Amendment_0002 _W912EF-15-R-0044 _IH_Turbine_Install.pdf

W68SBV50771656

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

Amendment 0002 revises the solicitation as stated in the Summary of Changes.

Proposal due date and time remain unchanged. Proposals are due no later than 4:00pm, local time, on 27 October 2015.

ICE HARBOR DAM REWINDS AND TURBINE RUNNER REPLACEMENTS

1. CONTRACT ID CODE PAGE OF PAGES

J 1 35

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 30-Sep-2015

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912EF-15-R-0044

X 9B. DATED (SEE ITEM 11)

01-Sep-2015

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

30-Sep-2015

CODE

USAED, WALLA WALLA - CONTRACTING DIV.

PHYLLIS L. BUERSTATTE

201 N. THIRD AVENUE

WALLA WALLA WA 99362-1876

W912EF 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912EF-15-R-0044

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

The following items are applicable to this modification:

AMENDMENT 0002

Summary of changes for Amendment 0002

Ice Harbor Turbine Installation and Rewind Units 1 – 3

1. Revised Bid schedule See Yellow highlights

Added Bid Item 1016 Removed Bid Item 4006

2. Solicitation provisions and contract clauses have been added or deleted as shown herein.

3. Revised 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

(4) See Yellow Highlights

4. Revised the following Specifications:

SECTION 01 22 00.00 28 MEASUREMENT AND PAYMENT

Added Item 1016 Furnish Complete Set Of Stator Coils, Supplies And Accessories for a Complete New Winding Including Factory Testing Unit 1

Removed Item 4006 Furnish Complete Set Of Stator Coils, Supplies And Accessories for a Complete New Winding Including Factory Testing Unit 1 (Optional)

SECTION 01 45 04.00 28 CONTRACTOR QUALITY CONTROL

Revised Paragraph 3.4.3 CQC Personnel

SECTION 48 13 16.00 26 REWIND OF HYDRAULIC-TURBINE DRIVEN

ALTERNATING CURRENT GENERATOR

Revised the following paragraphs:

1.1 GENERAL

1.4.2 Description of Generator

SECTION 48 13 13.03 26 EXISTING TURBINE COMPONENT REFURBISHMENT,

MODIFICATION AND REPLACEMENT

Revised the following paragraphs:

3.18.6 Facing Plate Replacement

3.21.4 Facing Plate Replacement

SECTION 00100 - BIDDING SCHEDULE/INSTRUCTIONS TO BIDDERS

The following have been added by reference:

252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

AUG 2015

The following have been added by full text:

52.217-5 EVALUATION OF OPTIONS (JUL 1990)

Except when it is determined in accordance with FAR 17.206(b) not to be in the Government's best interests, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

(End of provision)

The following have been modified:

BID SCHEDULE

Walla Walla District Corps of Engineers Ice Harbor Turbine Installation and Rewind Units 1-3

The magnitude of construction is estimated to be between $25,000,000 and $100,000,000 Unrestricted Competition

ITEM DESCRIPTION QUANTITY U/M U/P AMOUNT

BASE ITEMS APPLICABLE TO ALL UNITS

1001 Mobilization And Demobilization 1 JOB XXXXX $________ 1002 Furnish Special Tools, Equipment

And Scaffolding

1 JOB XXXXX $________

1003 Furnish Spare RTDs And Relays 1 JOB XXXXX $________ 1004 Furnish Turbine Maintenance

Platform

1 JOB XXXXX $________

1005 Drain and Dispose of Dirty Oil from Tanks and Piping

Est. 17,500 GAL $________ $________

1006 Supply Clean Oil for Tank and Piping

Est. 9,500 GAL $________ $________

1007 Manufacture Prototype Coils And Perform Accelerated Life Test

1 JOB XXXXX $________

1008 Manufacture Prototype Coils And Perform Thermal Cycling Test

1 JOB XXXXX $________

1009 Furnish Generator Spare Parts 1 JOB XXXXX $________ 1010 Furnish Stator Core Materials And

Accessories for One Generating Unit Including Factory Tests

1 JOB XXXXX $________

1011 Perform Minor Stator Core Iron Repair

NTE 480 HR $________ $________

1012 Perform Special Field Tests 1 JOB XXXXX $________

1013 Disposal of Hydraulic and Lubricating Oil Units 4, 5 and 6

Est. 24,000 GAL $________ $________

1014 Provision of Hydraulic and Lubricating Oil Units 4, 5 and 6

Est. 24,000 GAL $________ $________

1015 Furnish Unit 2 Makup Oil Est. 750 GAL $________ $________

1016 Furnish Complete Set Of Stator Coils, Supplies And Accessories for a Complete New Winding Including Factory Testing Unit 1

1 JOB XXXXX $________

TOTAL BASE ITEMS APPLICABLE TO ALL UNITS $__________

BASE ITEMS APPLICABLE TO UNIT 2

2001 Phase 1 Thrust Bearing Inspection Unit 2 (Shoes, Runner, & Other)

1 JOB XXXXX $________

2002 Inspection Of Turbine And Generator Guide Bearings Unit 2

1 JOB XXXXX $________

2003 Replace Generator Air Coolers, Piping And Valves Unit 2

1 JOB XXXXX $________

2004 Replace Generator Cooling Water Air Operated Valves Unit 2

1 JOB XXXXX $________

2005 Construct Draft Tube Roof Fill Unit

1 JOB XXXXX $________

2006 Furnish Complete Set Of Stator Coils, Supplies And Accessories for a Complete New Winding Including Factory Testing Unit 2

