W912DR21B0007 Third High 09 Feb 2021.pdf

PROJECT TITLE: Third High Reservoir Maintenance and Improvements at the Washington Aqueduct in Washington, D.C.

The project w ill be acompetitive, f irm fixed price, contract procured in accordance w ith FAR 14, Sealed Bidding, via an Invitation for Bid (IFB).

The purpose of this project is to provide upgrades and improvements to the Third Hign Reservoir to address operational and sanitary survey issues.

The Construction project is being solicited as 100% Total Set-Aside for Small Busineses, under NAICS Code 237110 and a size standard of

$39.5M.

X

MARK R ANDREWS 410-962-4387

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

09-Feb-2021

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________298 calendar days after receiving aw ard, X notice to proceed. This performance period is mandatory, negotiable. (See _________________________52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________ (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______90 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

USACE, BALTMORE DISTRICT

2 HOPKINS PLAZA

BALTIMORE MD 21201

W912DR

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

(hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: 410-962-0175 TEL: FAX:

W912DR21B0007 72

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued)

(Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W912DR21B0007

Section 00 10 00 - Solicitation

BID SCHEDULE

ITEM NO

DESCRIPTION

QUANITY

UNIT

AMOUNT

All costs in connection with construction of improvements to the 3rd High Reservoir

Improvements complete as shown on the drawings and specified, but exclusive of work covered under Bid items 0002, 0003, and 0004 below.

1 Job $

All costs in connection with Building R-3-A and Building R-3-B including the demolition & reconstruction of the buildings complete, HVAC, lighting, security, communication, sampling station, plumbing, electrical wiring and breakers, floor access ports and hatch covers as shown in drawings S-02, S-03, S-04, A-01, A-02, A-03.

1 Job $

0003 All costs for the installation of a mixer system as specified in section 46 41 23 and shown in sheet M-02.

1 Job $

0004 All costs in connection with the installation of the perimeter fence.

1 Job $

Total $

NOTES TO BIDDERS

Offerors must bid on all items including Option Items. Failure to bid on all items may be cause for rejection of the proposal.

Optional items must be exercised at any time within 120 calendar days after the Notice to Proceed. The Contracting

Officer may exercise the Optional Item by written notice to the Contractor, postmarked within the period specified above. The Government may exercise any, all, or none of the listed optional items in any order.

No additional time for contract completion will be allowed when an Optional Item is exercised.

EVALUATION OF OPTIONS:

Except when it is determined not be in the Government’s best interests, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

VARIATION IN ESTIMATED QUANTITIES. If the quantity of a unit-price item in this contract is an estimated quantity and the actual quantity of the unit-price item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the

Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgment of the Contracting Officer, is justified. (FAR 52.211-18 APR 1984).

SCOPE OF WORK

Third High Reservoir Maintenance and Improvements Scope of Work

Build and implement the various improvements that have been designed for the Third High Reservoir that remedy the sanitary survey issues. That will bring the reservoir to full compliance from a sanitary survey perspective and provide improved water quality within the distribution system.

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

Section 00 21 13 - Instructions to Bidders

INSTRUCTIONS TO BIDDERS

VIRTUAL BID OPENING SOLICITATION INSTRUCTIONS

Due to COVID-19 health concerns, bids submitted in response to this solicitation will be submitted electronically.

The bid opening will be conducted via a telephone conference call that is open to the public.

Electronic Bid Submission

WHAT - Bids shall be submitted electronically, as described. The bid shall not contain classified data. The use of hyperlinks in bids is prohibited.

NOTE: The only authorized transmission method for bids in response to this solicitation is electronically via SAFE online submission. NO OTHER TRANSMISSION METHODS (E- MAIL, FACSIMILE, REGULAR MAIL, HAND CARRIED, ETC.) WILL BE ACCEPTED.

WHEN - Bids must be submitted not later than the time designated for bid submission. Bid opening and bid submission times are detailed below. Bids submitted after the bid submission time will be considered late bids.

Bids shall be submitted no earlier than five (5) calendar days before bid opening.

