G2.20_W9126G19B0029.pdf

Design-Bid-Build Invitation for Bid

69th Supply Support Activity (SSA) Warehouse Fort Hood, Texas

W9126G19B0029 August, 2019 Total Small Business Set Aside

US Army Corps of Engineers Fort Worth District

This page was intentionally left blank

69th SSA Complex FH69SSA

PROJECT TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

00 11 00.01 SOLICITATION, OFFER AND AWARD, SF-1442

00 11 00.02 CONTRACT LINE ITEM SCHEDULE

00 21 00 INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS

00 45 00 REPRESENTATIONS AND CERTIFICATIONS

00 72 00 CONTRACT CLAUSES

00 73 00 SPECIAL CONTRACT REQUIREMENTS

00 73 46 WAGE DETERMINATION SCHEDULE

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00.00 44 CONSTRUCTION SCHEDULE

01 01 10.00 44 SPECIAL PROJECT REQUIREMENTS

01 30 10.00 44 PARTNERING

01 31 19.00 44 PROJECT MEETINGS

01 32 01.00 10 PROJECT SCHEDULE

01 33 00 SUBMITTAL PROCEDURES

01 33 29 SUSTAINABILITY REPORTING

01 35 10.00 44 SPECIAL PROJECT PROCEDURES FOR FORT HOOD

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.00 10 QUALITY CONTROL

01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE(RMS CM)

01 45 35 SPECIAL INSPECTIONS

01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS

01 56 00.00 44 DUST CONTROL

01 56 39 TREE PROTECTION, REMOVAL AND PRUNING

01 57 20.00 10 ENVIRONMENTAL PROTECTION

01 57 23 TEMPORARY STORM WATER POLLUTION CONTROL

01 57 24.01 44 STORM WATER POLLUTION PREVENTION PLAN (TEXAS)

