W5J9JE15R0018.pdf

123456789

Site-Adapt Contract for the design and renovation of the existing Afghanistan National Police (ANP), Project ANP-15-B-002 , Jalalabad Female Compound, Nangarhar Province, Afghanistan.

The Government intends to aw ard a Firm Fixed Price contract as a result of this solicitation. This acquisition is UNRESTRICTED, Full and Open Competition.

The estimated magnitude of this project is $10,000,000 to $25,000,000.

Offerors must be registered in System for Aw ard Management (SAM) available at SAM.gov and in the Joint Contingency Contracting System available at https://jccs.gov/OLVRCA/bta-jccs-login.aspx. Offerors shall submit a completed copy of their Domestic Investment License issued by the Afdghanistan Investment Support Agency (AISA) w ith their proposal (http://w w w .asia.org.af/english/applications.html).

DANIEL PORTILLO 540-723-4949

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

20-Jun-2015

(RFP)

(IFB)

X

CALL:

Renovation of RTC Jalalabad Female Compound

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______15 calendar days and complete it w ithin ________500 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

YES X NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specified in Item 8 by ___________ local time ______________11 Jul 2015 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______120 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

TRANSATLANTIC AFGHANISTAN ENGINEER - TAA

DISTRICT (TAA), US ARMY CORPS OF ENGINEERS

CETAA-CT, BAGRAM AE 09354

W5J9JE

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

03:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

ANP-15-B-0002

8. ADDRESS OFFER TO (If Other Than Item 7)

540-665-2758FAX:TEL: 079-343-4105 TEL: FAX:

W5J9JE-15-R-0018 80

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W5J9JE-15-R-0018

Section 00010 - Solicitation Contract Form

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Design Program

FFP

Renovation of Regional Training Center (RTC) Jalalabad Female Compound, Nangarhar Province, Afghanistan Project number ANP-15-B-002 The Project consists of the site adapt and renovation of the existing ANP Regional Training Center (RTC) male compound to accommodate and train up to 300 female students conducting simultaneous courses. The female compound will include classrooms, instructor offices, billeting, dining facilities, prayer rooms, exercise room, and training yard. Furniture, fixtures, exercise equipment, IM/IT equipment will not be included in the acquisition package. The renovation and construction will be constructed in accordance with current building codes, safety, and security standards, and applicable to local standards.

FOB: Destination

PURCHASE REQUEST NUMBER: 123456789

NET AMT

0001AA 1 Lump Sum Site Survey

FFP

Provide a Site Survey in accordance with Scope of Work and Technical Specifications.

0001AB 1 Lump Sum Geotechnical Investigation & Report

FFP

Provide Geotechnical Investigation & Report In accordance with Scope of Work and Technical Specifications.

0001AC 1 Lump Sum Septic Site Assesment

FFP

Provide Septic Site Assesment in accordance with Scope of Work and Technical

0001AD 1 Lump Sum A/E Design to Include Waste Water Sewer

FFP

IProvide A/E Design for Waste Watrer Sewer in accordance with Scope of Work

0001AE 1 Lump Sum As-Built Drawqings

FFP

Provide As-Built Drawings in accordance with Scope of Work and Technical

SITE DEVELOPMENT IMPROVEMENTS

FFP

Provide Site Development Improvements in accordance with teh Scope of Work

0002AA 1 Lump Sum Mobilization/Demobilization

FFP

Mobilization and Demobilization shall consist of all labor, equipment, supplies and facilities required to stage all equipment and facilities needed for construction of this project.

0002AB 1 Lump Sum Site/Improvement/Grading

FFP

Provide Site Improvement/Grading In accordance with Scope of Work and Technical Specifications.

0002AC 1 Lump Sum Site Demolition

FFP

Provide Site Demolition in accordance with Scope of Work and Technical

0002AD 1 Lump Sum Relocation of Fuel Point/ Restoration

FFP

Relocation of Fuel Point/Relocation In accordance with Scope of Work and

0002AE 1 Lump Sum Site Electrical

FFP

Provide Site Electrical in accordance with Scope of Work and Technical

0002AF 1 Lump Sum Relocation of (2) 550-KVA Generators

FFP

Relocation of 550-KVA Generators In accordance with Scope of Work and

0002AG 1 Lump Sum Water Line Installation

FFP

Provide Water Line Installation In accordance with Scope of Work and Technical

0002AH 1 Lump Sum Sewer Line Installation

FFP

Provide Sewer Line Installation In accordance with Scope of Work and Technical

0002AJ 1 Lump Sum Aggregrate Road

FFP

Construcr Aggregrate Road In accordance with Scope of Work and Technical

0002AK 1 Lump Sum Concrete Side Walks

FFP

Construct Concrete Sidewals In accordance with Scope of Work and Technical

FACILITIES

FFP

Construct facilities in accordance with Scope of Work and TEchnical

0003AA 1 Lump Sum Entry Control Point

FFP

Construct an Entry Control Point (ECP) In accordance with Scope of Work and

0003AB 1 Lump Sum Parking Lot

FFP

Construct a Parking Lot In accordance with Scope of Work and Technical

0003AC 1 Lump Sum Compound Wall

FFP

Construct Compound Wall In accordance with Scope of Work and Technical

0003AD 1 Lump Sum Water Storage Tank- 25,000 litre elevate

FFP

Provide Water Storage tank 25,000 litre elevated in accordance with Scope of Work and Technical Specifications.I

0003AE 1 Lump Sum Water Storage Tank 100,000 liter ground

FFP

Provide Water Storage tank 100,000 litre ground In accordance with Scope of Work and Technical Specifications.

