16b2-Am-0004.pdf

1. CONTRACT ID CODE PAGE OF PAGES

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1 5

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicable)

AM-0004 09 May 16

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

CECT – Contracting Division USACE, Honolulu District Bldg 252 (CECT-POH) Ft Shafter, HI 96858-5440

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State, and Zip Code) (x) 9A. AMENDMENT OF SOLICITATION NO.

W9128A-16-B-0002 X

9B. DATED (SEE ITEM 11)

02/26/2016

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

[ X ]The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers [ X ] is extended, [ ] is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing Items 8 and 15, and returning __1__ copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

(x) A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor [ ] is not, [ ] is required to sign this document and return _ copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

FY14 MCA PN 059779 Echo Pier Restoration, U.S. Army Kwajalein Atoll (USAKA), Republic of the Marshall Islands

See Page 2 of 2 Pages

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR 15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 16C. DATE SIGNED

BY

(Signature of person authorized to sign) (Signature of Contracting Officer)

NSN 7540-01-152-8070

PREVIOUS EDITION UNUSABLE

30-105 STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

Am-0003 Standard Form 30

RFP No. W9128A-16-B-0002 Page 2 of 5 Pages

Item No. 14 (Continued)

1. CHANGES TO SPECIFICATIONS. Attached hereto are revised, replaced, deleted and additions to sections to the specifications. Revised pages replace like-numbered pages. The revision mark

(Am-0003) is shown on each revised page.

A. REVISED SECTIONS. The following changes were made to the solicitation and are indicated in bold:

Section 00 10 00, Bid Schedule, Item No. 0010 (Option 9)

Section 00 72 00, Clause 52.211-10, Commencement, Prosecution, and Completion of Work

Section 01 57 20 – paragraph: 3.5

Section 01 90 00 – pagraph 1.17

Section 03 20 00.00 10 – paragraphs: 2.3.1, 2.6.2, Section 05 12 00 – paragraphs: 2.2.1.1, 2.2.1.2, 2.2.1.3, 2.2.2.1, 2.2.2.2, 2.2.2.3, 2.2.3.1, 2.2.3.2, 2.2.3.3, 2.2.4.1, 2.2.4.2, 2.2.4.3, 2.2.4.4, 2.4, 2.6.2, 2.6.2.2

Section 05 50 13 – paragraphs: 2.1.5, 2.1.5.1, 2.1.5.2, 2.1.5.3, 2.1.7, 2.1.7.1, 2.1.7.2, 2.1.7.3, 2.1.7.4, 2.1.9, 2.6.2

Section 08 33 23 – paragraph: 2.3.1

Section 08 60 45 – paragraphs: 1.1, 2.5

Section 09 97 13.27 – paragraphs: 2.2, 2.5.1, 3.2

Section 26 27 29 – paragraph: 2.9.4

Section 26 56 00 – paragraph: 2.4

Section 31 00 00 – paragraphs: 1.1, 1.5, 3.1.2, 3.3, 3.7, 3.14.8

Section 31 41 16 – paragraph: 3.4.4.2

Section 32 01 19 – paragraphs: 1.2, 1.3.1, 1.3.2, 1.3.3, 3.1.2.2, 3.2, 3.2.1.1

Section 32 13 13.06 – paragraphs: 1.1, 1.2, 2.1.5.1

Section 32 31 13 – paragraphs: 2.7, 2.8, 2.16, 2.19, 2.20, 2.21, 3.1, 3.12, 3.13, 3.16

Section 33 11 00 – paragraphs: 1.1, 2.1.1.1, 2.3.4, 3.1.2.1

Section 33 70 02.00 10 – paragraph: 2.6

B. REPLACED SECTIONS. The following changes were made to the soliciatation and are to be replaced in its entirety.

Section 01 90 00 - Addendum 1

C. DELETED SECTIONS. The following sections are to be deleted from the specifications.

Section 03 40 00.00 10, Plant-Precast Concrete Products for Below Grade Construction

D. ADDITIONS TO SECTIONS. The following are added to the solicitation:

Section 26 42 13.00 20, Cathodic Protection by Galvanic Anodes

Section 00 73 00, Appendix D, Response to Request for Informations #51, 103, 166, and 195 to

