SOQ26_9357_OQ_Attachment_E_Qualifications_Fillin_FormIssue.xls
XLS spreadsheet 118 KB Posted
- Attached to
- SOQ26 9357 OQ Prequalification for Fern Creek UG 230kV T-Line and Water Main Civil Construction Services
- Solicitation number
- 9357
- Issued by
- Florida
About this file
This is a Statement of Qualifications (SOQ) attachment form for prequalification for Fern Creek Underground 230kV Transmission-Line and Water Main Civil Construction Services in Florida. The SOQ solicits qualified contractors to demonstrate capabilities in performing civil construction services related to underground utilities for high-voltage power transmission lines, including groundwork, ductbank, manhole, and handhole infrastructures, as well as underground wet utilities for pressure mains. Bidders must submit comprehensive qualifications packages addressing company background, primary contact information, licenses, insurance requirements, financial data, health and safety programs, screening procedures, and project-specific organizational details. The evaluation criteria emphasize past project experience completed within the last seven years, with preference for projects of at least 100kV or greater, minimum half-mile length with splicing in manholes, open cut trenching methodology with trench boxes, and at least one project demonstrating micro-tunneling construction technique experience. Project team members must provide resumes demonstrating a minimum of seven years of industry experience with similar project types.
Minimum insurance requirements include General Liability of $5 Million, Auto Liability of $1 Million with MCS-90 Endorsement Coverage, statutory Worker's Compensation, and Pollution Liability Coverage of $5 Million, with additional insured provisions and waiver of subrogation required for all coverage types except Workers Compensation. Contractors must demonstrate minimum bonding capacity of $30 Million for Payment and Performance Bonds with documentation from a qualified surety. Bidders must provide three reference projects performed in the last seven years, with preference for Florida experience and urban construction environments rather than greenfield construction. The form requests detailed project information including contractor role, contract values, crew composition, equipment used, contract dates, line distance, voltage specifications, and soil conditions. Additionally, contractors must disclose annual dollar volumes for the past four years, Dun and Bradstreet numbers, workers compensation experience modification ratings, OSHA incidence/frequency/severity rates, and details on drug-free workplace policies and emergency response capabilities.
View the file
Other files
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
General Background B-1
| Fern Creek 230kV Underground Transmission-Line and Water Main Civil Construction Services (Base Bid F) Tab B-1 Qualificatons Company Background | ||
| SOQ26 9357 OQ | Bidder’s are to demonstrate its firms qualifications to perform the work associated with civil contruction pertaining to underground utilities for high volatage power transmission lines inclusive of ground work, ductbank, manhole, and handhole infrastructures and underground wet utilites for pressure mains. Bidders interested in performing the associated work shall submit qualifications package as requested in Tabs B-1, B-2, B-3, B-4 & B-5 | |
| Qualifications | ||
| 1 | Company Background Data | |
| 1.1 | Name of Firm | |
| 1.2 | Name of Parent Company | |
| 1.3 | Complete Business Address | |
| 1.4 | State of Incorporation | |
| 2 | Company Primary Contact Information: | |
| 2.1 | Name | |
| 2.2 | Email Address | |
| 2.3 | Office Phone Number | |
| 2.4 | Mobile Phone Number | |
| 2.5 | Telefax Number | |
| 3 | Licenses | |
| 3.1 | Potential Bidders shall be properly licensed by the State of Florida to perform the type of services requested. Provide a copy of the applicable business license. | |
| 4 | Insurance | |
| 4.1 | Potential Bidders shall be properly insured in accordance with the Minimum specified OUC insurance requirements. Provide a sample copy of your firms insurance certificates. | |
| 4.2 | General Liability $5 Million | |
| 4.3 | Auto Liability $1 Million including MCS-90 Endorsement Coverage | |
| 4.4 | Worker Comp (Statutory) | |
| 4.5 | Pollution Liability Coverage $ 5M | |