0003AF 1 Lump Sum Officer Barracks (B-03)

FFP

ovide Officer Barracks In accordance with Scope of Work and Technical

0003AG 1 Lump Sum NCO Barracks (B-04)

FFP

Provide Barracks In accordance with Scope of Work and Technical Specifications.

0003AH 1 Lump Sum Enlisted Barracks (B-06)

FFP

Provide Barracks In accordance with Scope of Work and Technical Specifications.

0003AJ 1 Lump Sum Dining Facility (DF-04)

FFP

Provide Dining Facility in accordance with Scope of Work and Technical

0003AK 1 Lump Sum Day Care Center

FFP

Provide Day Care Center In accordance with Scope of Work and Technical

0003AL 1 Lump Sum Administrative Building (AD-19)

FFP

Provide Administrative Building In accordance with Scope of Work and Technical

0003AM 1 Lump Sum Classroom (CL-02)

FFP

Provide Classroom In accordance with Scope of Work and Technical

0003AN 1 Lump Sum Classroom (CL-03)

FFP

Provide Classroom In accordance with Scope of Work and Technical

0003AP 1 Lump Sum Medical Clinic (MED-01)

FFP

Build Medical Clinic in accordance with Scope of Work and Technical

0003AQ 1 Lump Sum Paved Parade Ground

FFP

Provide Paved Parade Ground In accordance with Scope of Work and Technical

0003AR 1 Lump Sum Review Stand (G-02)

FFP

Provide site-adapt Review Stand In accordance with Scope of Work and Technical

0003AS 1 Lump Sum Building 105 Renovation

FFP

IRenovate building per Technical Specifications and Scope of Work.

OPTION Collapsible Soils -Bid Option

FFP

In accordance with Scope of Work and Technical Specifications.

0004AA 1 Lump Sum OPTION Collapsible Soils Remediation

FFP

IProvide for Collapsible Soils Remediation in accordance with Scope of Work and

DBA INSURANCE

DBA INSURANCE

Reference FAR Clause 52.228-3 -- Workers Compensation Insurance (Defense Base Act)

Contractors are required to obtain Defense Base Act (DBA) insurance for its employees who will perform the services required herein.

Contractors shall obtain DBA insurance coverage from a Department of Labor (DOL) authorized insurance carrier unless the contractor is under a self-insurance program approved by the DOL or subject to a waiver.

The DOL approved carriers are available at http://www.dol.gov/owcp/dlhwc/lscarrier.htm DBA insurance is no longer a separate CLIN on a USACE contract. It is mandatory and Notice to Proceed will not be issued without verification the DBA is in place. It is recommended that you add this expense in your mobilization cost.

Additionally, offerors should be advised that the Government will not reimburse DBA costs above the original cost in the proposal.

INSPECTION AND ACCEPTANCE

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

DELIVERIES AND PERFORMANCE

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS UIC

0001 N/A N/A N/A N/A

Section 00100 - Bidding Schedule/Instructions to Bidders

INSTRUCTIONS TO BIDDERS

SECTION 00110

INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS

FULL AND OPEN LOWEST PRICED TECHNICALLY ACCEPTABLE (LPTA)

1. GENERAL INFORMATION

This Solicitation is for a firm-fixed price contract to acquire site- adapt and construction services for the renovation of the Regional Training Center (RTC) Jalalabad Female Compound Project, Nangarhar Province, Afghanistan.

This Solicitation is for a sight- adapt firm-fixed price contract to acquire construction services for the RTC Jalalabad Female Compound, Nangarhar Province, Afghanistan. The Project consists of the site-adapt and renovation of the existing ANP Regional Training Center (RTC) male compound to accommodate and train up to 300 female students conducting simultaneous courses. The female compound will include classrooms, instructor offices, billeting, dining facilities, prayer rooms, exercise room, and training yard. Furniture, fixtures, and exercise equipment will be included however IM/IT will not be included in the acquisition package.

The Project shall include but not be limited to the necessary site-adapt, site development and improvements, facilities, management, planning, materials, labor, and equipment for new female compound, water storage facility, and in-ground septic treatment and disposal system.

Oral explanations or instructions are not binding.

Any information given to an Offeror which impacts the solicitation and/or offer will be given in the form of a written amendment to the solicitation.

As this is a competitive negotiation acquisition, there is no public proposal opening and no information will be given out as to the number of Offerors or the results of the competition until all awards are made.

2. REQUIRED REGISTRATIONS

Offerors must have and must maintain an active registration in the following databases:

System for Award Management (SAM): Offerors must have and must maintain an active registration in the SAM database at www.sam.gov to be eligible for a Government contract award.

