11R0004_Am12.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

2. AMENDMENT/MODIFICAITON NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicble)

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

9A. AMENDMENT OF SOLICIATION NO.

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended, is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a)By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment your desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPIRATION DATA (If required)

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc. ) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

14. DESCRIPTION OF AMENDMENT/MODIFICATION ( Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

NSN 7540-01-152-8070

Previous edition unusable

0012 Mar 15, 2011

US Army Corps of Engineers Los Angeles District P.O. Box 2711 Los Angeles, CA 90017

US Army Corps of Engineers Los Angeles District P.O. Box 2711 Los Angeles, CA 90017

W912PL-11-R-0004

Dec 15, 2010

FY11 Design and Construction of the Aerospace Maintenance and Regeneration Group (AMARG), Hangar, Davis-Monthan AFB, Arizona

AMENDMENT 0012 is issued under Solicitation No. W912PL-11-R-0004 Due to the 12 Amendments that have been issued a second signature page of the 1442 is added for your use and Acknowledgement of the amendments. Also Attached is The ACM Report Please see the attached sheet for changes.

INSTRUCTIONS

Instructions for items other than those that are self-explanatory, are as follows:

Item 1 (Contract ID Code) . Insert the contract type identification code that appears in the title block of the contract being modified.

Item 3 (Effective date) .

(1)

(2)

(3)

(4)

(5)

For a solicitation amendment, change order, or administrative change, the effective date shall be the issue date of the amendment, change order, or administrative change.

For a supplemental agreement, the effective date shall be the date agreed to by the contracting parties.

For a modification issued as an initial or confirming notice of termination for the convenience of the Government, the effective date and the modification number of the confirming notice shall be the same as the effective date and modification number of the initial notice.

For a modification converting a termination for default to a termination for the convenience of the Government, the effective date shall be the same as the effective date of the termination for default.

For a modification confirming the contacting officer's determination of the amount due in settlement of a contract termination, the effective date shall be the same as the effective date of the initial decision.

(a)

(b)

(c)

(d)

(e)

(f)

Item 6 (Issued By) . Insert the name and address of the issuing office. If applicable, insert the appropriate issuing office code in the code block.

Item 8 (Name and Address of Contractor) . For modifications to a contract or order, enter the contractor's name, address, and code as shown in the original contract or order, unless changed by this or a previous modification.

Item 9, (Amendment of Solicitation No. - Dated), and 10, (Modification of Contract/Order No. - Dated ). Check the appropriate box and in the corresponding blanks insert the number and date of the original solicitation, contract, or order.

Item 12 (Accounting and Appropriation Data) .

When appropriate, indicate the impact of the modification on each affected accounting classification by inserting one of the following entries.

(2) Accounting classification Net decrease $

Include subject matter or short title of solicitation/contract where feasible.

Item 16B . The contracting officer's signature is not required on solicitation amendments. The contracting offier's signature is normally affixed last on supplemental agreements.

(i)

NOTE: If there are changes to multiple accounting classifications that cannot be placed in block 12, insert an asterisk and the words "See continuation sheet".

Item 13 . Check the appropriate box to indicate the type of modification. Insert in the corresponding blank the authority under which the modification is issued. Check whether or not contractor must sign this document. (See FAR 43.103.)

Item 14 (Description of Amendment/Modification) .

Organize amendments or modifications under the appropriate Uniform Contract Format (UCF) section headings from the applicable solicitation or contract. The UCF table of contents, however, shall not be set forth in this document Indicate the impact of the modification on the overall total contract price by inserting one of the following entries:

Total contract price increased by $

Total contract price decreased by $

Total contract price unchanged.

State reason for modification.

When removing, reinstating, or adding funds, identify the contract items and accounting classifications.

When the SF 30 is used to reflect a determination by the contracting officer of the amount due in settlement of a contract terminated for the convenience of the Government, the entry in Item 14 of the modification may be limited to --

A reference to the letter determination; and

A statement of the net amount determined to be due in settlement of the contract.