01 57 25.00 44 SWPP PLAN INSPECTION AND MAINTENANCE REPORT FORM

01 58 00 PROJECT IDENTIFICATION

01 62 35 RECYCLED / RECOVERED MATERIALS

01 71 23.00 44 SURVEY, LAYOUT, AND OTHER DATA

01 74 19 CONSTRUCTION WASTE MANAGEMENT AND DISPOSAL

01 78 00 CLOSEOUT SUBMITTALS

01 78 23 OPERATION AND MAINTENANCE DATA

01 91 00.15 TOTAL BUILDING COMMISSIONING

DIVISION 02 - EXISTING CONDITIONS

02 41 00 DEMOLITION

DIVISION 03 - CONCRETE

03 11 13.00 10 STRUCTURAL CAST-IN-PLACE CONCRETE FORMING

03 15 00.00 10 CONCRETE ACCESSORIES

03 20 00.00 10 CONCRETE REINFORCING

03 30 00.00 10 CAST-IN-PLACE CONCRETE

03 35 00.00 10 CONCRETE FINISHING

03 39 00.00 10 CONCRETE CURING

03 45 00 PRECAST ARCHITECTURAL CONCRETE

DIVISION 04 - MASONRY

04 20 00 UNIT MASONRY

PROJECT TABLE OF CONTENTS Page 1

DIVISION 05 - METALS

05 05 23.16 STRUCTURAL WELDING

05 30 00 STEEL DECKS

05 40 00 COLD-FORMED METAL FRAMING

05 50 13 MISCELLANEOUS METAL FABRICATIONS

05 51 33 METAL LADDERS

05 52 00 METAL RAILINGS

DIVISION 06 - WOOD, PLASTICS, AND COMPOSITES

06 10 00 ROUGH CARPENTRY

06 61 16 SOLID SURFACING FABRICATIONS

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 05 23 PRESSURE TESTING AN AIR BARRIER SYSTEM FOR AIR TIGHTNESS

07 21 13 BOARD AND BLOCK INSULATION

07 21 16 MINERAL FIBER BLANKET INSULATION

07 22 00 ROOF AND DECK INSULATION

07 27 10.00 10 BUILDING AIR BARRIER SYSTEM

07 27 19.01 SELF-ADHERING AIR BARRIERS

07 27 36 SPRAY FOAM AIR BARRIERS

07 42 63 FABRICATED WALL PANEL ASSEMBLIES

07 60 00 FLASHING AND SHEET METAL

07 61 14.00 20 STEEL STANDING SEAM ROOFING

07 61 16.00 20 HORIZONTAL FALL PROTECTION

07 84 00 FIRESTOPPING

07 92 00 JOINT SEALANTS

DIVISION 08 - OPENINGS

08 11 13 STEEL DOORS AND FRAMES

08 11 16 ALUMINUM DOORS AND FRAMES

08 33 23 OVERHEAD COILING DOORS

08 36 13 SECTIONAL OVERHEAD DOORS

08 51 13 ALUMINUM WINDOWS

08 60 45 TRANSLUCENT PANELS

08 71 00 DOOR HARDWARE

08 81 00 GLAZING

08 91 00 METAL WALL LOUVERS

DIVISION 09 - FINISHES

09 06 00 SCHEDULES FOR FINISHES

09 22 00 SUPPORTS FOR PLASTER AND GYPSUM BOARD

09 29 00 GYPSUM BOARD

09 30 10 CERAMIC, QUARRY, AND GLASS TILING

09 51 00 ACOUSTICAL CEILINGS

09 65 00 RESILIENT FLOORING

09 90 00 PAINTS AND COATINGS

09 96 00 HIGH-PERFORMANCE COATINGS

DIVISION 10 - SPECIALTIES

10 10 00 VISUAL COMMUNICATIONS SPECIALTIES

10 14 00.10 EXTERIOR SIGNAGE

10 14 00.20 INTERIOR SIGNAGE

PROJECT TABLE OF CONTENTS Page 2

10 21 13 TOILET COMPARTMENTS

10 22 13 WIRE MESH PARTITIONS

10 26 00 WALL AND DOOR PROTECTION

10 28 13 TOILET ACCESSORIES

10 44 16 FIRE EXTINGUISHERS

10 71 13 EXTERIOR SUN CONTROL DEVICE

DIVISION 11 - EQUIPMENT

11 13 19.13 LOADING DOCK LEVELERS

DIVISION 12 - FURNISHINGS

12 21 00 WINDOW BLINDS

12 48 13 ENTRANCE FLOOR MATS AND FRAMES

DIVISION 13 - SPECIAL CONSTRUCTION

13 09 00.00 44 ANTI-TERRORISM/FORCE PROTECTION MEASURES

13 34 19 METAL BUILDING SYSTEMS

DIVISION 21 - FIRE SUPPRESSION

21 13 13.00 10 WET PIPE SPRINKLER SYSTEM, FIRE PROTECTION

DIVISION 22 - PLUMBING

22 00 00 PLUMBING, GENERAL PURPOSE

DIVISION 23 - HEATING, VENTILATING, AND AIR CONDITIONING (HVAC)