If the Offeror is a Joint Venture (JV), the JV entity must have valid SAM registration in the SAM database representing the JV as one business/firm/entity. If at the time of award an Offeror is not actively and successfully registered in the SAM data base, the Government reserves the right to award to the next prospective Offeror.

On-Line Representations and Certifications: Prospective contractors shall complete electronic representations and certifications at www.sam.gov in conjunction with required registration in the SAM. If the Offeror has not completed the annual representation and certifications on the “Online Representations and Certifications” at www.sam.gov website, the proposal must contain the Offeror’s completed “Representations, Certifications, and Other Statements of Offerors” included in the solicitation (Section 00600).

Afghan Investment Support Agency (AISA): Offerors must have a valid Investment License issued by the AISA in order to be eligible for award. To obtain an AISA license, visit:

ANP-15-B-002

Renovation for RTC Jalalabad Female Compound, Nangarhar Province, AFG http://www.aisa.org.af/english/applications.html.

Joint Contingency Contracting System (JCCS): Offerors must be registered in the JCCS vendor vetting database at https://www.jccs.gov/olvr/. (This information was provided under Sources Sought Notice issued on 8 June, 2015.) Offerors who are not completely registered in JCCS at the time of evaluation will be removed from further consideration for award.

3. DEFINITIONS

When the word ‘Offeror’ is encountered throughout this Section 00110, it is intended to mean a company or Joint Venture seeking to do business with the Government that submits a proposal in response to this solicitation.

A ‘proposal’ is documentation prepared by the Offeror and submitted to the Government for evaluation purposes in response to this solicitation.

When the word ‘Government’ is encountered throughout this Section 00110, it is intended to mean the U.S. Army Corps of Engineers, Transatlantic Afghanistan District (TAA).

“System for Award Management” (SAM) database means the primary Government repository for Contractor information required for the conduct of business with the Government.

On-Line Representations and Certifications database means the replacement of the paper based representations and certifications in the solicitation with an Internet application. The Federal Acquisition Regulation (FAR) 52.204-8 mandates the use of the System for Award Management (SAM) at www.sam.gov.

4. SUBMISSION OF INQUIRIES:

Proposals for this solicitation will be accepted until the date and time indicated on Standard Form 1442.

Prospective Offerors should submit inquiries related to this solicitation only by e-mail to:

E-MAIL ADDRESS: charles.h.hollingsworth@usace.army.mil Include the solicitation number, and Project title with any questions/clarifications. Written questions must be received by this office not later than 7 calendar days prior to the date set for receipt of offers.

TELEPHONE INQUIRIES WILL NOT BE ACCEPTED.

5. DIRECTIONS FOR SUBMITTING PROPOSALS

Offers must be emailed to: Mr. Charles Hollingsworth via email at Charles.h.hollingsworth@usace.army.mil Subject Line of Email: ANP-15-B-0002 Solicitation Number: W5J9JE -15-R-0018 Offer Closing Date: See Standard Form 1442, Block 13A Offer Closing Time: 3:00 p.m. (Local Bagram Time)

PROPOSALS SUBMITTED AFTER THE DATE AND TIME ESTABLISHED FOR

SUBMISSION OF PROPOSALS WILL NOT BE EVALUATED.

6. SITE VISIT

It is strongly suggested that the contractor visit the Project Site prior to submission of a proposal. The selected Contractor will be responsible for turning over a complete and operational facility. This includes ensuring all work meets the applicable building codes and standards for the Project features of work.

7. ELECTRONIC PROPOSALS

Electronic proposals and their applicable modifications or cancellations, will be accepted. Send proposals to Mr. Charles Hollingsworth via email at Charles.h.hollingsworth@usace.army.mil. Proposals may be withdrawn in writing by e-mail. Any written notice to withdraw an offer sent to this office must be received in the office designated in the Request for Proposal (RFP) for receipt of offers not later than the exact date and time set for receipt of proposals.

8. PROPOSALS SHALL BE SUBMITTED IN THE FOLLOWING FORMAT:

Proposal Package: Email to Charles.h.hollingsworth@usace.army.mil Proposal Package Email Volume 1 Technical Proposal 1 FACTOR 1 – Technical Approach and Qualifications Site-Adapt- Build Experience FACTOR 2 – Past Performance FACTOR 3 – Management and Execution Plan

a. Executive Summary

b. Construction Management Plan

c. Quality Management/Control Plan

d. Key Personnel

e. Milestone Schedule Volume 1 shall also include the following:

・ Letters of Commitment from Subcontractors (if applicable)

・ Joint Venture Agreement (if applicable)

Volume 2 - Price and Administrative Submission 1 FACTOR 4 – Price Proposal Factor 4 shall also include the following:

・ Signed Standard Form 1442

・ Pricing Schedule

・ Representation and Certifications, Section 00600

・ All Amendments, signed and dated

・ Offeror’s e-mail address and cell phone number

・ Name, Address, CCR DUNS, CCR CAGE and TAX Identification Numbers of the Contractor submitting the proposal ・ Afghanistan Investment Support Agency (AISA) License

The Government will not make assumptions concerning intent, capabilities, or experience. Clear identification of proposal details shall be the sole responsibility of the Offeror. The Government may reject incomplete proposals after initial evaluation without further consideration. Complete proposals shall meet the basic requirements identified in the RFP.