(g)

(h)

(i)

(ii)

(1)

(2)

(3)

(4)

(5)

(6)

(i)

(ii)

(iii)

STANDARD FORM 30 (REV. 10-83) BACK

(1) Accounting classification Net increase $

W912PL-11-R-0004

Amendment No. 0012

1. SPECIFICATIONS: DELETE THE FOLLOWING LISTED PAGES AND SUBSTITUTE THE

PAGES ATTACHED HERETO. ON THE REVISED PAGES, FOR CONVENIENCE, CHANGES ARE

EMPHASIZED BY THE AMENDMENT NUMBER IN PARENTHESES BEFORE AND AFTER CHANGES

FROM THE PREVIOUS ISSUE. ALL PORTIONS OF THE REVISED (OR NEW) PAGES SHALL

APPLY WHETHER OR NOT CHANGES HAVE BEEN INDICATED.

Delete Page Insert Page

SF 1442, Pg. 2

00800, Pgs. 1, 2, 20, 21 00800, Pgs. 1, 2, 20, 21, Government Furnished Equipment Photos

01 35 26, Pgs. 2, 11 & 12 01 35 26, Pgs. 2, 11 & 12

Appendix Index Appendix Index

Appendix U

////////LAST ITEM////////

OFFER (Must be fully completed by offeror)

STANDARD FORM 1442 BACK (REV. 4-85)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within calendar days after the date offers are due. (Insert any number equal or greater than the minimum requirement stated in 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation - give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20B. SIGNATURE 20C. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24.SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) ( ) 41 U.S.C. 253(c) ( )

26. ADMINISTERED BY 27. PAYMENT WILL BE MADE BYCODE

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return copies to the issuing office.) Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and

(c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

29. AWARD. (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN

(Type or print)

30B. SIGNATURE 30C. DATE

31A. NAME OF CONTRACTING OFFICER (Type or print)

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

DUNS NO.: TAX ID NO.:

CAGE CODE NO.:

( ) - ; FAX ( ) -

SEE PRICING SCHEDULE, SECTION 00010

SECTION 00800 - SPECIAL CONTRACT REQUIREMENTS

CLAUSES INCORPORATED BY FULL TEXT

52.0000-4001 UNAUTHORIZED INSTRUCTIONS FROM GOVENRMENT OR OTHER

PERSONNEL (MAY 2000)

52.0001-4001 CONTRACT ADMINISTRATION DATA

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) 3

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

52.211-13 TIME EXTENSIONS (SEP 2000)

52.216-18 ORDERING (OCT 1995)

52.216-19 ORDER LIMITATIONS (OCT 1995)

52.217-5 EVALUATION OF OPTIONS (JUL 1990)

52.0028-4001 REQUIRED INSURANCE

252.227-7030 TECHNICAL DATA--WITHHOLDING OF PAYMENT (MAR 2000)

52.228-2 ADDITIONAL BOND SECURITY (OCT 1997)

52.228-12 PROSPECTIVE SUBCONTRACTOR REQUESTS FOR BONDS. (OCT 1995)

52.228-14 IRREVOCABLE LETTER OF CREDIT (DEC 1999)

52.228-15 PERFORMANCE AND PAYMENT BONDS--CONSTRUCTION (NOV 2006)

52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER—CENTRAL CONTRACTOR

REGISTRATION (OCT 2003)

52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

52.236-2 DIFFERING SITE CONDITIONS (APR 1984)

52.236-3 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 1984) 12

52.236-4 PHYSICAL DATA (APR 1984)

52.236-5 MATERIAL AND WORKMANSHIP (APR 1984)

52.236-6 SUPERINTENDENCE BY THE CONTRACTOR (APR 1984)

52.236-7 PERMITS AND RESPONSIBILITIES (NOV 1991)

52.236-8 OTHER CONTRACTS (APR 1984)

52.236-9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT,

UTILITIES, AND IMPROVEMENTS (APR 1984)

52.236-10 OPERATIONS AND STORAGE AREAS (APR 1984)