23 00 00 AIR SUPPLY, DISTRIBUTION, VENTILATION, AND EXHAUST SYSTEMS

23 05 93 TESTING, ADJUSTING, AND BALANCING FOR HVAC

23 07 00 THERMAL INSULATION FOR MECHANICAL SYSTEMS

23 09 00 INSTRUMENTATION AND CONTROL FOR HVAC

23 09 13 INSTRUMENTATION AND CONTROL DEVICES FOR HVAC

23 09 23.01 LONWORKS DIRECT DIGITAL CONTROL FOR HVAC AND OTHER

BUILDING CONTROL SYSTEMS

23 11 25 FACILITY GAS PIPING

23 54 16.00 10 HEATING SYSTEM; GAS-FIRED HEATERS

23 82 02.00 10 UNITARY HEATING AND COOLING EQUIPMENT

DIVISION 26 - ELECTRICAL

26 00 00.00 20 BASIC ELECTRICAL MATERIALS AND METHODS

26 20 00 INTERIOR DISTRIBUTION SYSTEM

26 29 23 VARIABLE FREQUENCY DRIVE SYSTEMS UNDER 600 VOLTS

26 41 00 LIGHTNING PROTECTION SYSTEM

26 51 00 INTERIOR LIGHTING

DIVISION 27 - COMMUNICATIONS

27 10 00 BUILDING TELECOMMUNICATIONS CABLING SYSTEM

DIVISION 28 - ELECTRONIC SAFETY AND SECURITY

28 31 49 CARBON MONOXIDE DETECTORS

28 31 76 INTERIOR FIRE ALARM AND MASS NOTIFICATION SYSTEM

PROJECT TABLE OF CONTENTS Page 3

DIVISION 31 - EARTHWORK

31 00 00 EARTHWORK

31 11 00 CLEARING AND GRUBBING

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 01 19 FIELD MOLDED SEALANTS FOR SEALING JOINTS IN RIGID

PAVEMENTS

32 11 23 AGGREGATE BASE COURSE

32 11 29 LIME-STABILIZED SUBGRADE

32 12 10 BITUMINOUS TACK AND PRIME COATS

32 12 16 HOT-MIX ASPHALT (HMA) FOR ROADS

32 13 13.06 PORTLAND CEMENT CONCRETE PAVEMENT FOR ROADS AND SITE

FACILITIES

32 16 13 CONCRETE SIDEWALKS AND CURBS AND GUTTERS

32 17 24.00 10 PAVEMENT MARKINGS

32 31 19 DECORATIVE METAL FENCES AND GATES

32 92 26 SPRIGGING AND SODDING

32 92 31.00 44 ESTABLISHMENT OF TURF

32 93 31.00 44 PLANTING OF TREES, SHRUBS, AND VINES

DIVISION 33 - UTILITIES

33 11 23 NATURAL GAS PIPING

33 71 02 UNDERGROUND ELECTRICAL DISTRIBUTION

33 82 00 TELECOMMUNICATIONS OUTSIDE PLANT (OSP)

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 4

(RFP)

(Include area code) (NO COLLECT CALLS)

(See _________________________

(If "YES," indicate within how many calendar days after award in Item 12B.)

(date).

(Construction, Alteration, or Repair)

(Title, identifying no., date):

(hour)

(If Other Than Item 7)

(Construction, Alteration, or Repair) the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

(Type or print)

(To be completed by Government)

(4 copies unless otherwise specified)

(Insert any number equal to or greater than

(Include ZIP Code) (Include area code)

(Include only if different than Item 14)

(Contractor is not required to sign this document.)

document and return _______ copies to issuing office.)

31A. NAME OF CONTRACTING OFFICER (Type or print)

(Type or print)

TEL: EMAIL:

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this

(M ust be fully completed by offeror)

IMPORTANT NOTES

General Decision Number: TX190230 01/04/2019 TX230 Superseded General Decision Number: TX20180279 State: Texas Construction Type: Building County: Bell County in Texas.

BUILDING CONSTRUCTION PROJECTS (does not include single family homes or apartments up to and including 4 stories).

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.60 for calendar year 2019 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015.

If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.60 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2019. If this contract is covered by the EO and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must pay workers in that classification at least the wage rate determined through the conformance process set forth in 29 CFR 5.5(a)(1)(ii) (or the EO minimum wage rate, if it is higher than the conformed wage rate). The EO minimum wage rate will be adjusted annually. Please note that this EO applies to the above-mentioned types of contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but it does not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60). Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date

0 01/04/2019

BOIL0074-003 01/01/2017

Rates Fringes

BOILERMAKER......................$ 28.00 22.35

ENGI0178-005 06/01/2014

Rates Fringes

POWER EQUIPMENT OPERATOR

(1) Tower Crane.............$ 29.00 10.60

(2) Cranes with Pile Driving or Caisson Attachment and Hydraulic Crane 60 tons and above.....$ 28.75 10.60

(3) Hydraulic cranes 59 Tons and under..............$ 27.50 10.60

* IRON0084-011 06/01/2018

Rates Fringes

IRONWORKER, ORNAMENTAL...........$ 23.77 7.12

PLUM0286-011 06/04/2018

Rates Fringes

PIPEFITTER (Excludes HVAC Pipe Installation)...............$ 29.50 12.82

SUTX2014-005 07/21/2014

Rates Fringes

BRICKLAYER.......................$ 19.09 0.00

CARPENTER, Excludes Drywall Hanging, and Metal Stud Installation.....................$ 17.28 1.71

CEMENT MASON/CONCRETE FINISHER...$ 14.00 0.00

DRYWALL HANGER AND METAL STUD

INSTALLER........................$ 14.59 0.00

ELECTRICIAN (Low Voltage Wiring Only).....................$ 28.28 2.44

ELECTRICIAN, Excludes Low Voltage Wiring...................$ 20.50 2.71

HVAC MECHANIC (HVAC Pipe Installation Only)...............$ 15.50 0.00

HVAC MECHANIC (Installation of HVAC Unit Only)...............$ 16.01 1.56

INSULATOR - MECHANICAL

(Duct, Pipe & Mechanical System Insulation)...............$ 19.77 7.13

IRONWORKER, REINFORCING..........$ 13.35 0.00

IRONWORKER, STRUCTURAL...........$ 18.35 4.90

LABORER: Common or General......$ 10.53 0.00

LABORER: Mason Tender - Brick...$ 9.98 0.00

LABORER: Mason Tender - Cement/Concrete..................$ 9.93 0.00

LABORER: Pipelayer..............$ 12.49 2.13

LABORER: Roof Tearoff...........$ 11.28 0.00

OPERATOR:

Backhoe/Excavator/Trackhoe.......$ 13.10 1.24

OPERATOR: Bobcat/Skid Steer/Skid Loader................$ 13.93 0.00

OPERATOR: Bulldozer.............$ 18.29 1.31

OPERATOR: Drill.................$ 16.22 0.34

OPERATOR: Forklift..............$ 14.00 0.00

OPERATOR: Grader/Blade..........$ 14.34 1.68

OPERATOR: Loader................$ 13.88 0.44

OPERATOR: Mechanic..............$ 17.52 3.33

OPERATOR: Paver (Asphalt, Aggregate, and Concrete).........$ 16.03 0.00

OPERATOR: Roller................$ 13.11 0.00

PAINTER (Brush, Roller, and Spray)...........................$ 15.00 0.81

PLUMBER, Excludes HVAC Pipe Installation.....................$ 21.18 7.57

ROOFER...........................$ 13.75 0.00

SHEET METAL WORKER (HVAC Duct Installation Only)...............$ 18.71 4.90

SHEET METAL WORKER, Excludes HVAC Duct Installation...........$ 14.89 1.55

SPRINKLER FITTER (Fire Sprinklers)......................$ 15.46 0.00

TILE FINISHER....................$ 11.22 0.00

TILE SETTER......................$ 14.74 0.00

TRUCK DRIVER: Dump Truck........$ 11.50 1.10

TRUCK DRIVER: Flatbed Truck.....$ 19.65 8.57

TRUCK DRIVER: Semi-Trailer Truck............................$ 12.50 0.00

TRUCK DRIVER: Water Truck.......$ 12.00 4.11

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year.

Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of "identifiers" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than "SU" or "UAVG" denotes that the union classification and rate were prevailing for that classification in the survey. Example:

PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the "SU" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.)

and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION

General Decision Number: TX190007 01/04/2019 TX7 Superseded General Decision Number: TX20180016 State: Texas Construction Types: Heavy and Highway Counties: Atascosa, Bandera, Bastrop, Bell, Bexar, Brazos, Burleson, Caldwell, Comal, Coryell, Guadalupe, Hays, Kendall, Lampasas, McLennan, Medina, Robertson, Travis, Williamson and Wilson Counties in Texas.

HEAVY (excluding tunnels and dams, not to be used for work on Sewage or Water Treatment Plants or Lift / Pump Stations in Bell, Coryell, McClennon and Williamson Counties) and HIGHWAY Construction Projects

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.60 for calendar year 2019 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015.

If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.60 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2019. If this contract is covered by the EO and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must pay workers in that classification at least the wage rate determined through the conformance process set forth in 29 CFR 5.5(a)(1)(ii) (or the EO minimum wage rate, if it is higher than the conformed wage rate). The EO minimum wage rate will be adjusted annually. Please note that this EO applies to the above-mentioned types of contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but it does not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60). Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date 0 01/04/2019

* SUTX2011-006 08/03/2011

Rates Fringes

CEMENT MASON/CONCRETE

FINISHER (Paving and Structures)......................$ 12.56

ELECTRICIAN......................$ 26.35

FORM BUILDER/FORM SETTER

Paving & Curb...............$ 12.94 Structures..................$ 12.87

LABORER

Asphalt Raker...............$ 12.12 Flagger.....................$ 9.45 Laborer, Common.............$ 10.50 Laborer, Utility............$ 12.27 Pipelayer...................$ 12.79 Work Zone Barricade Servicer....................$ 11.85

PAINTER (Structures).............$ 18.34

POWER EQUIPMENT OPERATOR:

Agricultural Tractor........$ 12.69 Asphalt Distributor.........$ 15.55 Asphalt Paving Machine......$ 14.36

Boom Truck..................$ 18.36 Broom or Sweeper............$ 11.04 Concrete Pavement Finishing Machine...........$ 15.48 Crane, Hydraulic 80 tons or less.....................$ 18.36 Crane, Lattice Boom 80 tons or less................$ 15.87 Crane, Lattice Boom over 80 tons.....................$ 19.38 Crawler Tractor.............$ 15.67 Directional Drilling Locator.....................$ 11.67 Directional Drilling Operator....................$ 17.24 Excavator 50,000 lbs or Less........................$ 12.88 Excavator over 50,000 lbs...$ 17.71 Foundation Drill, Truck Mounted.....................$ 16.93 Front End Loader, 3 CY or Less........................$ 13.04 Front End Loader, Over 3 CY.$ 13.21 Loader/Backhoe..............$ 14.12 Mechanic....................$ 17.10 Milling Machine.............$ 14.18 Motor Grader, Fine Grade....$ 18.51 Motor Grader, Rough.........$ 14.63 Pavement Marking Machine....$ 19.17 Reclaimer/Pulverizer........$ 12.88 Roller, Asphalt.............$ 12.78 Roller, Other...............$ 10.50 Scraper.....................$ 12.27 Spreader Box................$ 14.04 Trenching Machine, Heavy....$ 18.48