9. PROPOSAL SUBMISSION REQUIREMENTS AND INSTRUCTIONS

a. REQUIREMENT FOR SEPARATE TECHNICAL AND PRICE PROPOSALS DO NOT MIX CONTENTS OF VOLUME 1 (Technical) AND VOLUME 2 (Price) IN THE

SAME PDF.

1. The Proposal shall be typed and submitted in clearly-written English

2. Each Offeror must submit a Technical Proposal and a Price Proposal. The Technical Proposal and the Price Proposal must be submitted as separate attachments. Both the Technical and price proposal shall be paginated (contain consecutive page numbers on each page). The outside cover of each separate volume (Vol 1 – Technical; Vol 2 – Price) must be clearly marked to indicate its contents and the identity of the Offeror.

3. Both the Technical Proposal and the Price Proposal must be received by the closing date and time set for receipt of proposals.

4. Pricing Schedule, Vol 2, shall be completed in full.

5. Do not include any dollar amounts in the Technical Proposal that are taken from the Price Proposal.

6. All information intended to be evaluated as part of the Technical Proposal must be submitted within the Technical Proposal. Do not cross-reference material in the Price Proposal, or vice versa. Also, do not include links to websites in your proposal. Technical Proposals will not be provided to the price team and Price Proposals will not be provided to the technical team.

Therefore, information submitted in the wrong Volume could lead to the proposal being determined “unacceptable” if materially incomplete in any aspect.

7. Do not attempt to modify the terms and conditions of the solicitation in either the technical or price proposal or add conditions or qualifications to your offer. Should the Offeror include terms and conditions that conflict with the terms and conditions of the Solicitation, the offer may be determined "unacceptable" and thus ineligible for award. Any questions related to specific terms and conditions contained within the Solicitation should be resolved prior to submission of the offer. Notwithstanding the above, the Offeror must clearly describe on the Proposal Cover Sheet submitted with the Price Proposal any modifications to the contractual and/or technical terms and conditions of the solicitation contained in the Offer.

8. Failure to submit required documents or failure to properly complete documents may result in rejection of the offer without further evaluation. Therefore, Offerors are urged to follow instructions carefully and to speak with the Contracting Officer if the Offeror does not understand any part of the Solicitation.

b. DISCUSSIONS.

The Government intends to evaluate proposals and award a contract without discussions with Offerors. Therefore, the Offeror’s initial proposal should contain the Offeror’s best terms from a cost or price and technical standpoint. The Government reserves the right to conduct discussions if the Contracting Officer later determines them to be necessary. If the Contracting Officer determines that the number of proposals that would otherwise form the competitive range exceeds the number at which an efficient competition can be conducted, the Contracting Officer may limit the number of proposals in the competitive range to the greatest number that will permit an efficient competition among the most highly rated proposals.

c. GENERAL INSTRUCTIONS.

1. Submit only the documents specifically required in this section. Do not submit excess information; do not include audio-visual materials, additional electronic media, etc.

ELECTRONIC PROPOSALS, AMENDMENTS, OR CANCELLATIONS WILL BE

ACCEPTED

2. References to “Confidential” projects cannot be submitted to demonstrate capability unless all of the information required for evaluation as specified herein can be provided to the Government as part of the Offeror’s technical proposal. Offerors that include in their proposals information they do not want disclosed to the public for any purpose, or used by the Government except for evaluation purposes, must clearly mark their proposals in accordance with the instructions at FAR 52.215-1, “Instructions to Offerors— Competitive Acquisition,” paragraph (e), “Restriction on disclosure and use of data .”

3. In the case of an Offeror that is part of a large, multi-segmented business concern, provide information directly pertaining to the specific segment of the business concern (i.e., the division, group, unit, etc.) that will perform work under the prospective contract.

4. For submissions with page limitations, the pages will be counted as follows: One side of the paper is one page; information on both the back and front of one sheet of paper will be counted as two pages. Pages furnished for organizational purposes only, such as a “Table of Contents” or divider tabs, are not included in the page limitation.

5. Documents shall be in read-only format, using PDF files. Printing should be single spaced.

Each paragraph shall be separated by at least one blank line. A standard, 12-point minimum font size applies. Ariel or New Times Roman fonts are required. Tables and illustrations may use a reduced font size no less than 8-point and may be landscape.

