am_4_17DEC21.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

This Solicitation is for the Construction of Fort Hood Central Chilled Water Plant.

See SF30 Continuation Sheet(s)

NOTE: Proposal undergoing revisions/changes requested by the user to the Chilled Water Line connections. The forthcoming amendment Proposal Receipt date is extended from 17 December 2021; 1:00 pm, CT to 15 April 2022; 1:00 pm, CT.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 3

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X 9A. AMENDMENT OF SOLICITATION NO.

W9126G22R0043

X 9B. DATED (SEE ITEM 11)

08-Nov-2021

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended,X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

17-Dec-2021

CODE

US ARMY ENGINEER DISTRICT, FORT WORTH

ATTN: CESWF-CT

819 TAYLOR ST, ROOM 2A19

P.O. BOX 17300

FORT WORTH TX 76102-0300

W9126G 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W9126G22R0043

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

CHANGES TO SOLICITATION W9126G22R0043

CHANGES TO THE SPECIFICATIONS

1. Replacement Sections - Replace the sections noted below with the attached sections of the same number, W9126G22R0043, AMENDMENT 0003.

01 00 00.00 44 CONSTRUCTION SCHEDULE

01 35 10.00 44 SPECIAL PROJECT PROCEDURES FOR FORT HOOD

23 64 26 CHILLED, CHILLED-HOT, & CONDENSER WATER PIPING SYSTEMS

23 65 00 COOLING TOWERS & REMOVE EVAPORATIVELY-COOLED CONDENSERS

33 61 13.13 PREFABRICATED UNDERGROUND HYDDRONIC ENERGY DISTRIBUTION

2. All Sections - All references to Section 01 33 30 SUSTAINABILITY REPORTING should be redirected to Section 01 33 29 SUSTAINABILITY REPORTING.

CHANGES TO THE DRAWINGS

1. Replacement Drawing Sheets - Replace the sheets noted below with the attached sheets of the same number, W9126G22R0043, AMENDMENT 0003.

G-002 INDEX OF DRAWINGS

C-001 LEGEND AND ABBREVIATIONS

CD-103 DEMOLITION PLAN 3

CP-101 CEP SITE PAVING PLAN (BASE BID)

CP-101A CEP SITE PAVING PLAN (BASE BID + OPTION 2)

CP-101B CEP SITE PAVING PLAN (OPTION 2 & 3)

CP-102 CEP SITE PAVING JOINT ELEVATION PLAN (OPTION 2 & 3)

CS-101 CEP SITE PLAN

CU-102 UTILITY PLAN (BASE BID)

CU-102A UTILITY PLAN (BASE BID & OPTION 1)

CU-103 UTILITY PLAN 3 (BASE BID & OPTION 6)

CU-104 UTILITY PLAN 4 (BASE BID & OPTION 6)

CU-104A UTILITY PLAN 4 (BASE BID + OPTION 1 & 6)

CU-105 UTILITY PLAN (BASE BID & OPTION 6)

CU-105A UTILITY PLAN

S-101 FOUNDATION PLAN I

S-102 COOLING TOWER FOUNDATION

S-102A COOLING TOWER FOUNDTION (BID OPTION 4)

LS101 LIFE SAFETY PLAN

A-101 OVERALL FLOOR PLANS

A-201 BUILDING ELEVATIONS

A-202 BUILDING ELEVATIONS (OPTION 5)

A-601 DOOR SCHEDULE

A-641 EXTERIOR SIGNAGE PLAN

FA-101 FIRE ALARM PLAN

M-101 OVERALL MECHANICAL PLAN

MH101 OVERALL HAVAC AND SAFETY EQUIPMENT PLAN

M-503 MECHANICAL DETAILS

M-504 MECHANICAL DETAILS

M-601 MECHANICAL SCHEDULES

W9126G22R0043

EG101 LIGHTNING PROTECTION PLAN

EL101 LIGHTING PLAN

EP101 POWER PLAN

EP 601 POWER RISER DIAGRAM

ET101 TELECOMMUNICATIONS PLAN

End of Summary of Changes

Central Energy Plant FH20CEP

PROJECT TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

00 10 00 SOLICITATION, OFFER AND AWARD, SF-1442

00 11 00 CONTRACT LINE ITEM SCHEDULE

00 21 00 INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS

00 21 30 SITE VISITS

00 45 00 REPRESENTATIONS AND CERTIFICATIONS

00 72 00 CONTRACT CLAUSES

00 73 00 SPECIAL CONTRACT REQUIREMENTS

00 73 46 WAGE DETERMINATION SCHEDULE

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00.00 44 CONSTRUCTION SCHEDULE

01 01 10.00 44 SPECIAL PROJECT REQUIREMENTS

01 32 01.00 10 PROJECT SCHEDULE

01 33 00 SUBMITTAL PROCEDURES

01 33 29/30 SUSTAINABILITY REPORTING

01 35 10.00 44 SPECIAL PROJECT PROCEDURES FOR FORT HOOD

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.00 10 QUALITY CONTROL

01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE (RMS CM)

01 45 35 SPECIAL INSPECTIONS

01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS

01 56 00.00 44 DUST CONTROL

01 57 20.00 10 ENVIRONMENTAL PROTECTION

01 57 23 TEMPORARY STORM WATER POLLUTION CONTROL

01 57 24.01 44 STORM WATER POLLUTION PREVENTION PLAN (TEXAS)