1 JOB XXXXX $________

2007 Remove Existing Stator Winding, Install And Test New Stator Winding Unit 2

1 JOB XXXXX $________

2008 Inspect, Clean And Test Stator Core Unit 2

1 JOB XXXXX $________

2009 Inspect, Clean And Test Rotor Unit

1 JOB XXXXX $________

2010 Lead Based Paint Removal Including Disposal Unit 2

Est. 1,500 SF $________ $________

2011 Painting Unit 2 1 JOB XXXXX $________

2012 Disposal of Hydraulic and Lubricating Oil Unit 2

Est. 4,500 GAL $________ $________

2013 Disposal of Hub/Shafting Water Unit 2

Est. 2,000 GAL $________ $________

2014 Provision of Hydraulic and Lubricating Oil Unit 2

Est. 4,500 GAL $________ $________

2015 Pre-Disassembly Watered Operational Testing Unit 2

1 JOB XXXXX $________

2016 Generating Unit Disassembly Unit 2 1 JOB XXXXX $________

2017 Generating Unit Reassembly Unit 2 1 JOB XXXXX $________

2018 Commissioning for Turbine Replacement and Generator Rewind Unit 2

1 JOB XXXXX $________

2019 Refurbish Wicket Gates Unit 2 1 JOB XXXXX $________

2020 Stay Vane/Ring Refurbishment and Extension Installation Unit 2

1 JOB XXXXX $________

2021 Refurbish Bottom Ring Unit 2 1 JOB XXXXX $________

2022 Furnish Wicket Gate Operating Mechanism Bushings and Bearing Plate Unit 2

1 JOB XXXXX $________

2023 Refurbish Miscellaneous Wicket Gate Operating Mechanism Components Unit 2

1 JOB XXXXX $________

2024 Line Boring and Installation of Wicket Gate Stem Bushings Unit 2

1 JOB XXXXX $________

2025 Refurbish/Replace Turbine Air Admission Valves Unit 2

1 JOB XXXXX $________

2026 Refurbish Operating Ring Unit 2 1 JOB XXXXX $________

2027 Refurbish Wicket Gate Servomotors Unit 2

1 JOB XXXXX $________

2028 Modification of Unit 2 For Fixed Blade Operation

2029 Furnish and Install Turbine Water and Oil Piping Systems and Accessories Unit 2

1 JOB XXXXX $________

2030 Install Discharge Ring and Draft Tube Liner Transition Unit 2

1 JOB XXXXX $________

2031 Provide Electrical Equipment, Wiring, Removal, Installation Unit 2

1 JOB XXXXX $________

2032 Refurbish/Modify Intermediate Headcover Unit 2

1 JOB XXXXX $________

2033 Refurbish Outer Headcover Unit 2 1 JOB XXXXX $________

2034 Refurbish Turbine Shaft Unit 2 1 JOB XXXXX $________

2035 Refurbish Intermediate and Generator Shafts Unit 2

TOTAL BASE ITEMS APPLICABLE TO UNIT 2 $__________

BASE ITEMS APPLICABLE TO UNIT 3

3001 Phase 1 Thrust Bearing Inspection Unit 3 (Shoes, Runner, & Other)

1 JOB XXXXX $________

3002 Inspection Of Turbine And Generator Guide Bearings Unit 3

1 JOB XXXXX $________

3003 Replace Generator Air Coolers, Piping And Valves Unit 3

1 JOB XXXXX $________

3004 Replace Generator Cooling Water Air Operated Valves Unit 3

1 JOB XXXXX $________

3005 Construct Draft Tube Roof Fill Unit

1 JOB XXXXX $________

3006 Furnish Complete Set Of Stator Coils, Supplies And Accessories for a Complete New Winding Including Factory Testing Unit 3

1 JOB XXXXX $________

3007 Remove Existing Stator Winding, Install And Test New Stator Winding Unit 3

1 JOB XXXXX $________

3008 Inspect, Clean And Test Stator Core Unit 3

1 JOB XXXXX $________

3009 Inspect, Clean And Test Rotor Unit

1 JOB XXXXX $________

3010 Lead Based Paint Removal Including Disposal Unit 3

Est. 1,500 SF $________ $________

3011 Painting Unit 3 1 JOB XXXXX $________

3012 Disposal of Hydraulic and Lubricating Oil Unit 3

Est. 4,500 GAL $________ $________

3013 Disposal of Hub/Shafting Water Unit 3

Est. 2,000 GAL $________ $________

3014 Provision of Hydraulic and Lubricating Oil Unit 3

Est. 6,900 GAL $________ $________

3015 Pre-Disassembly Watered Operational Testing Unit 3

1 JOB XXXXX $________

3016 Generating Unit Disassembly Unit 3 1 JOB XXXXX $________

3017 Generating Unit Reassembly Unit 3 1 JOB XXXXX $________

3018 Commissioning for Turbine Replacement and Generator Rewind Unit 3

3019 Refurbish Wicket Gates Unit 3 1 JOB XXXXX $________

3020 Stay Vane/Ring Refurbishment and Extension Installation Unit 3

1 JOB XXXXX $________

3021 Refurbish Bottom Ring Unit 3 1 JOB XXXXX $________

3022 Furnish Wicket Gate Operating Mechanism Bushings and Bearing Plate Unit 3

1 JOB XXXXX $________

3023 Refurbish Miscellaneous Wicket Gate Operating Mechanism Components Unit 3

1 JOB XXXXX $________

3024 Line Boring and Installation of Wicket Gate Stem Bushings Unit 3

1 JOB XXXXX $________

3025 Refurbish/Replace Turbine Air Admission Valves Unit 3

1 JOB XXXXX $________

3026 Refurbish Operating Ring Unit 3 1 JOB XXXXX $________

3027 Refurbish Wicket Gate Servomotors Unit 3

1 JOB XXXXX $________

3028 Furnish and Install Turbine Water and Oil Piping Systems and Accessories Unit 3

1 JOB XXXXX $________

3029 Install Discharge Ring and Draft Tube Liner Transition Unit 3

1 JOB XXXXX $________

3030 Refurbish/Modify Intermediate Headcover Unit 3

1 JOB XXXXX $________

3031 Provide Electrical Equipment, Wiring, Removal, Installation Unit 3

1 JOB XXXXX $________

3032 Refurbish Turbine Shaft Unit 3 1 JOB XXXXX $________

3033 Refurbish Intermediate and Generator Shafts Unit 3

1 JOB XXXXX $________

3034 Refurbish Blade Operating Mechanism Components Unit 3

TOTAL BASE ITEMS APPLICABLE TO UNIT 3 $__________

BASE ITEMS APPLICABLE TO UNIT 1 (OPTIONAL)

