A01.07_Atch_2_Supplemental_Contract_Requirements.docx

DOCX document 21 KB Posted

Attached to
Kitchen/Cafeteria Remodel at DDJC Tracy, CA Federal contract opportunity
Solicitation number
W91238-17-R-0062
Issued by
Department of the Army Corps of Engineers Engineering District Sacramento

About this file

From the source

Attachment 2

View the file

Other files for this federal contract opportunity

Other files attached to Kitchen/Cafeteria Remodel at DDJC Tracy, CA, newest first.
File Type Posted
Amendment_0003.pdf PDF
Atch_1_Bldg_100_Kitchen_&_Bldg_16_Cafeteria_Renovation_SOW_Rev_9.1.17.docx DOCX document
Appendix_8__Specs-Intact_Submittal_Register_.txt TXT text file
Appendix_7__Specs-Intact_Master_File_.pdf PDF
Appendix_1__Renovate_Cafeteria_Buildings_100_and_16_Drawings_RTA.pdf.pdf PDF
W91238-17-R-0062_AM_002.pdf PDF
A01.07_Solicitation_17-R-0062_AM_01.pdf PDF
Site_walk_list.pdf PDF
Appendix_1_-_Renovate_Cafeteria_Buildings_100_and_16_-_Drawings_RTA.pdf PDF
A01.07_Atch_1_Bldg_100_Kitchen_&_Bldg_16_Cafeteria_Renovation_SOW_Rev_6.7.17_v_2.docx DOCX document
A01.07_Appendix_10__Division_23_Specifications.pdf PDF
A01.07_Atch_3_Davis_Bacon_Wage_Determination.docx DOCX document
A01.07_Appendix_9__Division_21_Specifications.pdf PDF
Solicitation_17-R-0062.pdf PDF
A01.07_Atch_4_Past_Performance_Worksheets.pdf PDF
A01.07_Appendix_5_-_Environmental_Checklist_for_Kitchen_at_Bldg_100.pdf PDF
A01.07_Appendix_8_Division_11_Specification.pdf PDF
A01.07_Appendix_1__Renovate_Cafeteria_Buildings_100_and_16_Drawings_RTA.pdf PDF
A01.07_Appendix_4_-_Environmental_Checklist_for_Cafeteria_at_Bldg_16.pdf PDF
A01.07_Appendix_6_-_Asbestos_and_Lead_Survey_Results.pdf PDF
A01.07_Appendix_3_-_Division_1_Specifications.pdf PDF
A01.07_Appendix_2_-_Renovate_Cafeteria_Buildings_100_and_16_Design_Analysis_RTA_.pdf PDF
A01.07_Appendix_7_Division_02_Specifications.pdf PDF
Show all 23

On GovTribe

Work with this file on GovTribe

  • Download the original file
  • Contacts named in this file
  • Similar government files
  • Ask GovTribe AI about this file
Try for free Login

Text version

The file's text, extracted by GovTribe without its formatting.

Attachment 2 W91238-17-R-0062 12 April 2017

SUPPLEMENTAL CONTRACT REQUIREMENTS

1. Performance Period. Refer to contract section 00700, page 12, FAR 52.211-10. The performance period for the work stated above shall be 300 calendar days.

2. Liquidated Damages. Refer to contract section 00700, page 13, FAR 52.211-12, Liquidated Damages-Construction. The Government may assess the contractor liquidated damages in the amount of $2,065.00 for each day of unexcused delay beyond the contract completion date.

3. Authorities. Only a warranted Contracting Officer (either PCO or ACO) acting within their delegated limits has the authority to issue modifications or otherwise change the terms and conditions of this contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this contract you shall not proceed with the change and shall immediately notify the Contracting Officer.

4. Wage Determination. General Decision No. CA170029 03/31/2017 CA29 in its most current modification at the time of award is hereby applicable to work performed under this task order.

See attachment 3 for further detail. You may also find the latest Davis-Bacon Wages at:

http://www.wdol.gov/wdol/scafiles/davisbacon/CA29.dvb?v=11

5. Time Extensions For Unusually Severe Weather. Refer to contract section 01505, Default (Fixed-Priced Construction). All weather delay will need to be submitted and approved by the Contracting Officer Representative.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK-TRACY AD/SHARPE CARBONA

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

(09) (05) (05) (03) (01) (00) (00) (00) (00) (01) (04) (08)

File details come from the government source that posted it. Updated .