shall identify trends, potential and actual problem areas, deficiencies, and any required corrective action. The contractor shall retain all records of inspections and corrective actions throughout the period of performance. Inspection documents shall be made available to the Government COR, Quality Assurance (QA) representative and the Contracting Office within 24 hours of written request by either party.

1.3.1. At a minimum the quality control plan should address:

Overall project management and administration.

Be a comprehensive program to plan and deliver quality services to the Government.

Cover and prioritize all services described in this contract.

Describe a method acceptable to the Government of identifying deficiencies in the quality of service performed under this contract before the level of performance becomes unacceptable and address processes for corrective actions without dependence upon Government direction.

Establish an inspection system covering all services required by this contract. This plan shall specify areas to be inspected on either a scheduled or an unscheduled basis and the title of the individual who will do the inspection.

Contain specific quality control techniques and standards for contract services identified in the Performance Requirements Summary and Inspection of Services Clause list. The quality control methods shall be comprehensive and adaptable to the reporting systems of the QCP. Control measures must be specified and metrics developed to ensure accurate program monitoring.

Include a customer complaint feedback system for correction of validated complaints and to inform the Government of corrections. The QCP shall describe how the Government may identify problem areas or situations to the contractor. The customer complaint program shall be compatible with the reporting and communication systems of the QCP.

Require documentation of all contractor quality control inspections and corrective actions to be maintained by the contractor throughout the term of this contract. Inspection documents and the corrective action taken shall be made available to the KO or designated representative.

1.3.2. The Quality Control Plan will be used by the contractor to collect data, evaluate and document performance against standards associated with each specific requirement. Performance is measured by assessing the required workload quantity in terms of quality and timeliness. The contractor shall use the format measure each line item in the PRS table.

1.4. Quality Assurance (QA): The Government will evaluate the Contractor’s performance under this contract in accordance with the Quality Assurance Surveillance Plan (QASP). This plan is primarily focused on what the Government must do to ensure that the Contractor has performed in accordance with the performance standards. It defines how the performance standards will be applied, the frequency of surveillance, and the maximum acceptable defect rate(s).

1.4.1. Deficiencies: The Government reserves the right to refuse final acceptance until all deficiencies have been resolved (per all stated requirements). The Government will review all results and prepare a list of deficiencies, if any. The deficiency list shall include any problem(s) detected/identified during testing and/or inspections conducted by either the contractor or the government, or both.

1.5. Recognized Holidays: The contractor is required to provide services on the Holidays listed below.

1.6. Hours of Operation: The contractor is responsible for provisioning, installation, coordination with Government Tech-Control Facilities (TCF), operation and maintenance of provided leased circuits, troubleshooting, routine maintenance (between the hours of 0730 - 1700, Monday through Friday, excluding ROK Legal Holidays and ROK executive order as a ROK Legal Holiday) and emergency maintenance (between the hours of 0000 - 2459, Monday thru Sunday, except when a government facility is closed due to local or national emergencies, administrative closings, or similar government directed facility closings). The contractor must at all times maintain an adequate work force for the uninterrupted performance of all tasks defined within this performance work statement when the government facility is not closed for the above reasons. When hiring personnel, the contractor shall keep in mind that the stability and continuity of the work force is essential.

1.7. Place of Performance: The work to be performed under this contract will be in locations where all trunks, circuits, telephones, cables and cable routing are installed. Minimum locations include Camp Casey, Camp Hovey, Camp Bonifay, Warrior Base, Camp Red Cloud, Camp Stanley, Camp Jackson, Camp Market, Yongsan Garrison, FEDE Compound, K-16 Airfield, Command Post Tango, Suwon Air Base (AB), Third Republic Of Korea Army (TROKA), First Republic Of Korea Army (FROKA), Osan AB, Camp Humphreys, Kunsan AB, Kwangju AB, Camp Mujuk, Camp Carroll, Camp Henry, Camp Walker, K2 AB, Second Republic Of Korea Army (SROKA), Camp Carroll, Busan Storage Facility, Pier #8, and Kimhae AB. Area of coverage may exceed what is currently documented – manned and unmanned mountain-top locations will be placed under this contract.

1.8. Security Requirements. All communication methods that includes analog/digital trunks, circuits, telephones, cables, duct and network or telecommunication long haul paths will be adequately protected to provide secure and uninterrupted services to the Government 24 hours a day 7 days a week. The secret-level security clearance is not required; however, the contractor is required to comply with the physical security as provided below.