01 57 25.00 44 SWPP PLAN INSPECTION AND MAINTENANCE REPORT FORM

01 58 00 PROJECT IDENTIFICATION

01 62 35 RECYCLED / RECOVERED MATERIALS

01 74 19 CONSTRUCTION WASTE MANAGEMENT AND DISPOSAL

01 78 00 CLOSEOUT SUBMITTALS

01 78 23 OPERATION AND MAINTENANCE DATA

01 91 00.15 10 TOTAL BUILDING COMMISSIONING

DIVISION 02 - EXISTING CONDITIONS

02 41 00 DEMOLITION

DIVISION 03 - CONCRETE

03 30 00 CAST-IN-PLACE CONCRETE

03 45 00 PRECAST ARCHITECTURAL CONCRETE

DIVISION 05 - METALS

05 05 23.16 STRUCTURAL WELDING

05 12 00 STRUCTURAL STEEL

05 21 00 STEEL JOIST FRAMING

05 30 00 STEEL DECKS

05 40 00 COLD-FORMED METAL FRAMING

05 50 13 MISCELLANEOUS METAL FABRICATIONS

PROJECT TABLE OF CONTENTS Page 1

03 47 13 TILT-UP CONCRETE

00 22 11 SELECTION PROCEDURES

01 30 00 ADMINISTRATIVE REQUIREMENTSE

(AM#04)> <(AM#04)

W9126G22R0043, AMENDMENT 0004

PROJECT TABLE OF CONTENTS Page 2

DIVISION 06 - WOOD, PLASTICS, AND COMPOSITES

06 10 00 ROUGH CARPENTRY

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 21 16 MINERAL FIBER BLANKET INSULATION

07 22 00 ROOF AND DECK INSULATION

07 54 23 THERMOPLASTIC POLYOLEFIN ROOFING

07 60 00 FLASHING AND SHEET METAL

07 92 00 JOINT SEALANTS

DIVISION 08 - OPENINGS

08 11 13 STEEL DOORS AND FRAMES

08 33 23 OVERHEAD COILING DOORS

08 71 00 DOOR HARDWARE

08 81 00 GLAZING

08 91 00 METAL WALL LOUVERS

DIVISION 09 - FINISHES

09 06 00 SCHEDULES FOR FINISHES

09 22 00 SUPPORTS FOR PLASTER AND GYPSUM BOARD

09 29 00 GYPSUM BOARD

09 62 38 STATIC-CONTROL FLOORING

09 90 00 PAINTS AND COATINGS

DIVISION 10 - SPECIALTIES

10 14 00.10 EXTERIOR SIGNAGE

10 14 00.20 INTERIOR SIGNAGE

10 44 16 FIRE EXTINGUISHERS

10 50 20 METAL CANOPIES

DIVISION 22 - PLUMBING

22 00 00 PLUMBING, GENERAL PURPOSE

22 15 14.00 40 GENERAL SERVICE COMPRESSED-AIR SYSTEMS, LOW PRESSURE

DIVISION 23 - HEATING, VENTILATING, AND AIR CONDITIONING (HVAC)

23 05 15 COMMON PIPING FOR HVAC

23 05 93 TESTING, ADJUSTING, AND BALANCING FOR HVAC

23 07 00 THERMAL INSULATION FOR MECHANICAL SYSTEMS

23 09 00 INSTRUMENTATION AND CONTROL FOR HVAC

23 09 13 INSTRUMENTATION AND CONTROL DEVICES FOR HVAC

23 09 23.01 LONWORKS DIRECT DIGITAL CONTROL FOR HVAC AND OTHER

BUILDING CONTROL SYSTEMS

23 11 20 FACILITY GAS PIPING

23 21 23 HYDRONIC PUMPS

23 25 00 CHEMICAL TREATMENT OF WATER FOR MECHANICAL SYSTEMS

23 30 00 HVAC AIR DISTRIBUTION

23 64 10 WATER CHILLERS, VAPOR COMPRESSION TYPE

23 64 26 CHILLED, CHILLED-HOT, AND CONDENSER WATER PIPING SYSTEMS

23 65 00 COOLING TOWERS AND REMOTE EVAPORATIVELY-COOLED CONDENSERS

23 81 00 DECENTRALIZED UNITARY HVAC EQUIPMENT

PROJECT TABLE OF CONTENTS Page 3

DIVISION 25 - INTEGRATED AUTOMATION

25 05 11 CYBERSECURITY FOR FACILITY-RELATED CONTROL SYSTEMS

25 10 10 UTILITY MONITORING AND CONTROL SYSTEM (UMCS) FRONT END

AND INTEGRATION

DIVISION 26 - ELECTRICAL

26 05 26.00 40 GROUNDING AND BONDING FOR ELECTRICAL SYSTEMS

26 08 00 APPARATUS INSPECTION AND TESTING

26 20 00 INTERIOR DISTRIBUTION SYSTEM

26 23 00 LOW-VOLTAGE SWITCHGEAR

26 27 13.10 30 ELECTRIC METERS

26 28 01.00 10 COORDINATED POWER SYSTEM PROTECTION

26 29 23 ADJUSTABLE SPEED DRIVE (ASD) SYSTEMS UNDER 600 VOLTS

26 41 00 LIGHTNING PROTECTION SYSTEM

26 42 14.00 10 CATHODIC PROTECTION SYSTEM (SACRIFICIAL ANODE)

26 51 00 INTERIOR LIGHTING

DIVISION 27 - COMMUNICATIONS

27 10 00 BUILDING TELECOMMUNICATIONS CABLING SYSTEM

DIVISION 28 - ELECTRONIC SAFETY AND SECURITY

28 31 70 INTERIOR FIRE ALARM SYSTEM, ADDRESSABLE

DIVISION 31 - EARTHWORK

31 00 00 EARTHWORK

31 31 16.13 CHEMICAL TERMITE CONTROL

31 63 26 DRILLED CAISSONS

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 11 23 AGGREGATE BASE COURSES

