SECTION F - DELIVERIES OR PERFORMANCE.pdf

SECTION F – DELIVERIES OR PERFORMANCE

F.1 DELIVERABLE ITEMS

All the services and reports listed under Section C of this contract shall be executed in accordance with the requirements of the contract and at the direction of the COR.

F.2 LOCATION

The work performed under this contract will be primarily located at Vienna, VA.

F.3 TERM OF CONTRACT

The contract is for 120 days after receiving the notice to proceed.

F.4 WORK SCHEDULE

The Contractor shall arrange their work so as not to interfere with the normal occurrence of Government business. All work schedules shall be submitted to and approved by the Contracting Officer or their designated representative. The

Contractor shall not change approved work schedules without the prior consent of the Contracting Officer or their designated representative. Whenever nonessential services have been scheduled on the date a holiday occurs, such services shall be performed on the following working day. Deviation from the work schedules is permissible only when approved by the Contracting Officer or their designated representative. For all unscheduled work the contractor shall obtain Contracting

Officer or their designated representative approval.

F.5 WORK OUTSIDE REGULAR WORKING HOURS

Except as otherwise specified in a specific task order, all work shall be performed during regular working hours. No work shall be scheduled and/or planned to be done on Saturdays, Sundays or Federal holidays, unless otherwise specified herein or directed by the Contracting Officer or their designated representative. Whenever periodic services have been scheduled on a date a Federal holiday occurs, then such services may be performed on the next normal working day. If the Contractor, without additional costs to the Government, desires to work Saturday, Sunday, holidays or outside the station's regular working hours, he must submit an application to the Contracting Officer or their designated representative, in writing, at least seventy-two (72) hours in advance. In no event shall the Contractor work outside of regular working hours without prior approval.

F.6 AVAILABILITY OF CONSTRUCTION SITE

F.6.1 The Government reserves the right to delay the start of construction due to site availability, if required, up to twenty-one calendar days from the start of each delivery order with no increase in the contract cost to the Government. When the start of construction is delayed due to the availability of the site, the delivery order completion date will be extended one calendar day for each day of delay beginning with the day the Contractor was ready to start on site work.

F.6.2 The Government reserves the right to periodically deny availability of the site during construction for the number of days listed in the table below for no additional cost to the Government. The completion date will be extended one calendar day for each day site access is denied*.

Original Task Order Duration Site Access Denial at No Cost

Up to 60 Days 2 working days

61 to 120 Days 3 working days

Over 120 Days 5 working days

* Closures due to extreme weather, Terrorist Threat Conditions, or other sovereign acts of the Government are NOT considered site access denials

F.7 NOTICE TO THE GOVERNMENT OF DELAYS

In the event the Contractor encounters difficulty in meeting performance requirements, or when the Contractor anticipates difficulty in complying with the contract delivery schedule or completion date, or whenever the Contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately notify the

Contracting Officer and the COR, in writing, giving pertinent details; provide, however, that this data shall be informational only in character and that this provision shall not be construed as a wavier by the Government or any delivery schedule or date, or any rights or remedies provided by law or under this contract.