4001 Phase 1 Thrust Bearing Inspection Unit 1 (Shoes, Runner, & Other) (Optional)

1 JOB XXXXX $________

4002 Inspection Of Turbine And Generator Guide Bearings Unit 1 (Optional)

1 JOB XXXXX $________

4003 Replace Generator Air Coolers, Piping And Valves Unit 1 (Optional)

1 JOB XXXXX $________

4004 Replace Generator Cooling Water Air Operated Valves Unit 1 (Optional)

1 JOB XXXXX $________

4005 Construct Draft Tube Roof Fill Unit 1 (Optional)

1 JOB XXXXX $________

4006 RESERVED

4007 Remove Existing Stator Winding, Install And Test New Stator Winding Unit 1 (Optional)

1 JOB XXXXX $________

4008 Inspect, Clean And Test Stator Core Unit 1 (Optional)

1 JOB XXXXX $________

4009 Inspect, Clean And Test Rotor Unit 1 (Optional)

1 JOB XXXXX $________

4010 Lead Based Paint Removal Including Disposal Unit 1 (Optional)

Est. 1,500 SF $________ $________

4011 Painting Unit 1 (Optional) 1 JOB XXXXX $________

4012 Disposal of Hydraulic and Lubricating Oil Unit 1 (Optional)

Est. 6,500 GAL $________ $________

4013 Provision of Hydraulic and Lubricating Oil Unit 1 (Optional)

Est. 6,900 GAL $________ $________

4014 Pre-Disassembly Watered Operational Testing Unit 1 (Optional)

1 JOB XXXXX $________

4015 Generating Unit Disassembly Unit 1 (Optional)

1 JOB XXXXX $________

4016 Generating Unit Reassembly Unit 1 (Optional)

4017 Commissioning for Turbine Replacement and Generator Rewind Unit 1 (Optional)

1 JOB XXXXX $________

4018 Refurbish Wicket Gates Unit 1 (Optional)

1 JOB XXXXX $________

4019 Stay Vane/Ring Refurbishment and Extension Installation Unit 1 (Optional)

1 JOB XXXXX $________

4020 Refurbish Bottom Ring Unit 1 (Optional)

1 JOB XXXXX $________

4021 Furnish Wicket Gate Operating Mechanism Bushings and Bearing Plate Unit 1 (Optional)

1 JOB XXXXX $________

4022 Refurbish Miscellaneous Wicket Gate Operating Mechanism Components Unit 1 (Optional)

1 JOB XXXXX $________

4023 Line Boring and Installation of Wicket Gate Stem Bushings Unit 1 (Optional)

1 JOB XXXXX $________

4024 Refurbish/Replace Turbine Air Admission Valves Unit 1 (Optional)

1 JOB XXXXX $________

4025 Refurbish Operating Ring Unit 1 (Optional)

1 JOB XXXXX $________

4026 Refurbish Wicket Gate Servomotors Unit 1 (Optional)

1 JOB XXXXX $________

4027 Furnish and Install Turbine Water and Oil Piping Systems and Accessories Unit 1 (Optional)

1 JOB XXXXX $________

4028 Install Discharge Ring and Draft Tube Liner Transition Unit 1 (Optional)

1 JOB XXXXX $________

4029 Refurbish/Modify Intermediate Headcover Unit 1 (Optional)

1 JOB XXXXX $________

4030 Provide Electrical Equipment, Wiring, Removal, Installation Unit 1

4031 Refurbish Turbine Shaft Unit 1 (Optional)

1 JOB XXXXX $________

4032 Refurbish Intermediate and Generator Shafts Unit 1 (Optional)

1 JOB XXXXX $________

4033 Refurbish Blade Operating Mechanism Components Unit 1

TOTAL BASE ITEMS APPLICABLE TO UNIT 1 (OPTIONAL) $__________

OPTIONAL ITEMS APPLICABLE TO ALL UNITS

5001 Miscellaneous Parts And Materials

(Optional)

NTE

$80,000

____ XXXXX $________

5002 Miscellaneous Welding (Optional) NTE

LB $________ $________

5003 T&M: Provide Skilled Welding Hire (Optional)

NTE

HR $________ $________

5004 T&M: Provide Skilled Machinist Hire (Optional)

NTE

HR $________ $________

5005 T&M: Provide Skilled Electrician Hire (Optional)

NTE

HR $________ $________

5006 T&M: Provide Skilled Painter Hire (Optional)

NTE

HR $________ $________

5007 T&M: Provide Skilled Millwright/Mechanic Hire (Optional)

NTE

HR $________ $________

5008 T&M: Provide Skilled General Laborer Hire (Optional)

NTE

HR $________ $________

5009 T&M: Provide Skilled Liquid Penetrant Testing (Optional)

NTE

HR $________ $________

5010 T&M: Provide Skilled Magnetic Particle Testing (Optional)

NTE

HR $________ $________

5011 T&M: Provide Skilled Ultrasonic Testing (Optional)

NTE

HR $________ $________

5012 Furnish Stator Core Materials and Accessories for One Generating Unit (Optional)

NTE

EA $________ $________

5013 Perform Additional Interlaminar Insulation Test (Optional)

TOTAL OPTIONAL ITEMS APPLICABLE TO ALL UNITS $__________

OPTIONAL ITEMS APPLICABLE TO UNIT 1

6001 Phase 2 Inspection of Thrust Shoes for Unit 1 (Optional)

1 JOB XXXXX $________

6002 Phase 2 Inspection of Thrust Bearing Runner and Thrust Collar for Unit 1 (Optional)

1 JOB XXXXX $________

6003 Refurbish Thrust Bearing Runner Unit 1 (Optional)

1 JOB XXXXX $________

6004 Machine Backside of Thrust Bearing Shoes for Unit 1 (Optional)

1 JOB XXXXX $________

6005 Machine Babbitted Face of Thrust Bearing Shoes for Unit 1 (Optional)

1 JOB XXXXX $________

6006 Refurbish Thrust Bearing Shoes Including Babbitting for Unit 1 (Optional)

1 JOB XXXXX $________

6007 Refurbish Thrust Bearing Collar for Unit 1 (Optional)

1 JOB XXXXX $________

6008 Refurbish Turbine Guide Bearing for Unit 1 (Optional)

1 JOB XXXXX $________

6009 Refurbish Generator Lower Guide Bearing Pads by Machining for Unit 1 (Optional)

1 JOB XXXXX $________

6010 Refurbish Generator Lower Guide Bearing Pads Including Babbitting for Unit 1 (Optional)

1 JOB XXXXX $________

6011 Refurbish Generator Upper Guide Bearing Pads by Machining for Unit 1 (Optional)

1 JOB XXXXX $________

6012 Refurbish Generator Upper Guide Bearing Pads Including Babbitting for Unit 1 (Optional)

1 JOB XXXXX $________

6013 Wicket Gate Additional Painting for Unit 1 (Optional)

2 EA $________ $________

6014 Stay Vane Additional Painting for Unit 1 (Optional)

2 EA $________ $________

6015 Generator Rotor Balancing for Unit 1 (Optional)

1 JOB XXXXX $________

6016 Remove Existing Stator Core, Install and Test New Stator Core for Unit 1 (Optional)

1 JOB XXXXX $________

6017 Refurbish Rotor Poles Unit 1

6018 Machine Stay Ring Flange Unit 1

(Optional)