1.8.1. Contractor and all associated sub-contractors employees shall provide all information required for background checks to meet installation access requirements to be accomplished by installation Provost Marshal Office, Director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements (FAR clause 52.204-9, Personal Identity Verification of Contractor Personnel) as directed by DOD, HQDA and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any individual facility or installation change, the Government may require changes in contractor security matters or processes.

1.8.2. Contractor and all associated sub-contractors employees shall comply with adjudication standards and procedures using the National Crime Information Center Interstate Identification Index (NCIC-III) and Terrorist Screening Database (TSDB) (Army Directive 2014-05/AR 190-13), applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative), or, at OCONUS locations, in accordance with status of forces agreements and other theater regulations.

1.8.3. The contractor and all associated sub-contractors shall brief all employees on the local iWATCH program (training standards provided by the requiring activity ATO). This local developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the COR.

This training shall be completed within 90 calendar days of contract award and within 60 calendar days of new employees commencing performance with the results reported to the COR NLT 30 calendar days after contract award.

1.9. Contractor’s Qualification. The prime contractor shall have the following qualifications:

a. Communications License issued by the Korean Communications Commission (KCC) (정보통신공사업등록증).

1.9.1 Personnel:

1.9.2 Key Personnel: The contractor shall provide a Contract Manager (CM) who shall be responsible for the performance of the work. The contract manager shall have full authority to act for the contractor on all contract matters relating to daily operation of this contract. The contract manager shall be available between the hours of 0000 - 2459, Monday thru Sunday, except when a government facility is closed due to local or national emergencies, administrative closings, or similar government directed facility closings. Qualifications for all key personnel are listed below:

1.9.3 Contract Manager (CM): The contractor shall provide a Contract Manager (CM) and validating resume with the following qualifications:

a. Minimum Bachelors of Science (BS) degree in Information Technology or related field.

b. Demonstrating a minimum of three (3) years of experience within the last five (5) years in contract management or project management with satisfactory prior experience relating to telecommunications support (installing, relocating, repairing, and removing fiber optics, copper, and Local Area Network).

c. CM shall be able to communicate and fully be able to carry a coherent conversation in English without constant stoppage due to inadequate English language skills or understanding.

Contract Manager’s resume must clearly identify the qualifications above in the following format:

a. Position title held.

b. A clear description of qualifying work experience.

c. Length of work experience (year/month/date – year/month/date).

d. Complete point of contract of employer (business name, point of contact information [name, phone number, email address]).

1.9.3.1 The Contractor shall ensure that the professional and technical personnel working on this contract have sufficient qualifications to perform the work in accordance with all requirements of this contract.

1.9.3.2 When working with non-1st Signal Brigade stakeholders, contractors shall provide technical advice or information only. Contractor employees shall clearly indicate that they do not represent the Government. The contractor shall not exercise any Governmental discretion by obligating Government by entering into agreements with stakeholders.

1.9.3.3 Identification of Contractor Personnel: Contractor identification requirements: In accordance with FAR subpart 37.114, l Contractor personnel attending meetings, answering Government telephones, and working in other situations where their Contractor status is not obvious are required to identify themselves as such to avoid being mistaken for Government officials. Contractors performing work at Government workplaces will provide their employees with an easily readable identification (ID) badge indicating the employee’s name, the Contractor’s name, the functional area of assignment, and a recent color photograph of the employee. Contractors shall require their employees to wear the ID badges visibly when performing work at Government workplaces. Contractor personnel must also ensure that all e-mails, documents or reports they produce are suitably marked as Contractor products or that Contractor participation is appropriately disclosed. All signature blocks on e-mails shall identify the contractor employee as such and identify the employing contractor. All e-mail address lines shall include CTR in the address line.

1.9.4.1 Safety Requirements: In performing work under this contract, the contractor shall:

1.9.4.2 Conform to the safety requirements contained in the contract for all activities related to the accomplishment of the work.

1.9.4.3 Perform work in a safe manner as required by OSHA 2206, General Industry, Occupational Safety and Health Standards (29 CFR 1910) and Korea Environmental Governing Standards by U.S. Forces Korea.

1.9.4.4 Develop and deliver a safety plan within 30 calendar days of contract award for the protection of government facilities and property and to provide a safe work environment for the contractor personnel.