10. INSTRUCTIONS FOR SUBMISSION OF JOINT VENTURE AGREEMENTS

a. A Joint Venture offeror must submit with its technical proposal a copy of the joint venture agreement upon which the Joint Venture organization has been formed. The joint venture agreement must indicate that the joint venture is in existence as of the date and time that proposals are due to be submitted.

b. If the original Joint Venture agreement is not written in English, the offeror must provide an English language copy of the joint venture instrument, accompanied by an original signed statement by an authorized officer or representative of each of the Joint Venture partners that the English translation is true and correct.

c. The Joint Venture agreement must be signed by a representative of each joint venture partner who has the requisite authority to bind the partner to the agreement, with the chief executive of each entity identified.

d. To be acceptable to the Government, the Joint Venture agreement must clearly state within its terms that each member of the joint venture is jointly and severally liable for all of the obligations of the Joint Venture itself with respect to completion of all work and services under the contract expected to result from the Solicitation.

e. The terms of the Joint Venture must detail, in terms of percentages, where appropriate, the relationship of the joint venture parties in terms of business ownership, capital contribution, and profit distribution or loss sharing.

f. Additionally, the Joint Venture agreement must specify who among the Joint Venture partners is authorized to sign the Solicitation's Standard Form 1442, acknowledge the amendments to the

Solicitation, if any, and bind the entire joint venture to its obligations under any contract which may result from the Solicitation.

11. SUBCONTRACTORS

a. If an Offeror wishes to receive credit for the key personnel of a subcontractor, including a firm that is a proposed subcontractor to the prime contractor or a joint venture partner, the Offeror must submit a letter of commitment to subcontract under the proposed Project, signed both by the subcontractor and the Offeror.

b. For purposes of this Solicitation, such a subcontractor shall be considered to be a “qualified subcontractor.”

c. The commitment letter must be submitted even if the subcontractor is in some way affiliated with a Joint Venture partner (for example, the subcontractor is a subsidiary of a Joint Venture partner, or a subsidiary of a firm to which the Joint Venture partner is also a subsidiary).

d. Include letters of commitment in Volume 1, Factor 1 ,Experience.

12. SPECIFIC INSTRUCTIONS FOR – TECHNICAL PROPOSAL

a. Number of Sets of the Technical Proposal. Submit one (1) copy of the Technical Proposal electronically.

b. Format and Contents of the Technical Proposal and List of Tabs. The technical proposal shall be organized using the tabs specified in the following chart. Note: The main tabs directly correlate to the evaluation factors identified in Section 00120.

TAB

Factor

CONTENTS OF THE TECHNICAL PROPOSAL PAGE LIMITS

TAB 1

Factor 1

TECHNICAL APPROACH AND

QUALIFICATIONS RELATED TO SITE

ADAPT‐BUILD EXPERIENCE

TAB 2

Factor 2

PAST PERFORMANCE 15

TAB

Factor 3

CONTENTS OF THE TECHNICAL PROPOSAL PAGE LIMITS

TABS 3a‐c MANAGEMENT AND

EXECUTION PLAN

TAB 3d KEY PERSONNEL 18

TAB 3e MILESTONE SCHEDULE 10

c. Page Limitations. The following page limitations are established for each factor described above:

・ Factor #1, Technical Approach and Qualifications related to Site Adapt Experience –

Limited to 12 pages (maximum of 3 Experience Forms x 2 pages each and 2 Narratives at a maximum of 6 pages), Letters of Commitment from subcontractors (if applicable) will NOT count against your page limitation. Place as a separate appendix so that pages are not counted as part of the total pages.

A Joint Venture agreement (if applicable) will NOT count against your page limitation.

・ Factor #2, Past Performance – Limited to 15 pages (maximum of 3 past performance questionnaire forms consisting of 5 pages per form per project). Offerors are reminded to remove the definitions page from each form submitted to stay within the 15 page limitation.

・ Factor #3a-c Management and Execution Plan- Limited to 15 pages. Offerors are reminded to remove the definitions page from each form submitted to stay within the 15 page limitation.

・ Factor #3d- Key Personnel- Limited to 18 pages. Offerors are reminded to remove the definitions page from each form submitted to stay within the 18 page limitation.

・ Factor #3e- Milestone schedule- Limited to 10 pages. Offerors are reminded to remove the definitions page from each form submitted to stay within the 10 page limitation.

Letters of recommendation, commendations, evaluations and/or awards will NOT count against your page limitation.

Pages submitted which exceed limitations listed above will not be evaluated. Tables of content, proposal cover letters, and tabs between proposal information do not count toward any page limitations in the proposal.

13. PROPOSAL FORMAT – TECHNICAL EVALUATION FACTORS

Offerors shall submit Proposals by the deadline as stated in this Solicitation.

FACTOR 1, TAB 1: TECHNICAL APPROACH AND QUALIFICATIONS RELATED TO SITE

ADAPT -BUILD EXPERIENCE

The Proposal must contain no more than three (3) projects using the attached Experience Information Form at the end of Section 00110, to contain the Offeror’s and or proposed team member’s experience performing work similar to that required in this solicitation.

***EXPERIENCE reflects whether the Offeror’s and or proposed team members have performed the following work before.

Demonstrate the experience of the Offeror and/or the proposed team, including sub-contractors and Joint Venture partners:

・ The Offeror shall complete and submit no more than three (3) Experience Information forms on projects. Additional forms will not be considered. All blocks must be completed and all data must be accurate, current, and complete.

・ To be considered for evaluation a submitted project must demonstrate that it is valued at a minimum of $6,000,000 AND demonstrate that it is between 75% - 100 % complete within the last 3 years from the Solicitation issue date. An ongoing project will be considered to be within the last three (3) years, but still must meet the percentage completion requirement.