1 JOB $________ $________

6019 Bore Wicket Gate Servomotor Cylinder Unit 1 (Optional)

2 EA $________ $________

6020 Chrome Plate Wicket Gate Servomotor Piston Rod Unit 1

2 EA $________ $________

TOTAL OPTIONAL ITEMS APPLICABLE TO UNIT 1 $__________

OPTIONAL ITEMS APPLICABLE TO UNIT 2

7001 Phase 2 Inspection of Thrust Shoes for Unit 2 (Optional)

1 JOB XXXXX $________

7002 Phase 2 Inspection of Thrust Bearing Runner and Thrust Collar for Unit 2 (Optional)

1 JOB XXXXX $________

7003 Refurbish Thrust Bearing Runner Unit 2 (Optional)

1 JOB XXXXX $________

7004 Machine Backside of Thrust Bearing Shoes for Unit 2 (Optional)

1 JOB XXXXX $________

7005 Machine Babbitted Face of Thrust Bearing Shoes for Unit 2 (Optional)

1 JOB XXXXX $________

7006 Refurbish Thrust Bearing Shoes Including Babbitting for Unit 2 (Optional)

1 JOB XXXXX $________

7007 Refurbish Thrust Bearing Collar for Unit 2 (Optional)

1 JOB XXXXX $________

7008 Refurbish Turbine Guide Bearing for Unit 2 (Optional)

1 JOB XXXXX $________

7009 Refurbish Generator Lower Guide Bearing Pads by Machining for Unit 2 (Optional)

1 JOB XXXXX $________

7010 Refurbish Generator Lower Guide Bearing Pads Including Babbitting for Unit 2 (Optional)

1 JOB XXXXX $________

7011 Refurbish Generator Upper Guide Bearing Pads by Machining for Unit 2 (Optional)

1 JOB XXXXX $________

7012 Refurbish Generator Upper Guide Bearing Pads Including Babbitting for Unit 2 (Optional)

1 JOB XXXXX $________

7013 Wicket Gate Additional Painting for Unit 2 (Optional)

2 EA $________ $________

7014 Stay Vane Additional Painting for Unit 2 (Optional)

2 EA $________ $________

7015 Generator Rotor Balancing for Unit 2 (Optional)

1 JOB XXXXX $________

7016 Remove Existing Stator Core, Install and Test New Stator Core for Unit 2 (Optional)

1 JOB XXXXX $________

7017 Refurbish Rotor Poles Unit 2

7018 Machine Stay Ring Flange Unit 2

(Optional)

1 JOB XXXXX $________

7019 Bore Wicket Gate Servomotor Cylinder Unit 2 (Optional)

2 EA $________ $________

7020 Chrome Plate Wicket Gate Servomotor Piston Rod Unit 2

TOTAL OPTIONAL ITEMS APPLICABLE TO UNIT 2 $__________

OPTIONAL ITEMS APPLICABLE TO UNIT 3

8001 Phase 2 Inspection of Thrust Shoes for Unit 3 (Optional)

1 JOB XXXXX $________

8002 Phase 2 Inspection of Thrust Bearing Runner and Thrust Collar for Unit 3 (Optional)

1 JOB XXXXX $________

8003 Refurbish Thrust Bearing Runner Unit 3 (Optional)

1 JOB XXXXX $________

8004 Machine Backside of Thrust Bearing Shoes for Unit 3 (Optional)

1 JOB XXXXX $________

8005 Machine Babbitted Face of Thrust Bearing Shoes for Unit 3 (Optional)

1 JOB XXXXX $________

8006 Refurbish Thrust Bearing Shoes Including Babbitting for Unit 3 (Optional)

1 JOB XXXXX $________

8007 Refurbish Thrust Bearing Collar for Unit 3 (Optional)

1 JOB XXXXX $________

8008 Refurbish Turbine Guide Bearing for Unit 3 (Optional)

1 JOB XXXXX $________

8009 Refurbish Generator Lower Guide Bearing Pads by Machining for Unit 3 (Optional)

1 JOB XXXXX $________

8010 Refurbish Generator Lower Guide Bearing Pads Including Babbitting for Unit 3 (Optional)

1 JOB XXXXX $________

8011 Refurbish Generator Upper Guide Bearing Pads by Machining for Unit 3 (Optional)

1 JOB XXXXX $________

8012 Refurbish Generator Upper Guide Bearing Pads Including Babbitting for Unit 3 (Optional)

1 JOB XXXXX $________

8013 Wicket Gate Additional Painting for Unit 3 (Optional)

2 EA $________ $________

8014 Stay Vane Additional Painting for Unit 3 (Optional)

2 EA $________ $________

8015 Generator Rotor Balancing for Unit 3 (Optional)

1 JOB XXXXX $________

8016 Remove Existing Stator Core, Install and Test New Stator Core for Unit 3 (Optional)

1 JOB XXXXX $________

8017 Refurbish Rotor Poles Unit 3

8018 Machine Stay Ring Flange Unit 3

(Optional)

1 JOB $________ $________

8019 Bore Wicket Gate Servomotor Cylinder Unit 3 (Optional)

2 EA $________ $________

8020 Chrome Plate Wicket Gate Servomotor Piston Rod Unit 3

TOTAL OPTIONAL ITEMS APPLICABLE TO UNIT 3 $__________

OPTIONAL ITEMS TOTAL $__________

SCHEDULE TOTAL $__________

IMPORTANT See Section 01 22 00.00 28; MEASUREMENT AND PAYMENT; Paragraph; Retainage of Payment, for withholding of payment for final deliverables.

NTE = Not To Exceed Est = Estimated

Quantities identified as Estimated (“Est”) in the bid schedule are subject to FAR Clause 52.211-18, VARIATION IN ESTIMATED QUANTITY, located in Section 00700.