| 4.5 | Does Policy allow for additional insured for all coverage types other than Workers Comp and waiver of subrogation for all coverage ttpes in favor of the Owner? | |
| 4.6 | Indicate your firms Bonding Capacity for Payment and Performance Bonds (Provide letter of good standing and Capacity from a qualified Sureity) (Minumum Bonding Capcity is $30M) | |
| 4.7 | Is your firm capable of providing Builders Risk Insurance Coverage values at 100% of the Contract value if selected for award of a Contract resulting form a future RFP in connection with this prequalifictaion process? | |
| 5 | Company Financial | |
| 5.1 | Dunn and Bradstreet Number | |
| 5.2 | Firms annual dollar volume for the last four years specific to the division of the firm to provide the services requested. 2025 through 2022 | 2025: |
| 2024: | ||
| 2023: | ||
| 2022: | ||
| 8 | WMBE Information | This is for informational Purposes Only and does not represent any specific Minumum WMBE Requirements having to be met for the Firm |
| 8.1 | Is firm a Women Owned or Minority Owned Business Enterprise? (YES or No) If yes, provide certification documentation. | |
| 8.2 | Does your firm have a Minority/Women business utilization program? | |
| 8.3 | If response was yes to item above, please describe program. | |
| 9 | Company Health and Safety Programs and Record | |
| 9.1 | Provided a copy of your firm’s Health & Safety Manual on CD. (YES OR NO) | |
| 9.1a | Firms Workman's Comp Exp Mod rating last 3 yrs. | 2025: |
| 2024: | ||
| 2023: | ||
| 9.1b | OSHA Incidence Rate for the last 3 years | 2025: |
| 2024: | ||
| 2023: | ||
| 9.1c | OSHA Frequency Rate for the last 3 years | 2025: |
| 2024: | ||
| 2023: | ||
| 9.1d | OSHA Severity Rate for the last 3 years | 2025: |
| 2024: | ||
| 2023: | ||
| 9.2 | Has you firm had any incidents resulting in loss of life within the past 5 years related to the production, supply or delivery for any of the chemicals being proposed. | |
| 9.2a | If response to 9.2 is yes please provide explanation | |
| 9.3 | Does your firm have a comprehensive employee and vehicle safety program that includes hazardous material response training, ongoing driver safety training, formal incident investigation with root cause analysis, and equipment and vehicle inspection? | |
| 9.3a | If Yes to 9.3 please provide a summary of these programs or otherwise specify the specific sections of your firms Health and Safety Manual this is covered by. | |
| 9.4 | Does your company have a program to ensure that all federal, state and local regulations are followed in the handling, storage and disposal of hazardous material? | |
| 9.4a | If yes to Item 9.4, please provide brief outline of program | |
| 9.5 | Has your company ever been issued a warning or violation by a regulatory agency for non-compliance with federal or state regulations? | |
| 9.5a | If yes to Item 9.5, please describe and include date of violation or warning. | |
| 9.6 | Does your company have a Drug Free Work Place policy? | |
| 9.6a | If yes, please provide an outline of your Drug Free Work Place policy Table of Contents. | |
| 10 | Please indicate below if your firm conducts the following screening and testing. | |
| 10.1 | Pre-Employment Criminal Background Checks? (YES or NO) | |
| 10.2 | Workers Compensation History Review? (YES or NO) | |
| 10.3 | Driver License Verification (YES or NO) | |
| 10.4 | Pre-employment Physical Exam (YES or NO) | |
| 10.5 | Provide outline of your firms emergency response programs and capabilities in support of your customers. | |
| 10.6 | Provide any additional information you feel will assist OUC in determining your firm’s qualifications. You may include any related services your company could provide. | |
| 11 | Project Specific Details | |
| 11.1 | Project Specific Org Chart- Should include Home Office Project Manager, Site Project Manager/Superintendents, Forman, Quality, and Safety. |
&C&"Arial,Bold"&12DESIGN BUILD SERVICES FOR LANDFILL GAS TO ENERGY PROJECTS
Transmission Quals -Ref B-2
| SOQ26 9357 OQ | Fern Creek 230kV Underground Transmission-Line Civil Construction Services (Base Bid F) Tab B-2 Qualifications Past Projects-References |
| Contractor shall provide 3 references of work that has been completed in the last 7 years of underground construction. These project references are to be of projects that are at least: |
o 100kV or greater o Minimum of half mile long with splicing in manholes o Use of open cut trenching methodology with trench box and sloping of earth.