・ At least one (1) of the projects must demonstrate that they are same or similar to the Project described in the Solicitation. “Same or Similar” as referenced below, is defined as experience on projects that are the same or similar in size, scope, complexity and dollar magnitude as the Project described in the Solicitation. Projects shall be considered similar in scope and complexity if they contain the following: site-adapt new construction and renovation of existing buildings to include classrooms, barracks, and training facilities, large capacity water storage facility, inground septic treatment and disposal system, and power generation. Security to be included in project.

・ At least one (1) project submitted must be valued at a minimum of $6,000,000 AND, completed in Afghanistan. This project must have been 100% complete in the last three (3) years from the Solicitation issue date. This project does not have to be the same or similar to the Project described in the Solicitation.

To receive credit as experience for work which the Prime Contractor previously performed as a Subcontractor, the experience form must state in detail the nature of the work performed as a Subcontractor, the total percentage of the overall contract performed as a Subcontractor and the total amount of work performed as a Subcontractor. Example: Job as a Subcontractor performed 50% of the work on a $40 Million contract, (0.5 X $40M = $20M). To receive credit as experience the total of work performed must be valued at over $20,000,000.00.

To receive credit as experience for work performed as a Joint Venture, the experience form must state in detail the nature of the work performed by both of the Joint Venture partners, the total percentage of the work performed by both of the Joint Venture partners, and the total amount of work performed by both of the Joint Venture partners. Example: Joint Venture member performed work as prime and the total amount of work performed was 60% on a $30Million contract, (0.6 X $30M = $18M). To receive credit as experience the total of work performed must be valued at over $18,000,000.00

Additionally, the Offeror shall demonstrate in narrative format, the Site-Adapt-Build experience approach on at least one project of their construction teams, not to exceed five (5) pages, to include:

・ Offerors’ experience

・ Individual Team Members’ qualifications and experience and prior experience working with the Offeror ・ Key Major Subcontractors’ qualifications and experience and prior experience working with the Offeror

FACTOR 2, TAB 2: PAST PERFORMANCE

・ The Proposal must include no more than five (5) Past Performance Questionnaire (PPQ) forms, representing the Offeror’s relevant Past Performance. PPQ forms are attached at the end of Section 00120 and consist of five (5) pages. Do not resubmit Adjective Ratings and Definitions.

Relevant Past Performance is defined as past performance on projects that is the same or similar in size, scope, complexity and dollar magnitude as the Project described in the solicitation Projects shall be considered similar in scope and complexity if they contain the following: siteadapt new construction and renovation of existing buildings to include classrooms, barracks, and training facilities, large capacity water storage facility, in-ground septic treatment and disposal system, and power generation. Security to be included in project.

***PAST PERFORMANCE describes how well the Offeror performed previous construction projects.

Performance under a project will be determined “acceptable” if the Offeror has obtained or demonstrates a performance evaluation rating of at least “satisfactory,” or equivalent, on the project and it meets the following requirements:

・ A project must demonstrate that it is the same or similar to the Project described in the solicitation.

・ Each submitted PPQ form must describe a project that is valued at over $6,000,000.00 AND demonstrate that it is at least 75% complete within the last three (3) years from the solicitation issue date.

・ The Offeror shall provide its System for Award Management (SAM) Commercial and Government Entity (CAGE) Code and Data Universal Numbering System (DUNS) in Block 1 of the PPQ. A DUNS number must be provided if the Offeror possesses a DUNS number. If not, the Offeror must state that it has no DUNS number.

・ To receive credit for past performance as a Joint Venture, the PPQ form MUST state in detail the nature of the work performed by both of the Joint Venture partners, the total percentage of the work performed by both of the Joint Venture partners, AND the total amount of work performed by both of the Joint Venture partners. The Offeror must have performed 60% of the work and would have to have been the prime contractor. Example: Joint Venture member performed work as prime and the total amount of work performed was 60% on a $30Million contract, (0.6 X $30M = $18M). To receive credit as past performance the total of work performed must be valued at over $3,000,000.00.

The Government will also consider the quality of the Offeror’s relevant past performance. The PPQ included in this solicitation is provided for the Offeror to submit to the client for each project the Offeror includes in its proposal for Factor 2 – Past Performance. Ensure correct phone numbers and email addresses are provided for the client point-of-contact. Completed PPQs must be submitted with your proposal. If the Offeror is unable to obtain a completed PPQ from a client for a project(s) before the proposal closing date, the Offeror should complete and submit with the proposal the first two (2) pages of the PPQ which will provide contract and client information for the respective project(s).

Offerors should follow-up with clients/references to ensure timely submittal of questionnaires.

OFFERORS SHALL NOT INCORPORATE BY REFERENCE INTO THEIR PROPOSAL PPQs PREVIOUSLY SUBMITTED FOR OTHER REQUEST FOR PROPOSALS. However, this does not preclude the Government from utilizing previously submitted PPQ information in the past performance evaluation.

While the Government may elect to consider data from other sources, the burden of providing detailed, current, accurate and complete past performance information rests with the Offeror.