LABOR HOUR AND TIME & MATERIALS LINE ITEMS: Contract Line Items # 1011, and 5001 through 5011 are labor hour or time-and-materials line items. The extended amount for each of these items is the established ceiling price. Without a modification pursuant to FAR Clause 52.243-3, Changes -- Time-and-Materials or Labor-Hours (Sep 2000), the Contractor exceeds the ceiling at his own risk.

SECTION 00600 - REPRESENTATIONS & CERTIFICATIONS

52.203-11 Certification And Disclosure Regarding Payments To

Influence Certain Federal Transactions

SEP 2007

252.215-7008 Only One Offer OCT 2013

SECTION 00700 - CONTRACT CLAUSES

52.228-15 Performance and Payment Bonds--Construction OCT 2010 52.247-34 F.O.B. Destination NOV 1991 252.204-7012 Safeguarding of Unclassified Controlled Technical

Information

AUG 2015

252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.247-7024 Notification Of Transportation Of Supplies By Sea MAR 2000

The following have been added by full text:

52.217-7 OPTION FOR INCREASED QUANTITY--SEPARATELY PRICED LINE ITEM (MAR 1989)

The Government may require the delivery of the numbered line item, identified in the Schedule as an option item, in the quantity and at the price stated in the Schedule. The Contracting Officer may exercise the option by written notice to the Contractor within the time periods stated below

CLIN DESCRIPTION TIMEFRAME WHEN OPTIONAL

ITEM MAY BE EXERCISED

IF EXERCISED, TIME

EXTENSION TO

COMPLETE WORK

FOR ITEM

4001 Phase 1 Thrust Bearing Inspection Unit 1 (Shoes, Runner, & Other) (Optional)

Prior to completion of Unit 3 Installation.

15 Months (15) from date of exercising the option.

4002 Inspection Of Turbine And Generator Guide Bearings Unit 1 (Optional) option.

4003 Replace Generator Air Coolers, Piping And Valves Unit (Optional) option.

4004 Replace Generator Cooling Water Air Operated Valves Unit 1 (Optional) option.

4005 Construct Draft Tube Roof Fill Unit 1 (Optional) option.

4006 RESERVED

4007 Remove Existing Stator Winding, Install And Test New Stator Winding Unit 1 (Optional) option.

4008 Inspect, Clean And Test Stator Core Unit 1 (Optional) option.

4009 Inspect, Clean And Test Rotor Unit 1 (Optional) option.

4010 Lead Based Paint Removal Including Disposal Unit 1 (Optional) option.

4011 Painting Unit 1 (Optional) Prior to completion of Unit 3 option.

4012 Disposal of Hydraulic and Lubricating Oil Unit 1 (Optional) option.

4013 Provision of Hydraulic and Lubricating Oil Unit 1 (Optional) option.

4014 Pre-Disassembly Watered Operational Testing Unit 1 (Optional) option.

4015 Generating Unit Disassembly Unit 1 (Optional) option.

4016 Generating Unit Reassembly Unit 1 (Optional) option.

4017 Commissioning for Turbine Replacement and Generator Rewind Unit 1 (Optional) option.

4018 Refurbish Wicket Gates Unit 1 (Optional) option.

4019 Stay Vane/Ring Refurbishment and Extension Installation Unit 1 (Optional)

4020 Refurbish Bottom Ring Unit 1 option.

4021 Furnish Wicket Gate Operating Mechanism Bushings and Bearing Plate Unit 1 (Optional) option.

4022 Refurbish Miscellaneous Wicket Gate Operating Mechanism Components Unit 1 (Optional) option.

4023 Line Boring and Installation of Wicket Gate Stem Bushings Unit 1 (Optional) option.

4024 Refurbish/Replace Turbine Air Admission Valves Unit 1 (Optional) option.

4025 Refurbish Operating Ring Unit 1 (Optional) option.

4026 Refurbish Wicket Gate Servomotors Unit 1 (Optional) option.

4027 Furnish and Install Turbine Water and Oil Piping Systems and Accessories Unit 1 (Optional) option.

4028 Install Discharge Ring and Draft Tube Liner Transition Unit 1 (Optional) option.

4029 Refurbish/Modify Intermediate Headcover Unit 1 (Optional) option.

4030 Provide Electrical Equipment, Wiring, Removal, Installation Unit 1 (Optional) option.

4031 Refurbish Turbine Shaft Unit 1 option.

4032 Refurbish Intermediate and Generator Shafts Unit 1 (Optional) option.

4033 Refurbish Blade Operating Mechanism Components Unit 1 (Optional)

ITEM DESCRIPTION TIMEFRAME WHEN OPTIONAL

ITEM WILL BE EXERCISED

IF EXERCISED, TIME

EXTENSION TO

COMPLETE WORK

FOR ITEM

5001 Miscellaneous Parts, Materials and Services (Optional)

Available until completion of onsite work

No additional time will be allowed

5002 Miscellaneous Welding (Optional) Available until completion of onsite work

No additional time will be allowed

5003 T&M: Provide Skilled Welding Hire (Optional)

Available until completion of onsite work

No additional time will be allowed

5004 T&M: Provide Skilled Machinist Hire (Optional)

Available until completion of onsite work

No additional time will be allowed

5005 T&M: Provide Skilled Electrician Hire (Optional)

Available until completion of onsite work

No additional time will be allowed

5006 T&M: Provide Skilled Painter Hire (Optional)

Available until completion of onsite work

No additional time will be allowed

5007 T&M: Provide Skilled Millwright/Mechanic Hire (Optional)

Available until completion of onsite work

No additional time will be allowed

5008 T&M: Provide Skilled General Laborer Hire (Optional)

Available until completion of onsite work

No additional time will be allowed

5009 T&M: Provide Skilled Liquid Penetrant Testing (Optional)

Available until completion of onsite work

No additional time will be allowed

5010 T&M: Provide Skilled Magnetic Particle Testing (Optional)

Available until completion of onsite work

No additional time will be allowed

5011 T&M: Provide Skilled Ultrasonic Testing (Optional)

Available until completion of onsite work

No additional time will be allowed

5012 Furnish Stator Core Materials and Accessories for One Generating Unit (Optional)

Within Fifteen (15) days after Government Approval of the Stator Inspection Report

No additional time will be allowed

5013 Perform Additional Interlaminar Insulation Test (Optional)

Within Fifteen (15) days after Government Approval of the Interlaminar Insulation Test

Fourteen (14) calendar days from date of exercising the option.