#270

2. CHANGES TO DRAWINGS.

A. REVISED DRAWINGS. The following revised drawings replaced like-numbered drawings and are issued herewith:

RFP No. W9128A-16-B-0002 Page 3 of 5 Pages

SHEET ID SHEET NO. MARK REVISION DATE

G-005 5 of 309 2 4/18/2016

G-006 6 of 309 2 4/18/2016

C-001 31 of 309 2 4/18/2016

CD102 34 of 309 2 4/18/2016

CD105 37 of 309 2 4/18/2016

CD106 38 of 309 2 4/18/2016

CG101 49 of 309 2 4/18/2016

CG103 51 of 309 2 4/18/2016

CP107 65 of 309 2 4/18/2016

CS101 66 of 309 2 4/18/2016

CS103 68 of 309 2 4/18/2016

CS104 69 of 309 2 4/18/2016

CS501 81 of 309 2 4/18/2016

CS502 82 of 309 2 4/18/2016

CS507 87 of 309 2 4/18/2016

CU101 90 of 309 2 4/18/2016

CU305 101 of 309 2 4/18/2016

CU502 111 of 309 2 4/18/2016

CU504 113 of 309 2 4/18/2016

CU507 116 of 309 2 4/18/2016

CU509 118 of 309 2 4/18/2016

S-011 121 of 309 2 4/26/2016

S-503 141 of 309 2 4/25/2016

S-507 145 of 309 2 4/21/2016

S-514 152 of 309 2 4/26/2016

SC502 172 of 309 2 4/20/2016

A-101 179 of 309 2 4/21/2016

A-111 181 of 309 2 4/21/2016

A-113 183 of 309 2 4/21/2016

A-301 189 of 309 2 4/21/2016

A-302 190 of 309 2 4/21/2016

A-501 193 of 309 2 4/21/2016

FX501 209 of 309 2 4/22/2016

M-001 219 of 309 2 4/22/2016

M-111 220 of 309 2 4/22/2016

M-112 221 of 309 2 4/22/2016

M-311 222 of 309 2 4/22/2016

M-312 223 of 309 2 4/22/2016

M-501 224 of 309 2 4/22/2016

RFP No. W9128A-16-B-0002 Page 4 of 5 Pages

E-001 227 of 309 2 4/18/2016

E-004 230 of 309 2 4/18/2016

E-005 231 of 309 2 4/18/2016

E-401 244 of 309 2 4/18/2016

E-403 246 of 309 2 4/18/2016

E-404 247 of 309 2 4/18/2016

E-405 248 of 309 2 4/18/2016

E-407 250 of 309 2 4/18/2016

E-501 251 of 309 2 4/18/2016

E-502 252 of 309 2 4/18/2016

E-503 253 of 309 2 4/18/2016

E-504 254 of 309 2 4/18/2016

E-505 255 of 309 2 4/18/2016

E-506 256 of 309 2 4/18/2016

E-507 257 of 309 2 4/18/2016

E-508 258 of 309 2 4/18/2016

ED101 268 of 309 2 4/18/2016

ED102 269 of 309 2 4/18/2016

ED103 270 of 309 2 4/18/2016

ED104 271 of 309 2 4/18/2016

ED105 272 of 309 2 4/18/2016

ED106 273 of 309 2 4/18/2016

ED107 274 of 309 2 4/18/2016

ES101 276 of 309 2 4/18/2016

ES102 277 of 309 2 4/18/2016

ES103 278 of 309 2 4/18/2016

ES104 279 of 309 2 4/18/2016

ES105 280 of 309 2 4/18/2016

ES106 281 of 309 2 4/18/2016

ES107 282 of 309 2 4/18/2016

ES108 283 of 309 2 4/05/2016

ES109 284 of 309 2 4/18/2016

ES112 287 of 309 2 4/18/2016

ES113 288 of 309 2 4/18/2016

EL101 303 of 309 2 4/22/2016

EL102 304 of 309 2 4/22/2016

EL601 306 of 309 2 4/22/2016

EP101 307 of 309 2 4/22/2016

RFP No. W9128A-16-B-0002 Page 5 of 5 Pages

B. DELETED DRAWINGS. The following drawings previously issued are deleted in their entirety:

CS112 77 of 309 2 4/18/2016

CS113 78 of 309 2 4/18/2016

CS114 79 of 309 2 4/18/2016

3. The bid opening has changed. See SF 1442, Page 1, Block 13A.

(Am-0004)

FY14 MCA PN 059779 Echo Pier Restoration, U.S. Army Kwajalein Atoll (USAKA), Republic of the Marshall Islands

X

DAYNA MATSUMURA 808-835-4379

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

26-Feb-2016

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION

INFORMATION

A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance within _______ 7 calendar days and complete it within ________ ** calendar days after receiving award, X notice to proceed. This performance period is X mandatory, negotiable. (See _______________.) 52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________ 1 copies to perform the work required are due at the place specified in Item 8 by ___________ local time ______________ 26 May 2016 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

due. B. An offer guarantee X is, is not not required.

