W912P721R0002 Amendment 4.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

See Summary of Changes on page 2 of this amendment for all changes to the solicitation documents.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 3

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912P721R0002

X 9B. DATED (SEE ITEM 11)

22-Jan-2021

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

U0004

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

8-Apr-2021

CODE

USACE, SAN FRANCISCO DISTRICT

450 GOLDEN GATE

SAN FRANCISCO CA 94102

W912P7 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912P721R0002

SUMMARY OF CHANGES

This amendment makes changes to the solicitation; these changes represent one of three types, either adding new information, deleting information, or revising existing information. Changes made by this amendment replace the previously issued sections of the advertisement, as referenced in the below summary of changes:

ADVERTISEMENT FRONT-END (DIVISION 00):

(1) Revised Section 00 72 00, General Conditions- deleted FAR 52.222-33- Notice of Requirement for Project Labor Agreement

(2) Revised Section 00 73 00, Supplementary Conditions, Added Required Insurance Schedule (Construction), Added Time Extensions for Unusually Severe Weather.

TECHNICAL SPECIFICATIONS (DIVISION 01-49):

(1) Revise specification 01 50 01

REQUESTS FOR INFORMATION (RFI) - QUESTIONS AND ANSWERS.

All offerors are required to acknowledge this amendment and provide a signed copy of this amendment (SF30) with their bid submission. If this amendment is not acknowledged or signed, the bid will be considered non-responsive.

W912P721R0002

SECTION 00 73 00 - SUPPLEMENTARY CONDITIONS

The following have been added by full text:

REQUIRED INSURANCE SCHEDULE (Construction) (AUG 2008) In accordance with the contract clause 52.228-5, Insurance—Work on a Government Installation, the contractor shall procure and maintain during the entire period of contract performance under this contract the following minimum insurance:

Type Amount Workmen’s Compensation coverage complying with applicable state statutes Employer’s Liability minimum amount of $100,000.00 General Liability on minimum limits of $500,000.00 per occurrence for bodily Comprehensive form of policy injury which includes, but is not limited to, insurance for work required herein Comprehensive Automobile minimum limits of $200,000.00 per person and $500,000.00 per Liability occurrence for bodily injury and $20,000.00 per occurrence for property damage

(End)

TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER:

(A) This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with the CONTRACT CLAUSE, Section 00 72 00, entitled "DEFAULT (FIXED-PRICE CONSTRUCTION)". In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

(B) The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all-weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

(8) (8) (6) (6) (3) (0) (0) (0) (2) (4) (4) (8)

(C) Upon acknowledgement of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled work day. (ER 415-1-15, 31 OCT 89)

(End of Summary of Changes)