6001 Phase 2 Inspection of Thrust Shoes for Unit 1 (Optional)

Within Fifteen (15) days after Government Approval of the Thrust Bearing Shoes As-Found Inspection Report

No additional time will be allowed

6002 Phase 2 Inspection of Thrust Bearing Runner and Thrust Collar for Unit 1 (Optional)

Within Fifteen (15) days after Government Approval of the Thrust Collar As-Found Inspection Report and Thrust Runner As-Found Inspection Report

No additional time will be allowed

6003 Refurbish Thrust Bearing Runner Unit 1 (Optional)

Within Fifteen (15) days after Government Approval of the Thrust Bearing Runner Phase 2 Inspection Report

No additional time will be allowed

6004 Machine Backside of Thrust Bearing Shoes for Unit 1 (Optional)

Within Fifteen (15) days after Government Approval of the Thrust Bearing Shoes Phase 2 Inspection Report

No additional time will be allowed

6005 Machine Babbitted Face of Thrust Bearing Shoes for Unit 1 (Optional)

Within Fifteen (15) days after Government Approval of the Thrust Bearing Shoes Phase 2 Inspection Report

No additional time will be allowed

6006 Refurbish Thrust Bearing Shoes Including Babbitting for Unit 1 (Optional)

Within Fifteen (15) days after Government Approval of the Thrust Bearing Shoes Phase 2 Inspection Report

No additional time will be allowed

6007 Refurbish Thrust Bearing Collar for Unit 1 (Optional)

Within Fifteen (15) days after Government Approval of the Thrust Bearing Collar Phase 2 Inspection Report

No additional time will be allowed

6008 Refurbish Turbine Guide Bearing for Unit 1 (Optional)

Within Fifteen (15) days after Government Approval of the Turbine Guide Bearing Site Inspection Report

No additional time will be allowed

6009 Refurbish Generator Lower Guide Bearing Pads by Machining for Unit 1 (Optional)

Within Fifteen (15) days after Government Approval of the Generator Guide Bearing Site Inspection Report

No additional time will be allowed

6010 Refurbish Generator Lower Guide Bearing Pads Including Babbitting for Unit 1 (Optional)

Within Fifteen (15) days after Government Approval of the Generator Guide Bearing Site Inspection Report

No additional time will be allowed

6011 Refurbish Generator Upper Guide Bearing Pads by Machining for Unit 1 (Optional)

Within Fifteen (15) days after Government Approval of the Generator Guide Bearing Site Inspection Report

No additional time will be allowed

6012 Refurbish Generator Upper Guide Bearing Pads Including Babbitting for Unit 1 (Optional)

Within Fifteen (15) days after Government Approval of the Generator Guide Bearing Site Inspection Report

No additional time will be allowed

6013 Wicket Gate Additional Painting for Unit 1 (Optional)

Within Ten (10) days of previous contract paint application

No additional time will be allowed

6014 Stay Vane Additional Painting for Unit 1 (Optional)

Within Forty Eight (48) hours of previous contract paint coat application

6015 Generator Rotor Balancing for Unit 1 (Optional)

Within Fifteen (15) days after Government Approval of the Pre-Disassembly Watered Operational Testing Report

Five (5) calendar days from date of exercising the option.

6016 Remove Existing Stator Core, Install and Test New Stator Core for Unit 1 (Optional)

Within Fifteen (15) days after Government Approval of the Interlaminar Insulation Test

An additional 15 days will be added to the schedule.

6017 Refurbish Rotor Poles Unit 1 (Optional)

Within Fifteen (15) days after Government Approval of the Rotor Test Report

No additional time will be allowed

6018 Machine Stay Ring Flange Unit 1 (Optional)

Within Fifteen (15) days after Government Approval of the Stay Ring As-Found Inspection Report

No additional time will be allowed

6019 Bore Wicket Gate Servomotor Cylinder Unit 1 (Optional)

Within Fifteen (15) days after Government Approval of the Wicket Gate As-Found Inspection Report

No additional time will be allowed

6020 Chrome Plate Wicket Gate Servomotor Piston Rod Unit 1 (Optional)

Within Fifteen (15) days after Government Approval of the Wicket Gate As-Found Inspection Report

No additional time will be allowed

7001 Phase 2 Inspection of Thrust Shoes for Unit 2 (Optional)

Within Fifteen (15) days after Government Approval of the Thrust Bearing Shoes As-Found Inspection Report

No additional time will be allowed

7002 Phase 2 Inspection of Thrust Bearing Runner and Thrust Collar for Unit 2 (Optional)

Within Fifteen (15) days after Government Approval of the Thrust Collar As-Found Inspection Report and Thrust Runner As-Found Inspection Report

No additional time will be allowed

7003 Refurbish Thrust Bearing Runner Unit 2 (Optional)

Within Fifteen (15) days after Government Approval of the Thrust Bearing Runner Phase 2 Inspection Report

No additional time will be allowed

7004 Machine Backside of Thrust Bearing Shoes for Unit 2 (Optional)

Within Fifteen (15) days after Government Approval of the Thrust Bearing Shoes Phase 2 Inspection Report

No additional time will be allowed

7005 Machine Babbitted Face of Thrust Bearing Shoes for Unit 2 (Optional)

Within Fifteen (15) days after Government Approval of the Thrust Bearing Shoes Phase 2 Inspection Report

7006 Refurbish Thrust Bearing Shoes Including Babbitting for Unit 2 (Optional)

Within Fifteen (15) days after Government Approval of the Thrust Bearing Shoes Phase 2 Inspection Report

No additional time will be allowed

7007 Refurbish Thrust Bearing Collar for Unit 2 (Optional)

Within Fifteen (15) days after Government Approval of the Thrust Bearing Collar Phase 2 Inspection Report

No additional time will be allowed

7008 Refurbish Turbine Guide Bearing for Unit 2 (Optional)

Within Fifteen (15) days after Government Approval of the Turbine Guide Bearing Site Inspection Report