o At least one project should note use of micro-tunnelling construction technique for a portion of the installation. If not, please include experience with micro-tunneling construction methodology.
RESUMES: The proposed team members of the project are to note in their resumes projects that are of similar type to the above referenced request. Ideally, it is recognized the proposed team member does not have longevity with the Contractor to be part of the project references provided. In this event, project team member’s resumes are to demonstrate minimum of 7 years of experience in the industry with similar project’s noted in their resume.
| SOQ26 9357 OQ | Qualifications | Suppliers Response |
| 1 | Is this scope being self performed or Subcontracted. | |
| 2 | Name of Firm | |
| 3 | Complete Business Address | |
| 4 | State of Incorporation | |
| 5 | Provide a narrative describing your firm’s capabilities in regards to the scope of work/services being requested in the SOQ for Roads Restorations Work Scope. Include the overall approach and specific methodology to provide the specified services. | |
| 6 | Number of Years your firm has been in business Supplying Underground Transmission Line Work. | |
| 7 | Number of Years your firm has been in business the peforming the type of work described in this SOQ in Florida | |
| 8 | Provide a narrative describing your firm’s capabilities in regards to the Underground Transmission scope being desribed in the SOQ. Include the overall approach and specific methodology to provide the specified services. | |
| 9 | Provide narrative of your firms past experience where your firm was responsible for obtaining and/or manageing and maintaining MOT permitting with The City of Orlando and/or FDOT in a similar Urban environment. | |
| References/Experience | References: Provide Three (3) projects performed within the last seven (7) years showing experience with preference to inlcude projects performed in Florida. Reference Projects should represent/demonstrare firms experience/qualifications to perform the work associated with civil construction for high voltage underground power transmission lines inclusive of ground work, ductbank, manhole, and handhole infrastructures.. Preference to Include experience references within the past 5 years pertaining to civil installations of ductbanks (via open cut) and manholes for 230kV underground transmission lines and or similar experience with civil installations of ductbanks (via trenchless/jack and bore). Preference is for incusion of Projects performed in an urban construction environment rather than greenfield contruction environment. | |
| Ref # 1 | ||
| R1-1 | Name of company or organization the service was provided for. | |
| R1-2 | Name of facility and its location. Was the work performed in urban area or green field? | |
| R1-3 | Description of Product/Service provided and Contractors Role | |
| R1-4 | Cost Method used and Dollar Value | |
| R1-5 | Final contract Dollar Value including change orders | |
| R1-6 | Crew Size and Make up | |
| R1-7 | Types of Equipment Used | |
| R1-8 | Dates of contract term | |
| R1-9 | What was the distance covered by the line construction? | |
| R1-10 | What was voltage of line construction? | |
| R1-11 | Was project located in sandy, weak (blow counts <10) soils with high (within 6’ of surface) water tables | |
| R1-12 | Did your firms work for this project include open cut trenching methodology with trench box and sloping of earth? | |
| R1-13 | Did your firms scope require the use of micro-tunnelling construction technique for a portion of the installation. If not, please include experience with micro-tunneling construction methodology. | |
| R1-14 | List Name of firm and type of work performed for any major Subcontractors used. | |
| R1-15 | Contact: Name, phone number, and e-mail address. Contact must be someone currently withing the firm which is familiar with the details of the actual performance of the contract who can comment on the contractor’s performance from an operations and maintenance perspective. | |
| R1-16 | Provide photos of the work that was performed. Any work by a subcontractor shall be clearly stated. | Provide photos as separate attachments. DO NOT insert photos in the Fill In Form response. |