1.9.4.5 Provide protection to government property in preventing damage during the period of time the property is under the control or in possession of the contractor.

1.9.4.6 Include a clause in all subcontractors contracts to require subcontractors to comply with the Safety provisions of this contract as applicable.

1.9.4.7. Report promptly (within one hour), 24 hours a day, 7 days a week, 365 days a year, to the Contracting Officer or Contracting Officer's Representative, all available facts relating to each instance of damage to government property and/or injury to either contractor or government personnel.

1.9.4.8. In the event of an accident/mishap, take reasonable and prudent actions to establish control of the accident/mishap scene, prevent further injury to persons or property, and preserve evidence until released by the accident/mishap investigative authority with the verbal and/or written concurrence of the Contract Officer.

1.9.4.9. If the government elects to conduct an investigation of the accident/mishap, cooperate fully and assist any government representative in the conduct of the investigation until the investigation is completed.

1.9.5. Include a clause in each applicable subcontract requiring the subcontractor’s cooperation and assistance with the accident reporting and investigation.

1.9.5.1. DA form 285, US Army Accident Report, shall be completed and submitted to HQs, 1st Signal Brigade, and ATTN: NETC-SKC-SA, Unit #15271, and APO AP 96205-0044 within five (5) working days after the occurrence of the accident. All blocks of the report shall be completed to include the descriptive narrative. Cost of damage and/or injuries shall be included in the report.

1.9.6. Enforcing Safety Regulations.

1.9.6.1. Providing annual training to all personnel on the safe practices and skills to include First Aid and Cardio pulmonary Resuscitation (CPR).

1.9.6.2 Establishing a fire prevention program at each work site location and ensure each employee is familiar with operating fire suppression equipment.

1.9.6.3 Ensuring a bilingual (Korean and English) Safety Standard Operating Procedures (SOP) is available at all operational work sites. Contract supervisors shall ensure that all personnel read and understand the Safety SOP.

1.9.6.4. Posting bilingual (Korean and English) accident prevention signs and symbols at designated and known physical hazard areas. Reference DA PAM 385-10 for design specifications and safety color-coding.

1.9.6.5. All contractor personnel working in maintenance holes shall have a ROK certificate of training for confined space entry and confined space rescue.

1.9.6.6. All contractor personnel performing direct labor for any delivery order shall have a valid ROK Cardiopulmonary resuscitation (CPR) and First Aid certificate.

1.9.7. Emergency Repairs/Relocations.

1.9.7.1. Emergency services are work that is required outside of normal duty hours for restoration of communications circuits or system identified by the 1st Signal Brigade, the COR, or their designated representatives. The initiation of emergency work after normal duty hours shall be directed by the Contracting Officer. The KO will give a verbal authorization for work to proceed and an order will be accomplished after the work has been completed. No other Government representative is authorized to order emergency repair and maintenance services. Emergency services ordered by anyone other than the KO will not be reimbursed.

1.9.7.2. The Contractor will be notified by the COR of the malfunction, location(s), and type of work required to include any special instructions or date deemed necessary for the required emergency work.

1.9.7.3. Emergency services shall be provided outside of normal duty hours, seven (7) days per week, on an on-call basis. Within ten (10) working days after contract award, the Contractor shall provide the Contracting Officer/Contracting Officer's Representative with a point of contact where notification of emergency requirements can be made at any time. The Contractor roving team for emergency services shall be at the suspected trouble area within four (4) hours after notification by the Contracting Officer.

1.9.7.4. It is anticipated that emergency services work would occur no more than three times per year.

PART 2

DEFINITIONS & ACRONYMS

2. DEFINITIONS AND ACRONYMS:

2.1. DEFINITIONS:

2.1.1. Contractor. A supplier or vendor having a contract to provide specific supplies or service to the government.

2.1.2. Contracting Officer (KO). An employee of the U.S. Government with authority to enter into, administer, and or terminate contracts, and make related determinations and findings on behalf of the government. Note: The only individual who can legally bind the government.

2.1.3 Ordering Officer (OO). An individual authorized by FAR to place orders against indefinite delivery contracts.

2.1.4 Contracting Officer’s Representative (COR): An employee of the U.S. Government appointed by the contracting officer to administer the contract. Such appointment shall be in writing and shall state the scope of authority and limitations. This individual has authority to provide technical direction to the Contractor as long as that direction is within the scope of the contract, does not constitute a change, and has no funding implications. This individual does NOT have authority to change the terms and conditions of the contract.