FACTOR 3, TAB 1a: MANAGEMENT AND EXECUTION

FACTOR 3, TAB 3a-c MANAGEMENT AND EXECUTION PLAN The Offeror must clearly demonstrate through a Management and Execution Plan, how the Offeror would proceed if awarded the Contract, to deliver the Project as described in the Solicitation, within the period of performance of 500 days, as specified in FAR clause 52.211-10. The Plan shall address the following topics:

a. Executive Summary – provide a narrative which clearly demonstrates your understanding of the project in the solicitation as it relates to the following: NTE 5 pages

1. Organizational Structure, with clear roles and responsibilities

2. Staffing – how the Offeror will provide staff to execute the Project as described in the Solicitation.

3. Integration and roles of Major Subcontractors, for both Site- Adapt and Construction efforts.

4. Identification of Project Risks and Mitigation Factors.

b. Construction Management Plan, to include an Outline Schedule - narrative NTE 5 pages;

Outline Schedule, pages do not count.

・ Demonstrate a clear understanding in narrative discussion and in an Outline Schedule, of the requirements to execute an aggressive construction schedule to include, at a minimum: mobilization; staffing, labor, equipment and materials requirements; identification of Critical Path work; construction submittals; water storage facility equipment, in-ground septic treatment and disposal system equipment, generators/transformers, circuits, etc and other materials’ procurement and delivery and Schedule management methods to complete the Project.

c. Quality Management / Control Plan – narrative NTE 5 pages

4.6 Describe Quality Management/Control for Site Adapt Phase.

・ Describe Quality Management/Control for Construction Phase.

・ Provide clear identification of personnel responsible for QC.

・ Description of tasks and functions of QC personnel.

FACTOR 3 Tab 3d: KEY PERSONNEL

The Offeror shall provide resumes which clearly demonstrate Site Adapt qualifications and experience of its intended key on-site construction management and supervision personnel as identified below and how they specifically relate to the requirements to execute the Project as described in the Solicitation; NTE 2 pages per resume:

1. Project Manager (overall responsible Point-of-Contact for the Project)

2. Electrical Transmission Specialist

3. Senior Mechanical Engineer

4. Senior Civil Engineer

5. On-Site Construction Superintendent

6. On-Site Safety Officer

7. On-Site Construction Quality Control (CAC) System Manager

8. Project Scheduler (Resume must indicate Scheduling Software experience (e.g., Primavera, Microsoft Project) Resumes for Key Personnel shall demonstrate relevant site-adapt and/or construction experience and qualifications for:

1. Site-Adapt construction of buildings and barracks on ANP bases

2. Site-Adapt construction of large capacity water storage facilities and in-ground septic treatment and disposal system on ANP bases All Resumes must include the following information and may NOT exceed two (2) pages per Resume:

・ Name and title.

・ Project positions held.

・ Name of firm.

・ Name of firm with which associated Years experience with the firm (in the key employee’s field of expertise/discipline) and years of experience with other firms (in your field of expertise/ discipline) Education degree(s), year, and educational institution(s) which issued these degree(s).

・ Active professional registration, year first registered, if applicable.

・ Other professional experience and qualifications, relevant to same/similar work requirements for the Project as described in this Solicitation.

・ List of projects in which the individual has worked to include Key Personnel position held, project responsibilities, Name of the project(s) and the project location(s).

The resumes of the following key personnel must indicate that they have degrees in the required disciplines:

・ Project Manager– Architecture or Engineering Degree

・ Electrical Transmission Specialist – Electrical Engineering Degree

・ Senior Mechanical Engineer – Mechanical Engineering Degree

・ Senior Civil Engineer – Civil Engineering Degree Degrees listed in resumes must be from recognized institutions of higher education, such as United States universities or colleges, Afghanistan universities, or international equivalents. Degrees offered with key personnel candidates must be United States or European bachelors’ degree (B.A.), masters’ degree (M.A.), doctorate (Ph.D.), or Afghanistan or international equivalent.

Resumes of Key Personnel must demonstrate that Key Personnel candidates have the minimum of number of years of relevant professional experience and qualifications, directly related to the requirements of this Solicitation. For example, the Project Manager must have a degree in Architectural or Engineering and a minimum of five (5) years of professional experience as a PM. The senior Civil Engineer must have a degree in Civil Engineering, a minimum of three (3) years of professional civil engineering experience as a Sr. Civil Engineer, and demonstrate experience in civil site work. The senior Electrical and Mechanical Engineers must have a degree in their respective fields, a minimum of five (5) years of professional electrical or mechanical engineer experience as a Sr. level Engineer and experience in site and building utilities’ and requirements. The Onsite Construction Superintendent must have five (5) years construction experience in supervising and directing civil site work and other horizontal construction, Site-Adapt and/or vertical construction and site utilities construction.

Resumes must document whether personnel proposed for work under the project are currently employed by the Offeror. When the Offeror is a joint venture, key personnel who are employees of any of the joint venture partners meet this requirement. When resumes indicate that key personnel candidates are not currently employed by the Offeror (this includes key personnel candidates currently employed by subcontractors), the resume must be accompanied by a signed letter of commitment, dated within one month before the date the Offeror submitted its proposal under the Solicitation, signed by both the key personnel candidate and the Offeror, and specifically referencing the Solicitation number and title. The signed letters of commitment will not count towards the 2-page limitation of either the resumes or the overall page limitation of this Section.