BID SUBMISSION TIME: 11:30 AM EST on 18 MAR 2021

Bids must be received by the Government by the date/time specified in the solicitation.

HOW - Bidders shall electronically send their bids using the following link:

https://safe.apps.mil/

WHO - The SAFE site will require contacts for bid submission to be provided. All requests for information and the bid submission must be sent to BOTH of the below contacts to ensure timely receipt of bids. Please use the following contact information to submit bids:

Contract Specialist: Rashurn Harrison at rashurn.l.harrison@usace.army.mil

Contracting Officer: Mary R. Andrews at mark.r.andrews@usace.army.mil

BIDDERS MUST REQUEST AN UPLOAD CODE: Bidders must e-mail the Contract Specialist and Contracting

Officer no later than five (5) working days prior to the bid opening date to receive a request code which will allow for file uploads via the SAFE site. Bidders that fail to request a code at least five (5) working days before bid opening date may not be able to receive a request code in time to upload their bids.

SUBMISSION FORMAT: Submission shall be in Adobe PDF format. You are limited to five (5) maximum files per upload (total size cannot exceed 2GB). If you have a large number of files, recommend that you combine or ZIP your files before uploading to the SAFE site. Bidders may use compression utility software such as WinZip or

PKZip to reduce file size and facilitate transmission.

BID GUARANTEE: This solicitation requires submission of a bid guarantee in accordance with FAR 52.228-1.

Electronic bid submissions must include a scanned copy of the original bid guarantee. In addition, the original bid guarantee with “wet” signature and raised seal (if applicable) must be mailed to the address below and received by the bid opening time and date:

U.S. Army Corps of Engineers

2 Hopkins Plaza https://safe.apps.mil/ mailto:rashurn.l.harrison@usace.army.mil mailto:mark.r.andrews@usace.army.mil c/o Contracting Division: Mark Ryan Andrews

Baltimore, MD 21201

Minor discrepancies in receipt of the original bid guarantee due to COVID-19 related impacts may be waived solely at the discretion of the Contracting Officer. A scanned copy of the original bid guarantee must be included in the electronic bid submission for the bid to be considered responsive.

FILE DESCRIPTION: Include a “File Description” for each file you upload. The “File Description” will be included in the e-mail notice to each of the recipients you choose to have access your file(s). NOTE: Do NOT enter

Privacy Act Data (Personal Identification Information (PII)) in the File Description.

INSTRUCTIONS TO FOLLOW ON THE SAFE WEBSITE:

1. Once at the SAFE website, select the “Drop-off” icon. This allows users without a Common Access

Card (CAC, an ID issued to certain Government users), or users whose computer is not configured to read a CAC the option to access the SAFE site as a guest.

2. After selecting the “Click Here” link, you will be prompted to add your personal information, file information, recipient (Government points of contact) information and e-mail settings.

3. When completing your file information, you will be required to enter the e- mail addresses for all recipients. For this solicitation, the recipients are the Contract Specialist and the Contracting Officer, listed above. Although the e- mail address of the Government employee who initiated the request code will be automatically entered, this address may not be correct. The Bidder must enter and add the e-mail addresses for both the Contracting Officer and Specialist listed above to the Recipient List. The

Bidder can enter an additional e-mail address if desired. After entering the e-mail address, click the

ADD button to add the e-mail to the “Recipients List” for your response. When your bid is submitted, a notification will be sent to the selected recipients.

NOTE: Do NOT send the SAFE site packages to group e-mail accounts.

Even if you successfully upload your bid to the SAFE site, notification will not be sent to the Government recipients until you verify your e-mail address. Entering an incorrect e-mail may result in the rejection of your submission for lateness. A Bidder can confirm proper submission by the ‘Drop-Off Completed” screen which generates based on proper file submission.

NOTE: It has been reported that documents are more quickly uploaded into the SAFE website when using a

Firefox web browser. The Government cannot verify that this is true and offers no guarantee that Bidders will have more success utilizing any particular browser.