Servicer.........................$ 14.51

Steel Worker Reinforcing.................$ 14.00 Structural..................$ 19.29

TRAFFIC SIGNAL INSTALLER

Traffic Signal/Light Pole Worker......................$ 16.00

TRUCK DRIVER

Lowboy-Float................$ 15.66 Off Road Hauler.............$ 11.88 Single Axle.................$ 11.79 Single or Tandem Axle Dump Truck.......................$ 11.68 Tandem Axle Tractor w/Semi Trailer.....................$ 12.81

WELDER...........................$ 15.97

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year.

Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of "identifiers" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than "SU" or "UAVG" denotes that the union classification and rate were prevailing for that classification in the survey. Example:

PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the "SU" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.)

and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor

200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION

SECTION 01 00 00.00 44

CONSTRUCTION SCHEDULE

PART 1 GENERAL

1.1 SCHEDULE

Commence, prosecute, and complete the work under this contract in accordance with the following schedule and Section 00 73 00 SPECIAL CONTRACT REQUIREMENTS COMMENCEMENT, PROSECUTION AND COMPLETION OF WORK and

LIQUIDATED DAMAGES:

Item of Work Commencement of Work

(Calendar days)

Completion of Work

(Calendar days)

Liquidated Damages per calendar days

(1) All work, including O&M Manuals and Final Record Drawings for the construction of the 69th ADA Supply Storage Activity Warehouse and Battalion Headquarters Complex.

See NTP. 540 $ 1,266.67

NOTE: All work on this project shall be completed within the number of calender days stated in Item of Work (1) above, inclusive of all review periods and Government phasing requirements specified. The liquidated damages stated above will be applied for each calendar day the Contractor exceeds the Contract scheduled duration.

a. Liquidated damages for individual items of work will not be combined. Only the rate of the affected item of work will be assessed.

b. Liquidated damages are not accumulative for multiple phases of work.

** Operation and Maintenance Manuals: See Section 01 78 00 CLOSEOUT SUBMITTALS, paragraph OPERATION AND MAINTENANCE MANUALS for requirements and withholding amount to ensure completion of O&M Manuals.

*** Record Drawings: See Section 01 78 00 CLOSEOUT SUBMITTALS, paragraph

SECTION 01 00 00.00 44 Page 1 titled RECORD DRAWINGS for requirements and withholding amount to ensure completion of record drawings.

1.1.1 Testing of Heating and Air-Conditioning Systems

The times stated for completion of this project includes all required testing specified in appropriate specification sections of heating, air conditioning and ventilation systems including HVAC Commissioning.

Exception: boiler combustion efficiency test, boiler full load tests, cooling tower performance tests, and refrigeration equipment full load tests, when specified in the applicable specifications, shall be performed in the appropriate heating/cooling season as determined by the Contracting Officer.

1.2 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (OCT 1989)

(ER 415-1-15)(52.0001-4038 1/96)

a. This provision specifies the procedure for determination of time extensions for unusually severe weather in accordance with the contract clause FAR 52.249-10 entitled "DEFAULT: (FIXED PRICE CONSTRUCTION)." In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor.

b. The following schedule of monthly anticipated adverse weather delays due to precipitation and temperature is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations.

The contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities. Wind is not considered in the Monthly Anticipated Adverse Weather Calendar Day Schedule.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

KILLEEN, TX AREA (FORT HOOD, BELTON AND STILLHOUSE LAKES AND

RESERVE CTRS. ALONG HWY 36 FROM HWY 79 TO HWY US67)

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

4 4 4 4 6 4 3 3 4 4 3 4

c. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the contractor's scheduled work day. Contractor to email COR and QAR on days that they are claimings weather days.

d. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in

SECTION 01 00 00.00 44 Page 2 previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph "b", above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the contract clause entitled "Default (Fixed Price Construction)."

