W9127822R0008 AM06.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE PAGE OF PAGES

1 4

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE 4. REQUISITION/PURCHASE 5. PROJECT NO. (If applicable)

W9127822R0008-0006 29 MAR 2022 MEF22002

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than item 6)

CODE

Corps of Engineers 109 St. Joseph St.

Mobile, AL 36602

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP code) 9A. AMENDMENT OF SOLICITATION

NO.

W9127822R0008

9B. DATED (SEE ITEM 11)

17 DEC 2021

10A. MODIFICATION OF

CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

CODE

FACILITY CODE

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in item 14. The hour and date specified for receipt of Offers is extended, is not extended. Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods: (a) By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (if required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO AUTHORITY OF FAR 43.103(b)

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible) The subject solicitation for: BUILDING 73 LAB EXPANSION, EGLIN AIR FORCE BASE, FLORIDA

Is modified in the following: REFER TO THE ENCLOSED REVISIONS FOR AMENDMENT NO. 0006.

NOTE: THE RECEIPT OF PROPOSAL DATE IS HEREBY REVISED BY THIS AMENDMENT. REFER TO THE ENCLOSED SF1442, SOLICITATION, OFFER & AWARD FORM.

Except as provided herein, all terms and conditions of the document reference in item 9A or 10A, as Heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICE (Type or print)

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

BY

(Signature of contracting officer)

16C. DATE SIGNED

NSN 7540-01-152-8070 30-105 STANDARD FORM 30 (REV. 10-83)

PREVIOUS EDITION UNUSABLE Prescribed by GSA

BUILDING 73 LAB EXPANSION W9127822R0008

EGLIN AIR FORCE BASE, FLORIDA MEF22002

SF 30 Page 2

REVISED BY AMENDMENT NO. W9127822R0008-0006

PART I-REVISIONS MADE BY ADDED AND/OR REPLACEMENT PARAGRAPHS/PAGES/SECTIONS

The items listed below are to be replaced by the corresponding added and/or revised paragraphs/pages or sections. Added and/or revised paragraphs/pages or sections are indicated by a note in bottom right hand corner of each paragraph or page. Added sections are hereby made a part of the contract and are to be inserted in the specification in the proper numerical/alphabetical sequence.

Within the specifications, deletions from the specifications are indicated by strikethrough, e.g.: deletions are marked with strikethrough and additions to the specifications including revisions/substitutions are indicated in bold, italic and underlined, e.g.: additions are indicated thus.

Corresponding Added or Revised Paragraph SECTION Page, and/or Section

VOLUME 1

Table of Contents Revised Table of Contents Page 3

SF1442 Revised Block 13.A

01 33 00 Revised Submittal Register for Sections 08 34 73 and 22 00 00

01 91 00.15 Revised paragraphs 1.6.2 and 1.6.3

VOLUME 2

Table of Contents Revised Table of Contents Page 3

08 34 73 Revised paragraphs 1.2, 2.1, and 2.4.4

21 13 13 Revised paragraph 3.4.10

22 00 00 Revised paragraphs 1.2 and 3.3.3; deleted paragraphs 2.6 and 3.8.1.1

23 05 93 Revised Appendix D; deleted paragraph 1.3.4

23 07 00 Revised Paragraphs 2.3.1 and 3.2.3.1; revised

Tables 1 and 2

23 09 00 Revised Paragraphs 1.2 and 3.8.5

23 30 00 Revised Paragraphs 2.9.4, 2.9.7, 2.12.1, 3.3;

deleted paragraphs 2.12.1.3 and 3.9

23 36 00.00 40 Revised Paragraph 1.3 and 2.1.3.4; deleted paragraph 2.1.2

23 81 00 Revised Paragraphs 2.1, 2.1.1, and 2.3.2.2.5.2;

deleted paragraphs 2.3.1 and 2.3.2.1.8

23 81 23 Revised Paragraph 2.1; deleted paragraphs 2.1.9 and 2.2.1.3

SF 30 Page 3

REVISED BY AMENDMENT NO. W9127822R0008-0006

VOLUME 3

Table of Contents Revised Table of Contents Page 3

28 31 76 Revised Paragraph 2.12.3

PART II - REVISIONS MADE BY DELETED PAGES/SECTIONS

The pages and/or sections listed below are to be deleted from the specifications by the bidders and marked "DELETED":

Page/Section

25 05 11 SECTION 25 05 11 AND SUBMITTAL REGISTERS ARE DELETED IN ITS

ENTIRETY

25 08 10 SECTION 25 08 10 AND SUBMITTAL REGISTERS ARE DELETED IN ITS

ENTIRETY

25 10 10 SECTION 25 10 10 AND SUBMITTAL REGISTERS ARE DELETED IN ITS

ENTIRETY

PART III - NOTE: Revised, replacement and added drawings are listed below.

These revised, replacement and added drawings are to be inserted into the folio in the proper numerical sequence. Drawings that have been revised or replaced by this amendment shall be deleted from the folio. All drawings listed below are revised unless indicated otherwise.