| R1-17 | Did your firms scope include any Roadway Restorations? If yes please describe and indicate if the work was self performed or performed by subcontractor. | |
| R1-18 | Describe any unusual operating conditions, requirements, or circumstances that may serve to distinguish your firm’s qualifications. | |
| Ref # 2 | ||
| R2-1 | Name of company or organization the service was provided for. | |
| R2-2 | Name of facility and its location. Was the work performed in urban area or green field? | |
| R2-3 | Description of Product/Service provided and Contractors Role | |
| R2-4 | Cost Method used and Dollar Value | |
| R2-5 | Final contract Dollar Value including change orders | |
| R2-6 | Crew Size and Make up | |
| R2-7 | Types of Equipment Used | |
| R2-8 | Dates of contract term | |
| R2-9 | What was the distance covered by the line construction? | |
| R2-10 | What was voltage of line construction? | |
| R2-11 | Was project located in sandy, weak (blow counts <10) soils with high (within 6’ of surface) water tables | |
| R2-12 | Did your firms work for this project include open cut trenching methodology with trench box and sloping of earth? | |
| R2-13 | Did your firms scope require the use of micro-tunnelling construction technique for a portion of the installation. If not, please include experience with micro-tunneling construction methodology. | |
| R2-14 | List Name of firm and type of work performed for any major Subcontractors used. | |
| R2-15 | Contact: Name, phone number, and e-mail address. Contact must be someone currently withing the firm which is familiar with the details of the actual performance of the contract who can comment on the contractor’s performance from an operations and maintenance perspective. | |
| R2-16 | Provide photos of the work that was performed. Any work by a subcontractor shall be clearly stated. | Provide photos as separate attachments. DO NOT insert photos in the Fill In Form response. |
| R2-17 | Did your firms scope include any Roadway Restorations? If yes please describe and indicate if the work was self performed or performed by subcontractor. | |
| R2-18 | Describe any unusual operating conditions, requirements, or circumstances that may serve to distinguish your firm’s qualifications. | |
| Ref # 3 | ||
| R3-1 | Name of company or organization the service was provided for. | |
| R3-2 | Name of facility and its location. Was the work performed in urban area or green field? | |
| R3-3 | Description of Product/Service provided and Contractors Role | |
| R3-4 | Cost Method used and Dollar Value | |
| R3-5 | Final contract Dollar Value including change orders | |
| R3-6 | Crew Size and Make up | |
| R3-7 | Types of Equipment Used | |
| R3-8 | Dates of contract term | |
| R3-9 | What was the distance covered by the line construction? | |
| R3-10 | What was voltage of line construction? | |
| R3-11 | Was project located in sandy, weak (blow counts <10) soils with high (within 6’ of surface) water tables | |
| R3-12 | Did your firms work for this project include open cut trenching methodology with trench box and sloping of earth? | |
| R3-13 | Did your firms scope require the use of micro-tunnelling construction technique for a portion of the installation. If not, please include experience with micro-tunneling construction methodology. | |
| R3-14 | List Name of firm and type of work performed for any major Subcontractors used. | |
| R3-15 | Contact: Name, phone number, and e-mail address. Contact must be someone currently withing the firm which is familiar with the details of the actual performance of the contract who can comment on the contractor’s performance from an operations and maintenance perspective. | |
| R3-16 | Provide photos of the work that was performed. Any work by a subcontractor shall be clearly stated. | Provide photos as separate attachments. DO NOT insert photos in the Fill In Form response. |
| R3-17 | Did your firms scope include any Roadway Restorations? If yes please describe and indicate if the work was self performed or performed by subcontractor. | |
| R3-18 | Describe any unusual operating conditions, requirements, or circumstances that may serve to distinguish your firm’s qualifications. | |
| Management, Personnel, Facilities and Resources, Other | ||