32 15 00 AGGREGATE SURFACING

32 16 19 CONCRETE CURBS, GUTTERS AND SIDEWALKS

32 31 13 CHAIN LINK FENCES AND GATES

32 92 23 SODDING

32 92 31.00 44 ESTABLISHMENT OF TURF

32 93 00 EXTERIOR PLANTS

DIVISION 33 - UTILITIES

33 40 00 STORM DRAINAGE UTILITIES

33 61 13.13 PREFABRICATED UNDERGROUND HYDRONIC ENERGY DISTRIBUTION

33 71 02 UNDERGROUND ELECTRICAL DISTRIBUTION

33 82 00 TELECOMMUNICATIONS OUTSIDE PLANT (OSP)

-- End of Project Table of Contents --

33 61 13.19 VALVES, PIPING & UNDERGROUND EQUIPMENT IN VALVE MANHOLESN

SECTION 01 00 00.00 44

CONSTRUCTION SCHEDULE

PART 1 GENERAL

1.1 SCHEDULE

Commence, prosecute, and complete the work under this contract in accordance with the following schedule and Section 00 73 00 SPECIAL

CONTRACT REQUIREMENTS.

Item of Work Commencement of Work

(Calendar days)

Completion of Work

(Calendar days)

Liquidated Damages per calendar days

(1) All work, including O&M Manuals and Final Record Drawings.

Upon receipt of Notice to Proceed.

720 $ 1,293.48

1.1.1 NOTES

All work on this project shall be completed within the number of calender days stated in Item of Work (1) above, inclusive of all review periods and Government phasing requirements specified. If the Government accepts a proposal for a completion period of lesser duration, and such proposal alters the time periods for review and phasing, the Contract shall be read to include the original periods for review and phasing. If a completion period of lesser duration is proposed and accepted by the Government, the accepted completion period will replace the original construction schedule listed above in the Schedule. If an alternate completion period is proposed, the Bid Schedule must reflect pricing information for the alternate proposed completion period. The liquidated damages stated above will be applied for each calendar day the Contractor exceeds the Contract scheduled duration.

1.1.2 Liquidated Damages

a. Liquidated damages are not accumulative for multiple phases of work.

SECTION 01 00 00.00 44 Page 1

b. Liquidated damages for individual items of work will not be combined. Only the affected item of work will be assessed.

1.1.3 Operation and Maintenance Manuals

See Section 01 78 00 CLOSEOUT SUBMITTALS, paragraph OPERATION AND MAINTENANCE MANUALS for requirements and for withholding amount to ensure completion of O&M Manuals.

1.1.4 Record Drawings

See Section 01 78 00 CLOSEOUT SUBMITTALS, paragraph titled RECORD DRAWINGS for requirements and for withholding amount to ensure completion of record drawings.

1.1.5 Testing of Heating and Air-Conditioning Systems

The times stated for completion of this project includes all required testing specified in appropriate specification sections of heating, air conditioning and ventilation systems including HVAC Commissioning.

Exception: boiler combustion efficiency test, boiler full load tests, cooling tower performance tests, and refrigeration equipment full load tests, when specified in the applicable specifications, shall be performed in the appropriate heating/cooling season as determined by the Contracting Officer.

1.2 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (OCT 1989)

(ER 415-1-15)(52.0001-4038 1/96)

a. This provision specifies the procedure for determination of time extensions for unusually severe weather in accordance with the contract clause FAR 52.249-10 entitled "DEFAULT: (FIXED PRICE CONSTRUCTION)."

In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor.

b. The following schedule of monthly anticipated adverse weather delays due to precipitation and temperature is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities. Wind is not considered in the Monthly Anticipated Adverse Weather Calendar Day Schedule.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

4 4 4 4 6 4 3 3 4 4 3 4

SECTION 01 00 00.00 44 Page 2

c. Upon reciept of the Notice to Proceed (NTP) and continuing throughout the contract, the contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the contractor's scheduled work day.

1.3

c. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph "b", above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the contract clause entitled "Default (Fixed Price Construction)."

WORK RESTRICTIONS

1.3.1 Working Hours

Normal working hours are Monday through Friday, 0730 to 1700 hours, unless otherwise indicated at the preconstruction conference. Requests to work at times other than the stated working hours, including scheduled utility outages discussed below, shall be submitted to the Contracting Officer for approval. Contractor shall not work outside of the above stated working hours without prior written approval of the Contracting Officer.

Notification shall be in writing by email by COB on the Wednesday prior to the weekend to be worked to the Project Engineer and Quality Assurance Representative.

1.3.2 SECURITY REQUIREMENTS

1.3.2.1 Installation Entrance Requirements

For the duration of this Contract, access to Fort Hood will be delayed between 5 minutes to 30 minutes or more due to increased security precautions, including the checking of vehicle occupants' IDs, vehicle manifests, and the searching of all vehicles. Any general or specific threat to the safety of those working or living at the Installation could result in longer waiting times at the access points to the Installation.

The following are the minimum requirements for contractor employees entering Fort Hood:

a. One form of picture ID.

b. A memo from the construction company on their letterhead stating the reason for entry, contract number, and the location at Fort Hood where the jobsite is located.

c. All delivery trucks must have a bill of lading and delivery truck drivers must have a picture ID.

SECTION 01 00 00.00 44 Page 3 d.

1.3.3 Identification of Employees

The Contractor shall be responsible for furnishing to each employee, and for requiring each employee engaged on the work to display, identification as approved and directed by the Contracting Officer. Prescribed identification shall immediately be delivered to the Contracting Officer for cancellation upon release of any employee. When required, the Contractor shall obtain and provide fingerprints of persons employed on the project. Contractor and subcontractor personnel shall wear identifying markings on hard hats clearly identifying the company for whom the employee works. Contractor personnel shall wear visible Contractor-furnished employee identification badges while physically on the Installation. Each badge shall include, as a minimum, the company name, employee name, photograph, Contract Title, Contract Number, and the expiration date of the badge.