Sheet Reference Number Title

G-001 AM06 COVER

CU101 UTILITY PLAN

CU502 UTILITY DETAILS

FL001 CODE SUMMARY

FA101 FLOOR PLAN – FIRE ALARM

FA102 MEZZANINE – FIRE ALARM

FA501 DETAILS – FIRE ALARM

FX501 DETAILS – FIRE PROTECTION

P-001 PLUMBING LEGENDS, NOTES & ABBREVIATION

P-101 GROUND FLOOR PLAN – PLUMBING BELOW SLAB

P-102 GROUND FLOOR PLAN – PLUMBING ABOVE SLAB

P-501 PLUMBING DETAILS-1

P-502 PLUMBING DETAILS-2

P-601 PLUMBING SCHEDULES-1

P-901 PLUMBING WASTE RISER DIAGRAMS

SF 30 Page 4

REVISED BY AMENDMENT NO. W9127822R0008-0006

P-902 PLUMBING DOMESTIC WATER RISER DIAGRAM

M-001 HVAC LEGENDS, NOTES & ABBREVIATION

M-101 HVAC GROUND FLOOR PLAN

M-102 HVAC MEZZANINE FLOOR PLAN

M-301 HVAC SECTIONS-1

M-302 HVAC SECTIONS-2

M-401 HVAC ENLARGED FLOOR PLAN

M-402 HVAC ENLARGED MEZZANINE FLOOR PLAN

M-501 HVAC DETAILS-1

M-502 HVAC DETAILS-2

M-503 HVAC DETAILS-3

M-601 HVAC SCHEDULES-1

M-701 HVAC CONTROLS-1

M-702 HVAC CONTROLS-2

M-703 HVAC CONTROLS-3

E-101 GROUND FLOOR POWER PLAN

Encl as stated:

Revised pages of the specifications as indicated in Part I.

31 Revised drawings as indicated in Part III.

Table of Contents Page 3

REVISED BY AMENDMENT NO. 0006

DIVISION 10 – SPECIALTIES

10 14 02 INTERIOR SIGNAGE

10 26 00 WALL AND DOOR PROTECTION

10 28 13 TOILET ACCESSORIES

10 44 16 FIRE EXTINGUISHERS

DIVISION 13 - SPECIAL CONSTRUCTION

13 12 20 EXTRUDED ALUMINUM CANOPY SYSTEM

DIVISION 14 - CONVEYING EQUIPMENT

14 25 02 MATERIAL LIFT

DIVISION 21 – FIRE SUPPRESSION

21 13 13 WET PIPE SPRINKLER SYSTEMS, FIRE PROTECTION

DIVISION 22 – PLUMBING

22 00 00 PLUMBING, GENERAL PURPOSE

DIVISION 23 – HEATING, VENTILATING, AND AIR CONDITIONING (HVAC)

23 05 93 TESTING, ADJUSTING, AND BALANCING FOR HVAC

23 07 00 THERMAL INSULATION FOR MECHANICAL SYSTEMS

23 09 00 INSTRUMENTATION AND CONTROL FOR HVAC

23 09 13 INSTRUMENTATION AND CONTROL DEVICES FOR HVAC

23 09 23.02 BACNET DIRECT DIGITAL CONTROL FOR HVAC AND OTHER BUILDING

CONTROL SYSTEMS

23 23 00 REFRIGERANT PIPING

23 30 00 HVAC AIR DISTRIBUTION

23 36 00.00 40 AIR TERMINAL UNITS

23 81 00 DECENTRALIZED UNITARY HVAC EQUIPMENT

23 81 23 COMPUTER ROOM AIR CONDITIONING UNIT

VOLUME 3 OF 5

DIVISION 25 – INTEGRATED AUTOMATION

25 05 11 CYBERSECURITY FOR FACILITY-RELATED CONTROL SYSTEMS

25 08 10 UTILITY MONITORING AND CONTROL SYSTEM TESTING

25 10 10 UTILITY MONITORING AND CONTROL SYSTEM (UMCS) FRONT END AND

INTEGRATION

DIVISION 26 – ELECTRICAL

26 08 00 APPARATUS INSPECTION AND TESTING

26 20 00 INTERIOR DISTRIBUTION SYSTEM

26 24 13 SWITCHBOARDS

26 28 01.00 10 COORDINATED POWER SYSTEM PROTECTION

26 41 00 LIGHTNING PROTECTION SYSTEM

26 42 14.00 10 CATHODIC PROTECTION SYSTEM (SACRIFICIAL ANODE)

26 51 00 INTERIOR LIGHTING

SOLICITATION, OFFER

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

W9127822R0008

2. TYPE OF

SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED

17 DEC 2021

PAGES OF PAGES

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

6. PROJECT NO.

MEF22002

7. ISSUED BY CODE CT 8. ADDRESS OFFER TO

U.S. ARMY ENGINEER DISTRICT, MOBILE

CONTRACTING DIVISION (CESAM-CT)

109 SAINT JOSEPH STREET

MOBILE, AL 36628-0001

SAME AS BLOCK 7

9. FOR INFORMATION

CALL : Ariel Chamberlain MAJ Humphrey Mararo

A. NAME

Ariel.S.Chamberlain@usace.army.mil Humphrey.W.Mararo@usace.army.mil

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

(251) 690-2473

(251) 441-5456

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date):

BUILDING 73 LAB EXPANSION, EGLIN AIR FORCE BASE, FLORIDA

* See Section 01 00 00, Paragraph “COMMENCEMENT, PROSECUTION AND COMPLETION OF WORK”.

**Block 13A. : Refer to Section 00 11 00 for the number of copies to submit with the original offer.

11. The Contractor shall begin performance within _8____ calendar days and complete it within __*__ calendar days after receiving award, notice to proceed.

This performance period is mandatory, negotiable. (See _ __ .)

12A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

YES NO

12B. CALENDAR DAYS

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and ___**___ copies to perform the work required are due at the place specified in Item 8 by _1400_ (hour) local time postponed indefinitely 13 APRIL 2022 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, is not required.