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______ 90 calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

CECT - CONTRACTING DIVISION

USACE, HONOLULU DISTRICT

DISTRICT

BLDG 252 (CECT-POH)

POH)

FT. SHAFTER HI 96858-5440

W9128A

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM

PM

(hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX: TEL: TEL: FAX:

W9128A-16-B-0002 72

** See Section 00 72 00, Clause 52.211-10

20B. SIGNATURE

(REV. 4-85) STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c)

2304(c)

41 U.S.C. 253(c)

CODE 27. PAYMENT WILL BE MADE BY: 26. ADMINISTERED BY

(Include ZIP Code) 14. NAME AND ADDRESS OF OFFEROR

DUNS No. ____________________

Cage Code: ___________________ TIN: ___________________

15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14) 16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your offer on this solicitation, is hereby accepted as to the items listed. This award con-to furnish and deliver all items or perform all work, requisitions identified summates the contract, which consists of (a) the Government solicitation and on this form and any continuation sheets for the consideration stated in this your offer, and (b) this contract award. No further contractual document is contract. The rights and obligations of the parties to this contract shall be necessary.

governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications or incorporated by refer-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this 28. NEGOTIATED AGREEMENT

(Must be fully completed by offeror) OFFER

Section 00 10 00 - 1

Am-0004

Solicitation No. W9128A-16-B-0002

SECTION 00 10 00

FY2014 MCA PN 059779, ECHO PIER RESTORATION

U.S. ARMY KWAJALEIN ATOLL (USAKA),

REPUBLIC OF THE MARSHALL ISLANDS

ITEM

NO. DESCRIPTION QUANTITY UNIT AMOUNT

0001 Echo Pier 1 JOB $______________

BL A Station 10+50.76 (end of pier) to BL A station 6+48.52

LSC SUPPORT SERVICES (See Special Contract Clause K-32) $______________

TOTAL BASE BID $______________

(Sum of Item No. 0001 & LSC Support Services)

OPTIONS:

Item

No.

Option

BL A

Begin

BL A

End

(a)

Bid Amt

(b)

LSC Amt

(a)+(b)=(c)

Option Price

0002 1 6+48.52 5+44.66 $ $ $

0003 2 5+44.66 4+64.66 $ $ $

0004 3 4+64.66 3+84.67 $ $ $

0005 4 3+84.67 3+12.33 $ $ $

0006 5 3+12.33 2+63.84 $ $ $

0007 6 2+63.84 1+70.00 $ $ $

0008 7 1+70.00 0+95.00 $ $ $

0009 8 0+95.00 0+00.00 $ $ $

0010 9 Pallet Storage Racks $ $ $

BASE BID (Item 0001) $ $ $

TOTAL OPTIONS 1 thru 9

(Item Nos. 0002 through 0010)

TOTAL BASE BID PLUS OPTIONS

THE FOLLOWING WILL BE COMPLETED BY THE CONTRACTING OFFICER UPON AWARD:

TOTAL AWARD AMOUNT (Total Base Bid plus Option Nos. _____________) $_________________

Section 00 10 00 - 2

NOTES TO BID SCHEDULE:

1. Available funding is limited to $56,087,246.

2. Failure to provide a bid on each of the items in the Bid Schedule (Base Bid and all Options) may cause the bid to be considered unresponsive.

3. Evaluation of bids for award will be based on the TOTAL BASE BID PLUS OPTIONS (column c), see

FAR 52.217-5, Evaluation of Options. By submission of a bid under OPTIONS, Bidder agrees that the Government may exercise any of Option Nos. 1 through 8 at time of award, or at any time within 270 calendar days following the date of the award of the basic contract.

4. Options 1 thru 8 (Items number 0002 thru 0009), if and when executed, will be executed in ascending numerical order, i.e. Option 1 will be the first option executed, followed by Option 2, then Option 3, etc. Option 9

(Item number 0010) may be executed independent of the other Options.

Section 00 10 00 - 3

PAYMENT(S)

Compensation for all work to be performed under this contract will be made under the payment items(s) listed herein. The principal features of the work to be included under the payment item(s) are noted. Work required by the drawings and specifications and not particularly mentioned shall be included in and be paid for under the contract price for the item to which the work pertains. Price(s) and payment(s) for the item(s) shall cover all work, complete and finished in accordance with the specifications, schedules, and drawings, and shall be full compensation for all work in connection therewith, including quality control and cost of performance-and payment-bond premiums as specified in the CONTRACT CLAUSES. Price(s) and payment(s) shall constitute full and final compensation for furnishing all materials, equipment, management, supervision, labor, transportation, fuel, power, water, and all incidental items necessary to complete the work, except as otherwise specified to be furnished by the Government.

For the purpose of CONTRACT CLAUSE entitled “PROMPT PAYMENT FOR CONSTRUCTION

CONTRACTS”, the term “designated billing office” and “designated payment office” are as follows:

a. Billing Office

U.S. Army Corps of Engineers, Honolulu District

ATTN: Kwajalein Resident Office, Bldg 1075

PSC 701

APO, AP 96555

b. Payment Office

USACE Finance Center

Attn: CEFC-FP

5722 Integrity Drive

Millington, TN 38054-5005

Item numbers mentioned herein after correspond to the item numbers in the BID SCHEDULE.