1.4 UTILITIES5

1.4.1 Payment for Utility Services

Utility availability and Payment For Utility Services are specified in Section 01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROL.

Water, sewer, gas, electricity, and refuse service are available and will be charged to the Contractor at rates as provided in Contract Clause

52.236-14 AVAILABILITY AND USE OF UTILITY SERVICES.

Electricity and gas are privatized and are 3rd party owned by Dominion Privitization Texas LLC. Water and sewer have been privatized and are 3rd party owned (American Water Enterprises (AWE).

1.4.2 Coordination

For Contractor Telephone And Internet Service, the Contractor shall coordinate with the local phone company for contractor telephone and internet service during construction.

1.4.3 Outages

The Contractor shall coordinate all requests for utility outages with the Contracting Officer in writing 14 days prior to date of requested outage.

1.5 PAPERLESS CONTRACT SUBMISSION

a. GENERAL INFORMATION ON PAPERLESS CONTRACT SUBMISSION

The goal is to reduce waste, decrease time, decrease associated costs, and to streamline most file transmission procedures.

b. METHODS OF DIGITAL SUBMISSION

This contract shall use digital submission methods to the greatest extent practicable. Acceptable methods are as follows, in order of precedence:

1. RMS - will be used to the greatest extent practicable. Some items may not be submittable via RMS due to program constraints. Those items shall use an alternate method. All ENGR 4025’s shall be generated and submitted in RMS.

SECTION 01 00 00.00 44 Page 4

1.3.4 Sequence of Work

Construction is ongoing at the 14000 block of barracks at Fort Hood.

Access to buildings 14019, 14020, 14022, and 14033 will not be provided to the Contractor until October 2022. <(AM#04)

(AM#04)>

2. Secure, Password Protected Web-Based System Access must be allowed and approved by the Government Representative. Access must be allowed and approved by the Government Representative. This method shall not be used for security sensitive documents.

3. E-mail – Items not submitted via RMS, as discussed above, shall be submitted via e-mail, if possible. E-mail limitations for file size must be considered prior to submission.

4. CD/DVD – Will be accepted if no other method is possible and upon prior approval.

c. ITEMS TO BE SUBMITTED VIA HARDCOPY

Product samples, color boards, and any other item not feasible to submit digitally, shall be submitted hard copy. ENGR 4025 shall be submitted digitally always. The Government reserves the right to request hard copy submission on any item, if deemed necessary.

Contractor shall be prepared to provide requested hard copy at any time.

1.6 CONTRACTOR PERFORMANCE EVALUATIONS

In accordance with the provisions of Subpart 36.201 (Evaluation of Contractor Performance) of the Federal Acquisition Regulation (FAR), construction contractor’s performance shall be evaluated throughout the performance of the contract. The United States Army Corps of Engineers (USACE) follows the procedures outlined in Engineering Regulation 415-1-17 to fulfill this FAR requirement. For construction contracts awarded at or above $750,000.00, the USACE will evaluate contractor’s performance and prepare a performance report using the Contractor Performance Assessment Reporting System (CPARS), which is now a web-based system. After an evaluation (interim or final) is written up by the USACE, the contractor will have the ability to access, review and comment on the evaluation for a period of 60 days. Accessing and using CPARS requires specific software, called PKI certification, which is installed on the user’s computer. The certification is a Department of Defense requirement and was implemented to provide security in electronic transactions. The certification software could cost approximately $110 - $125 per certificate per year and is purchased from an External Certificate Authorities (ECA) vendor. Current information about the PKI certification process and for contacting vendors can be found on the web site: http://www.cpars.csd.disa.mil/ If the Contractor wishes to participate in the performance evaluation process, access to CPARS and PKI certification is the sole responsibility of the Contractor.

1.7 CONTRACTOR PAYROLL RECORD

Contractor shall be required to log payrolls for all their own employees and subcontractors utilizing ENG Form 3180. Each subcontractor requires a separate ENG 3180 for their payrolls. The Contractor shall maintain the ENG 3180, along with the payrolls, on site and available for review by the Contracting Officer's Representative. The ENG 3180's shall be updated weekly as payrolls are submitted. After making copies for their files, the Contractor is required to submit the originals of each week’s payrolls to the Resident Office. Before final payment, the Contractor shall provide the completed ENG 3180’s to the Contracting Officer's Representatives.

SECTION 01 00 00.00 44 Page 5

1.8 CONTRACTOR SUPPLY and USE OF ELECTRONIC SOFTWARE FOR PROCESSING WAGE

RATE REQUIREMENTS CERTIFIED LABOR PAYROLLS

a. The contractor is required to use a commercially-available electronic system to process and submit certified payrolls electronically to the Government. The requirements for preparing, processing and providing certified labor payrolls are established by the Wage Rate Requirements statute.

b. The contractor shall be responsible for obtaining and providing for all access, licenses, and other services required to provide for receipt, processing, certifying, electronically transmitting to the Government, and storing weekly payrolls and other data required for the contractor to comply with the Wage Rate Requirements statute. When the contractor uses an electronic payroll system, the electronic payroll service shall be used by the contractor to prepare, process, and maintain the relevant payrolls and basic records during all work under this construction contract and the electronic payroll service shall be capable of preserving these payrolls and related basic records for the required 3 years after contract completion. The contractor shall obtain and provide electronic system access to the Government, as required to comply with the Wage Rate Requirements over the duration of this construction contract. The access shall include electronic review access by the Government contract administration office to the electronic payroll processing system used by the contractor.

c The contractor's provision and use of an electronic payroll processing system shall meet the following basic functional criteria:

(1) commercially available;

(2) compliant with appropriate Wage Rate Requirements statute payroll provisions in the Federal Acquisition Regulation (FAR);

(3) able to accommodate the required numbers of employees and subcontractors planned to be employed under the contract