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than __120__ calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

NSN 7540-01-155-3212 1442-101

STANDARD FORM 1442(REV. 4-85)

Prescribed by GSA FAR(48 CFR) 53.236-1(e)

REVISED BY AMENDMENT NO. W9127822R0008-0006

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within _________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation - give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER

(Type or print)

20B. SIGNATURE 20C. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT

23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) ( ) 41 U.S.C. 253(c) ( )

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (contractor is required to sign this document and return _______ copies to issuing office.) Contractor agrees to furnish and deliver all items or perform all work, requisitions identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award,

(b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED

TO SIGN (Type or print)

31A. NAME OF CONTRACTING OFFICER (Type or print)

30B. SIGNATURE

30C. DATE 31B. UNITED STATES OF AMERICA

BY

31C. AWARD

DATE

STANDARD FORM 1442 BACK (REV. 4-85)

REISSUED BY AMENDMENT NO. W9127822R0008-0006

SUBMITTAL FORM,Jan 96 PREVIOUS EDITION IS OBSOLETE PAGE 1 OF 2 PAGES

Building 73 Lab Expansion, Eglin AFB, FL

08 34 73 SD-02 Shop Drawings

2.1 GHollow Metal Sound Retardant

Doors

2.1 GDoor Frames

SD-03 Product Data

2.1 GHollow Metal Sound Retardant

Doors

2.1 GDoor Frames

2.1 GDoor Hardware

2.1 GIntumescent Seals and Gasketing

2.1 GThresholds

2.1 GAstragals

SD-05 Design Data

2.1 GStructural Calculations and Test

Data

SD-06 Test Reports

2.4.4 GAcoustical Tests

SD-07 Certificates

2.1 GHollow Metal Sound Retardant

Doors

2.1 GDoor Frames

2.1 GDoor Hardware

GIntumescent Seals,Gasketing and

Door Bottoms

2.1 GThresholds

2.1 GAstragals

SUBMITTAL REGISTER

CONTRACT NO.

TITLE AND LOCATION CONTRACTOR

CONTRACTOR:

SCHEDULE DATES

CONTRACTOR

ACTION

APPROVING AUTHORITY

A C T I V I T Y

N O

T R A N S M I T T A L

N O

S P E C

S E C T

DESCRIPTION

ITEM SUBMITTED

P A R A G R A P H

C L A S S I F I C A T I O N

G O V T

O R

A E

R E V W

R SUBMIT

APPROVAL

NEEDED

BY

MATERIAL

NEEDED

BY

A C T I O N

C O D E

DATE

OF

ACTION

DATE FWD

TO APPR

AUTH/

DATE RCD

FROM

CONTR

DATE FWD

TO OTHER

REVIEWER

DATE RCD

FROM OTH

REVIEWER

A C T I O N

C O D E

DATE

OF

ACTION

MAILED

TO

CONTR/

DATE RCD

FRM APPR

AUTH REMARKS

(a) (b) (c) (d) (e) (f) (g) (h) (i) (j) (k) (l) (m) (n) (o) (p) (q) (r)

SUBMITTAL FORM,Jan 96 PREVIOUS EDITION IS OBSOLETE PAGE 2 OF 2 PAGES

Building 73 Lab Expansion, Eglin AFB, FL

22 00 00 SD-02 Shop Drawings

3.8.1Plumbing System

SD-03 Product Data

2.5Fixtures

2.5.3Flush Valve Water Closets

2.5.4Wall Hung Lavatories

2.5.5Service Sinks

2.5.6 GDrinking-Water Coolers

2.8 GWater Heaters

1.5.1Welding

3.4Vibration-Absorbing Features

SD-06 Test Reports

3.8Tests, Flushing and Disinfection

SD-07 Certificates

1.3Materials and Equipment

2.2.1Bolts

SD-10 Operation and Maintenance

Data

3.8.1Plumbing System

SD-11 Closeout Submittals

2.1.1Water-Efficient Products

2.1.2Energy-Efficient Water Heaters

SUBMITTAL REGISTER

CONTRACT NO.

TITLE AND LOCATION CONTRACTOR

CONTRACTOR:

SCHEDULE DATES

CONTRACTOR

ACTION

APPROVING AUTHORITY

A C T I V I T Y

N O

T R A N S M I T T A L

N O

S P E C

S E C T

DESCRIPTION

ITEM SUBMITTED

P A R A G R A P H

C L A S S I F I C A T I O N

G O V T

O R

A E

R E V W

R SUBMIT

APPROVAL

NEEDED

BY

MATERIAL

NEEDED

BY

A C T I O N

C O D E

DATE

OF

ACTION

DATE FWD

TO APPR

AUTH/

DATE RCD

FROM

CONTR

DATE FWD

TO OTHER

REVIEWER

DATE RCD

FROM OTH

REVIEWER

A C T I O N

C O D E

DATE

OF

ACTION

MAILED

TO

CONTR/

DATE RCD

FRM APPR

AUTH REMARKS

(a) (b) (c) (d) (e) (f) (g) (h) (i) (j) (k) (l) (m) (n) (o) (p) (q) (r)

Section 01 91 00.15

Section 01 91 00.15

1.6.2 Technical Commissioning Specialists

Technical Commissioning Specialists, employed by the Commissioning Firm and that have the following qualifications, must perform the technical work specified herein associated with each system to be commissioned:

a. The technical work associated with mechanical systems including

Heating, Ventilating, Air Conditioning, and Refrigeration Systems;

Building Automation System; Utility Monitoring and Control System;

Plumbing Systems; Water Pumping and Mixing Systems; and lighting Systems must be performed by a Commissioning Specialist certified by NEBB, ACG, ICB/TABB, or BCA in the commissioning of HVAC systems with five years of experience in the commissioning of HVAC and lighting systems.

b. The technical work associated with electrical systems including Lighting Systems; must be performed by an engineering technician certified by the InterNational Electrical Testing Association (NETA) or the National Institute for Certification in Engineering Technologies (NICET) with five years of experience inspecting, testing, and calibrating electrical distribution and generation equipment, systems, and devices.

b c. Submit the Technical Commissioning Specialist's certification of qualifications including the name of the specialist and firm;

certifications; years of experience; and a listing of representative projects of similar size and complexity no later than 60 calendar days after Notice to Proceed. Submit one hard copy and an electronic copy.