TIMELINESS OF BIDS:

For the purposes of establishing whether a bid submission is considered timely, the Government considers the date and time the submission is completely uploaded into the SAFE website. For bids larger than the 2GB capacity of the

SAFE website and require multiple submissions, the Government will consider the date and time the last submission is completely uploaded into the SAFE website. Do not assume that electronic communication is instantaneous. It can take several minutes or even hours in some cases.

The Government will not be responsible for bids delivered to any location or to anyone other than those designated to receive bids. Bidders are responsible for ensuring that bids are submitted so as to reach the designated recipient.

Bidders are responsible for allowing sufficient time for the bid to be received in accordance with the instructions provided.

Bid Opening

Bids will be opened within 30 minutes after the time for bid submission noted above. This 30 minute delay is necessary to allow for downloading and to allow for technical delays. No Government officials will open electronic documents until the Independent Government Estimate is finalized and received by the Bid Opening Official.

BID OPENING TIME: 12:00 PM EST on 18 MAR 2021

The bid opening will be conducted via public conference call. Bidders and members of the public may use the below information to access the conference call:

Call In Number: (877)-336-4440

Access Code: 3070955

During the bid opening, the Bid Opening Official will read the bid totals in the order received electronically. The

Bid Opening Official will then read the line item prices and total for each submission. The Contract Specialist will record the bid opening results, which will be posted to www.beta.SAM.gov as quickly as practicable following the bid opening.

In accordance with FAR 14.402-1(c), interested persons may examine the bids after the bid opening. Interested persons may contact the Contract Specialist identified above following the bid opening to request an electronic copy of the bid(s). Please be considerate of limited Government resources and request bid copies only as necessary.

To preserve conference line stability, bidders are asked to limit the number of individual calls to the conference line to the minimum needed for participation. The bid opening will proceed as scheduled even if individual bidders or members of the public are not able to access the telephone line at the bid opening time. Any interested party may access the results of the bid opening on www.beta.SAM.gov shortly after the bid opening.

Additional Information:

a. SF 1442 BACK (Page 2 of the Solicitation): Offerors are required to acknowledge the receipt of all amendments to the Solicitation on the Standard Form 1442 in Block 19. Offerors shall fully complete all the required areas located under the section designated as “OFFER” (refer to Items 14 through 20C).

b. BID GUARANTEE: The bidders are required to submit a Bid Guarantee for this procurement. Any bidder failing to submit an authentic Bid Guarantee will be considered non-responsive to the Solicitation and ineligible for award.

The Bid Guarantee shall be in the amount of 20% of the bidder’s price or $3,000,000.00, whichever is less.

c. BONDS AND INSURANCE: The Contractor will be required to furnish proof of insurance, including copies of the required endorsements, and performance and payment bonds within 10 calendar days following the Contractor’s receipt of the contract award.

Requests for information:

Technical inquiries and questions relating to this solicitation are to be submitted via Bidder Inquiry in ProjNet at

(https://www.projnet.org) No Later Than (NLT) 25 February 2021 at 11:00AM EST. To submit and review inquiry items, prospective vendors will need to use the Bidder Inquiry Key presented below and follow the instructions listed below the key for access. A prospective vendor who submits a comment /question will receive an acknowledgement of their comment/question via email. Another email to the same address will notify the prospective vendor once the reply is available for viewing.

Current Quick Add Key is: 66KEJK-P82QPH

Specific Instructions for ProjNet Bid Inquiry Access:

http://www.beta.sam.gov/ http://www.beta.sam.gov/

1. From the ProjNet home page linked above, click on Quick Add on the upper right side of the screen.

2. Identify the Agency. This should be marked as USACE.

3. Key. Enter the Bidder Inquiry Key listed above.

4. Email. Enter the email address you would like to use for communication.

5. Click Continue. A page will then open saying that a user account was not found and will ask you to create one using the provided form.

6. Enter your First Name, Last Name, Company, City, State, Phone, Email, Secret Question, Secret Answer, and

Time Zone. Make sure to remember your Secret Question and Answer as they will be used from this point on to access the ProjNet system.

7. Click Add User. Once this is completed you are now registered within ProjNet and are currently logged into the system.

Specific Instructions for Future ProjNet Bid Inquiry Access:

1. For future access to ProjNet, you will not be provided any type of password. You will utilize your Secret Question and Secret Answer to log in.