(4) capable of producing an Excel spreadsheet-compatible electronic output of weekly payroll records for export in an Excel spreadsheet

(5) demonstrated security of data and data entry rights;

(6) ability to produce contractor-certified electronic versions of weekly payroll data;

(7) ability to identify erroneous entries and track the date/time of all versions of the certified Wage Rate Requirements statute payrolls submitted to the government over the life of the contract;

(8) capable of generating a durable record copy, that is, a CD or DVD and PDF file record of data from the system database at end of the contract closeout. This durable record copy of data from the electronic payroll processing system shall be provided to the Government during contract closeout.

d. All contractor-incurred costs related to the contractor's provision and use of an electronic payroll processing service shall be included in the contractor's price for the overall work under the contract. The

SECTION 01 00 00.00 44 Page 6 costs for compliance with the Wage Rate Requirements statute by using electronic payroll processing services shall not be a separately bid or reimbursed item under this contract.

1.9 ADDITIONAL CONTRACTOR PAYROLL RECORD

The Fort Worth District requires the contractor and all sub-contractors to use an electronic payroll system meeting the requirements the above referenced requirements and the following.

a. The Certified Labor Payrolls must be tracked electronically via WEB-based software and all data must be submitted via WEB. Payroll guidelines,"Instructions to Contractors on Contract Labor Requirements, published as "Appendix A, SWFP 1185-1-1" (also known as the Green book), will be provided to advise/inform contractors how these labor provisions will be administered and enforced.

b. The WEB-based software must be capable of downloading data directly from existing electronic payrolls, track workers to ensure that overtime is being paid when overtime status is reached on Government contracts whether on one or multiple contracts or different sub-contractors. The software must track apprentices and journeyman ratios, create and track SF-1444 "Request for Authorization of Additional Classification and Rate", track workers by name/address/with or without Social Security Numbers, allow automated redaction of information appearing on payroll statements for agency response to Freedom of Information Act (FOIA requests), and provide free online training by the software provider to any user of the software.

c. The software must allow fringe benefit statement to track fringe benefits "whether cash or into an approved plan, fund, or program. If the fringe benefits are paid into a plan, fund, or program the company's name (receiving benefits), phone number, and address shall be listed on the Statement of Compliance Form (DD Form 879 or WH-347).

d. Software must provide a method of tracking standard and non-standard deductions such as restitution, alimony, child support, and allow for custom entries. Method of tracking must list the deductions on the statement of compliance or be listed as an attachment.

e. The Contractor is required to provide the updated 3180's and notify the Contracting Officer's Representatives weekly by email when the current payrolls are complete and ready for inspection/review on the WEB.

Before final payment, the Contractor shall provide the completed ENG For 3180's and 3 disks (CD/DVD) which include complete copies of the Contractor and sub-contractor's payrolls/attachments, to the Contracting Officer's Representatives.

f. Electronic copies of electronically/manually signed forms/memos/letters such as SF 1413 Statement of Acknowledgement (sub-contractor agreement), SF-1444 "Request for Authorization of Additional Classification and Rate", employee deduction authorization, certification of apprentices and trainees shall be provided to the Contracting Officer's Representative as required by FAR.

1.10 STREET CLOSINGS

The Contractor shall coordinate all requests for street closings with the Contracting Officer in writing 14 days prior to date of requested outage:

SECTION 01 00 00.00 44 Page 7

a. One lane traffic shall be maintained at all times (except that a total closing may be allowed for specific 8-hour periods).

b. The final street repair shall be completed within 14 days after the start of any street crossing. Any part of the street returned to service prior to final repair shall be maintained smooth with hot-mix cold-lay surface course.

c. Open cuts across paved roads and streets for utility crossings will not be allowed. Utility crossings will be accomplished by boring or jacking procedures only.

PART 2 PRODUCTS (NOT USED).1

PART 3 EXECUTION (NOT USED)

-- End of Section --

SECTION 01 00 00.00 44 Page 8

(AM#04)> SECTION 01 33 29/01 33 30 <(AM#04)

SUSTAINABILITY REPORTING

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

AMERICAN SOCIETY OF HEATING, REFRIGERATING AND AIR-CONDITIONING

ENGINEERS (ASHRAE)

ASHRAE 189.1 (2014) Standard for the Design of High-Performance Green Buildings Except Low-Rise Residential Buildings

COUNCIL ON ENVIRONMENTAL QUALITY (CEQ) (WHITE HOUSE)

HPSB Guiding Principles (2016) Guiding Principles for Sustainable Federal Buildings and Determining Compliance with the Guiding Principles for Sustainable Federal Buildings

U.S. DEPARTMENT OF AGRICULTURE (USDA)

FSRIA 9002 Farm Security and Rural Investment Act Section 9002 (USDA Biopreferred Program)

U.S. DEPARTMENT OF ENERGY (DOE)

Energy Star (1992; R 2006) Energy Star Energy Efficiency Labeling System (FEMP)

U.S. NATIONAL ARCHIVES AND RECORDS ADMINISTRATION (NARA)

40 CFR 247 Comprehensive Procurement Guideline for Products Containing Recovered Materials

1.2 SUMMARY

This specification includes general requirements and procedures for this project to be constructed and documented per the federally mandated High Performance and Sustainable Building or HPSB Guiding Principles (GP), Third Party Certification (TPC) requirements, UFC 1-200-02 High Performance and Sustainable Building Requirements, and other requirements identified in this specification.(AM#04)> All references to Section 01 33 29 and Section 01 33 30 should be redirected to Section 01 33 29/30 SUSTAINABILITY

REPORTING.<(AM#04)

1.3 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submittals with an "S" are for inclusion in the Sustainability eNotebook, in conformance to this

(AM#04)> SECTION 01 33 29/01 33 30 <(AM#04) Page 1 section. Submit the following in accordance with Section 01 33 00

SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Preliminary High Performance and Sustainable Building Checklist; G

Sustainability Action Plan; G

Preliminary Sustainability eNotebook; G

SD-11 Closeout Submittals

Final High Performance and Sustainable Building Checklist; G

Final Sustainability eNotebook; G

Amended Final Sustainability eNotebook; G

Amended Final High Performance & Sustainable Building Checklist; G

1.4 GUIDING PRINCIPLES VALIDATION (GPV)

Provide construction related sustainability documentation to verify achievement of HPSB Guiding Principles Validation (GPV). Provide the following for GPV:

a. Refer to HPSB Checklist at the end of this specification section.