1.6.3 Commissioning Standard

Comply with the requirements of the commissioning standard under which the Commissioning Firm and Specialists qualifications are approved. When the firm and specialists are certified by BCA, AEE, ASHRAE, or the University of Wisconsin-Madison, comply with the requirements of one of the acceptable standards unless otherwise stated herein. The acceptable standards are ACG Commissioning Guideline, NEBB Commissioning Standard, SMACNA 1429, or ASHRAE

202. Comply with applicable NETA and NICET testing standards for electrical systems.

a. Implement all recommendations and suggested practices contained in the

Commissioning Standard and electrical test standards.

b. b. Use the Commissioning Standard for all aspects of Commissioning, including calibration of instruments.

c. Where the instrument manufacturer calibration recommendations are more stringent than those listed in the Commissioning Standard, adhere to the manufacturer calibration recommendations.

d. All quality assurance provisions of the Commissioning Standard such as performance guarantees are part of this contract.

Section 01 91 00.15

e. The Commissioning Specialists must develop commissioning procedures for any systems or system components not covered in the Commissioning Standard.

f. Use any new requirements, recommendations, and procedures published or adopted prior to contract solicitation by the body responsible for the Commissioning Standard.

Note: The remainder of the section is unchanged by this amendment.

DIVISION 10 – SPECIALTIES

10 14 02 INTERIOR SIGNAGE

10 26 00 WALL AND DOOR PROTECTION

10 28 13 TOILET ACCESSORIES

10 44 16 FIRE EXTINGUISHERS

DIVISION 13 - SPECIAL CONSTRUCTION

13 12 20 EXTRUDED ALUMINUM CANOPY SYSTEM

DIVISION 14 - CONVEYING EQUIPMENT

14 25 02 MATERIAL LIFT

DIVISION 21 – FIRE SUPPRESSION

21 13 13 WET PIPE SPRINKLER SYSTEMS, FIRE PROTECTION

DIVISION 22 – PLUMBING

22 00 00 PLUMBING, GENERAL PURPOSE

DIVISION 23 – HEATING, VENTILATING, AND AIR CONDITIONING (HVAC)

23 05 93 TESTING, ADJUSTING, AND BALANCING FOR HVAC

23 07 00 THERMAL INSULATION FOR MECHANICAL SYSTEMS

23 09 00 INSTRUMENTATION AND CONTROL FOR HVAC

23 09 13 INSTRUMENTATION AND CONTROL DEVICES FOR HVAC

23 09 23.02 BACNET DIRECT DIGITAL CONTROL FOR HVAC AND OTHER BUILDING

CONTROL SYSTEMS

23 23 00 REFRIGERANT PIPING

23 30 00 HVAC AIR DISTRIBUTION

23 36 00.00 40 AIR TERMINAL UNITS

25 05 11 CYBERSECURITY FOR FACILITY-RELATED CONTROL SYSTEMS

25 08 10 UTILITY MONITORING AND CONTROL SYSTEM TESTING

25 10 10 UTILITY MONITORING AND CONTROL SYSTEM (UMCS) FRONT END AND

INTEGRATION

DIVISION 26 – ELECTRICAL

26 08 00 APPARATUS INSPECTION AND TESTING

26 20 00 INTERIOR DISTRIBUTION SYSTEM

26 24 13 SWITCHBOARDS

26 28 01.00 10 COORDINATED POWER SYSTEM PROTECTION

26 41 00 LIGHTNING PROTECTION SYSTEM

Section 08 34 73

Section 08 34 73

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-02 Shop Drawings

Hollow Metal Sound Retardant Doors; G

Door Frames; G

SD-03 Product Data

Door Hardware; G

Intumescent Seals and Gasketing; G

Thresholds; G

Astragals; G

SD-05 Design Data

Structural Calculations and Test Data; G

Structural calculations and test data demonstrating compliance with design pressures (for exterior STC doors only).

SD-06 Test Reports

Wind Loading Tests; G

Water Leakage Tests; G

Acoustical Tests; G

Air Infiltration Tests; G

SD-07 Certificates

Door Hardware; G

Section 08 34 73

Intumescent Seals, Gasketing and Door Bottoms; G

Thresholds; G

Astragals; G

2.1 SYSTEM DESCRIPTION

Provide sound retardant door assemblies of the thickness, width, and height indicated, complete with perimeter seals, seal housings, gasketing, automatic door bottoms, thresholds, door frames, and astragals as required to conform to the specified STC per ASTM E90 and ASTM E1289.

For exterior STC doors, provide galvanized pre-engineered STC/blast-rated door and frame assembly to meet STC requirement as shown on architectural drawings and design wind pressures and associated notes as indicated on structural drawings. Submit structural calculations and test data demonstrating compliance with design pressures.

Submit fabrication drawings for Hollow Metal Sound Retardant Doors, Wood Sound Retardant Doors, and Door Frames.

Submit certificates showing conformance with the referenced standards in this section, and manufacturer's catalog data including STC ratings and UL fire rating, where applicable, for the following items: Hollow metal sound retardant doors; wood sound retardant doors; door frames; door hardware; intumescent seals and gasketing; thresholds; and astragals.

Provide assemblies that are complete with metal frame, wood door(s), sealing system, and Cam-lift hinges (when required).