52.236-11 USE AND POSSESSION PRIOR TO COMPLETION (APR 1984)

52.236-12 CLEANING UP (APR 1984)

52.236-13 ACCIDENT PREVENTION (NOV 1991)

52.236-14 AVAILABILITY AND USE OF UTILITY SERVICES (APR 1984)

52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (APR 1984)

52.236-17 LAYOUT OF WORK (APR 1984)

52.236-21 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (FEB 1997)

52.236-21 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (FEB 1997) -

ALTERNATE I (APR 1984

52.236-26 PRECONSTRUCTION CONFERENCE (FEB 1995)

252.236-7000 MODIFICATION PROPOSALS - PRICE BREAKDOWN. (DEC 1991)

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

252.236-7013 REQUIREMENT FOR COMPETITION OPPORTUNITY FOR AMERICAN STEEL

PRODUCERS, FABRICATORS, AND MANUFACTURERS (JAN 2009)

52.245-3 IDENTIFICATION OF GOVERNMENT-FURNISHED PROPERTY (APR 1984)

ER 415-1-15 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (31 OCT 89)

SCR.1 DESIGN-BUILD CONTRACT ORDER OF PRECEDENCE – AUG 1997

SCR 2. KEY PERSONNNEL, SUBCONTRACTORS AND OUTSIDE ASSOCIATES OR

CONSULTANTS – MAY 2006

(12) (12)

00800 - 2

SCR 3. DESIGNER OF RECORD – APR 1999

SCR 4. RESPONSIBILITY OF THE CONTRACTOR FOR DESIGN – MAY 2002

SCR 5. WARRANTY OF CONSTRUCTION WORK – AUG 1997

SCR 7. SEQUENCE OF DESIGN-CONSTRUCTION – AUG 1997

SCR 9. CONSTRUCTOR’S ROLE DURING DESIGN – JUN 1998

SCR 10. RECOMMENDED INSURANCE COVERAGE

SCR 12. DESIGN CONFERENCES – AUG 1997

00800 - 20

252.236-7013 REQUIREMENT FOR COMPETITION OPPORTUNITY FOR AMERICAN STEEL PRODUCERS, FABRICATORS, AND MANUFACTURERS (JAN 2009)

(a) Definition. Construction material, as used in this clause, means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work.

(b) The Contractor shall provide American steel producers, fabricators, and manufacturers the opportunity to compete when acquiring steel as a construction material (e.g., steel beams, rods, cables, plates).

(c) The Contractor shall insert the substance of this clause, including this paragraph (c), in any subcontract that involves the acquisition of steel as a construction material.

(End of clause)

52.245-3 IDENTIFICATION OF GOVERNMENT-FURNISHED PROPERTY (APR 1984).

(a) The Government will furnish to the Contractor the property identified in the Schedule to be incorporated or installed into the work or used in performing the contract. The listed property will be furnished to the Contractor from a location on Davis-Monthan AFB. The Contractor is required to accept delivery, and unload and transport the property to the job site at its own expense. When the property is delivered, the Contractor shall verify its quantity and condition and acknowledge receipt in writing to the Contracting Officer. The Contractor shall also report in writing to the Contracting Officer within 24 hours of delivery any damage to or shortage of the property as received. All such property shall be installed or incorporated into the work at the expense of the Contractor, unless otherwise indicated in this contract.

(b) Each item of property to be furnished under this clause shall be identified in the following Schedule (See attached photographs).

(c) The Contractor will be responsible for the proper storage and maintenance of the property from the time of acceptance until such time as it is returned to the Government.

(d) Government-furnished property will be provided to the Contractor upon request to the Contracting Officer.

GOVERNMENT-FURNISHED PROPERTY SCHEDULE

Item Quantity Description Delivery Date

1 (See attached photographs)

Space Saver Filing Cabinets (As requested)

(End of clause)

ER 415-1-15 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (31 OCT 89)

This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with the Contract Clause entitled “DEFAULT (FIXED PRICE CONSTRUCTION)”. In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more sever that the adverse weather anticipated for the project location during any given month.