1.3 WORK RESTRICTIONS

1.3.1 Working Hours

Normal working hours are Monday through Friday, 0630 to 1700 hours, unless otherwise indicated at the preconstruction conference. Requests to work at times other than the stated working hours, including scheduled utility outages discussed below, shall be submitted to the Contracting Officer for approval. Contractor shall not work outside of the above stated working hours without prior written approval of the Contracting Officer.

Notification shall be in writing by email by COB on the Wednesday prior to the weekend to be worked to the Project Engineer and Quality Assurance Representative.

1.3.2 Security Requirements

1.3.2.1 Installation Entrance Requirements

Entrance requirements to the Installation are specified in Section 01 35

10.00 44 SPECIAL PROJECT PROCEDURES FOR Fort Hood.

1.3.3 Identification of Employees

The Contractor shall be responsible for furnishing to each employee, and for requiring each employee engaged on the work to display, identification as approved and directed by the Contracting Officer. Prescribed identification shall immediately be delivered to the Contracting Officer for cancellation upon release of any employee. When required, the Contractor shall obtain and provide fingerprints of persons employed on the project. Contractor and subcontractor personnel shall wear identifying markings on hard hats clearly identifying the company for whom the employee works.

Contractor personnel shall wear visible Contractor-furnished employee identification badges while physically on the Installation. Each badge shall include, as a minimum, the company name, employee name, photograph, Contract Title, Contract Number, and the expiration date of the badge.

1.4 UTILITIES

1.4.1 Payment for Utility Services

The utilities on Fort Hood are owned and operated by the following Government Contractors: Dominion Privatization Texas, LLC for natural gas, electrical, and site lighting features, and American Water (AW) Enterprises Military Service Group for water and sanitary sewer.

All utilities are administered by the Government regardless of ownership.

a) Use of Government services:

SECTION 01 00 00.00 44 Page 3

(1) Contractors must reimburse Government for utilities usage (electricity, gas, water, sewer, and refuse) for admin trailer and construction sites.

(2) A utilities sales agreement must be signed by Contractor prior to connection/use of utilities services.

(3) Contractor must provide all metering devices (per Fort Hood Specification) for trailer and construction project.

(4) Current utilities rates can be obtained from 254-287-7671.

b) Meters and Temporary Connections

The Contractor, at its expense and in a manner satisfactory to the Contracting Officer, shall provide and maintain necessary temporary connections, distribution lines, and meter bases required to measure the amount of each utility used for the purpose of determining charges.

The Contractor shall notify the Contracting Officer, in writing, 5 working days before utility (gas, water, sewer, electricity) connection is desired so that a utilities contract can be established. The Contractor will provide a meter and make the final hot connection after inspection and approval of the Contractor's temporary wiring installation. Sewage usage is based on water usage and does not require a meter.

c) Advance Deposit

An advance deposit for utilities consisting of an estimated month's usage or a minimum of $50.00 will be required. The last monthly bills for the fiscal year will normally be offset by the deposit and adjustments will be billed or returned as appropriate. Services to be rendered for the next fiscal year, beginning 1 October, will require a new deposit. Notification of the due date for this deposit will be mailed to the Contractor prior to the end of the current fiscal year.

d) Final Meter Reading

Before completion of the work and final acceptance of the work by the Government, the Contractor shall notify the Contracting Officer, in writing, 5 working days before termination is desired. The Government will take a final meter reading; and thereafter, the Contractor shall disconnect service, and remove the meters. The Contractor shall also remove all the temporary distribution lines, meter bases, and associated paraphernalia. The Contractor shall pay all outstanding utility bills before final acceptance of the work by the Government.

1.4.2 Coordination

For Contractor Telephone And Internet Service, the Contractor shall coordinate with ITBC and the local phone company for contractor telephone and internet service during construction.

1.4.3 Outages

The Contractor shall coordinate all requests for utility outages with the Contracting Officer in writing 14 days prior to date of requested outage:

a. Water and sewer outages shall be held to a maximum duration of 4 hours unless otherwise approved in writing.

SECTION 01 00 00.00 44 Page 4

b. Gas and electrical outages are prohibited. Connections to gas and electrical lines shall be connected Hot without an outage. The Contractor shall submit a Work Plan for Electrical Connections 14 calendar days before the requested connections.

c. All utility outages shall be scheduled only on Saturdays, Sundays, or holidays unless specific approval is otherwise received.

1.5 PAPERLESS CONTRACT SUBMISSION

a. GENERAL INFORMATION ON PAPERLESS CONTRACT SUBMISSION

The goal is to reduce waste, decrease time, decrease associated costs, and to streamline most file transmission procedures.

b. METHODS OF DIGITAL SUBMISSION

This contract shall use digital submission methods to the greatest extent practicable. Acceptable methods are as follows, in order of precedence:

1. RMS - will be used to the greatest extent practicable. Some items may not be submittable via RMS due to program constraints.