2.4.4 Guarantee

Provide written guarantee that each door delivered to the project is equal in construction, sound transmission classification (STC), and positive pressure test rating where applicable, with appropriate labeling and markings, to that of the sample door tested. Clearly state in written guarantee that each door assembly, when installed in accordance with the manufacturer's printed instructions, has an in-place STC within 3 decibels of the specimen tested. Submit the following test data and Certificates with the written Guarantee:

a. Wind Loading Tests

b. Water Leakage Tests a c. Acoustical Tests

d. Air Infiltration Tests b e. Positive Pressure Tests

Section 21 13 13

Section 21 13 13

3.4.10 Inspector's Test Connection

Unless otherwise indicated, the test connection must consist of 1-inch pipe connected to the remote branch line; a test valve located no higher than 72 inches approximately 7 feet above the floor; a smooth bore brass outlet equivalent to the smallest orifice sprinkler used in the system; and a painted metal identification sign affixed to the valve with the words "Inspector's Test". All test connection piping must be inside of the building and penetrate the exterior wall at the location of the discharge orifice only. The discharge orifice must be located outside the building wall no more than 2 feet above finished grade, directed so as not to cause damage to adjacent construction or landscaping during full flow discharge, or to the sanitary sewer. Discharge to the exterior must not interfere with exiting from the facility. Water discharge or runoff must not cross the path of egress from the building. Do not discharge to the roof. Discharge to floor drains, janitor sinks or similar fixtures is not permitted.

Provide concrete splash blocks at all drain and inspector's test connection discharge locations if not discharging to a concrete surface. Splash blocks must be large enough to mitigate erosion and not become dislodged during a full flow of the drain. Ensure all discharged water drains away from the facility and does not cause property damage.

Section 22 00 00

Section 22 00 00

1.2 SUBMITTALS

Government approval is required for submittals with a “G” designation;

submittals not having a "G" designation are for Contractor Quality Control approval. Submit the following in accordance with Section 01 33 00 SUBMITTAL

PROCEDURES:

Plumbing System

Detail drawings consisting of schedules, performance charts, instructions, diagrams, and other information to illustrate the requirements and operations of systems that are not covered by the Plumbing Code. Detail drawings for the complete plumbing system including piping layouts and locations of connections; dimensions for roughing-in, foundation, and support points; schematic diagrams and wiring diagrams or connection and interconnection diagrams. Detail drawings shall indicate clearances required for maintenance and operation. Where piping and equipment are to be supported other than as indicated, details shall include loadings and proposed support methods. Mechanical drawing plans, elevations, views, and details, shall be drawn to scale.

Fixtures

List of installed fixtures with manufacturer, model, and flow rate.

Flush Valve Water Closets

Wall Hung Lavatories

Service Sinks

Drinking-Water Coolers; G

Water Heaters; G

Backflow Prevention Assemblies; G

Welding

A copy of qualified procedures and a list of names and identification symbols of qualified welders and welding operators.

Vibration-Absorbing Features

Details of vibration-absorbing features, including arrangement, foundation plan, dimensions and specifications.

SD-06 Test Reports

Tests, Flushing and Disinfection

Test reports in booklet form showing all field tests performed to adjust each component and all field tests performed to prove compliance with the specified performance criteria, completion and testing of the installed system. Each test report shall indicate the final position of controls.

Test of Backflow Prevention Assemblies; G

Certification of proper operation shall be as accomplished in accordance with state regulations by an individual certified by the state to perform such tests. If no state requirement exists, the Contractor shall have the manufacturer's representative test the device, to ensure the unit is properly installed and performing as intended. The Contractor shall provide written documentation of the tests performed and signed by the individual performing the tests.

SD-07 Certificates

Materials and Equipment

Where equipment is specified to conform to requirements of the ASME Boiler and Pressure Vessel Code, the design, fabrication, and installation shall conform to the code.

Bolts

Written certification by the bolt manufacturer that the bolts furnished comply with the specified requirements.

SD-10 Operation and Maintenance Data

Plumbing System

Submit in accordance with Section 01 78 23 OPERATION AND

MAINTENANCE DATA.

SD-11 Closeout Submittals

Water-Efficient Products

Energy-Efficient Water Heaters

2.6 BACKFLOW PREVENTERS

Backflow prevention devices must be approved by the State or local regulatory agencies. If there is no State or local regulatory agency requirements, the backflow prevention devices must be listed by the Foundation for Cross-Connection Control & Hydraulic Research, or any other approved testing laboratory having equivalent capabilities for both laboratory and field evaluation of backflow prevention devices and assemblies.

Reduced pressure principle assemblies, double check valve assemblies, atmospheric (nonpressure) type vacuum breakers, and pressure type vacuum breakers shall be meet the above requirements.

Backflow preventers with intermediate atmospheric vent shall conform to ASSE 1012. Reduced pressure principle backflow preventers shall conform to ASSE 1013. Hose connection vacuum breakers shall conform to ASSE 1011.

Pipe applied atmospheric type vacuum breakers shall conform to ASSE 1001.

Pressure vacuum breaker assembly shall conform to ASSE 1020. Air gaps in plumbing systems shall conform to ASME A112.1.2.

3.3.3 Height of Fixture Rims Above Floor

Lavatories shall be mounted with rim 31 34 inches above finished floor.

Wall-hung drinking fountains and water coolers shall be installed with rim 42 36 inches above floor. Wall-hung service sinks shall be mounted with rim 28 inches above the floor. Installation of fixtures for use by the physically handicapped shall be in accordance with ICC A117.1 COMM.

3.8.1.1 Test of Backflow Prevention Assemblies

Backflow prevention assembly shall be tested using gauges specifically designed for the testing of backflow prevention assemblies.

Backflow prevention assembly test gauges shall be tested annually for accuracy in accordance with the requirements of State or local regulatory agencies. If there is no State or local regulatory agency requirements, gauges shall be tested annually for accuracy in accordance with the requirements of University of Southern California's Foundation of Cross Connection Control and Hydraulic Research or the American Water Works Association Manual of Cross Connection (Manual M-14), or any other approved testing laboratory having equivalent capabilities for both laboratory and field evaluation of backflow prevention assembly test gauges. Report form for each assembly shall include, as a minimum, the following:

Data on Device Data on Testing Firm Type of Assembly Name Manufacturer Address Model Number Certified Tester Serial Number Certified Tester No.