Resumes MUST clearly demonstrate that the following nine (9) Key Personnel have the required minimum years of professional experience in their field and discipline:

1. Project Manager (PM) – The PM hall have a minimum of five (5) years of project management experience on similar electrical projects.

2. Electrical Transmission Specialist – The Specialist shall be a U.S. Registered Professional Engineer (or other recognized licensure process from another country through which an engineer becomes authorized to provide professional services to the public), with at least 5 years experience on similar transmission projects

3. Senior Mechanical Engineer – The Senior Mechanical Engineer shall be a U.S. Registered Professional Engineer (or other recognized licensure process from another country through which an engineer becomes authorized to provide professional services to the public), with at least 5 years experience on similar transmission projects

4. Senior Civil Engineer – The Senior Civil Engineer shall be a U.S. Registered Professional Engineer (or other recognized licensure process from another country through which an engineer becomes authorized to provide professional services to the public), with at least 5 years experience on similar transmission.

5. On-Site Construction Superintendent - The Construction Superintendent shall have a Bachelor’s Degree in Engineering (Civil or Electrical) and a minimum of 5 years experience as a Construction Manager, with a minimum of two (2) of those five (5) years on similar projects.

6. On-Site Safety Officer (Site Safety and Health Officer (SSHO) – The SSHO hall have a minimum of five (5) years of safety experience on construction projects with a minimum of two

(2) years of safety experience on similar electrical projects.

7. On-Site Construction Quality Control (CAC) System Manager (Contractor quality Contract Systems Manager (CQCSM)) – The CQCSM shall have a Bachelor’s Degree in Engineering of Sciences and a minimum of five (5) years experience as a CQC or Superintendent, with a minimum of two (2) of those five (5) years on similar projects.

8. Project Scheduler – The Project Scheduler hall have a minimum of three (3) years of construction project scheduling experience on similar electrical projects

FACTOR 3, TAB 3e: MILESTONE SCHEDULE This factor evaluates the offeror’s proposed schedule to meet the period of performance identified in the solicitation.

A bar chart (or network) schedule shall be submitted that reflects the construction phase activities from Notice to Proceed through final completion. The schedule shall indicate start and finish dates of events and float time. The project schedule shall become a part of the contract between the successful offeror and the Government. Any proposal showing construction completion of more than 500 days after NTP will be deemed unacceptable. The preliminary proposal shall provide sufficient information to clearly demonstrate the contractor’s intent and ability to meet the functional requirements set forth herein for operational use of the facility. Any functions not specifically identified herein shall be developed to meet the overall project requirements. The schedule must clearly identify the critical path and at a minimum, identify the following milestones (NTE 10 pages) ・ Notice to Proceed (NTP)

・ 100% Approval

・ Mobilization

・ Start of Construction

・ Completion of new and renovated buildings

・ Completion of water storage facility

・ Completion of in-ground septic treatment and disposal system

・ Construction Complete

・ As-built drawings

・ As-built drawings Offeror to also address the schedule to procure the necessary equipment high voltage equipment required for the project.

・ Identify long lead items

・ Develop plan and corresponding schedule for long-lead items

・ Plan and schedule for managing shipping, tracking and managing customs of long-lead items.

・ Identify activities that can be completed concurrently to ensure construction completion date of

500 days after NTP will be met.

15. SPECIFIC INSTRUCTIONS FOR TECHNICAL PROPOSAL AND PRICE

PROPOSAL

15.1 Technical Proposal

1. Number of Sets of the Technical Proposal. Submit one copy of the Technical Proposal electronically.

2. Format and Contents of the Technical Proposal and List of Tabs. The original technical proposal will be appropriately labeled as such. The technical proposal shall be organized using the tabs specified in the following chart. Note: The main tabs directly correlate to the evaluation factors identified in Section 00120.

3. Page Limitations. The following page limitations are established for the factor described above:

・ Factor #3, Management and Execution Plan – Limited to 43 pages (15 pages for Executive

Summary, 2 pages per resume for 9 resumes, 10 pages for Milestone Schedule) Pages submitted which exceed limitations listed above will not be evaluated. Tables of content, proposal cover letters, and tabs between proposal information do not count toward any page limitations in the proposal.

FACTOR 3, TAB 3a-c MANAGEMENT AND EXECUTION PLAN The Offeror must clearly demonstrate through a Management and Execution Plan, how the Offeror would proceed if awarded the Contract, to deliver the Project as described in the Solicitation, within the period of performance of 500 days, as specified in FAR clause 52.211-10. The Plan shall address the following topics:

a. Executive Summary – provide a narrative which clearly demonstrates your understanding of the project in the solicitation as it relates to the following: NTE 5 pages

1. Organizational Structure, with clear roles and responsibilities

2. Staffing – how the Offeror will provide staff to execute the Project as described in the Solicitation.

3. Integration and roles of Major Subcontractors, for both Site- Adapt and Construction efforts.

4.…