Those items shall use an alternate method. All ENGR 4025’s shall be generated and submitted in RMS.

2. Secure, Password Protected Web-Based System Access must be allowed and approved by the Government Representative. Access must be allowed and approved by the Government Representative. This method shall not be used for security sensitive documents.

3. E-mail – Items not submitted via RMS, as discussed above, shall be submitted via e-mail, if possible. E-mail limitations for file size must be considered prior to submission. Under current conditions, 5 megabytes is the limitation for any single file/e-mail.

4. CD/DVD – Will be accepted if no other method is possible and upon prior approval.

c. ITEMS TO BE SUBMITTED VIA HARDCOPY

Product samples, color boards, and any other item not feasible to submit digitally, shall be submitted hard copy. ENGR 4025 shall be submitted digitally always. The Government reserves the right to request hard copy submission on any item, if deemed necessary.

Contractor shall be prepared to provide requested hard copy at any time.

1.6 CONTRACTOR PERFORMANCE EVALUATIONS

In accordance with the provisions of Subpart 36.201 (Evaluation of Contractor Performance) of the Federal Acquisition Regulation (FAR), construction contractor’s performance shall be evaluated throughout the performance of the contract. The United States Army Corps of Engineers (USACE) follows the procedures outlined in Engineering Regulation 415-1-17 to fulfill this FAR requirement. For construction contracts awarded at or above $700,000.00, the USACE will evaluate contractor’s performance and prepare a performance report using the Contractor Performance Assessment Reporting System (CPARS), which is now a web-based system. After an

SECTION 01 00 00.00 44 Page 5 evaluation (interim or final) is written up by the USACE, the contractor will have the ability to access, review and comment on the evaluation for a period of 60 days. Accessing and using CPARS requires specific software, called PKI certification, which is installed on the user’s computer. The certification is a Department of Defense requirement and was implemented to provide security in electronic transactions. The certification software could cost approximately $110 - $125 per certificate per year and is purchased from an External Certificate Authorities (ECA) vendor. Current information about the PKI certification process and for contacting vendors can be found on the web site: http://www.cpars.csd.disa.mil/. If the Contractor wishes to participate in the performance evaluation process, access to CPARS and PKI certification is the sole responsibility of the Contractor.

1.7 CONTRACTOR PAYROLL RECORD

Contractor shall be required to log payrolls for all their own employees and subcontractors utilizing ENG Form 3180. Each subcontractor requires a separate ENG 3180 for their payrolls. The Contractor shall maintain the ENG 3180, along with the payrolls, on site and available for review by the Contracting Officer's Representative. The ENG 3180's shall be updated weekly as payrolls are submitted. After making copies for their files, the Contractor is required to submit the originals of each week’s payrolls to the Resident Office. Before final payment, the Contractor shall provide the completed ENG 3180’s to the Contracting Officer's Representatives.

1.8 (S-102) CONTRACTOR SUPPLY and USE OF ELECTRONIC SOFTWARE FOR PROCESSING DAVIS-BACON ACT CERTIFIED LABOR PAYROLLS (April 2011)

The contractor is required to use a commercially-available electronic system to process and submit certified payrolls electronically to the Government. The requirements for preparing, processing and providing certified labor payrolls are established by the Davis-Bacon Act as stated in FAR 52.222-8, PAYROLLS AND BASIC RECORDS and FAR 52.222-13, COMPLIANCE

WITH DAVIS-BACON AND RELATED ACT REGULATIONS.

The contractor shall be responsible for obtaining and providing for all access, licenses, and other services required to provide for receipt, processing, certifying, electronically transmitting to the Government, and storing weekly payrolls and other data required for the contractor to comply with Davis-Bacon and related Act regulations. When the contractor uses an electronic Davis-Bacon payroll system, the electronic payroll service shall be used by the contractor to prepare, process, and maintain the relevant payrolls and basic records during all work under this construction contract and the electronic payroll service shall be capable of preserving these payrolls and related basic records for the required 3 years after contract completion. The contractor shall obtain and provide electronic system access to the Government, as required to comply with the Davis-Bacon and related Act regulations over the duration of this construction contract. The access shall include electronic review access by the Government contract administration office to the electronic payroll processing system used by the contractor.