These requirements are based on legislative mandates that must be met by all projects. (Multiple checklists indicate multiple buildings that require HPSB tracking.)

b. No variations to the HPSB Checklist are allowed without written consent from the Contracting Officer. Immediately bring to the attention of the Contracting Officer any changes that impact meeting the approved HPSB Guiding Principles Requirements for this project.

c. All work, including "S" submittals, required to incorporate the applicable HPSB Guiding Principles Requirements indicated on the HPSB Checklist and in this contract.

d. Sustainability Action Plan

e. Construction related documentation for the project Sustainability eNotebook, and keep updated with regularly-scheduled construction meetings. Include construction related documentation containing the following components;

(1) HPSB Checklist

(2) Sustainability Action Plan

(3) Documentation illustrating HPSB Guiding Principles Requirements compliance (including "S" submittals)

1.4.1 Sustainability Action Plan

Include the following information in the Sustainability Action Plan:

(AM#04)> SECTION 01 33 29/01 33 30 <(AM#04) Page 2

a. Planned method to achieve each construction related GP requirement.

b. For each designated construction related HPSB Guiding Principles Requirements that is applicable, as defined in UFC 1-200-02, provide justification narrative explaining what precludes achieving specific sustainability requirement or goal. Provide analysis of particular requirement and level to which project is able to comply. Final government-approved narrative(s) must be included with the HPSB Checklist submittal.

c. Name and contact information for: Point of Contact (POC) responsible for ensuring sustainability goals are accomplished and documentation is assembled. For TPC that include on-site visit by third party representative, provide list of required attendees.

d. Include the Indoor Air Quality plan with the Sustainability Action Plan.

1.4.2 Costs

Bear all costs associated with constructing, demonstrating, and documenting that project complies with approved HPSB Guiding Principles Requirements.

1.4.3 Calculations

Provide calculations, product data, labels and product certifications, required in this section to demonstrate compliance with the HPSB Guiding Principles Requirements.

1.5 SUSTAINABILITY SUBMITTALS

Provide HPSB Checklist and other documentation in the Sustainability eNotebook to indicate compliance with the sustainability requirements of the project.

1.5.1 High Performance Sustainable Building (HPSB) Checklist

Provide construction documentation that provides proof of and supports compliance with the completed HPSB Checklist.

1.5.1.1 HPSB Checklist Submittals

Submit updated HPSB Checklist with each Sustainability eNotebook submittal. Attach final HPSB Checklist(s) to draft final DD1354 Real Property Record Submittal.

1.5.2 "S" Submittals for Sustainability Documentation

Submit the GPV sustainability documentation required in this specification as "S" submittals in all affected UFGS Sections.

a. Highlight GPV compliance data in "S" submittal.

b. Add "S" submittals to the Sustainability eNotebook only after submittal approval, and bookmark them as required in paragraph SUSTAINABILITY eNOTEBOOK below.

c. Ensure all approved "S" submittals (the sustainability documentation requirements) are included in each Sustainability eNotebook submittal.

(AM#04)> SECTION 01 33 29/01 33 30 <(AM#04) Page 3

1.5.3 Sustainability eNotebook

The Sustainability eNotebook is an electronic organizational file that serves as a repository for all required sustainability submittals. To support documentation of compliance with an approved HPSB checklist, provide and maintain a comprehensive and current Sustainability eNotebook Sustainability eNotebook must contain all required data to support full compliance with the HPSB Guiding Principles Requirements, including:

a. HPSB checklist

b. Sustainable Action Plan

c. Calculations

d. Labels

e. "S" submittals (sustainability documentation requirements)

Provide sustainability eNotebook in the form of an Adobe PDF file; bookmark each HPSB Guiding Principles Requirement and sub-bookmark at each document. Match format to HPSB Guiding Principles numbering system indicated herein. Maintain up-to-date information, spreadsheets, templates, and other required documentation with each current submittal.

Contracting Officer may deduct from the monthly progress payment accordingly if Sustainability eNotebook information is not current, until information is updated and on track per project goals.

1.5.3.1 Sustainability eNotebook Submittal Schedule

Provide Sustainability eNotebook Submittals at the following milestones of the project:

a. Preliminary Sustainability eNotebook

Submit preliminary Sustainability eNotebook for approval at the Pre-construction conference. Include Preliminary High Performance and Sustainable Building Checklist.

b. Construction Progress Meetings. Provide up-to-date GP documentation in the Sustainability eNotebook for each meeting.

c. Final Sustainability eNotebook

Provide up-to-date Sustainability eNotebook at the Beneficial Occupancy Date (BOD). Final progress payment retainage may be held by Contracting Officer until final sustainability documentation is complete. Submit three electronic copies of the Final Sustainability eNotebook on DVDs to the Government. Include Final High Performance and Sustainable Building Checklist.

d. Amended Final Sustainability eNotebook

Amend and resubmit the Final Sustainability eNotebook to include post-occupancy corrections, updates, and requirements. Include Amended Final High Performance and Sustainable Building Checklist. Final progress payment retainage may be held by Contracting Officer until

(AM#04)> SECTION 01 33 29/01 33 30 <(AM#04) Page 4 amended final sustainability documentation is complete. Submit 3 final electronic copies of the Amended Final Sustainability eNotebook Submittal on DVDs to the Government no longer than 30 days after the GP designated data collection period.