The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault of negligence of the Contractor.

(12)

00800 - 21

a. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time extensions. The contractor’s progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

Monthly Anticipated Adverse Weather Delay

Work Days Based on 5 Day Work Week

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

6 2 2 1 1 0 2 2 1 1 1 3

b. Upon acknowledgement of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor will record o the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor’s scheduled work day.

c. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in pervious month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph (b), above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the contract clause entitled “Default (Fixed Price Construction)”.

THE NEXT PAGES CONTAIN THE SEPCIAL CONTRACT REQIREMENTS CLAUSES

APPLICABLE TO FIXED PRICE DESIGN-BUILD CONSTRUCTION CONTRACTS/TASK

ORDERS.

PHOTOS OF GOVERNMENT-FURNISHED PROPERTY

01 35 26-2

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2008) Safety -- Safety and Health Requirements

U.S. NATIONAL ARCHIVES AND RECORDS ADMINISTRATION (NARA)

29 CFR 1910 Occupational Safety and Health Standards

29 CFR 1910.146 Permit-required Confined Spaces

29 CFR 1915 Confined and Enclosed Spaces and Other Dangerous

Atmospheres in Shipyard Employment

29 CFR 1919 Gear Certification

29 CFR 1926 Safety and Health Regulations for Construction

29 CFR 1926.500 Fall Protection

29 CFR 1926.1101 Asbestos Exposure

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Zero Accident Program (ZAP)

Accident Prevention Plan (APP)

Activity Hazard Analysis (AHA)

Crane Critical Lift Plan

Proof of qualification for Crane Operators;

SD-06 Test Reports

Reports

Submit reports as their incidence occurs, in accordance with the requirements of the paragraph entitled, "Reports".

Accident Reports

Monthly Exposure Reports

Crane Reports

(12) (12)

01 35 26-11 minimum of 30 minutes after completion of the task or as specified on the hot work permit.

When starting work in the facility, require personnel to familiarize themselves with the location of the nearest fire alarm boxes and place in memory the emergency Davis-Monthan AFB Fire Division phone number. ANY

FIRE, NO MATTER HOW SMALL, SHALL BE REPORTED TO THE RESPONSIBLE FIRE

DIVISION IMMEDIATELY.

1.14 FACILITY OCCUPANCY CLOSURE

Streets, walks, and other facilities occupied and used by the Government shall not be closed or obstructed without written permission from the Contracting Officer.

1.15 SEVERE STORM PLAN

In the event of a severe storm warning, the Contractor must:

a. Secure outside equipment and materials and place materials that could be damaged in protected areas.

b. Check surrounding area, including roof, for loose material, equipment, debris, and other objects that could be blown away or against existing facilities.

c. Ensure that temporary erosion controls are adequate.

PART 2 - PRODUCTS

Not used.

PART 3 - EXECUTION

3.1 CONSTRUCTION AND/OR OTHER WORK

3.1.1 Hazardous Material Exclusions

Notwithstanding any other hazardous material used in this contract, radioactive materials or instruments capable of producing ionizing/non-ionizing radiation (with the exception of radioactive material and devices used in accordance with USACE EM 385-1-1 such as nuclear density meters for compaction testing and laboratory equipment with radioactive sources) as well as materials which contain asbestos, mercury or polychlorinated biphenyls, di-isocynates, lead-based paint are prohibited.

The Contracting Officer, upon written request by the Contractor, may consider exceptions to the use of any of the above excluded materials.

3.1.2 Unforeseen Hazardous Material

Asbestos has been identified in buildings 7410, 7411, 7412, 7413 and 7416 that are scheduled for demolition as part of construction. Lead paint was

(12)

W912PL-11-R-0004

01 35 26-12 not detected in the buildings. Tables and drawings indicating the locations of the asbestos are in Appendix V. If additional material, not indicated, that may be hazardous to human health upon disturbance during construction operations is encountered, stop that portion of work and notify the Contracting Officer immediately. Within 14 calendar days the Government will determine if the material is hazardous. If material is not hazardous or poses no danger, the Government will direct the Contractor to proceed without change. If material is hazardous and handling of the material is necessary to accomplish the work, the Government will issue a modification pursuant to "FAR 52.243-4, Changes" and "FAR 52.236-2, Differing Site Conditions".