Size Date of Test Location Test Pressure Readings Serial Number and Test Data of

Gauges

If the unit fails to meet specified requirements, the unit shall be repaired and retested.

Section 23 05 93

Section 23 05 93

1.3.4 Related Requirements

Appendix D

REQUIREMENTS FOR DUCT AIR LEAK TESTING

| SYSTEMS |

| VAV |

| Unit |

Duct System Static | | Pressure in inches W.C. | | for Supply | 3 | System Oval/Round Duct | | and Rectangular Duct | | SMACNA Seal Class | | for Supply | A | System Oval/Round Duct | |

SMACNA Leak Class | | for Supply | 6 |

System Rectangular Duct | |

SMACNA Leak Class | | for Supply | 6 |

Duct Test Pressure | | in inches W.C. | | for Supply | 3 |

Appendix D

REQUIREMENTS FOR DUCT AIR LEAK TESTING

Series VAV Terminal Boxes Unit

Exhaust Systems Unit

Duct System Static Pressure, in W.C.

for Supply 3 n/a for Return 0.5 n/a for Exhaust n/a 1 for Outside Air n/a n/a

System Round Duct and Rectangular Duct SMACNA Seal Class for Supply A for Return A for Exhaust A for Outside Air

A A

System Round Duct SMACNA Leak Class for Supply 6 n/a for Return 6 n/a for Exhaust n/a 6 for Outside Air n/a n/a

System Rectangular Duct SMACNA Leak Class for Supply 6 n/a for Return 6 n/a for Exhaust n/a 6 for Outside Air n/a n/a

Duct Test Pressure, in inches W.C.

for Supply 3 n/a for Return 0.5 n/a for Exhaust n/a 1 for Outside Air n/a n/a

Section 23 07 00

Section 23 07 00

2.3.1 Aboveground Cold Pipeline ( -30 to 60 deg. F)

Insulation for outdoor, indoor, exposed or concealed applications, shall be as follows:

a. Cellular Glass: ASTM C 552, Type II, and Type III. Supply the insulation with manufacturer's recommended factory-applied jacket/vapor barrier.

a b. Flexible Elastomeric Cellular Insulation: ASTM C 534/C 534M, Grade 1, Type I or II. Type II shall have vapor retarder/vapor barrier skin on one or both sides of the insulation.

3.2.3.1 General Requirements

All hot pipe lines above 60 degrees F, except those piping listed in subparagraph Pipe Insulation in PART 3 as to be omitted, shall be insulated in accordance with Table 2. This includes but is not limited to the following:

a. Domestic hot water supply & re-circulating system.

b. Steam.

Insulation shall be covered, in accordance with manufacturer's recommendations, with a factory applied Type I jacket or field applied aluminum where required or seal welded PVC.

3.2.1.6 Pipe Insulation Material and Thickness

TABLE 1

Insulation Material For Piping (°F)

Service Material Spec-Type-Class Vapor Retard/

Vapor Barr'r Required

Hot & Cold

Mineral Fiber ASTM C547 I 1

Yes

Domestic

Water Piping, Makeup Water

Drinking Fount Flex Elast Cell'r ASTM C534/C534M I No Drain Piping

Refrigerant Flex Elast Cell'r ASTM C534/C534M I No Suction Piping

(35°F nominal)

Exposed Lav'ry Flex Elast Cell'r ASTM C534/C534M I No Drains, Expo'd

Domestic Water

Piping & Drains to Areas for Handicap Personnel

A/C condensate Drain Located Inside Bldg.

A/C condensate Drain Located Inside Bldg. Flex Elast Cell'r ASTM C534/C534M I No

Steam and Condensate Return (201 to 250°F) Flex Elast Cell'r ASTM C 534/C 534M I 2 No

TABLE 2

Piping Insulation Thickness (inch and °F)

Tube And Pipe Size (Inches)

Service Material <1 1- <1.5 1.5- <4 4- <8 >or = to 8

Hot & Cold Domestic Water Piping, Makeup Water

Mineral Fiber 1 1 1 1 1

Drinking Fountain Mineral Fiber 1 1 1 1.5 1.5 Drain Piping

Refrigerant Flex Elas Cell'r 0.5 0.5 1 N/A N/A Suction Piping

(35°F nominal)

Exposed Lavatory Flex Elas Cell'r 0.5 0.5 0.5 0.5 0.5 Drains, Exposed

Domestic Water

Piping & Drains to Areas for

Handicap Personnel

A/C condensate

Drain Located Flex Elas Cell'r 1 1 1 N/A N/A Inside Bldg.

Steam, and Condensate Return (201°F to 250°F)_

Flex Elast Cell'r

N/A

N/A

Section 23 09 00

Section 23 09 00

1.2 RELATED SECTIONS

Related work specified elsewhere:

a. Section 23 09 23.02 BACNET DIRECT DIGITAL CONTROL FOR HVAC AND OTHER BUILDING CONTROL SYSTEMS for BACnet systems with or without Niagara Framework.

b. Section 23 09 13 INSTRUMENTATION AND CONTROL DEVICES FOR HVAC

c. Eglin AFB EMCS (DDC) System

d. Section 25 08 10 UTILITY MONITORING AND CONTROL SYSTEMS TESTING

e. Section 25 10 10 UTILITY MONITORING AND CONTROL SYSTEMS (UMCS) FRONT

END AND INTEGRATION

f. Section 25 05 11 CYBERSECURITY FOR FACILITY-RELATED CONTROL SYSTEMS d g. Section 01 91 00.15 TOTAL BUILDING COMMISSIONING

3.8.5 Emergency Service

The Government will initiate service calls when the system is not functioning properly. Qualified personnel must be available to provide service to the system. A telephone number where the service supervisor can be reached at all times must be provided. Service personnel must be at the site within 24 hours after receiving a request for service. The control system must be restored to proper operating condition as required per Section 01 78 00

CLOSEOUT SUBMITTALS.