2. From the ProjNet home page linked above, click on Quick Add on the upper right side of the screen.

3. Identify the Agency. This should be marked as USACE.

4. Key. Enter the Bidder Inquiry Key listed above.

5. Email. Enter the email address you used to register previously in ProjNet.

6. Click Continue. A page will then open asking you to enter the answer to your Secret Question.

7. Enter your Secret Answer and click Login. Once this is completed you are now logged into the system.

Responses to RFIs via ProjNet are for informational purposes only. Official responses will be provided by amendment.

****** NOTE: QUESTIONS ANSWERED IN PROJNET ARE NOT OFFICIAL UNTIL AN AMENDMENT IS

ISSUED. ***

CLAUSES INCORPORATED BY REFERENCE

52.214-3 Amendments To Invitations For Bids DEC 2016

52.225-10 Notice of Buy American Requirement--Construction

Materials

MAY 2014

52.236-28 Preparation of Proposals--Construction OCT 1997

CLAUSES INCORPORATED BY FULL TEXT

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm-Fixed Price contract resulting from this solicitation.

(End of provision)

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance

Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

28.0% 6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract

Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from

Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract

Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is DC District of

Columbia; MD Charles; MD Montgomery, MD Prince Georges; VA Arlington; VA Fairfax; VA Loudoun; VA

Prince William; VA Alexandria; VA Fairfax City; VA Falls Church.

52.225-12 NOTICE OF BUY AMERICAN REQUIREMENT-- CONSTRUCTION MATERIALS UNDER

TRADE AGREEMENTS (MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “designated country construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American -- Construction Materials Under

Trade Agreements” (Federal Acquisition Regulation (FAR) clause 52.225-11).

(b) Requests for determination of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of FAR clause 52.225-11 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the

Buy American statute, based on claimed unreasonable cost of domestic construction materials, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph

(b)(4)(i) of FAR clause 52.225-11.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers. (1) When an offer includes foreign construction material, other than designated country construction material, that is not listed by the Government in this solicitation in paragraph (b)(3) of FAR clause

52.225-11, the offeror also may submit an alternate offer based on use of equivalent domestic or designated country construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of FAR clause 52.225-11 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of FAR clause 52.225-11 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic or designated country construction material, and the offeror shall be required to furnish such domestic or designated country construction material. An offer based on use of the foreign construction material for which an exception was requested-- (i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be Twenty (20) percent of the bid price or $3,000,000.00, whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from

(Email): Mark.R.Andrews@usace.army.mil

(For mailed protests):

U.S. ARMY CORPS OF ENGINEERS, BALTIMORE DISTRICT

2 HOPKINS PLAZA

ATTN: CONTRACTING ROOM 03-G-01

BALTIMORE, MD 21201

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) A pre-bid site visit will be held at 0900 hrs. on 18 February 2021 at the Third High Reservoir located at 5900

MacArthur Blvd., NW., Washington, DC 20016. Individuals interested in attending the site visit MUST submit their

Name, Company Name, Date of Birth, Driver's License Number and issuing State to Nikolai Gurdian by email

(Nikolai.E.Gurdian@usace.army.mil) no later than 2:00 p.m. on the business day before the site visit in order to be mailto:Mark.R.Andrews@usace.army.mil mailto:Nikolai.E.Gurdian@usace.army.mil admitted to the site. Upon arriving for the site visit, individuals will be required to show their Driver's License.

Individuals who do not have a driver's license will need to submit the information from a government issued ID

(State or Federal) and be prepared to show that ID upon arrival.

In response to COVID-19 Pandemic and the requirements for social distancing, the Washington Aqueduct facilities are closed to everyone except employees, unless authorized in advance. For those authorized entry onto Washington

Aqueduct property for this site visit, the following health and safety precautions will be adopted:

• No more than two employees from an individual company will be permitted to attend this site visit.

• All participants shall maintain a 6 foot minimum distance from Government personnel at all times.

• All persons entering Government property are to provide and wear cloth face coverings meeting the CDC guidelines at all times.