Item No. 0001 Echo Pier, will be paid for at the contract price, complete in place and ready for use, including mobilization and demobilization, demolition and reconstruction of the pier structure from BL A station 10+50.76 thru BL A station 6+48.52, Pier Warehouse, On-Shore Warehouse, all temporary and permanent utilities supporting the warehouses and the pier, environmental protection, settlement monitoring, testing, cleanup, and all incidentals necessary to complete the work.

Item Nos. 0002 thru 0009, Options 1 thru 8, will be paid for at the contract price, complete in place and ready for use, including demolition and pier reconstruction between the BL A stations indicated for each option, permanent below grade utilities, testing, cleanup, and all incidentals necessary to complete the work.

Item No. 0010 Pallet Storage Racks, Option 9, will be paid for at the contract price, complete in place and ready for use, including procurement, shipping and installation into both warehouses, cleanup, and all incidentals necessary to complete the work.

Section 00 10 00 - 4

FOR INFORMATION ONLY:

1. In the table below, provide a breakout of the price of each Part (a through d) of the Total Base Bid Price, Item

No. 0001, and the LSC SUPPORT SERVICES. Information provided in this table will not be used to evaluate bids for the purpose of award.

a. The estimated cost for Part A below should include all costs associated with all work on the pier, BL A

Station 6+48.52 to BL A Station 10+50.76, including mobilization, demobilization, demolition, and temporary and permanent utilities.

b. The estimated cost for Items B below should include the total in-place cost of the scope associated with

Modernizing Pier Building,, incorporating costs of all materials, installed equipment, labor – direct and indirect, associated with construction of the facility inside the facility 5’-0” line.

c. The estimated cost for Part C below should include the total in-place of the scope associated with New

On-Shore Building, incorporating costs of all materials, installed equipment, labor (direct and indirect), associated with the construction of the facility inside the 5’0” line.

d. The estimated cost for Part d below should include all costs associated with all work outside the facilities’ 5’-0” line up to the beginning of the pier (BL A Station 0+00), including site improvements, demolition and utilities.

Part of Item No. 0001 – Base Bid Price

A. Modernize Pier

B. Modernize Pier Building

C. New On-Shore Building

D. Supporting Facilities

TOTAL BASE BID PRICE

(Item No. 0001)

2. If contaminated soil is encountered during construction, the Contractor may be required to provide or perform some of the following items. To minimize delays associated with encountering contaminated soil during construction, Bidder shall provide a unit price for each of the following items. The unit price for each item should reflect the total cost (including direct costs, indirect costs, markups, etc.) for that specific item. If contaminated soil is encountered during construction, the Contractor shall promptly notify the Contracting Officer that such a condition has been encountered, describe the condition encountered, and provide a listing of which of the following items may be necessary. Upon notification of encountering contaminated soil, the Contracting Officer will promptly investigate the matter, and if necessary, may issue a Change Order directing the Contractor to proceed with any or all of the required items. Bidders are advised that the following unit prices will not be part of the contract, but are merely a starting point for initiating the change order process.

A. DESCRIPTION Unit Unit Price

1) Prepare Sampling and Analysis Plan Ea $_________

2) Prepare Site Safety and Health Plan Ea $_________

3) Perform Tests:

Section 00 10 00 - 5

a) Polynuclear Aromatic Hydrocarbons (PAHs) Ea $_________

b) Aromatic and Halogenated Volatile Organic

Compounds (including Methyl Ethyl Ketone) Ea $_________

c) Lead/Cadmium Ea $_________

d) Polychlorinated Biphenyls (PCBs) Ea $_________

e) TPH- Diesel/Oil Range Organics (Excavated area) Ea $_________

f) TPH-Gasoline Range Organics Ea $_________

g) TCLP (for hazardous waste characterization stockpile) Ea $_________

h) TPH- Diesel/Oil Range Organics (Stockpiles) Ea $_________

4) Handling of Contaminated Soil

a. Remove and Dispose Contaminated Soil CY $_________

b. Replace with New Soil CY $_________

B. PAYMENT

The Item numbers described below correspond to the item numbers above in Note 2A.

a. Item No. 1) Prepare Sampling Analysis Plan, will be paid for at the contract unit price, including all incidental items necessary to complete the work.

b. Item No. 2) Prepare Site Safety and Health Plan, will be paid for at the contract unit price, including all incidental items necessary to complete the work.

c. Item No. 3)a, 3)b, 3)c, 3)d, 3)e, 3)f, 3)g, and 3)h. Perform Tests, will be paid for at the contract unit price, including sampling, analyses, reports and all incidental items necessary to complete the work.

d. Item No.4a), Remove and Dispose Contaminated Soil:

(1) Measurement for payment will be to the nearest cubic yard of contaminated soil acceptably removed and disposed.

(2) Payment for contaminated soil acceptably removed and disposed will be made at the applicable contract unit price per cubic yard, including, cleanup, and all incidental items necessary to complete the work.

e. Item No.4b), Replace with New Soil:

(1) Measurement for payment will be to the nearest cubic yard of new soil placed.