Section 23 30 00

Section 23 30 00

2.9.4 Air Supply And Exhaust Air Dampers

Provide outdoor air supply and exhaust air dampers that have a maximum leakage rate when tested in accordance with AMCA 500-D as required by ASHRAE

90.1 - IP and UFC 4-010-01 DoD Minimum Antiterrorism Standards for Buildings, including maximum Damper Leakage for:

a. Climate Zones 1,2,6,7,8 the maximum damper leakage at 1.0 inch w.g. for motorized dampers is 4 3 cfm per square foot of damper area and non-motorized dampers are not allowed.

Dampers smaller than 24 inches in either direction may have leakage of 40 cfm per square foot.

2.9.7 Diffusers, Registers, and Grilles

Provide factory-fabricated units of corrosion-resistant steel or aluminum that distribute the specified quantity of air evenly over space intended without causing noticeable drafts, air movement faster than 50 fpm in occupied zone, or dead spots anywhere in the conditioned area. Provide outlets for diffusion, spread, throw, and noise level as required for specified performance. Certify performance according to ASHRAE 70. Provide sound rated and certified inlets and outlets according to ASHRAE 70.

Provide sound power level as indicated. Provide diffusers and registers with volume damper with accessible operator, unless otherwise indicated;

or if standard with the manufacturer, an automatically controlled device is acceptable. Provide opposed blade type volume dampers for all diffusers and registers at duct take off to check supply diffusers or registers.

Volume dampers are not required on return air grilles. ,except linear slot diffusers. Provide linear slot diffusers with round or elliptical balancing dampers. Where the inlet and outlet openings are located less than 7 feet above the floor, protect them by a grille or screen according to NFPA 90A.

2.12.1 Variable Air Volume (VAV) and Dual Duct Terminal Units

2.12.1.3 Reheat Units.

3.3 EQUIPMENT PADS

Provide equipment pads to the dimensions shown or, if not shown, to conform to the shape of each piece of equipment served with a minimum 6-inch margin around the equipment and supports. Allow equipment bases and foundations, when constructed of concrete or grout, to cure a minimum of 28 calendar days before being loaded.

Section 23 30 00

3.9 DUCTWORK LEAK TEST

Perform ductwork leak test for the entire air distribution and exhaust system, including fans, coils, [filters, etc.][filters, etc. designated as static pressure Class 3 inch water gauge through Class 10 inch water gauge.] Provide test procedure, apparatus, and report that conform to SMACNA 1972 CD.

The maximum allowable leakage rate is [_____] cfm. Complete ductwork leak test with satisfactory results prior to applying insulation to ductwork exterior or concealing ductwork.

Section 23 36 00.00 40

Section 23 36 00.00 40

1.3 SUBMITTALS

Government approval is required for submittals with a "G" classification.

Submittals not having a "G" classification are for Contractor Quality Control approval. Submit the following in accordance with Section 01 33 00 SUBMITTAL

PROCEDURES:

SD-01 Preconstruction Submittals

Records of Existing Conditions

Bypass Single-Duct Air Terminal Units; G

Shutoff Single-Duct Air Terminal Units; G

Bypass Single-Duct Air Terminal Units; G

Shutoff Single-Duct Air Terminal Units; G

SD-07 Certificates

List of Spare Parts

SD-10 Operation and Maintenance Data

Operation and Maintenance Manuals

SD-11 Closeout Submittals

Record Drawings

2.1.2 Bypass Single-Duct Air Terminal Units

2.1.3.4 Electric Heating Coil

Provide a slip-in-type, open-coil design with integral control box factory wired and installed. Include the following features:

a. Primary and secondary over-temperature protection

b. Nickel chrome 80/20 heating elements

c. Airflow switch

d. Non-interlocking disconnect switch

Section 23 36 00.00 40

e. Fuses (for coils more than 48 A)

f. Mercury contactors

g. Modulating SCR controller

h. Magnetic contactor for each step of control (for three-phase coils)

Section 23 81 00

Section 23 81 00

2.1 ENERGY EFFICIENCY REQUIREMENTS

42 USC 8259b requires the procurement of energy efficient products in product categories covered by the Energy Star program or the Federal Energy Management Program for designated products. A list of covered product categories is available from the Federal Energy Management Web site at http://energy.gov/eere/femp/covered-product-categories. A list of qualified light commercial products is available at http://www.energystar.gov/productfinder/product/certified-light-commercial-hvac/results

Submit Material, Equipment, and Fixtures List of all supplied products within a covered product category, including manufacturer's catalog numbers, specification and drawing reference number, warranty information, fabrication site, and energy performance data. For product categories covered by the Energy Star program, submit documentation that the product is Energy Star-qualified. For product categories covered by the Federal Energy Management Program, submit documentation that the product meets or exceeds FEMP-designated efficiency requirements.

2.1.1 Room Air Conditioners

Selected room air conditioners are required to meet performance requirements specified by Energy Star. Information on the requirements can be found at ENERGY STAR Version 4.0 Room Air Conditioners Program Requirements.

2.3.1 Computer Room Air Conditioner

2.3.2.1.8 Primary/Supplemental Heat

Provide heating unit with internal thermal insulation having a fire hazard rating not to exceed 25 for flame spread and 50 for smoke developed as determined by ASTM E84.

2.3.2.2.5.2 Evaporative Condenser NOT USED

The unit must have fan assemblies built into the unit base, with all moving parts factory mounted and aligned. Primary construction of the pan section and the cabinet must not be lighter than 16-gauge steel, protected against corrosion by a zinc coating. Conform the zinc coating ASTM A153/A153M and ASTM A123/A123M, as applicable and have an extra heavy coating of not less than 2.5 ounces/square foot of surface. Give cut edges a protective coating of zinc-rich compound. After assembly, apply the manufacturer's standard zinc chromatized aluminum or epoxy paint finish to the exterior of the unit. Unit must be rated in accordance with AHRI 490 I-P and tested in accordance with the requirements of ASHRAE 64.