| Location of the local service office to for Underground Transmission Services within OUC's service territory. | ||
| Locations of any other facilties that may be utilized in support of a contract resulting from this RFP. | ||
| Provide a brief description of current technical and management capabilities and availability to perform the work. | ||
| Previous Client experience | ||
| Provide a listing of previous experience with Orlando Utilities Commission within the last five (5) years. | ||
| For staff who would be assigned to the contract, provide the following: | ||
| List names phone and email for the following within your firm responsible for the Underground Transmission Line Services. | President: | |
| Vice President | ||
| Outside Sales/Account Manager: | ||
| Site Superintendants | ||
| Site Foreman | ||
| Provide outline of your firms emergency response programs and capabilities for the specified services. | ||
| Decribe your firms total workforce availability – In the event this project is subject to limits of construction activity in certain road jurisdictions or based on MOT plans, or the project falls behind schedule, the contractor must show the ability to work at multiple sites (multiple crews) simultaneously along the project route. | ||
| Provide Resumes for Project Manager, Superintendents, and Foreman that would be assigned to perform work under a resulting contract. The proposed team members of the project are to note in their resumes projects that are of similar type to the above referenced request. Ideally, it is recognized the proposed team member does not have longevity with the Contractor to be part of the project references provided. In this event, project team member’s resumes are to demonstrate minimum of 7 years of experience in the industry with similar project’s noted in their resume. | ||
| Describe any training and or other value added support services your firm provides/offers to its customers pertaining to the specified services |
Water Main Quals -Ref B-3
| SOQ26 9357 OQ | Fern Creek 230kV Water Main Civil Construction Services (Base Bid F) Tab B-3 Qualifications Past Projects-References | |
| Tab B-3 | ||
| WATER DISTRIBUTION CONSTRUCTION SERVICE QUALIFICATIONS | Suppliers Response | |
| 1 | Number of Years your firm has been in business Installing Potable Water Mains. | |
| 2 | Number of Years your firm has been in business Installing Potable Water Mains via jacking and boring (with or without a Subcontractor is acceptable). If a subcontractor was employed for this work, list the subcontractor(s) you have worked with in the past and intend to work with for this project. | |
| 3 | Number of Years your firm has been in business Installing Potable Water Mains via directional drilling (with or without a Subcontractor is acceptable). If a subcontractor was employed for this work, list the subcontractor(s) you have worked with in the past and intend to work with for this project. | |
| 4 | Number of Years your firm has been in business Supplying Underground Water Main Line Work in Florida. | |
| 5 | List of projects or experience directly with OUC within the past 5 years. | |
| 6 | Provide narrative of your firms past experience where your firm was responsible for obtaining and/or manageing and maintaining MOT permitting with the City of Orlando and/or FDOT in a similar Urban environment. | |
| Provide three (3) project references for work completed within the past seven (7) years that demonstrate your firm’s qualifications in civil construction involving installation or modification of pressurized buried pipelines (potable water, reclaimed water, or wastewater force mains) of at least 1,000 linear feet, with at least one project including a minimum of 2,500 linear feet within a residential subdivision. Projects should involve pipe diameters of 6-inch or greater, with experience up to 16-inch ductile iron pipe (DIP), and include associated service connections, maintenance of traffic, and restoration of driveways and sidewalks. Work must have been performed adjacent to existing live watermains, maintaining uninterrupted customer service throughout construction. Projects are preferably located within 100 miles of OUC’s Reliable One Plaza. | ||
| Ref # 1 | ||
| R1-1 | Name of company or organization the service was provided for. | |