(2) Payment for new soil placed will be made at the applicable contract unit price per cubic yard, including, cleanup, and all incidental items necessary to complete the work.

Section 00 21 13 - 1

Section 00 21 13 - Instructions to Bidders

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management JUL 2013 52.214-3 Amendments To Invitations For Bids DEC 1989 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids MAR 1997 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.214-27 Price Reduction for Defective Certified Cost or Pricing Data - Modifications -

Sealed Bidding

AUG 2011

52.214-28 Subcontracting Certified Cost Or Pricing Data--Modifications--Sealed Bidding OCT 2010 52.214-34 Submission Of Offers In The English Language APR 1991 52.214-35 Submission Of Offers In U.S. Currency APR 1991 52.217-5 Evaluation of Options JUL 1990 52.225-12 Notice of Buy American Requirement - Construction Materials Under

Trade Agreements

MAY 2014

52.232-13 Notice Of Progress Payments APR 1984 252.203-7005 Representation Relating to Compensation of Former DoD Officials NOV 2011 252.204-7004 Alt A System for Award Management Alternate A FEB 2014 252.222-7007 Representation Regarding Combating Trafficking in Persons JAN 2015

CLAUSES INCORPORATED BY FULL TEXT

52.211-14 NOTICE OF PRIORITY RATING FOR NATIONAL DEFENSE, EMERGENCY PREPAREDNESS, AND ENERGY PROGRAM USE (APR 2008)

Any contract awarded as a result of this solicitation will be a DO rated order certified for national defense, emergency preparedness, and energy program use under the Defense Priorities and Allocations System (DPAS) (15 CFR 700), and the Contractor will be required to follow all of the requirements of this regulation.

(End of provision)

52.214-5000 APPARENT CLERICAL MISTAKES (MAR 1995)—EFARS

(a) For the purpose of initial evaluations of bids, the following will be utilized in the resolving arithmetic discrepancies found on the face of bidding schedule as submitted by the bidder:

(1) Obviously misplaced decimal points will be corrected;

(2) Discrepancy between unit price and extended price, the unit price will govern;

(3) Apparent errors in extension of unit prices will be corrected;

(4) Apparent errors in addition of lump-sum and extended prices will be corrected.

Section 00 21 13 - 2

(b) For the purpose of bid evaluation, the government will proceed on the assumption that the bidder intends his bid to be evaluated on basis of the unit prices, the totals arrived at by resolution of arithmetic discrepancies as provided above and the bid will be so reflected on the abstract of bids.

(c) These correction procedures shall not be used to resolve any ambiguity concerning which bid is low.

(End of statement)

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a firm fixed-price construction contract resulting from this solicitation.

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

69.1% 6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

Section 00 21 13 - 3

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is U.S. Army Kwajalein Atoll, Republic of the Marshall Islands

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be twenty (20) percent of the bid price or $3,000,000, whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 14 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from

U.S. Army Corps of Engineers, Honolulu District Contracting Division, Attn: Contracting Officer (W9128A-16-B-0002) Otake Street, Building 230 Fort Shafter, Hawaii 96858-5440

Section 00 21 13 - 4

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the

GAO.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil/ http://farsite.hill.af.mil/vfdfara.htm http://www.usace.army.mil/Portals/2/docs/Contracting/UAI_Version%203__1%20NOV%202014.pdf

K-4 PRE-BID SITE INVESTIGATION AND CONFERENCE (SEP 2015)

(a) A pre-bid site investigation and conference will be conducted by the Government on March 17, 2016 at 2:00 p.m. and March 18, 2016 at 9:00 a.m. at U.S. Army Kwajalein, Republic of the Marshall Islands. All planholders (prime contractors, subcontractors, and suppliers) are urged to attend. Due to limited logistical support, only one representative from the prime contractor will be allowed to travel for purposes of attending the pre-bid site investigation and conference. Representatives who plan to attend will need to contact Ms. Dayna Matsumura and Ms. Jennifer Ko at dayna.n.matsumura@usace.army.mil and jennifer.i.ko@us.army.mil, and provide a completed 55r and Food and Lodging worksheet by February 26, 2016.

(b) Upon arrival at the Kwajalein Airport, representatives (planholders) will be met by a Government representative.

Planholders are cautioned to schedule flights by contacting their commercial travel agent or United Airlines for arrival at Kwajalein not later than March 16, 2016. (Kwajalein time is 22 hours ahead of Hawaiian Standard Time.)

Departure from Kwajalein is recommended on March 18, 2016.

(c) A pre-bid conference will be conducted on March 17, 2016 at the Command Conference Room at Bldg 730, and a pre-bid site investigation will be conducted on March 18, 2016 at the Echo Pier, Dock Security Checkpoint, Building 623.

(d) Any Requests for Information (RFIs) from planholders (including those not attending the conference) concerning the project, plans, or specifications shall be submitted via e-mail on letterhead stationery, 7 days in advance of the conference.