Section 23 81 00

a. Provide a watertight pan complete with drain, overflow, and make-up water connections. Provide standard pan accessories to include circular access doors, a lift-out strainer of anti-vortexing design and a brass make-up valve with float ball.

b. Provide a direct driven, statically and dynamically balanced, centrifugal type fan. Enclose motors in totally enclosed enclosure that is suitable for the indicated service. Design the condensing unit design to prevent water from entering into the fan section.

c. Provide condensing coils with copper tubes of 3/8 inch minimum diameter without fins. Protect coil in accordance with paragraph CORROSION PROTECTION. Provide galvanized steel casing. Avoid contact of dissimilar metals. Test coils in accordance with ANSI/ASHRAE 15 & 34 at the factory and ensure suitability for the working pressure of the installed system. Dehydrate and seal each coil after testing and prior to evaluation and charging. Provide each unit with a factory operating charge of refrigerant and oil or a holding charge. Field charge unit shipped with a holding charge with refrigerant and oil.

Section 23 81 23

Section 23 81 23

2.1 COMPUTER ROOM AIR CONDITIONER (CRAC)

Provide complete working CRACs, designed, and factory assembled, and factory tested. Equipment must be listed in UL Elec Equip Dir or ETL DLP for computer room application. CRACs must have a minimum sensible coefficient of performance in accordance with ASHRAE 127. Provide equipment with minimum efficiencies as required by ASHRAE 90.1 - IP. CRACs must include room cabinet and frame, floor stand, fan section, filter section, cooling coil, reheat coil, humidifier, compressors, condensers, controls, and, interconnecting piping internal to the CRAC. Provide units rated in accordance with AHRI 1360.

2.1.9 Floorstand

Provide an adjustable floorstand for each CRAC for freestanding installation on the main building structural floor. Floorstand must elevate the unit to the height of the raised computer floor and must allow for leveling and locking at the desired height. Floorstand must be retractable, or removable, for installing the unit directly on the raised floor. Unit must be fully gasketed (rubber or neoprene) to prevent air leakage at the raised floor penetration. Provide radiused turning vane integral to floorstand.

2.2.1.3 Leak Detection NOT USED

Provide [spot][ or ][rope] moisture detection system for each computer room.

Leak detection must be designed for installation on the subfloor below the raised floor of the computer room. Leak detection system must interface with the associated CRAC control panel to alarm upon detection of moisture on the subfloor.

DIVISION 10 – SPECIALTIES

10 14 02 INTERIOR SIGNAGE

10 26 00 WALL AND DOOR PROTECTION

10 28 13 TOILET ACCESSORIES

10 44 16 FIRE EXTINGUISHERS

DIVISION 13 - SPECIAL CONSTRUCTION

13 12 20 EXTRUDED ALUMINUM CANOPY SYSTEM

DIVISION 14 - CONVEYING EQUIPMENT

14 25 02 MATERIAL LIFT

DIVISION 21 – FIRE SUPPRESSION

21 13 13 WET PIPE SPRINKLER SYSTEMS, FIRE PROTECTION

DIVISION 22 – PLUMBING

22 00 00 PLUMBING, GENERAL PURPOSE

DIVISION 23 – HEATING, VENTILATING, AND AIR CONDITIONING (HVAC)

23 05 93 TESTING, ADJUSTING, AND BALANCING FOR HVAC

23 07 00 THERMAL INSULATION FOR MECHANICAL SYSTEMS

23 09 00 INSTRUMENTATION AND CONTROL FOR HVAC

23 09 13 INSTRUMENTATION AND CONTROL DEVICES FOR HVAC

23 09 23.02 BACNET DIRECT DIGITAL CONTROL FOR HVAC AND OTHER BUILDING

CONTROL SYSTEMS

23 23 00 REFRIGERANT PIPING

23 30 00 HVAC AIR DISTRIBUTION

23 36 00.00 40 AIR TERMINAL UNITS

25 05 11 CYBERSECURITY FOR FACILITY-RELATED CONTROL SYSTEMS

25 08 10 UTILITY MONITORING AND CONTROL SYSTEM TESTING

25 10 10 UTILITY MONITORING AND CONTROL SYSTEM (UMCS) FRONT END AND

INTEGRATION

DIVISION 26 – ELECTRICAL

26 08 00 APPARATUS INSPECTION AND TESTING

26 20 00 INTERIOR DISTRIBUTION SYSTEM

26 24 13 SWITCHBOARDS

26 28 01.00 10 COORDINATED POWER SYSTEM PROTECTION

26 41 00 LIGHTNING PROTECTION SYSTEM

Section 28 31 76

Section 28 31 76

2.13.3 Textual Display Signs

Textual display signs must be LED fixed letter scrolling and must not exceed 16 inches long by 6 inches high by 3 inches deep with a height necessary to meet the requirements of NFPA 72).The text display must spell out the word "EVACUATE" or "ANNOUNCEMENT" and the remainder of the emergency instructions as appropriate. The design of text display must be such that it cannot be read when not illuminated.

LED scrolling text displays must meet the following requirements at a minimum:

a. Two lines of information for high priority messaging.

b. Minimum of 20 characters per line (40 total) displayed.

c. Text must be no less than height requirements and color/contrast requirements of NFPA 72.

d. 32K character memory.

e. Display must be wall or ceiling mounted.

f. Mounting brackets for a convenient wall/cubicle mount.

g. During non-emergency periods, display date and time.

h. The system must interface with the textual display sign control panel to activate the proper message.