1.6 DOCUMENTATION REQUIREMENTS

a. Incorporate each of the following HPSB Guiding Principles Requirements into project construction; and provide documentation that proves compliance with each listed requirement. Items below are organized according to the HPSB Guiding Principles. For life-cycle cost analysis requirements, one document with all analyses is acceptable, with Contracting Officer approval.

b. For each of the following paragraphs that require the use of products listed on Government-required websites, provide documentation of the process used to select products, or process used to determine why listed products do not meet project performance requirements.

1.6.1 Commissioning

Submit approved Final Commissioning Report required by Section 01 91 00.15 TOTAL BUILDING COMMISSIONING as proof of this tracking requirement.

1.6.2 Energy Efficient Products

Provide only energy-using products that are Energy Star rated, or have the Federal Energy Management Program (FEMP) recommended efficiency. Where Energy Star or FEMP recommendations have not been established, provide most efficient products that are life-cycle cost effective. Provide only energy using products that meet FEMP requirements for low standby power consumption. Energy efficient products can be found at:

https://energy.gov/eere/femp/federal-energy-management-program and https://www.energystar.gov/

Provide the following documentation:

Proof that products are labeled energy efficient and comply with the cited requirements.

1.6.3 Indoor Water Use

Provide only water-consuming products that are EPA WaterSense labeled, or the most efficient water fixtures available that meet the requirements of ASHRAE 189.1 Section 6.3.2, when EPA WaterSense products are not available.

Provide the following documentation:

For products available with EPA WaterSense labeling, proof that fixtures are labeled EPA WaterSense or Energy Star; for all other fixtures, proof they comply with the cited efficiency requirements.

1.6.4 Reduce Volatile Organic Compounds (VOC) (Low Emitting Materials)

Meet the requirements of Table 3-1 at the end of this specification.

Provide the following documentation:

Provide certifications or labels that demonstrate compliance with cited requirements.

(AM#04)> SECTION 01 33 29/01 33 30 <(AM#04) Page 5

1.6.5 Indoor Air Quality During Construction

Prior to construction, create indoor air quality (IAQ) plan. Develop and implement the IAQ construction management plan during construction and flush building air before occupancy.

For new construction and for renovation of unoccupied existing buildings, indoor air quality plan must meet the requirements of ASHRAE 189.1 Section

10.3.1.4. (Indoor Air Quality (IAQ) Construction Management), with maximum outdoor air consistent with achieving relative humidity no greater than 60 percent.

Provide documentation showing that after construction ends and prior to occupancy, HVAC filters were replaced and building air was flushed out in accordance with the cited standard.

1.6.6 Recycled Content

Comply with 40 CFR 247. Refer to https://www.epa.gov/smm/comprehensive-procurement-guideline-cpg-program for assistance identifying products cited in 40 CFR 247. Selected products must comply with non-proprietary requirements of the Federal Acquisition Regulation, and must meet performance requirements. Provide the following documentation:

a. Manufacturers’ documents stating the recycled content by material, or written justification for claiming one of the exceptions allowed on the cited website.

b. Substitutions: Submit for Government approval, proposed alternative products or systems that provide equivalent performance and appearance and have greater contribution to project recycled content requirements. For all such proposed substitutions, submit with the Sustainability Action Plan accompanied by product data demonstrating equivalence.

c. In order to complete compliance with FAR 52.223-9 Estimate of Percentage of Recovered Material Content for EPA Designated Items, refer to submittal requirement for recycled/recovered material content in Section 01 78 00.

1.6.7 Bio-Based Products

Provide products and material composed of the highest percentage of biobased materials (including rapidly renewable resources and certified sustainably harvested products), consistent with FSRIA 9002 USDA BioPreferred Program, to the maximum extent possible without jeopardizing the intended end use or detracting from the overall quality delivered to the end user. Use only supplies and materials of a type and quality that conform to applicable specifications and standards.

Comply with FSRIA 9002 USDA BioPreferred Program. Refer to https://www.biopreferred.gov/BioPreferred/ for the product categories and BioPreferred Catalog. Selected products must comply with non-proprietary requirements of the Federal Acquisition Regulation, and must meet performance requirements. Provide the following documentation:

a. USDA BioPreferred label for each product; for bio-based products used

(AM#04)> SECTION 01 33 29/01 33 30 <(AM#04) Page 6 on project but not listed with BioPreferred program, provide bio-based content and percentage.

b. In order to complete compliance with FAR 52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts, refer to submittal requirement for biobased products in Section 01 78 00.

1.6.8 Waste Material Management (Recycling – Construction)

Divert construction debris from landfill disposal where markets or on-site recycling exists, and provide documentation in accordance with Section

01 74 19 CONSTRUCTION WASTE MANAGEMENT AND DISPOSAL.

1.6.9 Additional Sustainability Requirements

1.6.9.1 Validation and Certification Restrictions

Purchase of renewable energy certificates (RECs) specifically to meet project sustainability goals is prohibited.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

3.1 SUSTAINABILITY COORDINATION

3.1.1 Coordinating Sustainability Documentation Progress

Provide sustainability focus and coordination at the following meetings to achieve sustainability goals. The designated sustainability professional responsible for GP documentation must participate in the following meetings to coordinate documentation completion.

a. Pre-Construction Conference: Discuss the following: HPSB Checklist, Sustainability Action Plan, Construction submittal requirements and schedule, individuals responsible for achieving each Guiding Principle Requirement.

b. Construction Progress Meetings: Review GP sustainability requirements with project team including contractor and sub-contractor representatives. Demonstrate GP documentation is being collected and updated to the Sustainability eNotebook.