(e) Written RFIs submitted by planholders and answers provided by the Government, will be provided by amendment. Any answers, clarifications, or explanations given at the conference is not binding and will not qualify or change the terms of the RFP (including the plans and specifications), unless the RFP is amended in writing.

http://farsite.hill.af.mil/ http://farsite.hill.af.mil/vfdfara.htm http://www.usace.army.mil/Portals/2/docs/Contracting/UAI_Version%203__1%20NOV%202014.pdf mailto:dayna.n.matsumura@usace.army.mil mailto:jennifer.i.ko@us.army.mil

Section 00 21 13 - 5

(f) Attendance at the pre-proposal site investigation and conference, including transportation and lodging, will be at the expense of the planholder.

[End of Statement]

S-19A U.S. ARMY CORPS OF ENGINEERS SAFETY AND HEALTH REQUIREMENTS MANUAL, EM 385- 1-1 (Nov 2015)

This paragraph applies to contracts and purchase orders that require the contractor to comply with EM 385-1-1 (e.g., contracts that include the Accident Prevention clause at FAR 52.236-13 and/or other safety provisions.) EM 385-1-1 and its changes are available at the following web site:

http://www.publications.usace.army.mil/Portals/76/Publications/EngineerManuals/EM_385-1-1.pdf

The Contractor shall be responsible for complying with the current edition and all changes posted on the web as of the effective date of this solicitation.

Per EM 385-1-1 (latest version) Contractors shall ensure timely accident reporting is strictly adhered to. PODR 265 will be completed within 24 hours of all accidents (excluding first aid injuries). ENG 3394 forms will be completed within 5 days of lost time accident and forwarded to the Contracting Officer or Contracting Officer Representative.

All accidents will be reported through the Honolulu Engineer District Safety Office, (808) 835-4009 within 24 hours of the incident.

S-2 ASBESTOS ABATEMENT (AUG 1996)

Asbestos abatement is part of the scope of work for the proposed contract. Refer to paragraphs entitled, "ASBESTOS --- (OCCUPATIONAL HEALTH AND ENVIRONMENTAL)" in Section 00 73 00 and applicable sections of the technical specifications and drawings. The Contractor shall inform responsible representatives of their insurer(s)/surety(ies) that asbestos abatement is required for the proposed contract.

S-28.1 EXECUTION OF BID BOND (AUG 1994)

If the bidder's name and address on the bid form (Standard Form 1442) and those on the bid bond form (Standard Form 24) are different from each other, the bid may be rejected as nonresponsive. Accordingly, for its own protection, each bidder shall see to it that the name and address on both forms are identical.

http://www.publications.usace.army.mil/Portals/76/Publications/EngineerManuals/EM_385-1-1.pdf

Section 00 21 13 - 6

S-28.2 PENAL SUM AND FORM OF BID BOND

(Applicable to bids exceeding $100,000)

Each bidder shall submit with its bid a separate Bid Bond (Standard Form 24) with good and sufficient surety or sureties acceptable to the Government, or other security as provided in contract clause entitled "BID GUARANTEE", in the CONTRACT CLAUSES section of the solicitation. The bid bond penalty may be expressed in terms of a percentage of the bid price or may be expressed in dollars and cents.

Failure to submit a bid guarantee by the time set for opening of bids may be cause for rejection of a bid, except as provided in "LATE SUBMISSIONS, MODIFICATIONS, AND WITHDRAWALS OF BIDS" of this solicitation.

[FAR 28.101-2]

S-36.18 ACCIDENT PREVENTION PLAN (DEC 1998)

Within 15 days after receipt of Notice of Award of the contract, and at least 7 days prior to the preconstruction conference, four copies of the Accident Prevention Program shall be submitted to the Contracting Officer for review and acceptance. The program shall consist of the following forms and documents:

(a) An executed POD Form 248-R Rev (1 Jun 98), Accident Prevention Program, Administrative Plan.

(b) An executed POD Form 184-R Rev (16 Oct 98), Activity Hazard Analysis. (At the Contracting Officer's discretion, the Contractor may submit its Activity Hazard Analysis only for the first phase of construction provided that it is accompanied by an outline of the remaining phases of construction. All remaining phases shall be submitted and accepted prior to the beginning of work in each phase.)

(c) A copy of company policy statement of accident prevention and any other guidance statements normally provided new employees.

Contractor shall not commence physical work at the site until the program has been accepted by the Contracting Officer, or his authorized representative. In developing and implementing its Accident Prevention Program, the Contractor is also responsible for reviewing Section 1 of the most current edition of US Army Corps of Engineers Safety and Health Requirements Manual, Engineer Manual 385-1-1. [See paragraph entitled, SAFETY STANDARDS, in Section 00 73 00]

S-36.2 MAGNITUDE OF THE PROPOSED PROJECT [FAR 36.204]

(a) Physical Characteristics:

This design-bid-build project is to repair and modernize an existing pier at Kwajalein Atoll, and construct two new general purpose storage facilities and installation of infrastructure and utility systems. This project is in a remote location with a highly corrosive, hot, humid, and salt laden environment.