No additional time will be allowed

7009 Refurbish Generator Lower Guide Bearing Pads by Machining for Unit 2 (Optional)

Within Fifteen (15) days after Government Approval of the Generator Guide Bearing Site Inspection Report

No additional time will be allowed

7010 Refurbish Generator Lower Guide Bearing Pads Including Babbitting for Unit 2 (Optional)

Within Fifteen (15) days after Government Approval of the Generator Guide Bearing Site Inspection Report

No additional time will be allowed

7011 Refurbish Generator Upper Guide Bearing Pads by Machining for Unit 2 (Optional)

Within Fifteen (15) days after Government Approval of the Generator Guide Bearing Site Inspection Report

No additional time will be allowed

7012 Refurbish Generator Upper Guide Bearing Pads Including Babbitting for Unit 2 (Optional)

Within Fifteen (15) days after Government Approval of the Generator Guide Bearing Site Inspection Report

No additional time will be allowed

7013 Wicket Gate Additional Painting for Unit 2 (Optional)

Within Ten (10) days of previous contract paint application

No additional time will be allowed

7014 Stay Vane Additional Painting for Unit 2 (Optional)

Within Forty Eight (48) hours of previous contract paint coat application

No additional time will be allowed

7015 Generator Rotor Balancing for Unit 2 (Optional)

Within Fifteen (15) days after Government Approval of the Pre-Disassembly Watered Operational Testing Report

Five (5) calendar days from date of exercising the option.

7016 Remove Existing Stator Core, Install and Test New Stator Core for Unit 2 (Optional)

Within Fifteen (15) days after Government Approval of the Interlaminar Insulation Test

An additional 15 days will be added to the schedule.

7017 Refurbish Rotor Poles Unit 2 (Optional)

Within Fifteen (15) days after Government Approval of the Rotor Test Report

7018 Machine Stay Ring Flange Unit 2

Within Fifteen (15) days after Government Approval of the Stay Ring As-Found Inspection Report

No additional time will be allowed

7019 Bore Wicket Gate Servomotor Cylinder Unit 2 (Optional)

Within Fifteen (15) days after Government Approval of the Wicket Gate As-Found Inspection Report

No additional time will be allowed

7020 Chrome Plate Wicket Gate Servomotor Piston Rod Unit 2 (Optional)

Within Fifteen (15) days after Government Approval of the Wicket Gate As-Found Inspection Report

No additional time will be allowed

8001 Phase 2 Inspection of Thrust Shoes for Unit 3 (Optional)

Within Fifteen (15) days after Government Approval of the Thrust Bearing Shoes As-Found Inspection Report

No additional time will be allowed

8002 Phase 2 Inspection of Thrust Bearing Runner and Thrust Collar for Unit 3 (Optional)

Within Fifteen (15) days after Government Approval of the Thrust Collar As-Found Inspection Report and Thrust Runner As-Found Inspection Report

No additional time will be allowed

8003 Refurbish Thrust Bearing Runner Unit 3 (Optional)

Within Fifteen (15) days after Government Approval of the Thrust Bearing Runner Phase 2 Inspection Report

No additional time will be allowed

8004 Machine Backside of Thrust Bearing Shoes for Unit 3 (Optional)

Within Fifteen (15) days after Government Approval of the Thrust Bearing Shoes Phase 2 Inspection Report

No additional time will be allowed

8005 Machine Babbitted Face of Thrust Bearing Shoes for Unit 3 (Optional)

Within Fifteen (15) days after Government Approval of the Thrust Bearing Shoes Phase 2 Inspection Report

No additional time will be allowed

8006 Refurbish Thrust Bearing Shoes Including Babbitting for Unit 3 (Optional)

Within Fifteen (15) days after Government Approval of the Thrust Bearing Shoes Phase 2 Inspection Report

No additional time will be allowed

8007 Refurbish Thrust Bearing Collar for Unit 3 (Optional)

Within Fifteen (15) days after Government Approval of the Thrust Bearing Collar Phase 2 Inspection Report

No additional time will be allowed

8008 Refurbish Turbine Guide Bearing for Unit 3 (Optional)

Within Fifteen (15) days after Government Approval of the Turbine Guide Bearing Site Inspection Report

8009 Refurbish Generator Lower Guide Bearing Pads by Machining for Unit 3 (Optional)

Within Fifteen (15) days after Government Approval of the Generator Guide Bearing Site Inspection Report

No additional time will be allowed

8010 Refurbish Generator Lower Guide Bearing Pads Including Babbitting for Unit 3 (Optional)

Within Fifteen (15) days after Government Approval of the Generator Guide Bearing Site Inspection Report

No additional time will be allowed

8011 Refurbish Generator Upper Guide Bearing Pads by Machining for Unit 3 (Optional)

Within Fifteen (15) days after Government Approval of the Generator Guide Bearing Site Inspection Report

No additional time will be allowed

8012 Refurbish Generator Upper Guide Bearing Pads Including Babbitting for Unit 3 (Optional)

Within Fifteen (15) days after Government Approval of the Generator Guide Bearing Site Inspection Report

No additional time will be allowed

8013 Wicket Gate Additional Painting for Unit 3 (Optional)

Within Ten (10) days of previous contract paint application

No additional time will be allowed

8014 Stay Vane Additional Painting for Unit 3 (Optional)

Within Forty Eight (48) hours of previous contract paint coat application

No additional time will be allowed

8015 Generator Rotor Balancing for Unit 3 (Optional)

Within Fifteen (15) days after Government Approval of the Pre-Disassembly Watered Operational Testing Report

Five (5) calendar days from date of exercising the option.

8016 Remove Existing Stator Core, Install and Test New Stator Core for Unit 3 (Optional)

Within Fifteen (15) days after Government Approval of the Interlaminar Insulation Test

An additional 15 days will be added to the schedule.

8017 Refurbish Rotor Poles Unit 3 (Optional)

Within Fifteen (15) days after Government Approval of the Rotor Test Report

No additional time will be allowed

8018 Machine Stay Ring Flange Unit 3 (Optional)

Within Fifteen (15) days after Government Approval of the Stay Ring As-Found Inspection Report

No additional time will be allowed

8019 Bore Wicket Gate Servomotor Cylinder Unit 3 (Optional)

Within Fifteen (15) days after Government Approval of the Wicket Gate As-Found Inspection Report

No additional time will be allowed

8020 Chrome Plate Wicket Gate Servomotor Piston Rod Unit 3 (Optional)

Within Fifteen (15) days after Government Approval of the Wicket Gate As-Found Inspection Report

(End of clause)

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to

(a) Commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed,

(b) prosecute the work diligently, and

(c) complete the entire work ready for use not later than the timeframes listed below.