| R1-2 | Name of project and its location | |
| R1-3 | Description of Product/Service provided and Contractors Role | |
| R1-4 | Cost Method used and Dollar Value | |
| R1-5 | Crew Size and Make up | |
| R1-6 | Types of Equipment Used | |
| R1-7 | Did work include open cut, horizontal directional drill or trenchless jack and bore methodology? | |
| R1-8 | Provide length of pipeline project | |
| R1-9 | Provide material of pipeline installed | |
| R1-10 | Provide diameter of pipeline installed | |
| R1-11 | List Name of firm and type of work performed for any major Subcontractors used. | |
| R1-12 | Dates of contract term | |
| R1-13 | Contact: Name, phone number, and e-mail address. Contact must be someone familiar with the details of the actual performance of the contract who can comment on the contractor’s performance from an operations and maintenance perspective. | |
| R1-14 | Describe any unusual operating conditions, requirements, or circumstances that may serve to distinguish your firm’s qualifications. | |
| R1-15 | Did your firms scope include any Roadway Restorations? If yes please describe and indicate if the work was self performed or performed by subcontractor. | |
| R1-16 | Provide photos of the work that was performed. Any work by a subcontractor shall be clearly stated. | Provide photos as separate attachments. DO NOT insert photos in the Fill In Form response. |
| Ref # 2 | ||
| R2-1 | Name of company or organization the service was provided for. | |
| R2-2 | Name of project and its location | |
| R2-3 | Description of Product/Service provided and Contractors Role | |
| R2-4 | Cost Method used and Dollar Value | |
| R2-5 | Crew Size and Make up | |
| R2-6 | Types of Equipment Used | |
| R2-7 | Did work include open cut, horizontal directional drill or trenchless jack and bore methodology? | |
| R2-8 | Provide length of pipeline project | |
| R2-9 | Provide material of pipeline installed | |
| R2-10 | Provide diameter of pipeline installed | |
| R2-11 | List Name of firm and type of work performed for any major Subcontractors used. | |
| R2-12 | Dates of contract term | |
| R2-13 | Contact: Name, phone number, and e-mail address. Contact must be someone familiar with the details of the actual performance of the contract who can comment on the contractor’s performance from an operations and maintenance perspective. | |
| R2-14 | Describe any unusual operating conditions, requirements, or circumstances that may serve to distinguish your firm’s qualifications. | |
| R2-15 | Did your firms scope include any Roadway Restorations? If yes please describe and indicate if the work was self performed or performed by subcontractor. | |
| R2-16 | Provide photos of the work that was performed. Any work by a subcontractor shall be clearly stated. | Provide photos as separate attachments. DO NOT insert photos in the Fill In Form response. |
| Ref # 3 | ||
| R3-1 | Name of company or organization the service was provided for. | |
| R3-2 | Name of project and its location | |
| R3-3 | Description of Product/Service provided and Contractors Role | |
| R3-4 | Cost Method used and Dollar Value | |
| R3-5 | Crew Size and Make up | |
| R3-6 | Types of Equipment Used | |
| R3-7 | Did work include open cut, horizontal directional drill or trenchless jack and bore methodology? | |
| R3-8 | Provide length of pipeline project | |
| R3-9 | Provide material of pipeline installed | |
| R3-10 | Provide diameter of pipeline installed | |
| R3-11 | List Name of firm and type of work performed for any major Subcontractors used. | |
| R3-12 | Dates of contract term | |
| R3-13 | Contact: Name, phone number, and e-mail address. Contact must be someone familiar with the details of the actual performance of the contract who can comment on the contractor’s performance from an operations and maintenance perspective. | |
| R3-14 | Describe any unusual operating conditions, requirements, or circumstances that may serve to distinguish your firm’s qualifications. | |
| R3-15 | Did your firms scope include any Roadway Restorations? If yes please describe and indicate if the work was self performed or performed by subcontractor. | |
| R3-16 | Provide photos of the work that was performed. Any work by a subcontractor shall be clearly stated. | Provide photos as separate attachments. DO NOT insert photos in the Fill In Form response. |
