W912P822B0029 Amendment 0008.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

West Shore Lake Pontchartrain, LA Hurricane and Storm Damage Risk Reduction Project, WSLP-SP1, Site Preparation Contract 1, St. Charles Parish and John the Baptist Parish, LA (ED-22-013) has been amended to:

1. Provide responses to questions.

Bid Opening date remains scheduled for Tuesday, March 29, 2022 at 11:30 AM CST as per Amendment 0006.

1. CONTRACT ID CODE PAGE OF PAGES

1 4

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 25-Mar-2022

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W912P822B0029

X 9B. DATED (SEE ITEM 11)

08-Feb-2022

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

25-Mar-2022

CODE

USACE, CONTRACTING DIVISION

ATTN: CEMVN-CT, ROOM 172

7400 LEAKE AVE.

NEW ORLEANS LA 70118-3651

W912P8 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912P822B0029

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE

The following have been added by full text:

AMENDMENT 0008

Question 1:

If Option Work 2 is issued, will it be only after Option Work 1 is issued so it can be accessed if those options are deemed to be exercised by the government?

Response: 1:

Options would be awarded sequentially.

Question 2:

Will there be consideration to widen the sand fill in areas for

Response 2:

No

Question 3:

Will geogrid be allowed?

Response 3:

Question 4:

Is there anticipation for water to surpass 3' elevation?

Response 4:

See hydrograph Sheet X-01

Question 5:

Will contractor be charged for the sand coming from the stockpile?

Response 5:

Question 6:

Do stumps have to be fully removed at the root?

Response 6:

Yes

Question 7:

Where are the locations for the settlement plates? We do not see the locations on the drawings.

Response 7:

See Note 1, Sheet C-004

Question 8:

Due to standing water, will contractor be given weather days when rain floods the site? Will those days be compensable?

Response 8:

Much of the site always has standing water and this in itself will not be a reason for a time extension due to weather. Time extensions for unusually severe weather will be granted in accordance with the Default clause (FAR 52.249-10) and Section 01100, Paragraph 1 if weather causes a delay to the completion of the project. The contractor will not be financially compensated.

Question 9:

Is there an economic adjustment for increased fuel prices?

Response 9:

Question 10:

How many projects will simultaneously be going on in area?

Response 10:

See notes, Sheet C-001

Question 11:

Will government widen access road for congestion?

Response 11:

Question 12:

Is there only one access point via access J or will there be another access point from other end?

Response 12:

No other access is available.

Question 13:

Is there a separate staging area for disposal of trees and debris? If so, please provide its location and size.

Response 13:

(End of Summary of Changes)