W912P822B0029 Amendment 0002.pdf

W912P822B0029

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

West Shore Lake Pontchartrain, LA Hurricane and Storm Damage Risk Reduction Project, WSLP-SP1, Site Preparation Contract 1, St. Charles Parish and John the Baptist Parish, LA (ED-22-013) has been amended to:

1. Make changes to the Specif ications

2. Clarify Instructions to Bidders

1. CONTRACT ID CODE PAGE OF PAGES

1 5

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 07-Mar-2022

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W912P822B0029

X 9B. DATED (SEE ITEM 11)

08-Feb-2022

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

07-Mar-2022

CODE

USACE, CONTRACTING DIVISION

ATTN: CEMVN-CT, ROOM 172

7400 LEAKE AVE.

NEW ORLEANS LA 70118-3651

W912P8 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE

The following have been added by full text:

AMENDMENT 0002

SECTION 31 11 00.00 12

1. Page 4, paragraph 3.3.3. Delete this paragraph in its entirety.

2. Page 4, paragraph 3.4.1. Delete this paragraph in its entirety and substitute the following therefore:

“3.4.1 General

All cleared material shall be disposed of offsite or burned. All grubbed material shall be stockpiled outside of the sand base. If burning, the burning permit must be approved before any burning is allowed. Windrows will not be allowed.”

3. Page 5, paragraph 3.4.3. Delete this paragraph in its entirety.

4. Page 5, paragraph 3.4.4. Delete this paragraph in its entirety and substitute the following therefore:

“3.4.4 Removal From Site of Work

The Contractor shall remove debris from the site of work except for the grubbed material to be left onsite as specified elsewhere. Such materials shall be removed from the site of the work before the date of completion of the work. If debris from clearing operations is placed on adjacent property, the Contractor shall obtain, without cost to the Government, additional right-of-way for such purposes. Such material shall be so placed as not to interfere with roads, drainage or other improvements and in such a manner as to eliminate the possibility of its entering into channels, ditches, or streams. The Contractor shall submit written evidence to the Contracting Officer that he/she has obtained from the property owner permission for disposal of material on the owner's property. The written evidence shall consist of an authenticated copy of the conveyance under which the Contractor acquired the property rights and access thereto, prepared and executed in accordance with the laws of the State of Louisiana. If temporary rights are obtained by the Contractor, then the period of time shall coincide with the requirements in the Clause in Section 00700 CONTRACT CLAUSES, entitled COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (FAR 52.211-10), plus any extension authorized under the Contract Clause entitled, DEFAULT (FIXED-PRICE CONSTRUCTION) (FAR 52.249-10), subparagraph (b) (1). However, delay resulting from acquisition of additional rights-of-way for alternate disposal areas will not qualify as excusable delays if suitable Government-furnished disposal areas are available.

Approved disposal sites in the vicinity are as follows:

River Birch Landfill

2000 Hwy. 90 Avondale, LA 70094

Jefferson Parish Landfill 5800 Hwy. 90 Avondale, LA 70094

Industrial Pipe-Plaquemines Parish 11266 Highway 23 Belle Chasse, LA 70037

Amid Landfill, Orleans Parish 11005 Almonaster Ave.

New Orleans, LA”

SECTION 31 24 00.00 12

1. Page 4, paragraph 2.1.2. Delete this paragraph in its entirety and substitute the following therefore:

“2.1.2 Suitability of Material

All fill materials shall be free from concentrated masses of unsuitable materials (excludes organic matter content as defined in ASTM D 2974, Method C) and other non-soil materials including, but not limited to, sticks, branches and roots. “

2. Page 5, paragraph 2.1.2.1. Delete this paragraph in its entirety.

3. Page 5, paragraph 2.2. Delete this paragraph in its entirety.

DRAWINGS

SHEET ID No. C-004. Delete this drawing in its entirety and substitute the attached revised SHEET ID No. C-004, therefore.

Electronic Submission of Bids:

MVN will utilize mail for receipt of electronic bids under IFB Solicitations. In order to submit an electronic bid please follow these steps:

Send an email containing your name, email address and proposal to BOTH the following Contracting Officer and Contract Specialist associated with the IFB:

Contracting Officer – Ms. Veronica Garner-Flint email: Veronica.Garner-Flint@usace.army.mil

Contract Specialist – Ms. Cori Caimi, email: Cori.A.Caimi@usace.army.mil

Once the Contracting Officer or Contract Specialist receives your Proposal, you will then receive a confirmation email stating your Proposal was received.

(End of Summary of Changes)