Pier work will include encapsulating a portion of the pier and filling the area, installing new piling, and installation of new decking. Work includes splash zone areas, repairs to existing berths, installation of new anchor rods, repair

Section 00 21 13 - 7 to pile caps, provide marine fenders, bollards and chocks, Antiterrorism/Force Protection measures, Energy Monitoring and Control Systems (EMCS) connections, and building information systems. Work also includes demolishing an existing general purpose storage facility. Supporting facilities includes utility systems supporting the pier (electric, potable water, non-potable water, fire water, sanitary sewer service, lighting, and communications) to include installation of new utility connections appropriate to each berthing location.

(b) Estimated Price Range: The estimated price range of this work is: $40,000,000 to $60,000,000

S-4.1 JOINT VENTURE OFFERORS (JUN 2003)

All Offerors in a Joint Venture shall submit their executed joint venture agreement. In addition, Joint Venture firms must obtain/submit their tax identification number (TIN), Data Universal Numbering System (DUNS) No., Section 00 45 00, Representations and Certifications and register in System for Award Management (SAM) https://www.sam.gov/portal/public/SAM/#1.

https://www.sam.gov/portal/public/SAM/#1

Section 00 72 00 - 1

Section 00 72 00 - General Conditions

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions NOV 2013

52.203-3 Gratuities APR 1984

52.203-5 Covenant Against Contingent Fees MAY 2014

52.203-7 Anti-Kickback Procedures MAY 2014

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014

52.203-12 Limitation On Payments To Influence Certain Federal Transactions OCT 2010

52.203-13 Contractor Code of Business Ethics and Conduct OCT 2015

52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform

Employees of Whistleblower Rights

APR 2014

52.204-2 Alt II Security Requirements (Aug 1996) - Alternate II APR 1984

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper MAY 2011

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards OCT 2015

52.204-13 System for Award Management Maintenance JUL 2013

52.204-14 Service Contract Reporting Requirements JAN 2014

52.204-18 Commercial and Government Entity Code Maintenance JUL 2015

52.204-19 Incorporation by Reference of Representations and Certifications. DEC 2014

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors

Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters JUL 2013

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations NOV 2015

52.210-1 Market Research APR 2011

52.211-13 Time Extensions SEP 2000

52.211-15 Defense Priority And Allocation Requirements APR 2008

52.214-26 Audit and Records--Sealed Bidding OCT 2010

52.214-27 Price Reduction for Defective Certified Cost or Pricing Data - Modifications -

Sealed Bidding

AUG 2011

52.214-28 Subcontracting Certified Cost Or Pricing Data--Modifications--Sealed Bidding OCT 2010

52.219-4 Notice of Price Evaluation Preference for HUBZone Small Business Concerns OCT 2014

52.222-21 Prohibition Of Segregated Facilities APR 2015

52.222-26 Equal Opportunity APR 2015

52.222-27 Affirmative Action Compliance Requirements for Construction APR 2015

52.222-29 Notification Of Visa Denial APR 2015

52.223-3 Hazardous Material Identification And Material Safety Data JAN 1997

52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011

52.223-6 Drug-Free Workplace MAY 2001

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving AUG 2011

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008

52.227-1 Authorization and Consent DEC 2007

52.227-2 Notice And Assistance Regarding Patent And Copyright Infringement DEC 2007

52.227-4 Patent Indemnity-Construction Contracts DEC 2007

52.228-2 Additional Bond Security OCT 1997

52.228-3 Worker's Compensation Insurance (Defense Base Act) JUL 2014

52.228-5 Insurance - Work On A Government Installation JAN 1997

52.228-11 Pledges Of Assets JAN 2012

52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014

52.228-14 Irrevocable Letter of Credit NOV 2014

52.228-15 Performance and Payment Bonds--Construction OCT 2010

Section 00 72 00 - 2

52.229-6 Taxes--Foreign Fixed-Price Contracts FEB 2013

52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014

52.232-17 Interest MAY 2014

52.232-27 Prompt Payment for Construction Contracts MAY 2014

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013

52.232-40 Providing Accelerated Payments to Small Business Subcontractors DEC 2013

52.233-1 Alt I Disputes (May 2014) - Alternate I DEC 1991

52.233-3 Protest After Award AUG 1996

52.233-4 Applicable Law for Breach of Contract Claim OCT 2004

52.236-2 Differing Site Conditions APR 1984

52.236-3 Site Investigation and Conditions Affecting the Work APR 1984

52.236-5 Material and Workmanship APR 1984

52.236-6 Superintendence by the Contractor APR 1984

52.236-7 Permits and Responsibilities NOV 1991

52.236-8 Other Contracts APR 1984

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and

Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984

52.236-11 Use and Possession Prior to Completion APR 1984

52.236-12 Cleaning Up APR 1984

52.236-13 Accident Prevention NOV 1991

52.236-21 Alt I Specifications and Drawings for Construction (Feb 1997) - Alternate I APR 1984