2.1.5 Defective Service. A service output that does not meet the standard of performance associated with it in the Performance Work Statement.

2.1.6 Deliverable. Anything that can be physically delivered but may include non-physical things such as meeting minutes.

2.1.7 Key Personnel. Contractor personnel that are evaluated in a source selection process and that may be required to be used in the performance of a contract by the Key Personnel listed in the PWS. When key personnel are used as an evaluation factor in best value procurement, an offer can be rejected if it does not have a firm commitment from the persons that are listed in the proposal.

2.1.8 Physical Security. Actions that prevent the loss or damage of Government property.

2.1.9 Quality Assurance. The government procedures to verify that services being performed by the Contractor are performed according to acceptable standards.

2.1.10 Quality Assurance Surveillance Plan (QASP). An organized written document specifying the surveillance methodology to be used for surveillance of contractor performance.

2.1.11 Quality Control. All necessary measures taken by the contractor to assure that the quality of an end product or service shall meet contract requirements.

2.1.12 Subcontractor. One that enters into a contract with a prime contractor. The Government does not have privities of contract with the subcontractor.

2.1.13 Work Day. The number of hours per day the Contractor provides services in accordance with the contract.

2.1.14 Work Week. Is defined as Monday through Friday, unless specified otherwise.

2.2. ACRONYMS:

CFM Contractor Furnished Material CFR Code of Federal Regulations COR Contracting Officer’s Representative

CSA Communications Services Agreement DID Direct Inward Dialing DOD Direct Outward Dialing FAR Federal Acquisition Regulation FSC Federal Service Code GFM Government Furnished Material IDIQ Indefinite delivery indefinite quantity KO Contracting Officer OCI Organizational Conflict of Interest OSHA Occupational Safety and Health Act of 1970 PWS Performance Work Statement ROK Republic of Korea QA Quality Assurance QASP Quality Assurance Surveillance Plan QC Quality Control QCP Quality Control Plan ROK Republic of Korea TCF Technical Control Facility UIC Unit Identification Code XML Extensible Markup Language

PART 3

GOVERNMENT FURNISHED PROPERTY, EQUIPMENT, SERVICES, AND FACILITY

3. GOVERNMENT FURNISHED ITEMS AND SERVICES:

3.1. GENERAL: The Government will provide material listed below, as required by individual Engineering Design Plan (EDP). Material for each EDP requirement will be delivered to Camp Humphreys and/or within USFK before contractor performs each EDP.

3.1.1 COPPER CABLE INSTALLATION PROJECTS

3.1.1.1 Copper Cable, 24AWG, Jelly Filled, 12pr, 25pr, 50pr, 100pr, 200pr, 300pr

3.1.1.2 Copper Splice Closure Kit for Maintenance hole, 50 pr, 200 pr, 400 pr, 600 pr, 900 pr, 1,200 pr, 1,800 pr

3.1.1.3 Copper Splice Closure Kit for Cable Vault, 600 pr, 900 pr

3.1.1.4 Water Protection Compound for Copper Cable

3.1.1.5 Cable Cleaning Kit

3.1.1.6 Double and/or Triple End Cap for Copper Cable, 3", 4", 5", 7", 9"

3.1.1.7 Splice Modules

3.1.1.8 Splice Module Sealant

3.1.1.9 Splice Connectors

3.1.1.10 Building Terminal, 66-Block, 25 pr, 50 pr, 100 pr

3.1.1.11 Building Terminal, 110-Block, 25 pr, 50 pr, 100 pr

3.1.1.12 MDF Center Connector, 100 pr

3.1.2 FIBER OPTIC CABLE INSTALLATION PROJECTS

3.1.2.1 Splice Organizer Tray, 12-24 core

3.1.2.2 Fiber Optic Cable, Single Mode (SM), 12 core, 24 core, 48 core, 72 core, 96 core, 144 core

3.1.2.3 Fiber Optic Cable, Single Mode (SM), 12 core, Aerial Cable

3.1.2.4 Fiber Optic Cable, Multi-Mode (MM), 12 core

3.1.2.5 Splice Closure, Large, Small, Additional

3.1.2.6 Fiber Optic Cable, Single…