• All persons entering Government property must consent to temperature screening. A temperature reading of <100.4 degrees Fahrenheit is the criterion for participation in this site visit

• Hand sanitizer and/or wipes will be made available for participants.

The Point of Contact for the site visit:

Name: Rashurn Harrison

E-mail Address: rashurn.l.harrison@usace.army.mil

Telephone: 410-962-3526

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://acquisition.gov/far/index.html

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (NOV 2020)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the provision.

INFORMATIONAL TEXT

CONSTRUCTION DURATION

The anticipated construction duration for this procurement is 298 calendar days.

mailto:rashurn.l.harrison@usace.army.mil

MAGNITUDE OF CONSTRUCTION PROJECT

The estimated magnitude of construction is between $1,000,000.00 and $5,000,000.00.

PREAWARD SAFETY CONFERENCE

Where an apparent low bidder, in performance of contracts during the previous three year period incurred one or more accidents, or where, in the opinion of the Contracting Officer, there is any question regarding his compliance with any safety or accident prevention requirement, such bidder, on request of the

Contracting Officer prior to any award under this solicitation, shall attend a conference with representatives of the Contracting Officer to discuss any such accidents or non-compliance, the reasons for their occurrence, and measures which will be taken to preclude any recurrence thereof. Information elicited at this conference will be used by the Contracting Officer, in conjunction with other information obtained in the pre award survey, in determining the bidder's responsibility. The items discussed, the preventive measures considered, and any conclusions reached in this conference shall be recorded in minutes of the meeting, which shall be authenticated by the signatures of representatives of the bidder and the Contracting Officer, and any procedures noted therein as agreed upon shall become an obligation of the bidder, along with all other safety and accident prevention requirements of the contract, if award is made to him.

Section 00 45 00 - Representations and Certifications

52.203-2 Certificate Of Independent Price Determination APR 1985

52.204-24 Representation Regarding Certain Telecommunications and

Video Surveillance Services or Equipment.

AUG 2020

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

AUG 2020

52.209-7 Information Regarding Responsibility Matters OCT 2018

52.222-22 Previous Contracts And Compliance Reports FEB 1999

252.215-7008 Only One Offer JUL 2019

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAR 2020)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 237110.

(2) The small business size standard is $39,500.000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or

Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at

52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services--Representation. This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xvi) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased

Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and

III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $83,099, the provision with its Alternate II applies.

(D) If the acquisition value is $83,099 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at

52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for

Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain

Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA-

Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR

4.1201); except for the changes identified below [ offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

52.209-11 REPRESENTATION BY CORPORATIONS REGARDING DELINQUENT TAX LIABILITY OR A

FELONY CONVICTION UNDER ANY FEDERAL LAW (FEB 2016)

(a) As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations

Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that--https://www.sam.gov/

(1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or

(2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.

(b) The Offeror represents that--

(1) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and

(2) It is [ ] is not [ ] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.

52.219-1 SMALL BUSINESS PROGRAM REPRESENTATIONS (NOV 2020)

(a) Definitions. As used in this provision--

Economically disadvantaged women-owned small business (EDWOSB) concern means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business concern eligible under the WOSB Program.

Service-disabled veteran-owned small business concern--

(1) Means a small business concern--

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

Small business concern--

(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13

CFR part 121 and the size standard in paragraph (b) of this provision.

(2) Affiliates, as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the others, or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13

CFR 121.103.

Small disadvantaged business concern, consistent with 13 CFR 124.1002, means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States, and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13 CFR 124.106) by individuals who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

Veteran-owned small business concern means a small business concern--

(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

Women-owned small business concern means a small business concern--

(1) That is at least 51 percent owned by one or more women; or, in the case of any publicly owned business, at least

51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127), means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the

United States.

(b)(1) The North American Industry Classification System (NAICS) code for this acquisition 237110.

(2) The small business size standard is $39.5M.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture (i.e., nonmanufacturer), is 500 employees.

(c) Representations. (1) The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a small business concern. (2) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [ ___ ] is, [ ___ ] is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.

(3) [Complete only if the offeror represented itself as a small business concern in…