52.236-26 Preconstruction Conference FEB 1995

52.242-13 Bankruptcy JUL 1995

52.242-14 Suspension of Work APR 1984

52.243-4 Changes JUN 2007

52.244-6 Subcontracts for Commercial Items DEC 2015

52.246-12 Inspection of Construction AUG 1996

52.246-21 Warranty of Construction MAR 1994

52.248-3 Value Engineering-Construction OCT 2015

52.249-2 Alt I Termination for Convenience of the Government (Fixed-Price) (Apr 2012) -

Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984

52.253-1 Computer Generated Forms JAN 1991

252.201-7000 Contracting Officer's Representative DEC 1991

252.203-7000 Requirements Relating to Compensation of Former DoD Officials SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense-Contract-Related

Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013

252.203-7003 Agency Office of the Inspector General DEC 2012

252.204-7000 Disclosure Of Information AUG 2013

252.204-7003 Control Of Government Personnel Work Product APR 1992

252.204-7005 Oral Attestation of Security Responsibilities NOV 2001

252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By The Government of a Country that is a State Sponsor of Terrorism

OCT 2015

252.222-7002 Compliance With Local Labor Laws (Overseas) JUN 1997

252.223-7001 Hazard Warning Labels DEC 1991

252.223-7004 Drug Free Work Force SEP 1988

252.225-7005 Identification Of Expenditures In The United States JUN 2005

252.225-7041 Correspondence in English JUN 1997

252.225-7993

(Dev)

Prohibition on Providing Funds to the Enemy (Deviation 2015-O0016) SEP 2015

252.227-7033 Rights in Shop Drawings APR 1966

252.232-7003 Electronic Submission of Payment Requests and Receiving Reports JUN 2012

Section 00 72 00 - 3

252.232-7008 Assignment of Claims (Overseas) JUN 1997

252.232-7010 Levies on Contract Payments DEC 2006

252.236-7000 Modification Proposals-Price Breakdown DEC 1991

252.236-7001 Contract Drawings, and Specifications AUG 2000

252.236-7002 Obstruction of Navigable Waterways DEC 1991

252.236-7013 Requirement for Competition Opportunity for American Steel Producers, Fabricators, and Manufacturers

JUN 2013

252.243-7001 Pricing Of Contract Modifications DEC 1991

252.243-7002 Requests for Equitable Adjustment DEC 2012

252.247-7023 Transportation of Supplies by Sea APR 2014

252.247-7024 Notification Of Transportation Of Supplies By Sea MAR 2000

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within seven (7) calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use is seven hundred sixty-three (763) calendar days for the total base bid (Item No. 0001). The performance period for Option 1 – Item No. 0002 is thirty (30) calendar days; Option 2 – Item No. 0003 is thirty

(30) calendar days; Option 3 – Item No. 0004 is thirty (30) calendar days; Option 4 – Item No. 0005 is thirty (30) calendar days; Option 5 – Item No. 0006 is thirty (30) calendar days; Option 6 – Item No. 0007 is thirty (30) calendar days; Option 7 – Item No. 0008 is thirty (30) calendar days; and Option 8 – Item No. 0009 is thirty (30) calendar days. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $4,150.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.222-50 COMBATING TRAFFICKING IN PERSONS (MAR 2015) ALTERNATE I (MAR 2015)

(a) Definitions. As used in this clause—

Section 00 72 00 - 4

“Agent” means any individual, including a director, an officer, an employee, or an independent contractor, authorized to act on behalf of the organization.

“Coercion” means—

(1) Threats of serious harm to or physical restraint against any person;

(2) Any scheme, plan, or pattern intended to cause a person to believe that failure to perform an act would result in serious harm to or physical restraint against any person; or

(3) The abuse or threatened abuse of the legal process.

“Commercial sex act” means any sex act on account of which anything of value is given to or received by any person.

“Commercially available off-the-shelf (COTS) item” means--

(1) Any item of supply (including construction material) that is—

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

“Debt bondage” means the status or condition of a debtor arising from a pledge by the debtor of his or her personal services or of those of a person under his or her control as a security for debt, if the value of those services as reasonably assessed is not applied toward the liquidation of the debt or the length and nature of those services are not respectively limited and defined.

“Employee” means an employee of the Contractor directly engaged in the performance of work under the contract who has other than a minimal impact or involvement in contract performance.

“Forced labor” means knowingly providing or obtaining the labor or services of a person—

(1) By threats of serious harm to, or physical restraint against, that person or another person;

(2) By means of any scheme, plan, or pattern intended to cause the person to believe that, if the person did not perform such labor or services, that person or another person would suffer serious harm or physical restraint; or

(3) By means of the abuse or threatened abuse of law or the legal process.

“Involuntary…