| Management, Personnel, Facilities and Resources, Other | ||
| 6 | Location of the local service office to for these Services. | |
| 7 | Locations of any other facilities that may be utilized in support of a contract resulting from this RFP. | |
| 8 | Provide a brief description of current technical and management capabilities and availability to perform the work. | |
| 9 | Provide a listing of previous experience with Orlando Utilities Commission within the last five (5) years. | |
| For staff who would be assigned to the contract, provide the following: | ||
| 10 | Provide Contact Information to include name, phone, and email for the following within your firm responsible for these Services. | |
| 11 | President | |
| 12 | Vice President | |
| 13 | Outside Sales/ Office Project-Account Manager: | |
| 14 | Site Superintendents | |
| 15 | Site Foreman | |
| 16 | Provide outline of your firms emergency response programs and capabilities for the specified services. | |
| 17 | Describe any other value added support services your firm provides/offers to its customers pertaining to the specified services | |
| 18 | Describe your firms total workforce availability – In the event this project is subject to limits of construction activity in certain road jurisdictions or based on MOT plans, or the project falls behind schedule, the contractor must show the ability to work at multiple sites (multiple crews) simultaneously along the project route. |
B-4 Clarifications-Exceptions
| EXCEPTIONS AND OR CLARIFICATIONS | |||||
| No exceptions will be allowed after the response is submitted. | |||||
| Please indicate yes or none below if clarifications and or exceptions have been taken as part of your firms proposal. | |||||
| Commercial Clarifications Yes ___ None___ Commercial Exceptions Yes___ None ___ | |||||
| Technical Clarifications Yes___ None ___ Technical Exceptions Yes___ None ___ | |||||
| NOTE: If the Supplier’s has checked the Exceptions block indicating it’s proposal includes clarifications and or exceptions the Supplier shall clearly identify each clarification and or exception below. | |||||
| All exceptions and or clarifications shall be specific and reference the applicable SOQ article number, and meet with all SOQ requirements. | |||||
| Respondent shall check the None blocks if the Respondent does not have any commercial or technical exceptions and or clarifications to declare from the requirements of the SOQ documents. | |||||
| Fern Creek 230kV Underground Transmission-Line and Water Main Civil Construction Services (Base Bid F) Tab B-4 Clarifications and Exceptions | |||||
| SOQ26 9357 OQ | |||||
| Exceptions | Clarifications | ||||
| The Respondent's specific Exceptions herein itemized and included with the Resonse represent an exhaustive list of any and all explicit variations or deviations from the requirements of the SOQ documents. | All of Respondent’s Clarifications herein itemized and included with the Response do not constitute explicit variation or deviation from the prequalifications in strict accordance with the requirements of SOQ documents. | ||||
| Commercial Exceptions | Commercial Clarifications | ||||
| Item | Reference Article | Stated Commercial Exceptions | Item | Reference Article | Stated Commercial Clarifications |
| CE1 | CC1 | ||||
| CE2 | CC2 | ||||
| CE3 | CC3 | ||||
| CE4 | CC4 | ||||
| CE5 | CC5 | ||||
| CE6 | CC6 | ||||
| CE7 | CC7 | ||||
| CE8 | CC8 | ||||
| CE9 | CC9 | ||||
| CE10 | CC10 | ||||
| Technical Exceptions | Technical Clarifications | ||||
| Item | Reference | Stated Technical Exceptions | Item | Reference | Stated Technical Clarifications |
| TE1 | TC1 | ||||
| TE2 | TC2 | ||||
| TE3 | TC3 | ||||
| TE4 | TC4 | ||||
| TE5 | TC5 | ||||
| TE6 | TC6 | ||||
| TE7 | TC7 | ||||
| TE8 | TC8 | ||||
| TE9 | TC9 | ||||
| TE10 | TC10 |
B-5 Addendum Acknowledments
| ADDENDA for Solicitation #: SOQ26 9357 OQ | |
| The undersigned Respondent acknowledges receipt of the following Addenda, which | |
| have been considered in preparing this Response. | |
| Addendum No. 1 | Dated |
| Addendum No. 2 | Dated |
| Addendum No. 3 | Dated |
| Addendum No. 4 | Dated |
File details come from the government source that posted it. Updated .