(1) The work shall commence at Unit 2 (fixed blade runner with stator rewind) followed by Unit 3 (adjustable blade runner with stator rewind) followed by Optional Unit 1 (adjustable blade runner with stator rewind). No two units may be out of service at the same time unless allowed by the Contracting Officer. Each unit must be completely operational, commissioned and ready for operation prior to taking another unit out of service.

i. The Contractor shall include 15 calendar days in the schedule for the Government to dewater and prepare each unit for work to start. This time includes initial asbestos abatement pre-cleaning of the generator area (by others).

ii. When disassembling the generator, the Contractor shall place the rotor on the existing rotor pedestal and provide a dust containment structure over and around the rotor. The structure shall be adequate for the abatement of asbestos (by others) and containment of any dust as a result of the abatement effort. The Contractor shall provide a safe working platform for all work conducted on the stator, including asbestos abatement and lead based paint removal (by others). The Contractor shall include an additional 28 calendar days (in addition to the 15 calendar days stated in subparagraph (c)(1)(i) above) in the schedule for asbestos abatement of the stator and rotor.

During this time frame the Contractor shall allow for unimpeded access to the rotor and stator for asbestos abatement. The Contractor can proceed with other work in the powerhouse but will not be allowed to work in the generator/turbine pit areas that are subjected to the asbestos abatement operations. Actual time may vary depending on the extent of the abatements as required. Asbestos abatement will be performed under a separate contract by others.

iii. Upon completion and acceptance of work on the first unit (Unit 2), the Government requires 5 calendar days to perform the pre-operational test phase. Operational testing performed by the Government will require 5 additional calendar days, which will include Commissioning Support provided by the Contractor, prior to returning the unit to service. See Section 01 32 01.00 28 PROJECT SCHEDULE: paragraph Mandatory Tasks; sub paragraph q for additional information.

Upon completion of commissioning, the Government will require an additional 15 calendar days to dewater and prepare the second unit for work to start. This time includes initial asbestos abatement pre-cleaning of the generator (by others)

iv. Upon completion and acceptance of work on the Second unit, the Government requires 5 calendar days to perform pre-operational test phase. Operational testing phase performed by the Government will require 5 additional calendar days, which will include Commissioning Support provided by the Contractor, prior to returning this unit to service. Upon completion of commissioning, the Government will require an additional 10 calendar days to dewater and prepare the third unit for work to start.

v. Upon completion and acceptance of work on the Third unit, the Government requires 5 calendar days to perform pre-operational test phase. Operational testing phase performed by the Government will require 5 additional calendar days, which will include Commissioning Support provided by the Contractor, prior to returning this unit to service. Upon completion of commissioning, the Government will require an additional 10 calendar days to return to Unit 2 to dewater and prepare to complete the stator core rewind.

(2) The Contractor shall complete final cleanup and demobilization by not later than 15 calendar days after completion of work in (1) above.

(3) The Contractor shall complete final submission of, working “as-built” contract drawings and final approved versions of Contractor prepared drawings (see Section 01 78 00.00 28) by not later than 30 calendar days after completion of work in (1) above.

(4) The timeframes to complete the work will be based on the accepted proposed schedule as awarded, but shall not exceed a total of 1000 calendar days for Units 2 and Unit 3, and an additional 450 calendar days for Optional Unit 1, from notice to proceed to completion of final demobilization, unless otherwise agreed by the Contracting Officer. See instructions to offers, for factor I, sub-factor d for additional schedule instructions.

(End of clause)

The following have been deleted:

252.204-7012 Safeguarding of Unclassified Controlled Technical

Information

NOV 2013

SECTION 00800 - SPECIAL CONTRACT REQUIREMENTS

LOCAL REQUIREMENTS

Invoices/Payment Requests

Invoices/payment requests must be submitted to Walla Walla District, Corps of Engineers, Attention: Construction Branch, 201 N. Third Ave., Walla Walla, WA 99362.

PERFORMANCE AND PAYMENT BONDS: If the successful offeror, upon acceptance of its offer by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after the date of contract award, the Contracting Officer may terminate the contract for default. In the event the contract is terminated for default, the offeror is liable for any cost of acquiring the work that exceeds the amount of its offer.

TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with CLAUSE: DEFAULT (FIXED-PRICE CONSTRUCTION) of the CONTRACT CLAUSES. In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. A weather delay day is any day when the maximum temperature does not exceed 32 degrees Fahrenheit or when 0.10 inch or more of precipitation occurs. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

Monthly Anticipated Adverse Weather Delay Work Days Based on (7) Day Work Week

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

9 4 4 4 3 3 1 1 1 3 4 8

Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor shall record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work.

Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled workday. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph 4.2, above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days and issue a modification in accordance with the CLAUSE: DEFAULT (FIXED PRICE CONSTRUCTION) of the CONTRACT CLAUSES.

EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE (MAR 1995) [UAI 31.105-101]

(a) This clause does not apply to terminations. See 52.249-5000, Basis for Settlement of Proposals and FAR Part

49.

(b) Allowable cost for construction and marine plant and equipment in sound workable condition owned or controlled and furnished by a contractor or subcontractor at any tier shall be based on actual cost data for each piece of equipment or groups of similar serial and series for which the Government can determine both ownership and operating costs from the contractor's accounting records. When both ownership and operating costs cannot be determined for any piece of equipment or groups of similar serial or series equipment from the contractor's accounting records, costs for that equipment shall be based upon the applicable provisions of EP 1110-1-8, Construction Equipment Ownership and Operating Expense Schedule, Region VIII. Working conditions shall be considered to be average for determining equipment rates using the schedule unless specified otherwise by the contracting officer. For equipment not included in the schedule, rates for comparable pieces of equipment may be used or a rate may be developed using the formula provided in the schedule. For forward pricing, the schedule in effect at the time of negotiations shall apply. For retroactive pricing, the schedule in effect at the time the work was performed shall apply.

(c) Equipment rental costs are allowable, subject to the provisions of FAR 31.105(d)(ii) and FAR 31.205-36, Rental Costs.