3.2 PRE-OUTAGE COORDINATION MEETING

Contractors are required to apply for utility outages at least 15 days in advance. As a minimum, the request should include the location of the outage, utilities being affected, duration of outage and any necessary sketches. Special requirements for electrical outage requests are contained elsewhere in this specification section. Once approved, and prior to beginning work on the utility system requiring shut down, attend a pre-outage coordination meeting with the Contracting Officer and the Installation representative to review the scope of work and the lock-out/tag-out procedures for worker protection. No work will be performed on energized electrical circuits unless proof is provided that no other means exist.

3.3 SAFETY LOCKOUT/TAGOUT PROCEDURES

Contractor shall ensure that each employee is familiar with and complies with these procedures and 29 CFR 1910.147.

Contracting Officer will, at the Contractor's request, apply lockout/tagout tags and take other actions that, because of experience and knowledge, are known to be necessary to make the particular equipment safe to work on.

No person, regardless of position or authority, shall operate any switch, valve, or equipment that has an official lockout/tagout tag attached to it, nor shall such tag be removed except as provided in this section.

No person shall work on any equipment that requires a lockout/tagout tag unless he, his immediate supervisor, project leader, or a subordinate has in his possession the stubs of the required lockout/tagout tags.

When work is to be performed on electrical circuits, only qualified personnel shall perform work on electrical circuits.

A supervisor who is required to enter an area protected by a lockout/tagout tag will be considered a member of the protected group provided he notifies the holder of the tag stub each time he enters and departs from the protected area.

Identification markings on building light and power distribution circuits shall not be relied on for established safe work conditions.

(12) (12) i

APPENDIX INDEX

APPENDIX A - DESIGN COMPATIBILITY STANDARDS, DAVIS-MONTHAN AIR

FORCE BASE, TUCSON, ARIZONA

APPENDIX B – DOD UNIFIED FACILITIES CRITERIA (UFC) MINIMUM

ANTITERRORISM STANDARDS FOR BUILDINGS

APPENDIX C – AEIM, CHAPTER II, CIVIL

APPENDIX D – ARCHITECTURAL DESIGN DEVELOPMENT SHEETS

APPENDIX E - DRAFTING STANDARDS

APPENDIX F – STRUCTURAL DRAFTING STANDARDS

APPENDIX G - DESIGN ANALYSIS GUIDANCE

APPENDIX H - SPECIFICATION GUIDANCE

APPENDIX I – LANDSCAPE DEVELOPMENT PLAN - INSTALLATION PLANT

LIST

APPENDIX J - STORM WATER POLLUTION PREVENTION PLAN OUTLINE AND

PERMIT APPLICATIONS

APPENDIX K – CIVIL DESIGN DEVELOPMENT DRAWINGS

APPENDIX L – GEOTECHNICAL INFORMATION

APPENDIX M – SMALL COMMERCIAL SOLAR ELECTRIC SYSTEM

(PHOTOVOLTAIC)

APPENDIX N – REVEGETATION AND EROSION CONTROL

APPENDIX O – ROOM DATA SHEETS

APPENDIX P – FLOW DATA

APPENDIX Q – FIRE PROTECTION WATERFLOW AND SITE UTILITIES

DETAILS

APPENDIX R – BUILDING INFORMATION MODELING REQUIREMENTS

APPENDIX S – AS-BUILT DRAWINGS

APPENDIX T – STANDARDS MANUAL FOR DRAINAGE DESIGN AND FLOODPLAIN

MANAGEMENT IN TUCSON, ARIZONA

APPENDIX U – TUG VEHICLE DATA

APPENDIX V – ASBESTOS SUMMARY TABLES AND MAPS

(5) (5)

APPENDIX V

ASBESTOS SUMMARY TABLES AND MAPS