The contractor's provision and use of an electronic payroll processing system shall meet the following basic functional criteria: commercially available; compliant with appropriate Davis Bacon Act payroll provisions in the FAR; able to accommodate the required numbers of employees and subcontractors planned to be employed under the contract; demonstrated security of data and data entry rights; ability to produce

SECTION 01 00 00.00 44 Page 6 contractor-certified electronic versions of weekly payroll data; ability to identify erroneous entries and track the data/time of all versions of the certified Davis Bacon payrolls submitted to the government over the life of the contract; capable of generating a durable record copy, that is, a CD or DVD and PDF file record of data from the system database at end of the contract closeout. This durable record copy of data from the electronic Davis-Bacon payroll processing system shall be provided to the Government during contract closeout.

All contractor-incurred costs related to the contractor's provision and use of an electronic payroll processing service shall be included in the contractor's price for the overall work under the contract. The costs for Davis-Bacon Act compliance using electronic payroll processing services shall not be a separately bid/proposed or reimbursed item under this contract.

1.9 ADDITIONAL CONTRACTOR PAYROLL RECORD

(1) Reference the Special Contract Requirement (S-102) CONTRACTOR SUPPLY

AND USE OF ELECTRONIC SOFTWARE FOR PROCESSING DAVIS-BACON ACT CERTIFIED

LABOR PAYROLLS. The Fort Worth District requires the contractor and all sub-contractors to use an electronic payroll system meeting the requirements aboved refereced and the following.

(a) The Certified Labor Payrolls must be tracked electronically via WEB-based software and all data must be submitted via WEB. Payroll guidelines,"Instructions to Contractors on Contract Labor Requirements, published as "Appendix A, SWFP 1185-1-1" (also known as the Green book), will be provided to advise/inform contractors how these labor provisions will be administered and enforced.

(b) The WEB-based software must be capable of downloading data directly from existing electronic payrolls, track workers to ensure that overtime is being paid when overtime status is reached on Government contracts whether on one or multiple contracts or different sub-contractors. The software must track apprentices and journeyman ratios, create and track SF-1444 "Request for Authorization of Additional Classification and Rate", track workers by name/address/with or without Social Security Numbers, allow automated redaction of information appearing on payroll statements for agency response to Freedom of Information Act (FOIA requests), and provide free online training by the software provider to any user of the software.

(c) The software must allow fringe benefit statement to track fringe benefits "whether cash or into an approved plan, fund, or program. If the fringe benefits are paid into a plan, fund, or program the company's name (receiving benefits), phone number, and address shall be listed on the Statement of Compliance Form (DD Form 879 or WH-347).

(d) Software must provide a method of tracking standard and non-standard deductions such as restitution, alimony, child support, and allow for custom entries. Method of tracking must list the deductions on the statement of compliance or be listed as an attachment.

(e) The Contractor is required to provide the updated 3080's and notify the Contracting Officer's Representatives weekly by email when the current payrolls are complete and ready for inspection/review on the WEB. Before final payment, the Contractor shall provide the completed ENG For 3180's and 3 disks (CD/DVD) which include complete copies of the Contractor and sub-contractor's payrolls/attachments, to the Contracting Officer's

SECTION 01 00 00.00 44 Page 7

Representatives.

(2) Electronic copies of electronically/manually signed forms/memos/letters such as SF 1413 Statement of Acknowledgement (sub-contractor agreement), SF-1444 "Request for Authorization of Additional Classification and Rate", employee deduction authorization, certification of apprentices and trainees shall be provided to the Contracting Officer's Representative as required by FAR.

1.10 STREET CLOSINGS

The Contractor shall coordinate all requests for street closings with the Contracting Officer in writing 21 days prior to date of requested outage:

a. One lane traffic shall be maintained at all times (except that a total closing may be allowed for specific 8-hour periods).

b. The final street repair shall be completed within 21 calendar days after the start of any street crossing. Any part of the street returned to service prior to final repair shall be maintained smooth with hot-mix cold-lay surface course.

c. Open cuts across paved roads and streets for utility crossings will not be allowed. Utility crossings will be accomplished by boring or jacking procedures only.

1.11 Veterans Employment Emphasis for U.S. Army Corps of Engineers Contracts

In addition to complying with the requirements outlined in FAR Part 22.13, FAR Provision 52.222-38, FAR Clause 52.222-35, FAR Clause 52.222-37, DFARS

222.13 and Department of Labor regulations, U.S. Army Corps of Engineers (USACE) contractors and subcontractors at all tiers are encouraged to promote the training and employment of U.S. veterans while performing under a USACE contract.