(1) For TPC that include on-site visit by third party representative, execute, coordinate, and facilitate the visit.

(2) Facility Turnover Meetings: Review Sustainability eNotebook for completeness and identify any outstanding issues relating to final documentation requirements.

(3) Final Sustainability eNotebook Review

(AM#04)> SECTION 01 33 29/01 33 30 <(AM#04) Page 7

3.2 TABLE 3-1 VOLATILE ORGANIC COMPOUNDS (VOC) (LOW EMITTING MATERIALS)

REQUIREMENTS

TABLE 3-1 Volatile Organic Compounds (VOC) (Low Emitting Materials) Requirements

Source: ASHRAE 189.1 section 8.4.2 (Materials)(Interior Applications Only)

MATERIAL

CATEGORY

EMISSIONS

REQUIREMENT

MATERIALS WITH

ADDED VOC

REQUIREMENT

MATERIAL

CATEGORY

Adhesives and Sealants

CDPH/EHLB/Standard method V1.1 (California Section 01350) (Use "office" or "classroom" space limits for all applications) or Adhesives (carpet, resilient, wood flooring;

panel; primers) Sealants (acoustical;

firestop; HVAC Air duct;

primers) Caulks

SCAQMD Rule 1168 (Use "other" category for HVAC duct sealant) (for firestop adhesive, UFC 3-600-01 overrides conflicting requirements)

Aerosol adhesives

Section 3 of Green Seal Standard GS-36 (except:

cleaners, solvent cements, and primers used with plastic piping and conduit in plumbing, fire suppression, and electrical systems; HVAC air duct sealants when the application space air temp is less than 40 F (4.5 C).

Paints and Coatings

CDPH/EHLB/Standard method V1.1 (California Section 01350) (Use "office" or "classroom" space limits for all applications) or Flat and nonflat topcoats, primers, undercoaters, and anti-corrosive coatings

Green Seal Standard GS-11

(AM#04)> SECTION 01 33 29/01 33 30 <(AM#04) Page 8

TABLE 3-1 Volatile Organic Compounds (VOC) (Low Emitting Materials) Requirements

Source: ASHRAE 189.1 section 8.4.2 (Materials)(Interior Applications Only)

MATERIAL

CATEGORY

EMISSIONS

REQUIREMENT

MATERIALS WITH

ADDED VOC

REQUIREMENT

MATERIAL

CATEGORY

Paints and Coatings

CDPH/EHLB/Standard method V1.1 (California Section 01350) (Use "office" or "classroom" space limits for all applications) or Concrete/masonry sealers (waterproofing concrete/masonry sealers), concrete curing compounds, dry fog coatings, faux finishing coatings, fire resistive coatings, floor coatings, graphic arts (sign) coatings, industrial maintenance coatings, mastic texture coatings, metallic pigmented coatings, multicolor coatings, pretreatment wash primers, reactive penetrating sealers, recycled coatings, shellacs (clear and opaque), specialty primers, stains, wood coatings (clear wood finishes), wood preservatives, and zinc primers

California Air Resources Board

(CARB)

Suggested Control Measure for Architectural Coatings or SCAQMD Rule 1113

(AM#04)> SECTION 01 33 29/01 33 30 <(AM#04) Page 9

Requirements

Source: ASHRAE 189.1 section 8.4.2 (Materials)(Interior Applications Only)

MATERIAL

CATEGORY

EMISSIONS

REQUIREMENT

MATERIALS WITH

ADDED VOC

REQUIREMENT

MATERIAL

CATEGORY

Paints and Coatings

CDPH/EHLB/Standard method V1.1 (California Section 01350) (Use "office" or "classroom" space limits for all applications) or Basement specialty coatings, high-temperature coatings, low solids coatings, stone consolidants, swimming-pool coatings, tub-and tile-refining coatings, and waterproofing membranes

California Air Resources Board

(CARB)

Suggested Control Measure for Architectural Coatings

Floor Covering Materials

For carpet, all locations:

CDPH/EHLB/Standard Method V1.1 (California Section 01350) or label for Section 9 of CDPH/EHLB/Standard Method V1.1 (California Section 01350) none none

(AM#04)> SECTION 01 33 29/01 33 30 <(AM#04) Page 10

Requirements

Source: ASHRAE 189.1 section 8.4.2 (Materials)(Interior Applications Only)

MATERIAL

CATEGORY

EMISSIONS

REQUIREMENT

MATERIALS WITH

ADDED VOC

REQUIREMENT

MATERIAL

CATEGORY

Composite Wood, Wood Structural Panel, and Agrifiber Products particleboard medium density fiberboard (MDF) wheatboard strawboard panel substrates door cores no added urea-formaldehyde resins including laminating adhesives for composite wood and agrifiber assemblies

Third-party certification (approved by CARB) of California Air Resource Board's (CARB) regulation Airborne Toxic Control Measure to Reduce Formaldehyde Emissions from Composite Wood Products none none

CDPH/EHLB/Standard method V1.1 (California Section 01350) (Use "office" or "classroom" space limits for all applications) (except:

Structural panel components such as plywood, particle board, wafer board, and oriented strand board identified as "EXPOSURE 1," "EXTERIOR," or

"HUD-APPROVED"

are considered acceptable for interior use.)

(AM#04)> SECTION 01 33 29/01 33 30 <(AM#04) Page 11

Requirements

Source: ASHRAE 189.1 section 8.4.2 (Materials)(Interior Applications Only)

MATERIAL

CATEGORY

EMISSIONS

REQUIREMENT

MATERIALS WITH

ADDED VOC

REQUIREMENT

MATERIAL

CATEGORY

Office Furniture Systems and Seating installed prior to occupancy

ANSI/BIFMA X7.1

ANSI/BIFMA X7.1:

(95 percent of…